Attachment_1_-_Specifications_NKAK_17-1101(1-4)_Airfield_IDIQ.pdf

CLASSIFICATION: UNCLASSIFIED

STATEMENT OF WORK FOR PROJECT

IDIQ

AIRFIELD PAVEMENT SYSTEMS

NKAK 17-1101

NKAK 17-1101-1

NKAK 17-1101-2

NKAK 17-1101-3

NKAK 17-1101-4

Air Mobility Command

LITTLE ROCK AIR FORCE BASE

ARKANSAS

Prepared By

19TH CIVIL ENGINEER SQUADRON

22 January 2019

1 March 2019 i

TABLE OF CONTENTS

DIVISION 01 – GENERAL REQUIREMENTS

SECTION 01 11 00 – SUMMARY OF WORK

SECTION 01 14 16 – OCCUPANCY

SECTION 01 14 19 – COORDINATION

SECTION 01 33 00 – SUBMITTAL PROCEDURES

SECTION 01 45 00 – QUALITY CONTROL

SECTION 01 50 00 – CONSTRUCTION FACILITIES & TEMPORARY CONTROLS .. 19

SECTION 01 57 23 – STORM WATER POLLUTION PREVENTION MEASURES

SECTION 01 62 35 – RECYCLED / RECOVERED MATERIALS

SECTION 01 63 00 – SUBSTITUTIONS AND PRODUCT OPTIONS

SECTION 01 63 50 – MATERIAL SHIPMENTS

SECTION 01 69 99 – REAL PROPERTY RECORDS

DIVISION 02 – EXISTING CONDITIONS

SECTION 02 00 00 – EXISTING CONDITIONS

SECTION 02 42 00 – CONSTRUCTION & DEMOLITION WASTE MANAGEMENT ... 40

SECTION 02 60 00 – ASPHALT REMOVAL

DIVISION 26 – ELECTRICAL

SECTION 26 00 05 – GENERAL ELECTRICAL PROVISIONS

SECTION 26 05 04 - RACEWAYS

DIVISION 31 – EARTHWORK

SECTION 31 23 10 – EXCAVATION, TRENCHING, AND BACKFILLING FOR

AIRFIELD ELECTRICAL AND NAVAID SYSTEMS

DIVISION 32 – EXTERIOR IMPROVEMENTS

SECTION 32 01 11 – FRICTION TESTING

SECTION 32 01 12 – PAINT AND RUBBER REMOVAL FROM ROADWAY AND

AIRFIELD PAVEMENTS

SECTION 32 01 15 – REPAIR OF RIGID AIRFIELD PAVEMENTS

SECTION 32 01 16 – ASPHALT COLD MILLING

SECTION 32 01 17 – CRUSHED AIRFIELD CONCRETE

SECTION 32 01 18 – ASPHALT PAVING FABRIC

ii

SECTION 32 01 19 – FIELD MOLDED SEALANT

SECTION 32 01 20 – HOT-APPLIED SEALANT FOR ASPHALT CRACK REPAIR ... 120

SECTION 32 01 22 – BITUMINOUS REJUVENATION

SECTION 32 01 26 – GROOVING FOR AIRFIELD PAVEMENTS

SECTION 32 11 23 – GRADED-CRUSHED AGGREGATE BASE COURSE

SECTION 32 11 36 – LOW COMPRESSION CONCRETE

SECTION 32 12 10 – BITUMINOUS PRIME AND TACK COAT

SECTION 32 12 15 – HOT MIX ASPHALT (HMA) FOR AIRFIELDS

SECTION 32 17 24 – BARRICADES, CLOTH OR PLYWOOD CROSSES,

TEMPORARY PAVEMENT MARKINGS, AND PAVEMENT MARKINGS

SECTION 32 22 00 – FILL MATERIAL, GRADING, AND TOPSOIL

SECTION 32 92 20 – HYDROSEEDING

SECTION 32 92 23 – SODDING

DIVISION 33 – UTILITIES

SECTION 33 46 16 SUBDRAINAGE SYSTEMS

DIVISION 34 – TRANSPORTATION

SECTION 34 73 13 – AIRCRAFT TIEDOWN AND GROUNDING ROD

iii

REVISIONS

Number Date Description

1 3/1/2019 Added Contractor experience requirements in 01 11 00, 1.02-D

SUMMARY OF WORK 01 11 00 - 1

DIVISION 01 – GENERAL REQUIREMENTS

SECTION 01 11 00 – SUMMARY OF WORK

PART 1 - GENERAL

1.01 PROJECT SCOPE

Contractor shall provide all plant, labor, materials and equipment necessary to fully meet all requirements of this Summary of Work, Construction Specifications, Construction Drawings and all other Contract Documents related to and/or titled: : “IDIQ AIRFIELD PAVMENT/SYSTEMS, NKAK 17-1101(1-4)” at Little Rock AFB, Arkansas.

1.02 PRINCIPAL FEATURES

A. Principal features of the work consist of but are not limited to the following:

1. Temporary and permanent airfield markings.

2. Install erosion control measures.

3. Seal joints.

4. Spall repair.

5. Bitumen rejuvenation.

6. Random crack repair.

7. Rubber Removal

8. Friction Testing

9. Remove and disposal of concrete pavements.

10. Remove, crush, and stockpile concrete pavements.

11. Asphalt cold milling and disposal of milled material.

12. Asphalt cold milling and stockpile milled material

13. Placing, grading, and compacting government provided crushed concrete and asphalt millings.

14. Construction of new concrete pavements.

15. Groove the runway surface.

16. Install new tie-downs in new or existing pavement.

17. Placing hot mix asphalt.

18. Install subdrains.

19. Grading airfield areas to meet airfield criteria

20. Hydroseed and or sod disturbed areas.

SUMMARY OF WORK 01 11 00 - 1

B. The above general outline of the principal features does not in any way limit the responsibility of the Contractor to perform all work required by the plans and specifications.

C. Phasing: Some delivery orders may require that the project be completed in multiple phases in order to facilitate continuous airfield operations. No additional mobilization and/or demobilization costs will be permitted when a project is required to be phased.

D. Contractor Experience – The Contractor shall have a minimum of 5 years of experience with airfield maintenance and repair and successfully completing work types listed above on an active airfield.

1.03 PROJECT AREA LIMITATIONS

A. Airfield at Little Rock AFB to include but not limited to Runway 07-25, the Assault

Landing Zone, Taxiways, Parking Aprons, Hangar Aprons, and airfield area access roads.

B. All-American Landing Zone (AALZ) at Camp Robinson in North Little Rock, AR.

C. Security Operations Delays to Contractor

Security Operation delays to the Contractor will occur during the work. The length of time and frequency of these delays will be held to a minimum. Time required for processing Contractor Personnel, vehicles, and equipment for entrance to an exit from the Base shall be included in the bid, and will not be considered a compensable delay.

Also the time required for processing Contractor personnel, vehicles, and equipment for entrance to and exit from the Airfield will not be considered a compensable delay.

D. Airfield and Mission Operations Delays to Contractor

1. Airfield operations delays to the Contractor will occur during the work. The length of time and frequency will be held to a minimum. Mission delays to include but not limited to Distinguished Visitors, Operational Readiness Exercises, In-Flight Emergencies, and Air Shows will occur during the work and will not be considered a compensable delay.

2. For scheduled events to include but not limited to Air Shows, the contractor will be required to shut down. Currently known scheduled upcoming events will be detailed in the following paragraph, but this paragraph is not all inclusive for the duration of this Contract. There will be additional required shutdown periods during the duration of this contract. For shutdowns of this nature the contractor will be notified by the Contracting Officer of the required dates for the shutdown period. The Contractor shall conduct work so that no area will have incomplete work at the beginning of the shutdown period. The Contractor shall turn over the entire area for use by the Government during the shutdown period.

3. Currently Schedule Upcoming Events:

Air Show Shutdown Period: Tentatively 27-28 October 2020.

1.04 DOCUMENTS

The Contractor shall:

1. Check all Government furnished construction drawings immediately upon receipt;

SUMMARY OF WORK 01 11 00 - 2

2. Compare all Government furnished construction drawings and verify the figures before laying out the work;

3. Promptly notify the Contracting Officer of any discrepancies

4. Be responsible for any errors which might have been avoided by complying with this paragraph (1.04 A).

B. Large scale drawings shall, in general, govern over small scale drawings. Figures marked on drawings shall, in general, be followed in preference to scale measurements.

C. Omissions from the drawings or specifications or the misdescription of details of work which are manifestly necessary to carry out the intent of the drawings and specifications, or which are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work, but shall be performed as if fully and correctly set forth and described in the drawings and specifications.

D. The Contractor shall maintain a complete set of construction drawings, construction specifications, project related sketches, pictures, approved Contract modifications (if any) and all approved submittals on the job site at all times. One set of such construction drawings shall be designated the "Record Drawings" upon which as-built data shall be neatly recorded and dated in red ink by the Contractor. Contemporaneous annotation of accurate As-Built data on the Record Drawings is to be verified by the Contracting Officer and the COR, as a prerequisite to the Contractor receiving progress payments. Upon completion of construction, the Contractor shall submit a copy of record drawings and update Contractor furnished AutoCAD drawing files (*.dwg) with As-Built information and digitally stamp these all of these drawings as “As-Built”. The digital stamp shall include the wording “As Built,” the name of the construction Contractor and the month and year of construction completion. These drawing files shall be turned over to the Contracting Officer on 3 compact disks (CD) prior to final payment. Each CD shall have one complete set of AutoCAD drawings and a complete set in Adobe Acrobat format.

E. The Contractor shall perform an as-built geographic information survey (GIS) survey of all new or modified exterior construction and provide this information to the Government as specified in Section 01 33 00 SUBMITTAL PROCEDURES.

F. Where conflicts between the drawings and specifications occur, specifications shall govern in accordance with FAR 52.236-21.

1.05 EXISTING WORK

A. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work, which remain.

B. Repair or replace portions of existing work, which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work shall be in a condition equal to or better than that which existed before new work started.

C. Contractor shall protect all Government property against damage, to include but not limited to dust, fumes, impact, scratching, water, paint, joint compound, power failure, power surges, weather, heavy equipment, et cetera. All damages caused by the Contractor, whether to equipment, furniture, roads, landscaping, building components or any other type of Government property encountered at or near the project site shall be repaired or replaced

SUMMARY OF WORK 01 11 00 - 3

to match existing and to the satisfaction of the Contracting Officer at no cost to the Government.

PART 2 - PRODUCTS (Not Used) PART 3 - EXECUTION (Not Used)

END OF SECTION – SUMMARY OF WORK

OCCUPANCY 01 14 16 - 4

SECTION 01 14 16 – OCCUPANCY

PART 1 - GENERAL

1.01 OCCUPANCY

Airfield Operations will continue outside, but adjacent to the general area of construction.

PART 2 - PRODUCTS (Not Used)

END OF SECTION – OCCUPANCY

COORDINATION 01 14 19 - 5

SECTION 01 14 19 – COORDINATION

PART 1 - GENERAL

1.01 TERMS

The initials “CO” shall mean the Contracting Officer. The initials “COR” refer to the COR.

The COR will be the Construction Manager assigned from the 19th Civil Engineer Squadron to monitor this contract during construction. This is applicable to all specification sections.

1.02 WORK SCHEDULE

A. Little Rock Air Force Base work hours are 7:00 a.m. to 4:30 p.m. all days of the week except Saturday, Sunday, Federal Holidays and AMC Family Days (listing to be provided annually once received by the Government). Contractor shall not perform any work outside of these work hours without obtaining written approval from the Contracting Officer. If weekend or evening work is required due to utility outages or other requirements, such work shall not be performed without prior written approval of the Contracting Officer and such work shall be accomplished at no additional cost to the Government. The Contracting Officer requires at least three (3) business days’ notice, in writing, from the Contractor to provide written approval or disapproval.

B. NORMAL FLYING OPERATIONS will continue on other areas of the airfield.

1. To ensure that normal flying operations may resume at the scheduled date, the Contractor shall prosecute the work with sufficient work force, including extended daily work hours and work week if necessary, to complete the entire work within the stated number of calendar days. Work shall be accomplished during daylight hours only. Any extension of daily work hours and/or work week shall be approved by the CO and at no additional cost to the Government.

2. To closely coordinate work under this project, the Contractor shall prepare for and attend a weekly coordinating meeting with the COR and Base Operations Officer at which time the Contractor shall submit for approval his proposed daily work schedule for the next two week period. Temporary interruptions and protection of adjoining areas shall be included with the Contractor’s proposed two week work schedule. Additional coordinating meetings shall also be held on an as-needed basis when, in the opinion of the COR, they are required for safety or timely completion of the work.

3. There may be short periods of time due to in flight emergencies or unannounced visit from dignitaries when the Contractor shall be required to vacate the work site and move his personnel and equipment. Such removals, if required, may be given on short notice and expeditious action will be required. (See paragraph 1.02.B.8 of this section for details).

4. Contractor vehicles, equipment, or personnel will not be on or crossing the runway or taxiways, except during construction period closures as scheduled, or when clearance is given from the control tower. Crossings shall be controlled by flagmen with radio contact with the tower as required by the Government.

5. The Contractor shall schedule the work areas and airfield vehicle operation through the CO. The Contractor is responsible for obtaining general airfield operating instructions, to include a safety and flight line driving briefing, prior to beginning work. This is accomplished at Airfield Operations (Bldg 120). The Contractor shall provide the CO a complete list of all employees and shall provide updates to this list as they occur. The Contractor is responsible for ensuring all workmen are in compliance with these instructions.

COORDINATION 01 14 19 - 6

6. The All American Landing Zone is located between the point of artillery firing and the artillery impact zone used by the U.S. Army Reserve and Arkansas National Guard Units on Camp Robinson. The artillery firing is primarily on weekends. The Contractor shall avoid weekend work or closely coordinate weekend work with Camp Robinson authorities so as to avoid any work when artillery firing is planned. The Contractor shall coordinate his work schedule with Camp Robinson’s Operation and Plans Specialist (phone 212-5232).

7. The All American Landing Zone and adjacent area may be used for air drops during the construction period. The Contractor shall coordinate and schedule his work with the Little Rock Air Force Base Operations.

8. Downtime Due to Aircraft Operations

a. CLEARING THE RUNWAY: Upon notification by a representative of the CO, Base Operations, Air Traffic Control, Fire Department, or Security Police, the Contractor shall immediately cease operations and move all equipment and personnel a minimum distance of 250 feet from the edge of the runway or taxiway as directed. Equipment and personnel necessary to accomplish this condition shall be the responsibility of the Contractor. Upon notification that the runway is clear, the Contractor shall immediately move his equipment back to the runway and resume construction operations.

b. MEASUREMENT OF DOWNTIME: Downtime will be measured by the crew hour, to the nearest ten minutes, from the actual time construction operations cease until the time operations resume or to the end of the regular work period; excluding scheduled breaks such as lunch or rain or other. Any delay in vacating the runway or returning to the runway and resuming construction, due to the breakdown of equipment, negligence or convenience of the Contractor, will not be measured as downtime. The COR will keep a log of each period of downtime, showing the time it started, time it stopped, actual hours of downtime. The log shall be initialed each time by the COR and the Contractor. In the event there is a disagreement over time, the Contractor shall notify the CO of this disagreement within 24 hours. Failure to do so within the time specified shall constitute acceptance by the Contractor of time on the COR’s log. The minimum amount of downtime measured will be ten minutes. Any downtime measured less than ten minutes shall be recorded as ten minutes. Measurement of downtime will not begin until the temporary threshold is complete to include the distance to go markers and the changing of the edge lights. Downtime does not include those items specifically addressed in Specification 01 11 00 Paragraphs “Security Operations Delays to Contractor and “Airfield and Mission Operations Delays to Contractor”.

Additionally downtime does not include weather or natural events to include, but not limited to rain, flooding, tornado, high winds, and earthquakes.

c. PAYMENT for downtime measured as specified shall be paid for at the contract unit price per crew hour. A crew hour consists of all equipment, personnel, and related costs, including benefits, payroll taxes, FICA, and all overhead and profit

1.03 UTILITIES

A. Existing electrical service to the facility shall be maintained until new electrical service is in place and ready for operation.

COORDINATION 01 14 19 - 7

B. Utility interruptions shall be approved by the CO. The Contractor shall submit to the CO a written request for such work at least three (3) weeks prior to the desired date. The following shall apply:

1. Electrical primary power outages will be performed by Entergy Arkansas Inc. and shall be fully coordinated with the COR, LRAFB Utility Privatization Liaison and Entergy Arkansas Inc. The Contractor shall submit to the COR and LRAFB Utility Privatization Liaison a written request for such work at least three (3) weeks prior to the desired date. Electrical primary outages shall be limited to four (4) hours.

2. Water outages will be performed by the 19th Civil Engineer Squadron and shall be fully coordinated with the COR.

3. Communications Utilities.

The Contractor shall not disturb communication wiring to facilities. Where such facilities require removal of communication equipment and wiring to accomplish the work involved, the Contractor shall notify the CO at least five (5) work days in advance of the requirement, for scheduling such removals by the Government. The Contractor shall allow for the accomplishment of such removals by the telephone company or communications personnel for the systems they service. If construction activities damage any communication equipment or wiring, the Contractor shall restore services as soon as possible, but no later than 24-hours, and at no cost to the Government.

4. Excavating Around or Locating Existing Utilities.

Prior to the start of work, the Contractor shall identify and locate all valve or utility shut-off locations for use in the event of accidental damage. To preclude accidental damage, the Contractor shall locate all known utilities (i.e., communication, natural gas, fuel supply, etc.)

by hand digging prior to any excavation with power equipment. The Contractor shall note any utilities discovered during excavations that are missing or incorrect on the contract drawings (including any erroneous dimensions on Government record drawings), or those utilities staked by the user, and clearly identify those discoveries on the as-built drawings.

1.04 PROTECTION OF EXISTING FACILITIES

A. The Contractor shall conduct and schedule all work in a manner to cause as little disruption as possible to the existing facilities and operation. Phase work as may be indicated on drawings or required by this contract.

B. The Contractor shall ensure that the existing building is maintained weatherproof at all times. The buildings HVAC system shall also be maintained in full operating order by the Contractor. The Contractor shall provide and install 40% efficient construction filters and shall maintain the filters throughout the construction timeframe in all return air, outside air and exhaust air inlets in the construction area or where dust and debris may enter the duct.

1.05 SITE VISITATION

A. The Contractor shall be responsible to visit the project site prior to, and during, the course of construction to verify existing conditions, actual sizes, and other requirements outlined in the other sections of the specifications.

B. Existing Facilities/Job Site Verification.

Record drawings, showing existing facilities and underground utilities, are available to the Contractor through the Base Civil Engineer office. The Government does not guarantee the accuracy, availability or adequacy of existing as-built/record drawings. The Contractor is

COORDINATION 01 14 19 - 8

responsible to verify all dimensions and actual conditions when developing their contract proposal. Failure to verify the dimensions and locations will be at the Contractor’s risk and shall not relieve the Contractor from accomplishing the work required by the contract at the price awarded by the Government. The Contractor shall immediately repair any utility line shown on a record drawing (or made known to the Contractor) and damaged during construction work, at no cost to the Government.

1.06 BASE REGULATIONS

The Contractor shall conform to all base regulations and directives pertaining to security, safety, debris removal, fire, traffic and personnel clearances, insofar as they pertain to the Contractor's activities on Little Rock Air Force Base. Contractor shall ensure conformance by all employees and sub-contractors.

1.07 FIRE PROTECTION

The Contractor shall be responsible for conformance with base fire regulations and NFPA 241, including Appendix A. These regulations are available for review during duty hours at the Base Fire Station located in Building 239. Fire extinguishers required during the construction period shall be furnished and maintained by the Contractor and removed by the Contractor upon acceptance of the facility by the CO. No welding/cutting and open flame operation shall be allowed in facilities when automatic fire detection and suppression systems are out of service unless the Contractor posts a fire guard for 24 hours after welding/cutting and open flame operation or certifies the facility fire safe.

1.08 WELDING PERMIT

A. Prior to performing any welding, cutting or brazing, the Contractor shall obtain a properly completed AF Form 592 (Burning Permit) from the 19 CES Fire Department. A permit is required per job, per day. Contractor shall return all welding, cutting, or brazing permits to the 19 CES Fire Department at the end of each week, at a minimum. The Contractor shall maintain a fully charged fire extinguisher on site at all times regardless as to whether or not welding, cutting, or brazing is being performed.

B. Hot Welding (delete paragraph if no JP8 pipeline welding, UST/AST work, or other fuels work is being done): A step by step plan shall be submitted 15 days prior to hot welding to the CO and accepted by AMC. The plan shall cover the location of the weld, material to be used, size of the line, material in the line, safety precautions, welding procedures, etc. The Contractor shall comply with 29 CFR 1917.152 welding, cutting, heating (Hot work) and 29 CFR 1926 subpart J welding, cutting Fire prevention. The Contractor shall be responsible to verify a vapor free environment as defined by 29 CFR 1917 with a Backarach 514M meter.

The Government will not supply the meter. The plan shall also contain the dates of the proposed welds and the estimated time the fuel lines will be down. A Command Certified Liquid Fuels Manager (LFM) shall be on site during all hot work. NO WORK SHALL

PROCEED UNTIL THIS PLAN IS APPROVED.

1.09 CONSTRUCTION PERMIT (DIGGING PERMIT)

A. A properly completed AF Form 103, Base Civil Engineering Work Clearance Request, shall be obtained by the Contractor prior to performing any excavation.

B. A separate AF Form 103 shall be obtained by the Contractor for each excavation to be accomplished.

COORDINATION 01 14 19 - 9

C. Contractor shall submit a request for AF Form 103 a minimum of 14 calendar days and a maximum of 28 days prior to desired start of excavation. The Contractor shall allow a minimum of 14 calendar days for processing.

D. Each request shall be in writing and designate the location of the proposed excavation and the scheduled date.

E. The completed AF Form 103 will contain information for locating existing utilities and telephone lines. The Contractor shall keep the AF Form 103 at the excavation site and shall comply with instructions for hand excavation and with other methods of safeguarding the buried utilities. No digging permit will be issued until a Strom Water Pollution Prevention Plan is submitted and approved.

F. In addition to the requirement to obtain a construction permit and prior to any excavation, the Contractor shall perform a pipe/cable location survey using a variety of modern locating equipment suitable for locating various types of pipe and cable. The Contractor shall use a signal generating locator such as a Goldak Gold Digger 4400 for metallic pipe and cable.

For non-metallic pipe use a vibration generator such as a Fuji Tecom PL-130 or an RD-500.

For non-metallic sewer pipe use a snake with attached generator. The Contractor shall mark all locations on the ground. The Contractor shall submit a sketch showing the found locations of utilities to the COR for approval prior to beginning excavation. The COR will provide available information as to the existence and location of known utilities with the approved construction permit. The Contractor shall be responsible for repairing damage to utilities, whether known or unknown, due to any failure on the Contractor’s part to perform a rigorous survey.

1.10 OCCUPANCY OF GOVERNMENT FACILITIES

When the Contractor has complete or partial occupancy of any building or facility, the Contractor shall be responsible for properly informing the COR of any condition which would jeopardize the building or its contents, such as loss of heat, air conditioning, danger of pipes freezing, loss of electric power, water, sewer or gas services or loss of building security.

Contractor shall call telephone number 987-6434 and inform the COR or, if after duty hours, call 987-6553, CE Service Call. Contractor is responsible for correcting all situations under the scope of this contract or caused by the Contractor, and shall notify the COR and/or CE Service Call immediately for situations not covered by this contract, or emergency situations beyond the Contractor’s control.

1.11 CHLOROFLUOROCARBON (CFC) REFRIGERANTS: Restrictions, Precautions and Controls

A. The Contractor shall not vent or cause to be vented chlorofluorocarbon (CFC) and hydochlorofluorocarbon (HCFC) refrigerants (R-11, R-12, R-22, R-113, R-114, R-115, R- 501, R-502, or any other mixtures containing CFCs) to the atmosphere during repair or maintenance work on the equipment covered by this Contract.

B. The Contractor shall have available refrigerant recovery or reclaim equipment to perform the work. The Contractor shall submit to the CO a copy of the EPA registration of the recovery equipment. This registration shall also be provided during warranty work, if the equipment used is different than that used during construction.

C. Contractor personnel who operate refrigerant reclaim or recycling equipment shall possess the necessary state and local certificates for operating that equipment. The Contractor shall submit to the CO a copy of the CFC certification for the personnel removing the refrigerant.

COORDINATION 01 14 19 - 10

This certification shall also be provided during warranty work, if the personnel involved are different than those who installed the equipment.

D. Contractor shall be responsible for meeting all requirements, permitting the licensing and certification required by state or local ordinance to work on refrigeration systems.

E. The Contractor shall provide containers for the reclaimed refrigerant and shall return all reclaimed refrigerant and containers to the Government and provide documentation of the quantity recovered.

F. Replacement compressors and other replacement equipment used in repairing CFC-containing systems shall be compatible with CFC replacement refrigerants. If such would result in an increase in cost, the Contractor shall notify the CO prior to the replacement.

1.12 FLUORESCENT BALLAST AND LAMP DISPOSAL

A. All ballasts from demolished light fixtures shall be examined for markings, labels, etc. that identify the presence (or absence) of PCB’s. If no identifying Non-PCB characteristics can be determined, the ballast shall be considered as being PCB ballast. It shall be containerized, processed through the Centralized Accumulation Point (CAP), and then turned in to DRMO for PCB disposal. The ballasts that are clearly identifiable as Non-PCB may be recycled or disposed as solid wastes. The hours of the CAP office are 0700 to 1600, M-F, 987-8073. The Contractor shall call DRMO in advance for a turn-in appointment @ 987-3715. The Contractor shall not attempt to (1) turn-in PCB ballast without processing said items through the CAP and (2) deliver same to DRMO without an appointment.

B. Container: Contractor shall store all PCB ballasts in either new UN approved steel or plastic open head drums as specified in 49 CFR 178.504 and 509. All used and/or reconditioned containers are unacceptable. The steel or plastic drums may not exceed 55 gallons in size.

The total weight of container and PCB ballasts must not exceed the inscribed manufacturer container weight specifications. Contractor may store PCB containers on-site up to one week (five days), at which time the container shall be turned in to DRMO. The Contractor may turn in PCB containers at a more frequent rate, e.g., daily, etc., if so desired. PCB containers shall be stored within the confines of the immediate project site. The PCB containers shall not be exposed to the elements, placed in the open, nor allowed to collect rainwater. When not in use, each PCB container shall be covered with its appropriate lid.

Contractor shall label each container as specified in 40 CFR 761 and 49 CFR 172.101. The number of PCB ballasts in each container shall be provided to the COR prior to turn in to

DRMO.

C. Detached light fixtures that are clearly identified as having non-PCB ballasts shall be placed in Government supplied dumpsters which will be picked up, on site, by the Base Recycling Center.

D. Contractor shall be responsible for all QA/QC functions required in segregating PCB ballasts from non-PCB ballasts. The CAP will not perform any inspection, segregation, or identification of said ballast for the Contractor. The Contractor is fiscally responsible for any improper disposal of PCB ballasts. The Arkansas Department of Environmental Quality shall be notified should any Contractor be found violating any State or Federal regulations on PCB ballast disposal.

E. Fluorescent lamps shall be packaged, processed through the CAP, and then delivered to DRMO. Contractor may store fluorescent tubes in their original container or an appropriately sized cardboard box. In the event a cardboard box is used, each tube shall be protected from breakage by using appropriate egg crate or bubble-wrap packing.

COORDINATION 01 14 19 - 11

1.13 OIL FILLED TRANSFORMER DISPOSAL

Any demolished transformer and medium voltage equipment that contains insulating liquid shall be tested for PCBs prior to turn in to DRMO. The turn in procedure is as follows:

A. Oil filled transformers and other equipment containing insulating liquid must be tested for the presence of PCB’s by the Contractor at the Contractor’s expense.

B. Equipment cannot be leaking. All caps/covers etc. must be tight.

C. Contractor shall unload equipment themselves; there is no forklift support at DRMO on

LRAFB.

D. Contractor shall present HAZMO/CAP (Bldg. 1575, 501-987-5247) with analytical results, KVA rating, serial number, manufacturer, date equipment was taken out of service and an estimate of the original cost of the equipment. HAZMO will send proper forms to DRMO and inform Contractor to set up a turn-in appointment with DRMO.

E. The Contractor shall call DRMO in advance of delivering the equipment to DRMO for a turn-in appointment @ (501) 987-3715.

F. Contractor shall deliver and unload equipment to DRMO site on base per scheduled appointment.

G. The Contractor shall provide DRMO a copy of the complete analysis at the time of turn-in.

H. The Contractor will affix a single page of the analysis that reflects the PCB results for that particular piece of equipment to the side of the equipment.

I. Equipment must be secured to a pallet prior to transport to DRMO.

1.14 RADIOACTIVE MATERIALS

A. A request to bring radioactive materials onto Little Rock AFB shall be provided to the government at least 30 days prior to bringing materials onto the base. A copy will be given to the Bioenvironmental Engineer by the COR.

B. Before bringing any radioactive materials onto Little Rock AFB, the Contractor shall first submit the following information on an AF Form 3000, for review and approval by the 19th AW Bioenvironmental Engineer. Examples of materials that may contain radioactive materials are soil moisture and soil density testing instruments. Additional information on this subject can be found in AF 40-201 MANAGING RADIOACTIVE MATERIALS IN THE

U.S. AIR FORCE.

http://static.e-publishing.af.mil/production/1/af_sg/publication/afi40-201/afi40-201.pdf C. Proper Nuclear regulatory Committee (NRC) or Arkansas State license (Includes NRC

Reciprocity Form 241 and Arkansas State License). For DoE organizations and DoE Contractor’s written certification that they are exempt from NRC license requirements is required.

D. Copies of training certification for instrument operators.

E. Dates and location of use on Little Rock AFB.

F. Acknowledgement that instrument is transported in compliance with 49 CFR requirements.

G. All testing equipment, containing a radioactive source, shall be operated in accordance with an approved radioactive equipment plan. This plan shall be submitted to the CO and http://static.e-publishing.af.mil/production/1/af_sg/publication/afi40-201/afi40-201.pdf

COORDINATION 01 14 19 - 12

approved by the 19th AW Bioenvironmental Engineer, prior to bringing the equipment on to Little Rock AFB.

This plan shall include:

1. The name and type of equipment.

2. The type and size of radiation source.

3. The dates and locations of the equipment's usage.

4. The radiological controls that the Contractor will use while operating the equipment.

H. A different radioactive equipment plan will be required for each different type of equipment, type of radioactive source, or size of radioactive source. A data sheet for each piece of radioactive equipment shall be submitted to the CO to forward to the 19th AW Bioenvironmental Engineer. The data sheet shall contain the following information:

1. Name of equipment.

2. Name and address of equipment manufacturer.

3. Type and size of radiation source.

4. The location of the radioactive equipment on LRAFB.

5. PRODUCTS (Not Used)

6. EXECUTION (Not Used)

END OF SECTION – COORDINATION

SUBMITTAL PROCEDURES 01 33 00 - 13

SECTION 01 33 00 – SUBMITTAL PROCEDURES

PART 1 - GENERAL

1.01 SUBMITTALS

A. Catalog cut sheets, brochures, shop drawings and/or samples shall be clearly marked/indicated by the Contractor and submitted to the CO for the items on the schedule, drawings and other sections of the specifications. All salient features of materials required to be submitted shall be easily found in the submittal package for each item and not require research on the part of the Government to determine compliance with Contract requirements. Related items such as mechanical/electrical components shall be submitted at one time for coordination purposes. Color coordinated items such as paint, carpet, vinyl wall covering, vinyl composition tile, ceramic tile, toilet partitions, and so forth shall be submitted at one time to facilitate color comparison/selection by the Contracting Officer. An AF Form 3000 shall be utilized for each numbered submittal. Different categories of submittal items are not to be grouped on the same AF Form 3000.

B. All items shall be approved by the CO prior to purchase, delivery or installation.

C. All items shall be submitted electronically in pdf format not more than twenty (20) calendar days after Contractor's notification that they can proceed with construction. Samples of all items requiring color selection shall be submitted along with the electronic submittal.

Operations and Maintenance (O&M) manuals shall be submitted for approval by the Contracting Officer, prior to final inspection.

D. Not less than ten (10) business days shall be allowed for review of submittals by the Government.

E. Submittals will be returned to the Contractor unless otherwise specified. A sample of all items requiring color selection will be retained by the COR for reference.

F. Refer to Section 01 63 00 - Substitutions and Product Options.

G. Contractor shall be responsible for complying with the EPA’s buy recycled program. See

Section 01 62 35 RECYCLED/RECOVERED MATERIALS.

1.02 OPERATION AND MAINTENANCE MANUALS

A. The Contractor shall furnish three (3) copies, one (1) hard copy and two (2) CD ROM, of all operation and maintenance (O&M) manuals. O&M manuals shall contain complete instructions for the operation, inspection, testing and maintenance of the system, and shall include complete parts breakdown diagrams. Manuals shall also contain complete wiring schematics and diagrams. Manuals shall be in booklet form with binder and shall be arranged in logical sections for easy reference.

1.03 GEOGRAPHIC INFORMATION SYSTEM (GIS) SERVICE

A. The Contractor shall perform a geographic information system (GIS) survey of all exterior construction that is installed or modified in this contract. This includes changes to the building footprint, all at-grade or above-grade structures and pavements, all underground utilities and associated appurtenances, and newly planted trees.

B. The Contractor shall deliver all as-built survey data files in a format that is directly readable and compatible with the 19 CES Geospatial Data System (GDS). The database of the GIS shall include all files, both graphic and non-graphic, required for the project that are not

SUBMITTAL PROCEDURES 01 33 00 - 14

included in the GDS/CADD software (i.e., color tables, pen tables, font libraries, symbol libraries, user command files, plot configuration files, AML plot routines, etc.).

C. Nongraphic data shall be developed and delivered to 19 CES in the format specified in the Spatial Data Standard for Facilities, Infrastructure, and Environment (SDSFIE) Standards.

The Contractor will provide the nongraphic data in a format, which can be directly imported to, displayed and edited within, and output from the database software specified by the Government.

D. All GIS development (including geospatial data acquisition and map development for use in a GIS) shall conform to the most current release of SDSFIE. The most current release of the SDSFIE is available for download from the CADD/GIS Technology Center’s Internet Website (http:/tsc.wes.army.mil). All delivered digital GIS data files shall also be submitted in strict compliance with the SDSFIE for the target GIS software system (i.e., the most current version of the Environmental Systems Research Institute Inc. (ESRI) ArcGIS). The Contractor shall submit a written request for approval of any deviations from the Government’s established standards. No deviations from the Government’s established standards will be permitted unless the CO has issued prior written approval of such deviation.

E. The Contractor shall be required to provide professional services specific to the use and application of ESRI ArcGIS, including all components and extensions. The ArcGIS components and extensions shall include, but not be limited to, ArcView, ArcEditer, ArcInfo, ArcReader, ArcPac, ArcScene, ArcObjects, ArcSDE, ArcIMS, and relational database management systems (RDMS) software (e.g., Microsoft Access and SQL Server). The Contractor will be required to provide digital products directly supported by ArcGIS with no intermediate file translation required.

F. All surveying/mapping work performed as part of this contract shall conform to the Geospatial Positioning Accuracy Standards for Architecture, Engineering, Construction (A/E/C), and Facility Management. The most current standards of the Geospatial Positioning Accuracy Standards are available for download from the Federal Geographic Data Committee’s Internet Website http://www.fgdc.gov .

G. The Contractor shall provide metadata files for all geospatial data. Geospatial data are defined as information that identifies the geographic location and characteristics of natural or constructed features and boundaries on the earth. The Metadata file shall conform to the Federal Geographic Data Committee Metadata Standards. The most current standards of the Federal Geographic Data Committee are available for download from the Federal Geographic Data Committee’s Internet Website http://www.fgdc.gov . The digital metadata files shall be provided to the Government along with each final product deliverables.

H. The Contractor shall have the capability to submit digital products or deliverables on read-only memory (CD-ROM).

I. The Contractor shall be required to develop, deliver, install, and test the digital media containing the geospatial data at the Government’s target GDS.

J. The Government will only accept the final product for full operation, without conversion or reformatting, in the target software format for use on the target platform specified herein.

The target platform is a Microsoft Windows Based, with a Microsoft Windows XP operating system.

http://www.fgdc.gov/ http://www.fgdc.gov/

SUBMITTAL PROCEDURES 01 33 00 - 15

1.04 MATERIAL SAFETY DATA SHEET (MSDS)/SAFETY DATA SHEET (SDS) SUBMITTALS

A. All submittals for products shall include the MSDS/SDS when an MSDS/SDS is required by law for that product.

B. MSDS/SDS’s shall also be submitted on AF Form 3000 for all products to be used during the course of the project, not otherwise requiring a submittal, but which may be of a toxic, hazardous, flammable or otherwise dangerous nature.

C. Approval by the Hazardous Materials Office (HAZMO), Building 1575, 987-5247, is required before bringing the materials on base. Little Rock AFB AF-EMIS Contractor Worksheet and an MSDS/SDS must accompany the submitted material. This Contractor worksheet will be furnished by the Government along with an instruction guide. Additionally, the Contractor shall submit a Government supplied Contractor Hazardous Material Usage Data sheet to the Government once a month once the materials are brought on base and until the materials are used or removed from the base. The form shall list the amount of materials used and shall also list any materials which are considered a hazardous waste when the Contractor can no longer use the material for its intended form or reuse as a virgin product at a later date. All hazardous waste shall be turned in to the base Hazardous Material Office

(HAZMO), 987-5247.

D. All HAZMAT that is not used on the project but is still in usable condition must be removed from the base by the Contractor upon completion of the project. HAZMO will not accept unused HAZMAT such as paint, thinners etc. that are still usable as they belong to the Contractor.

PART 2 - PRODUCTS (Not Used)

END OF SECTION – SUBMITTAL PROCEDURES

QUALITY CONTROL 01 45 00 - 16

SECTION 01 45 00 – QUALITY CONTROL

PART 1 - GENERAL

1.01 WORKMANSHIP

All materials and equipment shall be installed in a manner accepted by standard trade practice. Workmen skilled in the type of work required shall accomplish the installation.

1.02 TRAFFIC SAFETY

Special efforts shall be made not to interfere with traffic flow or create safety hazards to traffic.

1.03 ENVIRONMENTAL MANAGEMENT SYSTEM

Environmental Management System (EMS) is an ISO 14,001 tool used by the USAF to identify and mitigate threats to our environment. LRAFB’s ultimate goal is to protect our environment (work environment and the natural environment) while accomplishing our mission. All Contractors working on LRAFB are expected to acknowledge their role in EMS while completing their mission. Threats associated with construction sites include, but are not limited to: hazardous materials, spills, equipment leaks, air-born dust, soil erosion, track-out, and lack of recycling. This will be communicated and documented initially for each project with monthly updates provided to the government COR. Contractor shall sign a LRAFB supplied form monthly acknowledging that they have kept sub-contractor’s aware of

EMS.

1.04 DEBRIS DISPOSAL

A. Debris shall be removed from the Base promptly, and as feasible, all equipment and materials shall be removed or secured at the end of each day. The Contractor is responsible for the daily cleanup of all construction areas and construction debris that has escaped from the construction site.

B. Work located on or near the airfield: It is imperative to maintain all work areas in a clean and orderly condition, subject to the satisfaction of the CO and the COR, to prevent Foreign Object Damage (FOD) to aircraft. Equipment, materials, etc. that can be transported by high winds shall be tied down and secured at all times when not in use during the day and secured at the end of each day. Contractor equipment and materials shall not be permitted to blow outside the construction site and the surrounding FOD fence. The Contractor shall promptly clean up all items (dirt, debris, etc.) that he, his employees or Sub-contractors, drop onto areas traversed by aircraft. The use of sweeping equipment with metal bristled brooms is prohibited along the flight-line and on all airfield pavements.

C. The Contractor shall exercise caution in not disturbing adjacent facilities, finishes, materials, grounds and other items not a part of this project. The Contractor shall clean daily all areas outside the project area of dirt, dust, and debris generated by this contract.

D. The Contractor shall use designated haul routes for both delivery and removals. Haul routes are noted on the drawings.

E. The Contractor shall direct all concrete washings, or slurries resulting from saw cutting activities that contain Portland cement, to areas on the construction site where the sediments will be filtered out into the soil and not directed towards trees. Do not allow washings to enter the storm drain system or any water course. The Contractor shall coordinate with the COR prior to any concrete truck arriving on base to determine an appropriate wash out area. If concrete wash water cannot be directed to a suitable area on

QUALITY CONTROL 01 45 00 - 17

the construction site, it must be properly contained, collected, and disposed of as construction debris. Excess concrete not used in construction activities shall not be dumped, and must be removed and disposed of off base. Spills of concrete, concrete wash water, or chemicals used with exposed aggregate, must be contained and cleaned up immediately to prevent the spill from entering any part of the storm sewer system.

F. All debris generated by the contract shall be properly disposed of by the Contractor off the base. Removal of debris and other material shall be handled, transported, stored, and disposed of by the Contractor and his sub-contractors in accordance with all applicable federal, state or local laws, ordinances, regulations, court orders or other types of rules or rulings having the effect of laws. These restrictions shall apply both on and off base.

G. The Contractor shall submit with the regular progress reports a Government supplied Contractor Construction and Demolition Debris Report. This form lists the amount of materials disposed at a landfill, recycled or otherwise reused. This submittal is required before progress payments can be made and also applies to any debris by sub-contractors.

H. The Contractor shall take all precautions to prevent spillage of materials from Contractor vehicles on base pavements. The Contractor shall provide adequate labor and equipment to keep paved areas free of debris, and to contain loose materials at all times.

I. RECYCLING MATERIALS

The Contractor shall notify the COR a minimum of two weeks prior to removing recyclable materials identified to be turned in to the Government. The COR will arrange with the Recycling Center for Government furnished dumpsters to be placed near the construction site. Each type of material will be placed in separate dumpsters. The following recyclable materials are to be turned in to the Government.

(Note to Project Manager. You need to find out from the Base Recycling Center what items can be recycled through the Base Recycling Center.)

1. Electrical wire, conduit, junction boxes, etc.

2. Metal pipe and plumbing fixtures

3. Sheet metal, such as in ductwork and flashing

4. Metal HVAC equipment (air handlers, chillers, pumps, condensers, etc.)

5. Metal components from roofs, framing, siding, doors and windows and ceiling grids

6. Window glass, except for wire reinforced safety glass.

7. Cardboard

8. All plastic that has the recycle emblem arrows (1, 2, 3, 4, etc.). This includes empty plastic pails, drums and shrink wrap.

J. All removed carpet shall be recycled and the Contractor shall provide written certification that the carpet was not placed in a landfill. Contractor certification shall indicate how the material was recycled and provide the address where it was delivered.

K. All removed ceiling tile shall be recycled and the Contractor shall provide written certification that the ceiling was not placed in a landfill. Contractor certification shall indicate how the material was recycled and provide the address where it was delivered.

QUALITY CONTROL 01 45 00 - 18

1.05 CULTURAL RESOURCE MANAGEMENT

For the protection of cultural, historic and prehistoric resources, the Contractor shall submit a signed…