Specifications_-_Comfort_Station.pdf

SPECIFICATIONS DIVISIONS 1 - 49

Final Construction Documents Submittal

CUYAHOGA VALLEY NATIONAL PARK

PMIS Number: 257393

Comfort Station Upgrade at Brandywine Falls 31 March, 2021

NATIONAL PARK SERVICE BRECKSVILLE, OH

03/31/2021

03/31/2021

BRANDYWINE FALLS COMFORT STATION UPGRADE CUVA-257393 TC-1

PROJECT MANUAL

BRANDYWINE FALLS COMFORT STATION UPGRADE

CUYAHOGA, OHIO

NATIONAL PARK SERVICE

PMIS 257393

TABLE OF CONTENTS

Division 1 - General Requirements Summary of Work 01 11 00 Contract Modification Procedures 01 26 01 Definition of Contract Line Items 01 27 00 Project Management & Coordination 01 31 00 Construction Schedule 01 32 16 Submittal Procedures 01 33 23 Archeological Protection 01 35 13.22 Safety Requirements 01 35 23 Quality Requirements 01 40 00 References 01 42 00 Temporary Facilities and Controls 01 50 00 Indoor Air Quality Management 01 57 19.11 Noise & Acoustics Management 01 57 19.12 Under-An-Acre Pollution Prevention 01 57 23 Product Requirements 01 67 00 Cutting and Patching 01 73 29 Execution 01 73 40 Construction Waste Management and Disposal 01 74 19 Closeout Procedures 01 77 00 Operation and Maintenance Data 01 78 23

Division 2 - Site Work

Building Demolition 02 41 00

Division 3 - Concrete

Concrete Formwork 03 10 00 Concrete Reinforcement 03 20 00 Cast-In-Place Concrete 03 30 00 Non-Shrink Grout 03 36 00 Grouting 03 60 00

Division 4 – Masonry Unit Masonry 04 20 00

Division 5 – Metals

Structural Steel 05 10 00 Metal Fabrications 05 50 00

Division 6 – Wood, Plastics and Composites

Rough Carpentry 06 10 00 Prefabricated Wood Trusses 06 19 00 Finish Carpentry 06 20 00 Wood Treatment 06 30 00

Division 7 - Thermal and Moisture Protection

Building Insulation 07 20 00 Flashing and Sheet Metal 07 60 00 Joint Sealers 07 92 00

BRANDYWINE FALLS COMFORT STATION UPGRADE CUVA-257393 TC-2

Division 8 – Openings

Metal Doors and Frames 08 11 13 Alum Manufactured Windows 08 52 10 Hardware and Specialties 08 71 00

Division 9 – Finishes Color Schedule 09 06 90

Gypsum Drywall 09 29 00 Painting 09 90 00 Resinous Floor Coatings 09 93 00

Division 10 - Specialties

Toilet Compartments and Cubicles 10 21 13 Toilet Accessories 10 28 13 Fire Fighting Devices 10 44 16

Divisions 11 thru 20 - Not Used

Division 21 – Fire Suppression Facility Fire Hydrants 21 11 16

Division 22 – Plumbing Common Requirements for Plumbing 22 04 00 Sleeves and Sleeve Seals for Plumbing Piping 22 05 17 Meters and Gages for Plumbing Piping 22 05 19 Plumbing Piping Insulation 22 07 19 Plumbing Piping 22 10 05 Plumbing Piping Specialties 22 10 06 Facility Septic Tanks 22 13 53 Ductile Iron Pipe 22 15 05 Miscellaneous Valves 22 15 10 Pipe Hangers and Supports 22 15 14 Commercial Electric Domestic Water Heaters 22 33 00 Plumbing Fixtures 22 40 00

Division 23 – Heating, Ventilating, and Air-Conditioning (HVAC) Common Requirements for HVAC 23 04 00 Testing, Adjusting, and Balancing for HVAC 23 05 93 Duct Insulation 23 07 13 HVAC Ducts and Casings 23 31 00 Air Duct Accessories 23 33 00 Air Outlets and Inlets 23 37 00 Packaged Air to Air Energy Recovery Units 23 72 23 Convection Heating and Cooling Units 23 82 00

Divisions 24 & 25 – Not Used

Division 26 – Electrical Common Requirements for Electrical 26 04 00 Low-Voltage Electrical Power Conductors and Cables 26 05 19 Grounding and Bonding 26 05 26 Hangers and Supports 26 05 29 Conduit 26 05 33.13 Boxes 26 05 33.16 Identification for Electrical Systems 26 05 53 Wiring Connections 26 05 83

Panelboards 26 24 16 Wiring Devices 26 27 26

BRANDYWINE FALLS COMFORT STATION UPGRADE CUVA-257393 TC-3

Fuses 26 28 13 Enclosed Switches 26 28 16.16

Surge Protection Devices 26 43 00 Interior Lighting 26 51 00

Divisions 27 thru 30 - Not Used

Division 31 – Earthwork

Earthwork 31 02 20 Trenching and Backfilling for Utilities 31 02 22 Site Clearing 31 10 00 Hot Asphalt Mix Paving 31 12 16 Dewatering 31 23 19

Division 32 – Exterior Improvements Chain Link Fence and Gates 32 28 31 Seeding and Sodding 32 29 30

Division 33 – Utilities Disinfection of Piping 33 13 00

Divisions 34 thru 49 - Not Used

CUVA - 257393 01 11 00 - 1

091015 SUMMARY OF WORK

SECTION 01 11 00 - SUMMARY OF WORK

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes the following:

1. Work covered by the Contract Documents.

2. Contractor use of premises.

3. Public use of site.

4. Work Restrictions.

5. Special Construction Requirements.

6. Additional Reports.

1.2 WORK COVERED BY CONTRACT DOCUMENTS

A. Project Location: Cuyahoga Valley National Park comfort station at Brandywine Falls, 15610 Vaughn Road, Brecksville, Ohio.

B. The Work consists of the following:

1. The Work includes the renovation/upgrade of the existing wood constructed vault toilet comfort station into a temperature-controlled flush toilet system with potable water and a septic tank/drain field sewer disposal system. The comfort station’s existing basement, foundation walls and floor structure shall remain. The new comfort station’s exterior walls will match the Park’s Canal Visitor Center comfort station’s split face masonry and overall aesthetic. New foundations will be built below a small addition needed for lavatories at both the men’s side and women’s side of the comfort station.

2. The Work also includes construction of a new water main to provide running water for this comfort station in compliance with EPA and Ohio design standards.

C. Project will be constructed under a single prime contract.

D. Period of Performance shall be 12 months from the issuance of the notice to proceed date.

1.3 CONTRACTOR USE OF SITE

A. General: Contractor shall have full use of the site for construction operations during the construction period. Contractor's use of the site is limited only by the Government's right to perform work or to retain other contractors on portions of Project.

B. Storage of Materials: Confine storage of materials to location directed by COR.

C. Preservation of Natural Features:

CUVA - 257393 01 11 00 - 2

1. Prevent damage to natural surroundings. Restore damaged areas, repairing or replacing damaged trees and plants, at no additional expense to the Government.

2. Provide temporary barriers to protect existing trees and plants and root zones.

3. Do not remove, injure, or destroy trees or other plants without prior approval. Consult with

Contracting Officer and remove agreed-on roots and branches that interfere with construction.

4. Do not fasten ropes, cables, or guys to existing trees.

5. Carefully supervise excavating, grading, filling, and other construction operations near trees to prevent damage.

D. Driveways and Entrances: Keep driveways, parking lot and entrances serving premises clear and available to Government, Government's employees, and emergency vehicles at all times. Do not use these areas for parking or storage of materials.

1. Schedule deliveries to minimize use of driveways and entrances.

2. Schedule deliveries to minimize space and time requirements for storage of materials and equipment on-site.

E. Construction Camp: Establishment of a camp within the park will not be permitted.

F. Hauling Restrictions: Comply with all legal load restrictions in the hauling of materials. Load restrictions on park roads are identical to the state load restrictions with such additional regulations as may be imposed by the Park Superintendent. Information regarding rules and regulations for vehicular traffic on park roads may be obtained from the Office of the Park Superintendent. A special permit will not relieve Contractor of liability for damage which may result from moving of equipment.

1.4 PUBLIC USE OF SITE

A. The building will be closed to the public during construction.

1.5 OCCUPANCY REQUIRMENTS FOR BUILIDINGS

A. New Buildings

1. Government Occupancy of Completed Areas of Construction: Government reserves the right to occupy and to place and install equipment in completed areas of building, provided such occupancy does not interfere with completion of the Work. Such placement of equipment and partial occupancy shall not constitute acceptance of the entire project.

a. COR will prepare a Beneficial Occupancy letter for each specific portion of the Work to be occupied before Government occupancy.

b. Obtain a Certificate of Occupancy from the NPS before Government occupancy.

c. Before partial Government occupancy, mechanical and electrical systems shall be fully operational, and required tests and inspections shall be successfully completed.

On occupancy, Government will operate and maintain mechanical and electrical systems serving occupied portions of building.

d. On occupancy, Government will assume responsibility for maintenance and custodial service for occupied portions of building.

CUVA - 257393 01 11 00 - 3

1.6 CONDUCT OF OPERATIONS

A. At all times the contractor shall conduct his operations in conformance with the rules and regulations promulgated by the Secretary of the Interior for the National Park Service, and applicable park rules and regulations prescribed by the Park Superintendent.

B. Work on Saturdays, Sundays, Federal holidays or at night may not be performed without prior consent from the COR. Submit requests 24 hours in advance of the work to the COR for approval.

C. No signs or advertisements (except those specified herein) shall be displayed on the construction site or within the park unless approved by the COR.

1.7 WORK RESTRICTIONS

A. On-Site Work Hours: Work shall be generally performed during normal business working hours of 6:30 a.m. to 5:00 p.m., Monday through Friday, except when otherwise indicated.

1. Weekend hours: If approved in advance. Contractor shall coordinate working hours with COR (Gates are open 24/7/365).

B. Existing Utilities

1. Existing Utilities: Notify COR and utility companies of proposed locations and times for excavation.

2. Contractor shall be responsible for locating and preventing damage to known utilities. If damage occurs, repair utility at no additional expense to the Government.

3. If damage occurs to an unknown utility, repair utility. An equitable adjustment will be made in accordance with the Changes clause of the contract.

C. Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by Government or others unless permitted under the following conditions and then only after arranging to provide temporary utility services according to requirements indicated:

1. Notify COR not less than two days in advance of proposed utility interruptions.

2. Do not proceed with utility interruptions without COR’s written permission.

3. Hours for Utility Shutdowns: 7:30 a.m. to 3:30 p.m. Maximum duration = 4 hours.

D. Nonsmoking Building: Smoking is not permitted within the building or within 25 feet of entrances, operable windows, or outdoor air intakes.

1.8 SPECIAL CONSTRUCTION REQUIREMENTS

A. Cuyahoga Valley National Park is always open, although visitation is heavier from April thru November. The Canal Exploration Visitation Center is closed to visitors 1 December thru 31 January each season.

B. Project Website: A project website administered by the NPS will be used for purposes of managing communication and documents during the construction stage.

1. See Section 01 31 00 “Project Management and Coordination” for requirements on using the Project Website.

CUVA - 257393 01 11 00 - 4

C. Verify with COR if the contractor will or will not be allowed to work on the following days:

1. New Year’s Day (January)

2. Birthday of Martin Luther King, Jr. (January)

3. Washington’s Birthday (February)

4. Memorial Day (May)

5. Independence Day (July)

6. Labor Day (September)

7. Columbus Day (October)

8. Veterans Day (November)

9. Thanksgiving (November)

10. Christmas Day (December)

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 11 00

CUVA - 257393 01 26 01 - 1

031414 CONTRACT MODIFICATION PROCEDURES

SECTION 01 26 01 – CONTRACT MODIFICATION PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. The work of this section consists of administrative and procedural requirements for contract modifications.

1.2 DEFINITIONS AND ALLOWANCES

A. Home Office Overhead: Those costs incurred in support of all of a contractor’s projects and not attributable to a specific job. The cost for home office overhead is only allowed as a percentage of all direct work excluding profit. The following items represent allowable home office overhead costs identified in Part 31 of the Federal Acquisition Regulation (FAR):

1. Rent

2. Utilities

3. Furnishings

4. Office equipment

5. Executive and management staff not exclusively assigned to the project

6. Support, accounting, and administrative staff

7. Preparation of cost proposals, estimating, and schedule analyses connected with

Modifications

8. Estimating and preconstruction services

9. Mortgage costs

10. Real estate and corporate taxes

11. Automobile maintenance and travel costs for home office personnel

12. Home office insurances i.e. structure, automotive, umbrella, flood, etc.

13. Depreciation of equipment and other assets

14. Home office supplies (paper, staples, etc.)

15. Legal services

16. Accounting and data processing

17. Professional fees/registration

B. General Conditions (Field Office Overhead): Management and administrative costs incurred on site for the designated project. Costs associated with the preparation of modifications will not be allowed. The costs for these items are to be included only in the general conditions of the modification estimate. Only in the case of a contract time extension are additional general conditions included in modifications. The following items, if applicable, are considered allowable costs for calculating General Conditions:

1. Project Manager, Assistant Project Manager

2. Superintendent, Assistant Superintendent

3. Quality Control, Safety Officer, Environmental Manager, etc.

4. Engineers

5. Travel, lodging, and per diem (as established by Federal Travel Regulations)

CUVA - 257393 01 26 01 - 2

6. Scheduling

7. Field Office Trailers and associated temporary utilities

8. Field office supplies

a. Mailing and couriers

b. Reproduction costs

c. Storage

d. Phones

e. Computers

f. Copiers

9. Personal vehicles i.e. Superintendent Pickup trucks

C. General Requirements: These are costs directly associated with the project and are necessary to perform the actual work of the modification. These costs shall be shown as direct costs in the estimate. The following items, if applicable, are considered allowable costs for calculating General Requirements:

1. Hoisting

2. Material handling

3. Temporary fencing

4. Port-a-lets

5. Trash removal, dumpsters

6. Barricades

7. Small tools

8. Safety supplies

9. Scaffolding

10. Daily cleaning

11. Traffic control

12. Temporary signage

13. Temporary heating and power

D. Personnel Costs: Costs included in the modification must only be for General Conditions staff and workers actually present and working on the project site. Modification costs for salaried workers are only allowed within the structure of a 40 hour week and no overtime or holiday pay will be allowed.

1. Worker Hourly Rates are costs directly associated with the individual worker and consist of the following:

a. Base Rate: This is the hourly rate paid directly to the worker

b. Labor Burden: Employer payments of all applicable burdens, this includes insurance and taxes that the business must pay on behalf of the worker to government entities and educational forums , such as:

1) Social Security

2) Medicare

3) Workers Compensation– Policy and company calculation to be made available.

4) FUTA– Cap Rate and percentage to be proportionally allocated over one year.

5) SUTA– Cap Rate and percentage to be proportionally allocated over one year.

CUVA - 257393 01 26 01 - 3

6) Union agreement costs – Other costs required under an enforceable collective bargaining agreement.

c. Fringe Benefits: Various non-wage compensations provided to employees such as:

1) Health Care Insurance Premiums

2) Cell Phone

3) Clothing

4) 401K and Pensions

5) Vehicle allowances

6) Gas allowance

7) Life insurance premiums

8) Disability insurance

9) Other Fringe Benefits required under an enforceable collective bargaining agreement

E. Bonuses or Deferred Compensation: No Bonus or Deferred Compensation will be allowed within any components of pricing including Home Office Overhead, General Conditions, General Requirements, Hourly Worker Rates, or the direct costs of work.

F. General Liability Insurance: An insurance policy that protects the contractor from claims resulting from bodily injury or property damage to a third party. Include this as a separate line item within all modification proposals and provide a current insurance quote upon request.

G. Performance and Payment Bonds: A performance bond is a surety bond issued by an insurance company or bank to guarantee satisfactory completion of a project. The Payment Bond guarantees that the contractor will pay the labor and material costs they have incurred. Banks and Insurance companies charge a premium for each individual project based on a sliding scale which relates to the size of the project. Include this as a separate line item in modification proposals and provide current company bonding rates upon request.

H. Builder’s Risk Insurance: This covers the contractor’s loss due to fire, high winds, or other natural forces. This is not reimbursed by the National Park Service (NPS) and shall not be included in modification proposals.

1.3 MODIFICATION PROPOSAL PRICING REQUIREMENTS

A. General:

1. Your proposal must be received in the format and within the time frame specified in the Request for Proposal letter. Costs or delays resulting from failure of contractor to submit within the time frame specified will not be compensable.

2. The proposal must be detailed with itemized lists of equipment, materials, labor, production rates, overhead, profit, and bond markup for each item. Labor costs must be itemized by craft and hourly rate, including Fringe Benefits and Labor Burden. If the costs of Fringe Benefits and Labor Burden are not itemized, it is assumed that that they are included in the hourly rate shown, or contractor is not requesting reimbursement.

Contractor may utilize the government provided Contractor Estimate Form, or their http://en.wikipedia.org/wiki/Employee http://en.wikipedia.org/wiki/Surety_bond http://en.wikipedia.org/wiki/Insurance http://en.wikipedia.org/wiki/Bank http://www.nps.gov/dscw/publicforms.htm#ct

CUVA - 257393 01 26 01 - 4

own form, provided that it contains the same information and level of detail as the Gov’t provided form.

3. Requests for extensions of contract time as a result of this change must be justified with a Time Impact Analysis (TIA). Refer to Division 01 Specification, “Construction Schedule”, for time impact analysis requirements. TIA and associated costs must be received with the proposal by the date shown within the Request for Proposal letter.

Contractor’s failure to submit within the specified time frame will be construed as the Contractor waiving the right for additional time and no time extension will be allowed.

4. All supporting documentation used to justify the proposed modification will be made available to the Contracting Officer upon request.

5. Contractor must review and approve all subcontractor/supplier pricing in detail for proper format, scope, production rates, and pricing prior to submission to the NPS. All delay costs associated with not reviewing and approving subcontractor/supplier pricing will be borne by the Contractor.

6. All pricing and production rates within the estimate must be based on fair and reasonable pricing and cannot include built-in contingency.

B. Labor:

1. Contractor shall estimate the cost of labor by itemizing each craft involved, indicating worker hourly rate (base rate + labor burden + fringe benefits) for each and itemizing the hours required for each craft that will be directly engaged in modification work.

Any work proposed that will require overtime work or premium pay shall be itemized separately. All rates shall be in accordance with the Davis-Bacon Act as incorporated herein. Labor Burden may include payroll taxes, Social Security, unemployment insurances, workers compensation insurance, FICA, FUTA, and other direct costs resulting from Federal, State or local laws.

2. Itemize labor costs for equipment operators separate from equipment costs.

3. The labor cost for foremen shall only be costs for related work required for the modification.

C. Materials:

1. The estimated cost for materials shall include quotes from multiple sources. Material prices must include all applicable fees and credits, including but not limited to, sales tax, freight and delivery charges, and tax rebates.

2. No markup shall be applied to any material provided by the NPS.

D. Equipment:

1. Equipment used for the project must be appropriately sized for the work being performed.

2. Do not include costs for “miscellaneous tools and equipment”, in your proposal for a replacement value of $500 or less. Costs shown in excess of $500 must be broken out separately.

3. Regardless of ownership, the rates to be used in determining equipment rental costs shall be the lowest cost from one of the following sources:

a. U.S. Army Corps of Engineers , Ownership and Operating Expense Schedule (use latest edition and applicable region)

b. Construction Blue Book

CUVA - 257393 01 26 01 - 5

c. Local equipment rental rates, documented by actual invoice charges, or itemized vendor quotes.

4. The estimated equipment rates shall include the operating costs of all fuel, oil, lubrication, supplies, small tools, necessary attachments, ground engaging components, tires & tracks, routine repairs and maintenance (cost of major repair and overhaul is not allowed per FAR 31.105(d)(2)), depreciation, storage, insurance, and all incidentals.

Mobilization, if applicable, may be included for equipment solely used on the modification work but must be listed separately.

5. Estimate the full rate for equipment only for the duration that the equipment will be utilized to accomplish the work of the modification.

6. Standby unit rates used are to be in accordance with paragraph 1.3, D, 2, above. If the US Army Corp of Engineers is utilized then their standby rates prevail. If Bluebook or local equipment pricing is accepted, then ½ of the equipment costs minus any operating costs, major repair and overhaul will be accepted.

7. If equipment is in standby mode due solely to a documented NPS delay, the established standby rate shall apply from the first day of the delay.

8. Equipment that is not used and on the jobsite for up to five consecutive days may be classified at standby rates, provided that the equipment is or has been used solely to perform work on the modification and will be necessary to complete additional modification work. Equipment that is still on the jobsite but not in use after five consecutive days will not be considered in the modification pricing.

9. Requests for compensation for equipment stand by time must be justified, documented and itemized separately.

10. The estimated timeframe (daily, weekly, monthly) for use of the equipment must reflect the lowest cost to the Government.

PART 2 - PRODUCTS

PART 3 - EXECUTION

END OF SECTION 012601

CUVA - 257393 01 27 00 - 1

082714 DEFINITION OF CONTRACT LINE ITEMS

SECTION 01 27 00 – DEFINITION OF CONTRACT LINE ITEMS

PART 1 - GENERAL

1.1 SUMMARY

A. The intent of this section is to explain, in general, what is and what is not included in a contract line item, and the limits or cut-off points where one item ends and another begins.

B. If no contract line item exists for a portion of the work, include the costs in a related item.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION

3.1 LIST OF CONTRACT LINE ITEMS

A. Contract Line Item No. 0001:

1. This item consists of demolition of above grade framing of existing comfort station, and construction of a new comfort station facility including utilities (electricity and potable water) and a septic tank/drain field disposal system.

2. Payment will be made at the contract lump sum price.

CUVA - 257393 01 31 00 - 1

091015 PROJECT MANAGEMENT AND COORDINATION

SECTION 01 31 00 - PROJECT MANAGEMENT AND COORDINATION

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes administrative provisions for coordinating construction operations on Project including, but not limited to, the following:

1. Construction Coordination.

2. Requests for Information (RFIs).

3. NPS/DSC SharePoint Project Website.

4. Project meetings.

5. Environmental Coordination.

6. Permits

7. Utility Fees

B. Related Requirements:

1. Section 01 32 16 “Construction Schedule” for preparing and submitting Contractor’s construction schedule.

2. Section 01 73 40 “Execution” for procedures for coordinating general installation and field-engineering services, including establishment of benchmarks and control points.

3. Section 01 77 00 “Closeout Procedures” for coordinating closeout of the Contract.

1.2 CONSTRUCTION COORDINATION

A. Coordination: Coordinate construction operations included in different Sections of the Specifications to ensure efficient and orderly installation of each part of the Work. Coordinate construction operations, included in different Sections, which depend on each other for proper installation, connection, and operation.

1. Schedule construction operations in sequence required to obtain the best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

2. Coordinate installation of different components with other Contractors to ensure maximum accessibility for required maintenance, service, and repair.

3. Make adequate provisions to accommodate items scheduled for later installation.

4. Where availability of space is limited, coordinate installation of different components to ensure maximum performance and accessibility for required maintenance, service, and repair of all components, including mechanical and electrical.

5. Properly plan construction operations to include permit requirements. Allow enough time to execute permit provisions to maintain work schedule, site visits, inspections, and reporting deadlines.

CUVA - 257393 01 31 00 - 2

B. Prepare memoranda for distribution to each party involved, outlining special procedures required for coordination. Include such items as required notices, reports, and list of attendees at meetings.

C. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities and activities of other contractors to avoid conflicts and to ensure orderly progress of the Work. Such administrative activities include, but are not limited to, the following:

1. Preparation of Contractor's Construction Schedule.

2. Preparation of the Schedule of Values.

3. Installation and removal of temporary facilities and controls.

4. Delivery and processing of submittals.

5. Progress meetings.

6. Permit requirements.

7. Utility Fee Requirements

8. Pre-installation conferences.

9. Project closeout activities.

1.3 SUBMITTALS

A. Division 01 documents: The following items shall be submitted a minimum of one week prior to the Preconstruction Conference. Contracting Officer will notify Contractor of tentative date for the Pre-Construction Conference.

1. Letter designating Project Superintendent.

2. Construction Schedule.

3. A comprehensive breakdown of the Schedule of Values.

4. Accident Prevention Plan.

5. A list of Subcontractors for this project.

6. Written statements from subcontractors certifying compliance with applicable labor standard clauses.

7. Satisfactory evidence of liability insurance coverage and workman’s compensation for the

Contactor and all subcontractors.

8. Waste Management Plan.

9. Quality Control Plan.

10. Temporary Storm Water Pollution Prevention Plan (SWPP or UPPP).

11. Indoor Air Quality (IAQ) Management Plan.

12. List of Required Construction Permits. Include the following information for each permit:

a. Name of Permit.

b. The Agency(ies) with Jurisdiction issuing the permit.

c. Information required from the Government to complete the permit application.

B. All items listed must be provided to the Contracting Officer before the Pre-Construction Conference is held. If all of these documents have not been received one week prior to the scheduled Pre-Construction Conference date, the conference will be cancelled, Notice to Proceed will not be issued, and the Contracting Officer will consider other contractual remedies. Work shall not commence until written Notice to Proceed has been issued.

CUVA - 257393 01 31 00 - 3

1.4 REQUESTS FOR INFORMATION (RFIs)

A. General: Immediately on discovery of the need for additional information or interpretation of the Contract Documents, Contractor shall prepare and submit an RFI utilizing the form created on the NPS/DSC SharePoint Project website.

1. COR will not respond to RFIs submitted by other entities controlled by Contractor.

2. Coordinate and submit RFIs in a prompt manner to avoid delays in the work.

B. Content of the RFI: Include a detailed, legible description of item needing information or interpretation and the following:

1. RFI number, numbered sequentially.

2. Date.

3. RFI subject.

4. Specification Section number and title and related paragraphs, as appropriate.

5. Drawing number and detail references, as appropriate.

6. Field dimensions and conditions, as appropriate.

7. Contractor's suggested resolution. If Contractor's suggested resolution impacts the

Contract Time or the Contract Sum, Contractor shall state impact in the RFI.

8. Contractor's signature.

9. Requested date for response.

10. Attachments: Include sketches, descriptions, measurements, photos, Product Data, Shop

Drawings, coordination drawings, and other information necessary to fully describe items needing interpretation.

a. Include dimensions, thicknesses, structural grid references, and details of affected materials, assemblies, and attachments on attached sketches.

A. RFI Form: Complete the RFI Form on the NPS/DSC SharePoint website as follows:

1. Enter the general information at the top of the form.

2. Under the “Action” section at the bottom of the form, select “Question” then select “CMR” in the drop-down of the “Send to” box.

3. Enter the details of the question and attach related documents.

4. Select “Submit Form” at the bottom of the page.

B. COR’s Action: CO will review each RFI, determine action required, and respond. CO will determine the critical nature of each RFI and issue a response accordingly.

1. The following are not considered to be RFIs and will receive no action:

a. Requests for approval of submittals.

b. Requests for approval of substitutions.

c. Requests for approval of Contractor's means and methods.

d. Requests for coordination information already indicated in the Contract Documents.

e. Requests for adjustments in the Contract Time or the Contract Sum.

f. Requests for interpretation of Architect's actions on submittals.

g. Incomplete RFIs or inaccurately prepared RFIs.

CUVA - 257393 01 31 00 - 4

2. COR's action may include a request for additional information, in which case time for response will date from time of receipt of additional information.

3. COR's action on RFIs may result in the need for a change to the Contract Time or the Contract Sum. All contract changes will be processed following the terms and conditions of the contract.

1.5 PROJECT WEB SITE

A. Use the NPS/DSC SharePoint Project website for communication throughout the contract period.

The NPS/DSC SharePoint Project website will be used for the following functions:

1. Project directory.

2. Project correspondence.

3. Meeting agendas and minutes.

4. Contract modifications forms and logs.

5. RFI form and processing.

6. Task and issue management.

7. Photo documentation.

8. Baseline schedule, schedule updates and calendar management.

9. Submittal form and processing.

10. Payment coordination documentation.

11. Drawing and specification document hosting, viewing, and updating.

12. Online document collaboration.

13. Reminder and tracking functions.

14. Archiving functions.

15. Notification of submittal and RFI statuses and current responsible party.

16. Permits and addendums

B. Some documents however are not suitable to be shared using the NPS/DSC SharePoint Project website. Documents containing Personal Identifying Information (PII) (i.e. certified payrolls) shall not be shared using the NPS/DSC SharePoint Project website and shall be coordinated with the SharePoint Project team as appropriate.

C. Submit to the CO a list of all employees who will need access to the website. The users will receive an invitation to register from the Department of Interior (DOI). Once the user is registered on the DOI website, they will be given access to the NPS/DSC SharePoint Project website. For login procedures and other SharePoint information, refer to the Workflows website at http://www.nps.gov/dscw/precon_spproj.htm.

D. All users will be required to have the following software packages:

1. Internet Explorer version 7 or later.

2. Adobe Acrobat Professional (Pro) version 9 or later

1.6 PROJECT MEETINGS

A. Preconstruction Conference: Before start of construction, Contracting Officer will arrange an on-site meeting with Contractor. The meeting agenda will include the following as a minimum:

http://www.nps.gov/dscw/precon_spproj.htm

CUVA - 257393 01 31 00 - 5

1. Roles & Responsibilities/ Lines of Authority.

2. Park rules and regulations.

3. Jobsite Safety.

4. Resolution of comments on required Division 01 documents.

5. Coordination of Subcontractors.

6. Labor law application.

7. Modifications.

8. Payments to Contractor.

9. Payroll reports.

10. Contract time.

11. Liquidated damages.

12. Contractor Performance Evaluation.

13. Display of Hotline posters.

14. Notice to proceed.

15. Correspondence procedures.

16. NPS/DSC SharePoint Project website.

17. Acceptance/rejection of work.

18. Progress meetings.

19. Submittal procedures.

20. NPS Final Accessibility Inspection.

21. Environmental requirements.

22. Permit requirements.

23. Utility Fee requirements (if required)

24. As-constructed drawings/operation and maintenance (O&M) manuals.

25. Saturday, Sunday, holiday and night work.

26. Reference materials.

27. Value engineering.

B. Progress Meetings: The COR will schedule bi-weekly meetings (every other week) with the Contractor.

1. Attendees: In addition to Government Representatives, each Contractor, Subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented at these meetings. All participants at the meeting shall be familiar with the Project and authorized to conclude matters relating to the Work.

2. Agenda: Review and correct or approve minutes of previous progress meeting. Review other items of significance that could affect progress. The meeting agenda will include the following:

a. Approval of minutes of previous meetings.

b. Submittal status.

c. Review of off-site fabrication and delivery schedules.

d. Requests for information (RFI) and other issues.

e. Modifications.

f. Work in progress and projected.

1) Status of required inspections (Special Inspections, Accessibility, etc.)

g. Inspections of work in progress and projected (Special inspections,

h. Construction Schedule update (provide updated CPM).

i. Status of Project Record Drawings and O&M manuals.

j. Other business relating to work.

CUVA - 257393 01 31 00 - 6

k. Permit requirements.

C. Preinstallation Conferences: Conduct a preinstallation conference at Project site before each construction activity that requires coordination with other construction.

1. Attendees: Installer and representatives of manufacturers and fabricators involved in or affected by the installation and its coordination or integration with other materials and installations that have preceded or will follow, shall attend the meeting. Advise COR of scheduled meeting dates.

2. Agenda: Review progress of other construction activities and preparations for the particular activity under consideration, including requirements for the following:

a. Contract Documents.

b. Options.

c. Related RFIs.

d. Related Change Orders.

e. Purchases.

f. Deliveries.

g. Submittals.

h. Sustainable goals.

i. Review of mockups.

j. Possible conflicts.

k. Compatibility requirements.

l. Time schedules.

m. Weather limitations.

n. Manufacturer's written instructions.

o. Warranty requirements.

p. Compatibility of materials.

q. Acceptability of substrates.

r. Temporary facilities and controls.

s. Space and access limitations.

t. Regulations of agency(ies) with jurisdiction.

u. Testing and inspecting requirements.

v. Installation procedures.

w. Coordination with other work.

x. Required performance results.

y. Protection of adjacent work.

z. Protection of construction and personnel.

3. Record significant conference discussions, agreements, and disagreements, including required corrective measures and actions.

4. Reporting: Distribute minutes of the meeting to each party present and to other parties requiring information.

5. Do not proceed with installation if the conference cannot be successfully concluded.

Initiate whatever actions are necessary to resolve impediments to performance of the Work and reconvene the conference at earliest feasible date.

CUVA - 257393 01 31 00 - 7

1.7 ENVIRONMENTAL COORDINATION

A. Contractor’s Environmental Manager: Designate an on-site party responsible for overseeing the Contractor’s conformance to environmental goals for the project and implementing procedures for environmental protection.

1. Qualifications: Minimum 3 years Construction experience on projects of similar size and scope; with environmental procedures similar to those of this project; must be familiar with environmental regulations applicable to construction operations.

2. Responsibilities: Responsibilities shall include:

a. Compliance with applicable Federal, State, and local environmental regulations, including maintaining required documentation.

b. Implementation of the Waste Management Plan(WMP).

c. Implementation of the Indoor Air Quality (IAQ) Management Plan.

d. Implementation of the Storm Water Pollution Prevention Plan(SWPPP).

e. Present an overview of environmental issues and summarize site specific procedures relating to management plans at the Preconstruction conference.

f. Training for Contractor personnel in accordance with their position requirements.

g. Monitoring and documentation of environmental procedures.

B. Perform project quality control in accordance with requirements specified in Related Sections, including:

1. Quality Requirements.

2. Regulatory Requirements.

3. Indoor Air Quality (IAQ) Management.

4. Construction Waste Management.

C. Contractor’s Environmental Training Program: Contractor shall provide environmental training for workers performing work on the project site. Training shall include the following:

1. Overview of environmental issues related to the building industry.

2. Overview of environmental issues related to the Project.

3. Review of site specific procedures and management plans:

a. Construction Waste Management.

b. Indoor Air Quality (IAQ) Management.

4. Pollution Prevention (P2) practices: Submit evidence of P2 practices.

5. Compliance with environmental regulations: As specified in Regulatory Requirements.

Submit Contractor 40 CFR employee training records upon request of Contracting Officer.

D. Provide documentation for environmental procedures as specified herein and in accordance with approved Waste Management Plan, IAQ Management Plan, and Storm Water Pollution Prevention Plan.

1.8 PERMITS

CUVA - 257393 01 31 00 - 8

1. Permits and Responsibilities: The Contractor shall, without additional expense to the Government, be responsible for obtaining any necessary licenses and permits, and for complying with any Federal, State and municipal laws, codes, and regulations applicable to the performance of the work. The Contractor shall also be responsible for all damages to persons or property that occur as a result of the Contractor’s fault or negligence. The Contractor shall also be responsible for all materials delivered and work performed until completion and acceptance of the work.

2. For the purpose of this contract the Contractor will not be considered an agent of the Government. Therefore the Contractor will comply with the appropriate Federal, State and local laws.

B. Potential Permits: The permits listed below were identified during the design process as likely to be required to submit to Ohio EPA based on typical means and methods of construction. The list is provided to assist the contractor in determining which permits will be required for the contract’s chosen means and methods. The list shall not be considered complete, as it is the responsibility of the contractor to determine means and methods, and obtain the required permits. It is the responsibility of the Contractor to obtain all permits required to legally conduct the work.

1. 4 copies of the Plans

2. (2) PTI Form A

3. (2) PTI Form B2

4. (2) Antidegradation Addendum Forms

5. (1) Soil Evaluations

6. (2) Copies of the Technical Specifications

7. (1) Check payable to the “Treasurer, State of Ohio”

8. Electrical Utility Hookup – NPS or American Electric Power

9. New Water Meter -- Cleveland Water or Insert Agency(ies) with Jurisdiction

10. Cleveland Water form to be filled out, and turned in with 3-4 sets of plans by NPS, and mailed to “Engineering – 2nd floor, 1201 Lakeside Ave. Cleveland, OH 44144” Olsson & Assoc. will assist NPS with this.

C. Coordination with Agency(ies) with Jurisdiction Issuing Permits

1. All permits, coordination with Jurisdiction issuing permits is the responsibility of the

Contractor. To include any other requirements needed: Coordinate meetings, reporting requirements, inspections, or any other requirements.

D. Administrative Procedures:

1. Coordinate scheduling and timing of required administrative provisions of project permits with Agency(ies) with Jurisdiction, Construction Manager, and Park to avoid conflicts and to ensure orderly execution of the Work.

2. Supply all needed information to Agency(ies) with Jurisdiction issuing permits, pay any fees required and provide all material needed to comply with the permit’s conditions and provisions.

3. The septic system permits (listed above) are to be mailed to the Northeast District: “2110 East Aurora Road, Twinsburg, Ohio 44087”.

1.9 UTILITY FEES

CUVA - 257393 01 31 00 - 9

1. Fees and Responsibilities: The Contractor shall, without additional expense to the Government, be responsible for payment of any necessary utility fees, and for complying with any Federal, State and municipal laws, codes, and regulations applicable to the performance of the work.

2. For the purposes of this contract the Contractor will not be considered an agent of the Government. Therefore the Contractor will comply with the appropriate Federal, State and local laws.

B. Known Fees: The fees listed below were identified during the design process as being required. The General Contractor shall include these fee costs in his/her bid.

1. Cleveland Water (CW): Existing Water Main Tap Fee: $6,085.80

2. Cleveland Water (CW): Water Meter Fee: $2,310.00

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 31 00

CUVA - 257393 01 32 16 - 1

031414 CONSTRUCTION SCHEDULE

SECTION 01 32 16 – CONSTRUCTION SCHEDULE

PART 1 - GENERAL

1.1 SUMMARY

A. This Section consists of Construction Schedule requirements including but not limited to the following:

1. Schedule of Values

2. Construction Schedule Requirements.

3. Construction Schedule Updates.

4. Time Impact Analysis.

B. Purpose: The purpose of the Construction Schedule is to ensure adequate planning, coordination, scheduling, and reporting during execution of the work by the Contractor. The Construction Schedule will assist the Contractor and Contracting Officer in monitoring the progress of the work, evaluating proposed changes, and processing the Contractor's monthly progress payment.

1.2 DEFINITIONS

A. Activity: A discrete part of a project that can be identified for planning, scheduling, monitoring, and controlling the construction project. Activities included in a construction schedule consume time and resources.

1. Critical activities are activities on the critical path. They must start and finish on the planned early start and finish times.

2. Predecessor Activity: An activity that precedes another activity in the network.

3. Successor Activity: An activity that follows another activity in the network.

B. Cost Loading: The allocation of the Schedule of Values for the completion of an activity as scheduled. The sum of costs for all activities must equal the total Contract Sum, unless otherwise approved by the Contracting Officer.

C. CPM: Critical path method, which is a method of planning and scheduling a construction project where activities are arranged based on activity relationships. Network calculations determine when activities can be performed and the critical path of Project.

D. Critical Path: The longest connected chain of interdependent activities through the network schedule that establishes the minimum overall Project duration and contains no float.

E. Float: The measure of leeway in starting and completing an activity.

1. Float: Float is not for the exclusive use or benefit of either the Government or the Contractor but is jointly owned.

2. Free float is the amount of time an activity can be delayed without adversely affecting the early start of the successor activity.

CUVA - 257393 01 32 16 - 2

3. Total float is the measure of leeway in starting or completing an activity without adversely affecting the planned Project completion date.

F. Resource Loading: The allocation of manpower and equipment necessary for the completion of an activity as scheduled.

G. Fragnet: A partial or fragmentary network that breaks down activities into smaller activities for greater detail.

1.3 SUBMITTALS

A. Electronic Copies: All schedules and reports submitted shall be posted on the NPS DSC SharePoint project website, provided in the native electronic file format. It is the intent of the Government to limit the number of printed reports to only those reports determined by the project team to be essential.

B. Schedule of Values: After contract award and before the Pre-Construction conference submit a schedule of dollar values based on the Contract Price Schedule.

C. Construction Baseline Schedule: After contract award and before the Pre-Construction conference, submit two paper copies of baseline schedule, large enough to show entire schedule for entire construction period.

D. CPM Reports: Concurrent with CPM schedule, submit three paper copies of each of the following computer-generated reports. Format for each activity in reports shall contain activity number, activity description, resource loading, original duration, remaining duration, early start date, early finish date, late start date, late finish date, and total float in calendar days.

1. Activity Report: List of all activities sorted by activity number and then early start date, or actual start date if known.

2. Logic Report: List of predecessor and successor tasks for all activities, sorted in ascending order by activity number and then early start date, or actual start date if known.

3. Total Float Report: List of all activities sorted in ascending order of total float.

E. Construction Schedule Updates: On or before the 7th day preceding the progress payment request date, submit estimates of the percent completion of each schedule activity and necessary supporting data. Provide two paper copies.

F. Construction Schedule Revisions and Time Impact Analysis: For each Construction Schedule revision submit two paper copies of a Time Impact Analysis. Each Time Impact Analysis shall include a Fragmentary Network (Fragnet), incorporated into the currently accepted Construction Schedule, demonstrating how the Contractor proposes to incorporate a modification, change, delay, or Contractor request.

1.4 QUALITY ASSURANCE

A. The Contractor shall meet with the Contracting Officer on the day of the preconstruction conference to go over the following:

CUVA - 257393 01 32 16 - 3

1. Review software limitations, content and format for reports.

2. Verify availability of qualified personnel needed to develop and update schedule.

3. Discuss constraints, including interim milestones.

4. Review schedule for work of separate Government contracts.

5. Review time required for review of submittals and re-submittals.

6. Review requirements for tests and inspections by independent testing and inspecting agencies.

7. Review time required for completion and startup procedures.

8. Review time required for obtaining and activating permits.

9. Review and finalize list of construction activities to be included in schedule.

10. Review baseline schedule comments, resolve issues and progress on incorporating them

11. Review procedures for updating schedule.

12. Discuss reporting requirements and establish a protocol for naming and transmitting electronic schedules.

B. Contractor's Schedule Representative: Before or at the preconstruction conference, designate an authorized representative to be responsible for the preparation and maintenance of the Construction Schedule. A resume outlining the qualifications of the Scheduler shall be submitted to the Contracting Officer for acceptance. The Scheduler shall have prepared and maintained at least 5 previous schedules of similar size and complexity similar to this Contract, demonstrating proficiency in the use of scheduling software. The authorized representative will be responsible for preparing the Baseline Schedule, all required updates, revisions, Time Impact Analyses, and preparation of reports.

1.5 COORDINATION

A. Coordinate preparation and processing of schedules and reports with performance of construction activities and with scheduling and reporting of separate Contractors.

B. Coordinate Construction Baseline Schedule with the Schedule of Values, list of subcontracts, Submittals Schedule, progress reports, payment requests, and other required schedules and reports.

1. In developing the Construction Baseline Schedule, ensure that the Subcontractor’s work at all tiers, as well as the prime Contractor’s work, is…