A-11_MATOC_Exhibits_A-D_F-G_Oct_2012.pdf

IDIQ MATOC RFP W912PQ-13-R-0002

EXHIBIT A PERFORMANCE RELEVANCY QUESTIONNAIRE

PART 1: Prepare not more than six (6) Part 1 forms for general construction.

Provide the following information requested in this format for each of the projects/contracts being described. Contractors should select their projects carefully because the quality of the contractor’s relevant performance is more important than the quantity of projects submitted. Projects may be on going, if complete to 70 % and cannot have been completed any earlier than 5 years prior to the solicitation issue date. . Provide frank, concise comments regarding YOUR PERFORMANCE on the contracts you identify. Use as much space as required.

A. Offeror (Your) Name (Company/Division):_______________________________________

B. Project/Contract Title:________________________________________________________

C. Contract Specifics:

1. Description of Effort as ___________Prime Contractor or _________Subcontractor

2. Contract Number__________________________________________________________

3. Original Contract $ Value _____________ Current/Final Contract $ Value ____________

4. If amounts in 3 above are different, provide a brief description of the reason:

5. Award and Completion

i. Award date: __________________Original Completion Date:_____________________

ii. Current Scheduled Completion Date( if ongoing): _____________ % complete: _____

iii. Estimate/Final Completion Date:_________________________________________

iv. If IDIQ Number of Task Orders issued:____________________________________

**If reference is for an IDIQ Contract provide items 1-3 above, contract completion date and number of task/delivery orders issued. The Basic Contract will not count as one of 6 contracts/projects. The basic contract alone will not be considered for relevancy. The proposal must discuss relevant task order(s) complete to 90%. Count each TO discussed as a single project/contract**

Task Order Number _____________________________________________________

Title__________________________________________________________________

Original TO $ Value _____________ Current/Final $ Value _____________________

If amounts above are different, provide a brief description of the reason:

Task Order Completion Date:

1. Original Date: _____________________________________________

2. Current Schedule if ongoing _________________________________% complete: _____

3. Estimate/Final Completion Date:_______________________________

4. Primary cause for Contract Modifications________________________

D. Provide detailed description of the work performed under the contract and describe why you believe the work is very relevant, relevant or somewhat-relevant to this solicited contract. Also discuss similarity of the client type, United States Green Building Council (USGBC) (LEED®) or similar sustainability requirements. Use as much space below as necessary to provide this description.

Exhibit A Part I continues on Next Page…

Additionally, please address the following items:

1. Describe the specific elements of the work performed by your firm.

2. Indicate what elements of work were performed by your major subcontractors and indicate if those same subcontractors will be used on MATOC projects.

3. Address any technical areas about this project you consider uniquely relevant to this solicitation.

4. Point of Contact for Owner/Government agency Contracting Officer and or inspector; include a current phone number and facsimile number. Email address is also desired.

End of Part 1- Questionnaire Requirements – Prepare and send Exhibit C Package to the reference(s) for each of the six (6) General Construction projects. A “Final” Performance Evaluation (Construction) ( also referred to as CCASS Evaluation ) issued for a project may be included in lieu of sending out reference package for the project.

EXHIBIT A PERFORMANCE RELEVANCY QUESTIONNAIRE

PART 2: Provide the following information one time.

Additional offeror information required, but not project specific. This information need only be provided once in your submission package.

2A: Applicable to all offerors - Describe your Compliance with the requirements of FAR clause 52.219-8, Utilization of Small Business Concerns (May 2004). Describe below the methods you have used to comply with this policy on prior federal contracts. Include any evidence, or a point of contact to verify this information, if available.

Even if you are a Small or Small Disadvantaged Business, this clause in Federal Contracts applies. It is the policy of the United States that small business concerns, veteran-owned small business concerns, service-disabled veteran-owned small business concerns, HUBZone small business concerns, small disadvantaged business concerns, and women-owned small business concerns shall have the maximum practicable opportunity to participate in performing contracts let by any Federal agency, including contracts and subcontracts for subsystems, assemblies, components, and related services for major systems.) It is also policy to establish procedures to ensure the timely payment of amounts due pursuant to the terms of their subcontracts.

2B: Name subcontractors and/or Teaming Partners to be utilized on this contract. Multiple subcontractors may be named for the same discipline, but are limited to a maximum of three (3) subcontractors per discipline. As a minimum, provide the name(s) of subcontractors to be utilized in the following areas:

Electrical:

Mechanical:

Roofing:

Horizontal disciplines: (include paving and civil site work)

Each major subcontractor and/or Teaming Partner must also complete an Exhibit B, “Subcontractor

Information and Consent Form” to be considered. Offerors shall have major subcontractors identify on the

Exhibit B three references, owners (if they were the Prime) or other Prime contractors they have worked for. References for subcontractors from the proposing offeror are not acceptable. See Exhibit “B” format for information to be provided. Written references for subcontractors may be included and are encouraged.

However, subcontractors do not need to send out Exhibit C questionnaires.

2C: Discuss assessment of liquidated damages on any contracts within the last five years. (frequency, circumstances, severity of problem, etc.)

2D: Offerors are strongly encouraged to include with their proposals information on problems encountered on relevant projects and the specific corrective actions taken to remedy the problems.

2E: (OPTIONAL) Other Past Performance Considerations. Information, if provided, shall be limited to the period starting 5 years prior to the solicitation release date.

Effectiveness of value engineering (VEC) proposals you submitted on prior contracts. (Provide a brief description; impact on cost, schedule, efficiency or quality; contract number; name and phone number of customer benefiting from the VEC).

Limit of five (5) of the following: Professional/Industry awards (Identify award type, date of award and copy of certificate if applicable), Letters of appreciation, recognition or commendations.

Discuss unique skills and accomplishments (Explain unique skills and/or accomplishments and provide supporting information for verification).

IDIQ MATOC, RFP W912PQ-13-R-0002

EXHIBIT B – SUBCONTRACTOR INFORMATION AND CONSENT FORM

Subcontractor and/or Teaming Partner Consent for the Release of Past Performance Information to the

Prime Contractor and Reference Information

Past performance information concerning subcontractors and teaming partners cannot be disclosed to a private party without the subcontractor’s or teaming partner’s consent. Because a prime contractor is a private party, the Government will need that consent before disclosing subcontractor/teaming partner past and present performance information to the prime during exchanges. In an effort to assist the Government in assessing your past performance we request that the following consent form be completed by the major subcontractors/teaming partners identified in your proposal. The completed consent forms should be submitted to the offering contractor for submission with past performance volume.

___________________(Name of Firm) is currently planning on participating as a (subcontractor and or a teaming partner) with ___________________(prime contractor or name of entity providing proposal) in responding to the Request for Proposal No. W912PQ-13-R-0002 for IDIQ Multiple Award Task Order

Contract (MATOC) for construction projects issued by the 105 th

Air Wing Newburgh, NY and the 106 th

Rescue Wing Westhampton Beach, NY.

We understand that the Government is placing increased emphasis on past performance in order to obtain best value in source selections. In order to facilitate the performance confidence assessment process we are signing this consent form to allow you to discuss our past and present performance information with the prime contractor during the source selection process.

(Signature) (Title of Individual with authority to sign for and

Legally bind the company)

Company Name: ________________________ Telephone #____________________

Address: ______________________________

City/State/Zip Code:______________________ Date:_____________________

Reference List (required):

1. Contract No. And Title___________________________________________________________

Describe your role (Prime/Sub) and work Performed ___________________________________

Reference POC Name____________________________ Phone___________ Fax____________

Email address: _________________________________________________________________

2. Contract No. And Title___________________________________________________________

3. Contract No. And Title___________________________________________________________

EXHIBIT C PACKAGE INFORMATION AND FORMS - A “Final” Performance Evaluation

(Construction) ( also referred to as CCASS Evaluation ) issued for a project may be included in lieu of sending out reference package for the project.

Instructions to Offeror for sending Reference Questionnaire Forms: Prepare and send a reference questionnaire package for each project listed on your Exhibit A, Performance Relevancy Questionnaires.

For Government contracts, send to Contracting Officer or Technical Representative. For commercial references send to personnel with duties similar to those for Government contracts. It is your responsibility to follow-up and to encourage your references to send in their questionnaire. If you have multiple references at one location (Base etc.), Send one cover letter and questionnaire for each contract you want a reference for. Your questionnaire package should contain the following.

Cover Letter (See SAMPLE) (Exhibit C1)

Respondent Info Rating Sheets (Exhibit C2) (the next 4 pages) Offeror should put name in spaces indicated and ensure it is on every page for identification purposes

Suggested - Pre Addressed stamped envelope to return to Contracting Officer.

OFFEROR SHOULD PLACE THEIR NAME ON TOP OF EACH QUESTIONNAIRE PAGE!!!

OFFEROR SHOULD DELETE THESE INSTRUCTIONS BEFORE SENDING OUT

QUESTIONNAIRES

EXHIBIT C1

SAMPLE TRANSMITTAL LETTER

AND

PAST PERFORMANCE EVALUATION QUESTIONNAIRE

Your Company Letterhead

Date: _________________

To: ______________________________________

We have listed your firm/agency as a reference for the work we have performed for you as listed below.

Our firm is submitting a proposal for a Multiple Award Construction Task Order Contract advertised by the 106 th

MSG/MSC, F.S. Gabreski ANG, 150 Riverhead Road, Westhampton Beach, NY 11978-1201. In accordance with Federal Acquisition Regulations (FAR), they will evaluate our firm's past performance.

Your candid response to the attached questionnaire will assist the evaluation team in this process. We understand that you have a busy schedule and your participation in this evaluation is greatly appreciated.

Please complete the enclosed questionnaire as thoroughly as possible. A “Final” Performance Evaluation

(Construction) (also referred to as CCASS Evaluation) issued for a project may be included in lieu of completing the reference package for the project. Space is provided for comments. Understand that while the responses to this questionnaire may be released to the offeror, FAR 15.306 (e) (4) prohibits the release of the names of the persons providing the responses. Complete confidentiality will be maintained. Only one response from each office is required.

Please send your completed questionnaire to the following address to arrive NOT LATER THAN

23 January 2013. Do not return them to our company.

MSG/MSC

F.S. Gabreski ANG

150 Riverhead Road

Westhampton Beach, NY 11978-1201 or fred.rodriguez@ang.af.mil and Kevin.fenner@ang.af.mil or Fax (631) 723-7569

If you have questions regarding the attached questionnaire, or require assistance, please contact Fred

Rodriguez, (631) 723-7562 fred.rodriguez@ang.af.mil or Kevin Fenner, (845) 563-2832. Thank you for your assistance. E-Mail is preferred.

Signature and Title mailto:fred.rodriguez@ang.af.mil mailto:Kevin.fenner@ang.af.mil

EXHIBIT C2

SOURCE SELECTION SENSITIVE WHEN COMPLETED*****NOT TO BE RELEASED OUTSIDE

GOVERNMENT CHANNELS***** RETURN THIS PAGE WITH QUESTIONNAIRE

RATING DESCRIPTIONS: Use the following descriptions as guidance in providing ratings.

RESPONDENT IDENTIFICATION AND RATINGS

(Part 1 Contractor submitting Proposal fill-in)

Reference is provided for:

Contract Number:

Project Title:

Date of Award:

Project Completion Date:

Project Location:

Dollar Value: $

Brief Description of Proj:

Your role in referenced contract:

(Part 2 Person providing Reference)

Reference is provided by:

Company/Agency:

Business Address:

Telephone Number:

Email Address:

Project Completion Date:

Relationship to Contract:

If information in Part I is not accurate please indicate.

To obtain an electronic version of the form please contact: Fred Rodriguez, (631) 723-7562 fred.rodriguez@ang.af.mil

THE QUESTIONNAIRE SHOULD BE SUBMITTED BY THE FOLLOWING MEANS: Return via FAX

Commercial (631) 723-7562 or DSN 456-7562 or via email to the email address shown above. Forms may

RATING DEFINITION

Outstanding (O) Indicates the contractor’s performance record within the area of evaluation

Exceeded that required by the contract.

Above Average (A) Indicates the contractor’s performance record within the area of evaluation

Met All contractual requirements.

Satisfactory (S) Indicates the contractor’s performance record within the area of evaluation

Met Essentially All contractual requirements.

Marginal (M) Indicates the contractor’s performance record within the area of evaluation

Met Some of the contractual requirements. However, changes to the contractor’s existing processes may be necessary in order to achieve contract requirements.

Unsatisfactory (U) Indicates the contractor’s performance record within the area of evaluation

Failed to Meet the minimum Government requirements.

Unknown or Not Applicable (N/A) The question does not apply. No performance record identifiable within the area of evaluation.

be mailed to 106 th

MSG/MSC, F.S. Gabreski ANG, 150 Riverhead Road, Westhampton Beach, NY 11978-

1201. Mark cover sheet: (Attention: RFP W912PQ-13-R-0002 “Source Selection Sensitive Information”)

Offeror Name______________________

SOURCE SELECTION SENSITIVE WHEN COMPLETED

Please provide evaluation of the following Performance Elements by placing an X in the appropriate column that corresponds to the rating definitions on the previous page.

QUALITY CONTROL

Outstand ing

Above

Average

Satisfact ory

Margina l

Unsatisf actory

Not

Applic able

(O) (A) (S) (M) (U) (N/A)

Quality of Workmanship

Adequacy of the quality control plan

Implementation of the Quality Control Plan

Quality of the Quality Control Documentation

Storage of Materials

Adequacy of Materials

Adequacy of Submittals

Adequacy of Quality Control Testing

Adequacy of As-Builts

Use of Specified Materials

Identification/Correction of Deficient work in a timely manner

Comments on Quality Control:

TIMELY PERFORMANCE

(O) (A) (S) (M) (U) (N/A)

Adequacy of Initial Progress Schedule

Adherence to Approved Schedule

Resolution of Delays

Submission of Required Documentation

Completion of Punchlist Items

Submission of Updated and Revised Progress

Schedules

Warranty Response

Comments on Timely Performance:

EFFECTIVENESS OF MANAGEMENT

Cooperation and Responsiveness

Management of Resources/Personnel

Coordination and Control of

Subcontractors

Adequacy of Site Clean Up

Effectiveness of Job-Site Supervision

Compliance with Laws and Regulations

Professional Conduct

Review/Resolution of Subcontractor

Issues

Implementation of Subcontracting Plan

Offeror Name______________________

SOURCE SELECTION SENSITIVE WHEN COMPLETED

Comments on Effectiveness of Management:

COMPLIANCE WITH LABOR STANDARDS

Correction of Noted Deficiencies

Payrolls Properly Completed and Submitted

Compliance with Labor Laws and Regulations with Specific Attention to the Davis-Bacon Act and EEO Requirements

Comments on Compliance With Labor Standards:

COMPLIANCE WITH SAFETY STANDARDS

Adequacy of Safety Plan

Implementation of Safety Plan

Correction of Noted Deficiencies

Comments on Compliance With Safety Standards:

OVERALL RATING of PERFORMANCE (O) (A) (S) (M) (U) (N/A)

Please provide any additional information you feel is important and not covered elsewhere in this evaluation:

Thank you for your remarks. Be sure to return to the Contracting Agency and not to the Contractor you are providing a reference for.

OFFEROR NAME___________________________

Respondent Signature ______________________________________Date Completed:______________________

EXHIBIT D – TECHNICAL PROPOSAL DATA

Offerors are cautioned to read sections 00800 and Division One of the solicitation documents before completing Exhibit D as your answers must meet the minimum requirements found in these sections.

Offerors are strongly encouraged to review the evaluation information found in Section 00120 as they complete their Exhibit D.

Each question should be covered in sufficient detail to clearly address all required information. Answer questions in order presented. You are NOT limited to the space provided; use as much space as necessary to provide answers. It is advisable to state the question then give the answer. This will aid in the evaluation.

In the event you reference another document or part of the proposal you must be clear as to where the information can be found to answer the particular question(s). Such statements as see Company profile or see Safety Plan are not acceptable. You must indicate on what page of the proposal the answer can be found in the referenced document. Failure to do so may make your proposal non-compliant.

The Project Management data is obtained for the purpose of evaluating technical capability in performance of future task order projects. The offeror is required to provide required information to show experience and capability to manage multiple disciplined projects.

1. CAPABILITY AND EXPERIENCE:

1A: Describe your experience and capability in managing construction projects for the dollar levels, disciplines, and locations you are requesting in “Areas of Consideration”. Why are you a good candidate for receiving an award? ( Note: You will be evaluated at all levels with considerable consideration given to the highest dollar level you are requesting. If you have no experience at the higher dollar levels consider asking for an award at a lower level and going to the higher amounts in the option years.)

1B: This contract requires short notice site visits/proposal meetings, normally within 2 calendar days, but can be as short as 240 minutes. (Consider reporting to the 105 th

Air Wing, Newburgh, NY and/or the 106

Rescue Wing, Westhampton Beach, NY, if you chose that location). Give details on how will you ensure compliance with these requirements?

1C: Discuss experience with constructing to United States Green Building Council (USGBC) LEED® standards. If no experience so state and indicate how you plan to overcome this weakness should a task order have these requirements.

1 D: Explain in detail how you will perform the minimum percentage required, 15%, with your own forces. Note: An offeror who has the capability to perform both as a General contractor and self perform a major element of construction, for example, Electrical, or Mechanical or Roofing, may be afforded additional consideration in the evaluation.

2. ORGANIZATION:

2A: Provide as an attachment an Organizational Chart listing company personnel and their roles.

(Titles) (Attachment 1)

2B: Provide names, duties and levels of responsibility of key personnel to include the Project Manager, Site Superintendent(s), Quality Control Manager and Safety Manager. Indicate to whom the Quality

Control and Safety Managers report. (Lines of authority)

2C: Provide a list of the in-house trades that you employ. Provide the number (not names) of these employees and if they are full-time, part- time etc.

2D: If applicable, describe the support and interface with your home office or corporate headquarters for such aspects as financial, management and technical support. If not applicable state 2D- Not applicable.

3. SPECIFIC PERSONNEL

3A: Discuss the education, training and experience in managing construction projects of the key personnel listed in 2B. (A resume may be submitted if it provides this information. Attachment # 2))

3B: Provide list of major subcontractors and their trades that you intend to use on these projects. (These also should have been listed in Exhibit A PART 2 and there must be an Exhibit B in the proposal for the named subcontractors or they will not be considered.)

3C: Tell us if you have worked together in the past. If yes, on what kind of jobs?

4. SCHEDULING METHODOLOGY - Adequate scheduling processes are necessary to ensure completion and control of the project from beginning to the end of the project.

4A: Discuss your scheduling capabilities. Include such things as programs and staff to do scheduling.

4B: Include a schedule for the prototypical project(s). Use a Notice to proceed date of 1 March, 2013, Offerors not being considered for task orders over $1M may provide schedule in any acceptable format, offerors being evaluated for orders over $1 Million should provide the schedule in Critical Path Method

(CPM) format to demonstrate capability. (This includes prototypical/seed projects valued at less than

$1M.) If the project is less than $1M an offeror may provide a sample CPM from a previously completed project to demonstrate capability but must also provide a schedule in any format for the prototypical project.

5. QUALITY CONTROL- (In addition to the information required in this question, information on personnel, duties, responsibilities and lines of authority provided in response to questions 2 and 3 will be used in the evaluation of Quality Control.)

5A: Discuss how quality issues will be dealt with on various types of construction projects. Include in the discussion as a minimum, meetings, inspections, submittal reviews, correction of non-compliant work and how you intend to ensure non-reoccurrence and reporting of quality problems to Government officials.

(Note: A full Quality Control Plan will be required if you are awarded a contract and is NOT required with the proposal. If you do provide a plan, indicate if it is a draft for this contract or a sample from another project. Also, provide in the answer to this question the page numbers where the required information (list of minimum information above) can be found. If you fail to follow these instructions, your proposal may not be adequately evaluated.) Full Quality Control Plans if provided WILL NOT be evaluated.

5B: Discuss your procedures for contract closeout (Punch list, as builts, etc.).

6. SAFETY

6A: Discuss your Safety Program in general, and provide as a minimum, details on training, documentation, and your plan to ensure adherence to OSHA Standards, and the USACOE EM 385-1-1

(Safety Manual).

(Note: A full Safety Plan will be required if you are awarded a contract and is NOT required with the proposal. If you do provide a plan, indicate if it is a draft for this contract, a sample from another project or a corporate plan. Also, provide in the answer to this question the page numbers where the required information (listed above) can be found. If you fail to follow these instructions, your proposal may not be adequately evaluated.) Full Safety Plans if provided WILL NOT be evaluated.

6B: Discuss the steps you took to promote safety during construction during the past three (3) years.

Attachments

1. Organization Chart (required)

2. Resumes (optional)

3. Schedule (required)

EXHIBIT F - PROPOSAL VOLUME CONTENTS AID

This listing is provided as an aid to offerors and in no way represents all information that is required in a proposal. Offerors must comply with Sections 00100, 00110 and 00120 of the solicitation.

Binder # 1 - VOLUME 1, PRICE/COST INFORMATION

( ) A Cover letter that contains a points of contact with names and email and phone numbers.

Provide the names of authorized negotiators. Cage Code, Duns number, Tax ID number. Statement of socio-economic size

( ) Offer and Section 00010 – Complete in its entirety the “Offeror” portion of the Standard Form

(SF) 1442. An official having the authority to contractually bind your company must sign the SF 1442 in accordance with FAR 4.102. Submit an original and the number of copies required by solicitation. An original signature is required on the original document.

( ) A completed Section 00010, Areas of Consideration

Prototypical project, Exhibit E

( ) Insert the price/cost associated with the prototypical project on the Prototypical Proposal Offer

Schedule(s)

( ) Representations and Certifications- Section 00600- Complete the Annual Certification on ORCA.

Insert the required certifications and representations in section 00600 and return with proposal.

Binder # 2 - VOLUME 2, PAST PERFORMANCE INFORMATION

**REMINDER- Send out Questionnaires to your former clients so responses reach Contracting Officer No later than solicitation closing date!!!**

( ) Exhibit A, Part 1: Performance Relevancy Questionnaire format, for six (6) general construction projects. Follow special instructions for IDIQ Contracts.

( ) Exhibit A, Part 2: Answer all questions.

( ) Exhibit B “Subcontractor Consent and Information Form” for each major subcontractor/ Teaming

Partner listed in Exhibit A Part 2.

( ) Exhibit C reference questionnaires: Provide list by name and company agency only who you sent reference questionnaires, or include a “final” performance Evaluation for Construction in lieu of sending out questionnaire. Be sure to send a reference package to all Clients listed on Exhibit As, Part 1, in sufficient time so as to have questionnaires reach the Contracting Officer not later than the closing date for the solicitation. Follow-up with clients as necessary.

Offerors lacking relevant Past Performance experience may submit three (3) references for each

Predecessor Company, Subcontractor or Key Personnel on an Exhibit C, or resume for key personnel.

Exhibit C Reference Packages should also be sent.

Binder # 2 VOLUME 3, TECHNICAL INFORMATION

( ) Exhibit D – Is format and instructions complied with?

( ) Did you review Section 00800 and Division One to ensure your answers meet the minimum requirements? Did you review Section 00120, Technical Evaluation, to ensure answers to questions and submission provide information needed for the evaluation?

( ) Are answers to the questions clear and detailed?

( ) Are all required attachments provided?

General:

( ) Did you submit an Original and one copy of Binder # 1 (Volume 1)?

( ) Did you submit an Original and 3 hard copies of Binder # 2 (Volumes 2 and 3)?

( ) Did you submit an electronic version of your proposal? (Exhibit E does not have be submitted in electronic version)

EXHIBIT G

PROPOSAL INQUIRY FORMAT

SOLICITATION W912PQ-13-R-0002

NOTE: ALL PRE-PROPOSAL INQUIRIES SHALL BE SUBMITTED VIA FAX OR EMAIL IN THIS

FORMAT OR WITH ALL INFORMATION SHOWN ON FORM!

FAX: (631) 723-7569 EMAIL: fred.rodriguez@ang.af.mil Kevin.Fenner@ang.af.mil

Date of Proposal Inquiry: _______________

From: ______________________________ Company Name: ________________________________

Address:_____________________________________________________________________________

Phone Number: _____________________________ Fax Number:______________________________

Email address: ________________________________________________________________________

Proposal Inquiry: (Please type or print clearly) mailto:Kevin.Fenner@ang.af.mil