Final RFP SAO HI Install SMA Active Power System.pdf

11. The Contractor shall begin performance 10 calendar days and complete it within 180 calendar days after receiving award, x notice to proceed. The performance period is x mandatory negotiable. (SeeSpecs dated June 2021 .)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

x YES NO 12b. CALENDAR DAYS

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

33330222RF0010009

2. TYPE OF SOLICITATION

SEALED BID (IFB)

x NEGOTIATED (RFP)

3. DATE ISSUED

01/12/2022

PAGE OF PAGES

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

1683701

7. ISSUED BY CODE

OCON

8. ADDRESS OFFER TO

Smithsonian Institution

Office of Contracting and Personal Property

MRC 1200, PO Box 37012

Washington, DC 20013-7012

SMITHSONIAN INSTITUTION

P.O. BOX 37012

MRC 1200

Washington DC 20013-7012

9. FOR a. NAME INFORMATION Virginia Chan

CALL:

b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

202-633-7253

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

This Solicitation is for the Smithsonian Astrophysical Observatory (SAO) Install

SMA Active Power System (Flywheel) Project, located at Submillimeter Array

Facility, Mauna Kea Science Reserve, Hawaii 96720. It is the intent of the

Smithsonian Institution to award a firm fixed price contract to offeror whose proposal represents lowest price technically acceptable as defined in FAR 15, Subpart 15.101-2. The Contractor receiving the award shall provide all supervision, labor, materials and equipment necessary to perform construction services to complete the work as described in this Request for Proposal (RFP) below and the

Contract Documents (as defined in Section B of this RFP), including, without limitation, the Drawings and Specifications for SF Project No. 1683701 dated June

2021, attached hereto as Appendix 1-2. All work shall be done in accordance with applicable codes and regulations.

This RFP consists of the following:

This Standard Form 1442;

Sections A-M, p. 1-129;

All Contract Documents (as defined in Section B below), including, without limitation, the Specifications and Drawings attached hereto as Appendix 1-2;

All other documents and attachments listed in Section J of this RFP below.

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and copies to perform the work required are due at the place specified in Item 8 by 1700 (hour) local time

03/01/2022 (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due .

b. An offer guarantee is, x is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than 60 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected .

NSN 7540-01-155-3212 STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is not required to sign this document.)(Contractor is required to sign this document and return

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

OFPAGE

SMITHSONIAN INSTITUTION

P.O. BOX 37012

MRC 1200

Washington DC 20013-7012

OCON

Willard B. Powell

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

2 129

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED

33330222RF0010009

PAGE OF

3 129

NAME OF OFFEROR OR CONTRACTOR

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

PRE-BID TOUR OF THE SITE

The Pre-proposal meeting is scheduled for Friday, January 28 at 10:30 AM HST. Address is:

Smithsonian Astrophysical Observatory

Submillimeter Array Facility

Mauna Kea Science Reserve, Hawaii

Bidders must confirm their participation in the site visit with COTR Simon Radford, (808)333-4871, simon.radford@cfa.harvard.edu

Starting point at 10:30AM HST will be the

Maunakea Mid-Level Station(Halepohaku). Then will proceed to the telescope in convoy (30 mins).

Bidders - please note requirement: 4wd vehicles must have been cleaned to prevent spread of invasive species. These requirements are included in the general conditions.

If the Maunakea access road is closed to the public because of bad weather, the site visit must be rescheduled.

QUESTIONS/CLARIFICATIONS

It is desired that all questions/clarifications be sent in, sequentially numbered for example first questions 1,2,3, second set of questions 4, 5, 6, etc. in word format to ChanVC@si.edu. It is requested that all questions be sent in not later than February 15, 2022 at 5PM EST.

Proposals are to be submitted in pdf form (1 pdf for Technical, 1 pdf for Cost) to DropBox.com using the link:

https://www.dropbox.com/request/p1Sxh07BDh3eGwq

GlORt

If any pricing information is on the Technical proposal, you will be disqualified.

THE PROPOSAL DUE DATE IS MARCH 1, 2022 AT 5:00PM

EASTERN STANDARD TIME

Davis Bacon Wage Determination HI20220001 dated

01/07/2022 shall apply.

Continued ...

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

mailto:simon.radford@cfa.harvard.edu mailto:ChanVC@si.edu https://www.dropbox.com/request/p1Sxh07BDh3eGwqGlORt https://www.dropbox.com/request/p1Sxh07BDh3eGwqGlORt

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED OFPAGE

33330222RF0010009

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

The period of performance for the Base

Contract is 180 Calendar Days from the date of

Notice to Proceed.

A – Standard Form SF 1442

B - Supplies or Services/Prices

C - Description/Specifications

D - Packaging and Marking

E - Inspection and Acceptance

F - Deliveries or Performance

G - Contract Administration Data

H - Special Contract Requirements

I - Contract Clauses

J - List of Documents, Exhibits and Other Attachments

K - Representations, Certifications, and Other Statements of Bidders

L - Instructions, Conditions, and Notices to Bidders

M - Evaluation Factors for Award

B - Supplies or Services/Prices

(Cost must be submitted in a separate electronic file)

B.3. Pricing – Offerors shall identify all costs associated with SAO-HI: Install SMA Active Power

System (Flywheel) project, to include Base Cost, as set forth in the Contract Documents. Offerors are required to provide the Base Cost Proposal Submission as per the Base Cost Proposal Submission

Form (B.3.1).

(Remainder of page intentionally left blank)

B.1. The Smithsonian Institution intends to award a firm fixed-price construction contract to the successful Contractor/Offeror. The successful Contractor shall furnish all supervision, labor, materials and equipment needed to Install SMA Active Power System (Flywheel), SF Project #

1683701, at the Smithsonian Institution’s Submillimeter Array (SMA) Base Facility, located at

Mauna Kea Science Reserve, Hawaii.

B.2. The term “Contract Documents” shall be deemed to include all Contract Clauses, the terms and conditions of this RFP, and all drawings and specifications referenced in Section J, including, without limitation, the drawings and specifications identified in Section B.2.1. below. All work shall be performed in strict accordance with the Contract Documents as shown or as may be changed by modification issued by the Contracting Officer. No deviations are permitted unless a change notice is issued and approved by the Smithsonian Institution Contracting Officer.

B.2.1. Contract Documents includes, without limitation, the Drawings and Specifications as referenced below:

1. SAO-HI: Install SMA Active Power System (Flywheel), SF Project No. 1683701

a. Drawings, dated June 2021:

• Sheets 1 through 25

b. Specifications, dated June 2021

• Pages 1 through 203

B.3.1. Base Cost Proposal Submission – Provide a comprehensive Base Cost Proposal Submission that includes cost for all work, including but not limited to supervision, labor, materials, coordination, overhead, profit and bonds, associated with SAO-HI: Install SMA Active Power System (Flywheel), SF Project

#1683701, to be performed entirely within the period of performance for the project, as set forth in Section C.

Base Cost Proposal Submission shall be submitted in the format below (CSI division of work). Price the work as a single complete project.

Base Bid: Base project all supervision, labor, materials, and equipment needed to construct an Active Power

System, improvements, and associated modifications.

Description Quantity Unit of Measure Amount

Div 1 General Conditions $ -

Div 2 Selective Demolition $ -

Div 3 Concrete $ -

Div 5 Metals $ -

Div 7 Thermal and Moisture Protection $ -

Div 9 Finishes $ -

Div 26 Electrical $ -

Div 26 263354 Rotary Uninterruptible Power Supply Unit $ -

Subtotal

Overhead and Profit $ -

Performance Bond $ -

Tax $ -

Total

C - Description/Specifications

C.1. The Smithsonian Institution is seeking offers to Install SMA Active Power System (Flywheel) at the

Submillimeter Array (SMA) Base Facility, located at Mauna Kea Science Reserve, Hawaii, as described herein and the Contract Documents, including, without limitation, in the Specifications and Drawings for

SF Project No. 1683701, both dated June 2021.

Submission instructions and requirements are set forth in Section L. Evaluation factors for qualifying offerors are set forth in Section M below. Upon the receipt of Technical and Cost Proposals (as further described in Section L) and the selection of a successful Offeror, the Smithsonian Institution will execute a Fixed Price construction contract. The Smithsonian currently estimates that the fixed price for the entire project will be between $1M and $2M (but, for the avoidance of doubt, this is just an estimate and will not be binding on the Smithsonian; the firm fixed price that is set forth in the construction contract will control).

The Period of Performance for the Base Contract is 180 Calendar Days from the date of Notice to

Proceed.

It shall be the responsibility of the contractor to immediately notify the Smithsonian Institution, if the target dates and proposed packages of work described herein adversely affect the Contractor’s Critical

Path Schedule (also refer to throughout this RFP as the Progress Schedule) for the final completion date of this project. Contractors may propose an alternate schedule which illustrates the completion of the project in advance of the completion date, for review by Smithsonian in accordance with the terms of the contract.

This Request for Proposal (RFP) is intended to provide all Offerors with sufficient information to enable them to prepare and submit offers for technical and cost review and consideration by the Smithsonian

Institution.

This solicitation neither commits the Smithsonian Institution to pay any proposal preparation costs nor obligates the Smithsonian to procure or contract for construction or any other services. It shall not be construed as authorization to proceed with or be reimbursed for any of the costs for any of the work specified herein.

The Smithsonian may cancel this RFP without prior notice.

C.2. PROJECT DESCRIPTION

C.2.1. The Contractor shall furnish all supervision, labor, materials and equipment needed to Install

SMA Active Power System (Flywheel) at the Smithsonian Institution’s Submillimeter Array Facility, located at Mauna Kea Science Reserve, Hawaii, as set forth on the Drawings for SF Project No: 1683701 sheets l through 25 and in these specifications, both dated June 2021.

The Work includes, but is not limited to:

• Erection of mezzanine to include but not limited to concrete footings, structural metal supports, metal grate decking, and access ladder

• Procurement and installation of the Active Power System (APS) and associated electrical infrastructure required to support the APS

Critical Elements of the Work: The successful Contractor shall be fully qualified to install critical elements of the Work.

• Installation, connection and commissioning of proposed APS.

• Facility shall have continuous power throughout operation. Shutdowns to be limited to agreed upon durations.

D - Packaging and Marking

See Section L below for submission instructions.

E - Inspection and Acceptance

52.246-12 Inspection of Construction. (AUG 1996)

(a) Definition. Work includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The

Contractor shall maintain complete inspection records and make them available to the

Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not -

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) below.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer's written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The

Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may (1) by contract or otherwise, replace or correct the work and charge the cost to the Contractor or (2) terminate for default the Contractor's right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the

Government's rights under any warranty or guarantee.

(End of clause)

52.246-S0038 Smithsonian Institution Inspection and Acceptance (Jun 2000)

Inspection and acceptance may be made on a daily basis on work performed at the job site, by the

Contracting Officers Technical Representative. All work shall be coordinated through the COTR for acceptance of work, payrolls and invoice(s).

52.246-S0039 Final Inspection and Tests (Jun 2000)

The requirements of the Inspection of Construction clause prescribed in FAR 52.246-12, are supplemented to provide that the Contractor shall give the Contracting Officer at least 10 calendar days advance written notice of the date the work will be fully completed and ready for final inspection and tests. Final inspection and tests will be started within 10 calendar days from the date specified in the aforesaid notice unless the

Contracting Officer determines that the work is not ready for final inspection and so informs the

Contractor.

52.246-S0057 Inspection

(a) Upon proper notice and during normal working hours, the Smithsonian Institution reserves the right to perform any inspections and tests as deemed necessary to assure that the Contractor is performing in accordance with the terms and specifications as set forth herein.

(b) Inspection may be at the Contractor's place of business or at any location where work is being performed in conjunction with this contract.

(c) Inspection by the Smithsonian Institution shall not relieve the Contractor of responsibility for any or all quality control aspects during the life of the contract. This shall include quality control for items covered by this contract that may be subcontracted.

52.246-S0058 Acceptance

(a) The supplies and services rendered under this contract will be accepted and approved by the Contracting

Officer or a designated representative thereto. Such approval will indicate acceptability to the Smithsonian

Institution of performance in accordance with the terms and conditions of this contract, and will be subject to applicable warranties. The Smithsonian Institution reserves the right to reject works not conforming to prescribed contract requirements.

(b) Neither the Smithsonian Institution's reviews, approval, or acceptance of services and/or supplies, nor payment for any of the services or supplies required under this contract shall be construed to operate as a waiver of action arising out of the performance of this contract. Furthermore, the Contractor shall be and remain liable to the Smithsonian Institution in accordance with applicable law for all damages to the

Smithsonian Institution caused by the Contractor's negligent performance of any of the supplies or services furnished under this contract.

(c) Acceptance by the Smithsonian Institution does not relieve the Contractor of responsibility for correction of errors or omissions that may arise after such acceptance if the errors and omissions are clearly a fault in Contractor performance.

F - Deliveries or Performance

52.211-S0025 Commencement, Prosecution, and Completion of Work (Jun 2000)

(a) Definitions.

(1) The Contract Time is the period of time allotted in the Contract Documents for Final Completion of the

Work as defined in this Construction Contract Clause, including authorized extensions thereto. The

Contractor shall complete his Work within the Contract Time as stated in the SF 1442, or as modified.

(2) The date of commencement of the Work is the date established in the Notice To Proceed issued by the

C.O. Submission by the Contractor of its Performance and Payment Bonds, Preliminary Schedule and all

Certificates of Insurance and their approval by the S.I. are conditions precedent to the issuance of the

Notice to Proceed. The Contractor shall not commence the Work or store materials or equipment on site until written Notice to Proceed is issued or until the Contractor otherwise receives the written consent of the C.O.

(3) The date of Substantial Completion of the Work or designated portion thereof is the date certified by the

COTR when the Work or a designated portion thereof is sufficiently complete, in accordance with the

Contract Documents, so the S.I. can fully occupy the Work or designated portion thereof for the use for which it is intended, with all of the Project's parts and systems operable as required by the Contract

Documents. Only punch list work and any final cleaning beyond that needed for the S.I.'s full use may remain for Final Completion.

(4) The date of Final Completion of the Work is the date certified by the COTR when the Work is totally complete, to include punch list work and final clean up, in accordance with the Contract Documents and the

S.I. may fully occupy and fully utilize the Work for the use for which it is intended.

(5) If a date or time of completion is included in the Contract, it shall be the Date of Final Completion as defined in this Construction Contract Clause, including authorized extensions thereto, unless otherwise provided.

(6) The term Day as used in the Contract Documents shall mean calendar day unless otherwise specifically designated. All dates shall mean midnight of the indicated day unless otherwise stipulated.

(b) Progress and Completion.

(1) All time limits stated in the Contract Documents are of the essence of the Contract.

(2) The Contractor shall prosecute the Work diligently to Final Completion.

(c) Delays and Extensions of Time.

(1) The time during which the Contractor is delayed in the performance of the Work, by the acts or omissions of the S.I., the Architect, or their employees or agents, acts of God, unusually severe and abnormal climatic conditions, fires, floods, epidemics, quarantine restrictions, strikes, riots, civil commotion or freight embargoes, or other conditions beyond the Contractor's control and which the

Contractor could not reasonably have foreseen and provided against, shall be added to the Contract Time;

provided, however, that no claim by the Contractor for an extension of time for delays will be considered unless made in compliance with the requirements of this Article and other provisions of the Contract

Documents.

(2) Neither the S.I., nor the Architect shall be obligated or liable to the Contractor for, and the Contractor hereby expressly waives any claims against the S.I. and the Architect on account of any indirect or direct damages, costs or expenses of any nature which the Contractor, Subcontractors, of Suppliers or any other person may incur as a result of any delays, interference, changes in sequence or the like, which are reasonable, foreseeable, contemplated, or avoidable by the Contractor, arising from or out of any act or omission of the S.I. of the Architect, or their agents, employees, consultants, separate contractors or any governmental representative, it being understood and agreed that the Contractor's sole and exclusive remedy in any such events shall be an extension of the Contract Time, but only as determined in accordance with the provisions of the Contract Documents.

(3) The Contract Time shall be adjusted only for Change Orders pursuant to the Construction Contract

Clause entitled "Changes", excusable delays pursuant to Construction Contract Clause entitled "Delays and

Extensions of Time" and Construction Contract Clause entitled "Smithsonian Institution's Right to Stop or to Suspend the Work". In the event the Contractor requests an extension of the Contract Time, he shall furnish such justification and supporting evidence as the C.O. may deem necessary for a determination of whether the Contractor is entitled to an extension of time under the provisions of the Contract. The burden of proof to substantiate a claim for an extension of the Contract Time shall rest with the Contractor, including evidence that the cause was beyond his control. The C.O. shall base his findings of fact and decision on such justification and supporting evidence and shall advise the Contractor in writing thereof. If the C.O. finds that the Contractor is entitled to any extension of the Contract Time, the C.O.'s determination of the total number of days' extension shall be based upon the currently approved Progress Schedule and on all data relevant to the extension. Such data will be incorporated into the Progress Schedule in the form of a revision thereto, accomplished in a timely manner. The Contractor acknowledges and agrees that actual delays (due to said changes, suspensions of work or excusable delays) in activities which, according to the

Progress Schedule, do not affect the Contract Time, do not have any effect upon the Contract Time and therefore will not be the basis for a change therein. The Contractor acknowledges and agrees that time extensions will be granted only to the extent that excusable delays exceed the available float in the

Contractor's Progress Schedule.

(4) Subject to other provisions of the Contract, the Contractor may be entitled to an extension of the

Contract Time (but no increase in the Contract Price) for delays arising from unforeseeable causes beyond the control and without the fault or negligence of the Contractor, his Subcontractors or Suppliers as follows:

(i) Labor disputes and strikes (including strikes affecting transportation), that do, in fact, directly and critically affect the progress of the Work; however, an extension of Contract time on account of an individual labor strike shall not exceed the number of days of said strike;

(ii) Acts of God, tornado, fire, hurricane, blizzard, earthquake, typhoon, or flood that damage completed work or stored materials.

(iii) Abnormal inclement weather; however, the Contract Time will not be extended due to normal inclement weather. The time for performance of this Contract, as stated in the Contract Documents, includes an allowance for calendar days, which may not be available for construction out-of-doors; for the purposes of the Contract, the Contractor agrees that said number of calendar days per month are to be considered as normal inclement weather. Unless the Contractor can substantiate to the satisfaction of the

S.I. that there was greater than normal inclement weather considering the full term of the Contract Time using a ten year average of accumulated record mean values from climatological data compiled by the U.S.

Department of Commerce, National Oceanic and Atmospheric Administration for the locale of the Project and that such alleged greater than normal inclement weather actually delayed the Work or portions thereof which had an effect upon the Contract Time, the Contractor shall not be entitled to an extension of time. If the total accumulated number of calendar days lost due to inclement weather, from the start of Work until

Final Completion, exceeds the total accumulated number to be expected for the same period from the aforesaid climatological data, time for completion will be extended by the number of calendar days needed to include the excess number of calendar days lost.

(iv) Acts of the public enemy, acts of the state, Federal or local government in its sovereign capacity, and acts of a separate contractor in the performance of its contract with the S.I. relating to the Project.

(5) The Contractor shall not be entitled to and hereby expressly waives any extension of time resulting from any conditions or cause unless said claim for extensions of time is made in writing to the C.O. within seven

(7) days of the first instance of delay. Circumstances and activities leading to such claim shall be indicated or referenced in a daily field inspection report for the day(s) affected; otherwise, all such claims are waived by the Contractor. In every such written claim, the Contractor shall provide the following information:

(i) Nature of the delay;

(ii) Date (or anticipated date) of commencement of delay;

(iii) Activities on the Progress Schedule affected by the delay, and/or new activities created by the delay and their relationship with existing activities;

(iv) Identification of person(s) or organizations(s) or event(s) responsible for the delay;

(v) Anticipated extent of the delay;

(vi) Recommended action to avoid or minimize the delay.

(d) Responsibility for Completion.

(1) The Contractor shall furnish such manpower, materials, facilities and equipment and shall work such hours, including night shifts, overtime operations and Sundays and holidays, as may be necessary to insure the progress and completion of the Work in accordance with the approved and currently updated Progress

Schedule. If Work actually in place falls behind the currently updated and approved Progress Schedule and it becomes apparent from the current Progress Schedule that the Work will not be completed within the

Contract Time, the Contractor agrees that he will, as necessary, take some or all of the following actions at no additional cost to the S.I., as required to eliminate substantially the backlog of the Work:

(i) Increase manpower in quantities and crafts necessary

(ii) Increase the number of work hours per shift, shifts per working day, working days per week, the amount of equipment, or any combination of the foregoing; and/or

(iii) Re-schedule activities to achieve maximum practical concurrence.

(2) The COTR may require the Contractor to submit a Recovery Schedule in accordance with the

Supplementary Construction Contract Clause, demonstrating his program and proposed plan to make up the lag in scheduled progress and to ensure completion of the Work within the Contract Time. If the COTR finds the proposed plan not acceptable, he may require the Contractor to submit a new plan. If the actions taken by the Contractor or the second plan proposed are not satisfactory, the COTR may require the contractor to take any of the actions set forth in this Construction Contract Clause without additional costs to the S.I., to make up the lag in scheduled progress.

(3) Failure of the Contractor to comply substantially with the requirements of this Construction Contract

Clause may be considered grounds for a determination by the S.I., pursuant to the Construction Contract

Clause entitled "Default", that the Contractor is failing to prosecute the Work with the sufficient diligence to ensure its completion with the Contract Time.

52.228-S0081 Period of Performance-Bonds & Insurance-Construction

Contractor must submit approved Certificate of Insurance and Performance/Payment Bonds within ten (10) days of contract award.

52.236-S0036 Smithsonian Institution's Right to Stop or to Suspend the Work (Jun 2000)

(a) If the Contractor fails to correct defective Work as required by the

Construction Contract Clause entitled "Correction of Work” or fails to carry out the Work or supply labor and materials in accordance with the

Contract Documents, the C.O. by a written order may order the

Contractor to stop the Work, or any portion thereof, without monetary compensation to the Contractor until the cause for such order has been eliminated.

(b) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the Work for such period of time as he may determine to be appropriate for the convenience of the

S.I.

(c) If the performance of all or any part of the Work is, for an unreasonable period of time, suspended, delayed, or interrupted by the

S.I. or its authorized representatives in the administration of this

Contract, or by failure of any one of them to act within the time specified in this Contract (or if no time is specified, within a reasonable time), an adjustment shall be made for an increase in the actual time required for performance of the Work by the Contractor, due solely to such unreasonable suspension, delay, or interruption and the Contract modified in writing accordingly. However, no claim for an extension of time shall be made under this Construction Contract Clause for any suspension, delay, or interruption pursuant to this Construction Contract

Clause, or for which claim is provided or excluded under any other provision of this Contract. No claim under this Construction Contract

Clause shall be allowed for any claim for an extension of time required for performance, unless within twenty (20) days after the act or failure to act involved, the Contractor submits to the COTR a written statement setting forth, as then practicable, the extent of such claimed time extension and unless the claim for an extension of time is asserted in writing as soon as practicable after the termination of such suspension, delay, or interruption. No claim shall be made for direct or indirect costs incurred by Contractor as a result of the events described in this

Construction Contract Clause, a time extension being the Contractor's sole remedy.

(d) A claim under this clause shall not be allowed (1) for any costs incurred more than twenty (20) days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order), and (2) unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

(e) In the event of a suspension of work or delay or interruption of work, the Contractor will and will cause his subcontractors to protect carefully his, and their materials and work against damage or injury from the weather and maintain completed and uncompleted portions of the work as required by the Contract Documents. If, in the opinion of the COTR, any work or material shall have been damaged or injured by reason of failure on the part of the Contractor or any of his subcontractors to so protect same, such work and materials shall be removed and replaced at the expense of the Contractor.

(f) No claim by the Contractor for an equitable adjustment under the

Construction Contract Clause entitled "Equitable Adjustments", shall be allowed if asserted after Final Payment under this Contract.

52.246-S0041 Additional Warranties and Guarantees (Jun 2000)

(a) The Contractor guarantees and warrants to the S.I. all work as follows:

(1) That all materials and equipment furnished under this Contract will be new and the best of its respective kind unless otherwise specified;

(2) That all Work will be first-class quality and free of omissions and faulty, poor quality, imperfect or defective material or workmanship;

(3) That where no standard is specified for such workmanship or materials, they shall be the best of their respective kinds;

(4) That the Work shall be entirely watertight and leakproof in accordance with all applicable industry customs and practices, and shall be free of shrinkage and settlement, (normal shrinkage inherent in the specified materials is acceptable);

(5) That the Work, including but not limited to, mechanical and electrical machines, devices and equipment shall be fit and fully usable for its intended and specified purpose and shall operate satisfactorily with ordinary care;

(6) That consistent with requirements of the Contract Documents the Work shall be installed and oriented in such a manner as to facilitate unrestricted access for the operation and maintenance of fixed equipment;

(7) That the Work will be free of abnormal or unusual deterioration which occurs because of poor quality materials, workmanship or unsuitable storage.

(b) All work not conforming to guarantees and warranties specified in the Contract Documents, including substitutions not properly approved and authorized, may be considered defective. If required by the COTR, the Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment.

This warranty is not limited by the provisions of the Construction Contract Clauses entitled "Uncovering of

Work" and "Correction of Work".

(c) The warranties set forth in this Construction Contract Clause entitled "Additional Warranties and

Guarantees" and elsewhere in the Contract Documents shall survive Final Completion of the Work under the Construction Contract Clause entitled "Payments and Completion".

(d) If, within one year after the Date of Final Completion of the Work or designated portion thereof or within one year after acceptance by the S.I. of designated equipment or within such longer period of time as may be prescribed by law or by the terms of any applicable special warranty required by the Contract

Documents, any of the Work is found to be defective, not in accordance with the Contract Documents, or not in accordance with the guarantees and warranties specified in the Contract Documents, the Contractor shall correct it within five (5) working days, or such other period as mutually agreed, after receipt of a written notice from the COTR to do so.

(e) Any materials or other portions of the Work, installed, furnished or stored on site which are not of the character or quality required by the specifications, or are otherwise not acceptable to the COTR, shall be immediately removed and replaced by the Contractor to the satisfaction of the COTR, when notified to do so by the COTR.

(f) If the Contractor fails to correct defective or nonconforming Work as required by the Construction

Contract Clause entitled "Correction of Work", or if the Contractor fails to remove defective or nonconforming Work from the site, as required by the Construction Contract Clause entitled "Uncovering of Work", the S.I. may elect to either correct such work in accordance with the Construction Contract

Clause entitled "Smithsonian Institution's Right to Carry Out The Work", or remove and store materials and equipment at the expense of the Contractor.

(g) The Contractor shall bear the cost of making good all work of the S.I., separate contractors or others, destroyed or damaged by such correction or removal required under this Construction Contract Clause or the Construction Contract Clauses entitled "Uncovering of Work" and "Correction of Work", or elsewhere in the Contract Documents.

(End of Section)

G - Contract Administration Data

52.202-S0059 Contract Management

Notwithstanding the Contractor's responsibility for total management during the performance of this contract, the administration of the contract will require maximum coordination between the Smithsonian and the Contractor. The following individuals will be the Smithsonian points of contact during the performance of the contract.

52.202-S0060 Contracting Officer

All contract administration will be effected by the Contracting Officer. Communications pertaining to contractual administrative matters will be addressed to the Contracting Officer. No changes in or deviation from the scope of work shall be effected without a written modification to the contract executed by the

Contracting Officer authorizing such changes.

52.202-S0061 Contracting Officer's Technical Representative (COTR) (Apr 1988)

(a) The Contracting Officer's Technical Representative (COTR) Simon Radford, (808) 333-4871, simon.radford@cfa.harvard.edu, or his authorized representative shall act for and on behalf of the

Contracting Officer in the administration of any resultant contract with respect to:

1. Resolution of issues that may arise between the Contractor and the Smithsonian Institution in connection with such matters as acceptability of workmanship and other technical requirements;

2. Evaluation on an overall basis of the acceptability of workmanship and Contractor's compliance with technical requirements; and

3. The approval and acceptance of work performed under this contract.

(b) This delegation does not authorize the modification of any of the contract's provisions, terms or conditions. All authorities not herein delegated are reserved to the Contracting Officer.

(c) The Contractor shall make available such records, reports and facilities as may be required to carry out this assignment.

52.202-S0062 Authorities

The Contractor is advised that only the Contracting Officer can change or modify the terms of this contract or take any other action which obligates the Smithsonian and then such action must be set forth in a formal modification to the Contract. The authority of the COTR is strictly limited to the specific duties set forth in her letter of appointment, a copy of which will be furnished the Contractor. Contractors who rely on direction from persons other than the Contracting Officer (or a COTR acting within the strict limits of his/her responsibilities as set forth in his/her letter of appointment) do so at their own risk and expense, as such actions do not bind the Smithsonian contractually. All questions concerning the authority of a

Smithsonian employee to direct the Contractor contractually should be referred to the Contracting Officer.

52.213-S0094 Application for Payment

The Contractor shall submit Application for Payment in triplicate copies and in accordance with the

Construction Contract Clauses. All Applications for Payment shall identify the Contract Number and

Project Title and shall be submitted to the COTR at the address specified by the Work Order.

Note: The Prompt Payment Act (31 U.S.C. Section 3901) is not applicable to the Smithsonian Institution.

The Smithsonian Institution shall take all reasonable measures to ensure that payment for invoice(s) properly documented and submitted shall be paid within thirty (30) days from receipt of an approved proper invoice.

mailto:radfords@si.edu

H - Special Contract Requirements

52.202-S0010 Use of Smithsonian Name (Jun 2000)

It is recognized and acknowledged that Contractor shall have no right to use the name "Smithsonian" or

"Smithsonian Institution", or the name of any Smithsonian Museum or part thereof, including the Facilities, in connection with any of its own advertising, marketing or promotion. However, any marketing or promotional programs concerning the Smithsonian, or the Project shall be submitted to the Smithsonian for review and approval prior to any implementation thereof. The Smithsonian may withhold any approval required hereunder as it wishes.

The Prime Contractor shall be responsible for compliance by any subcontractor or supplier or lower tier subcontractor or lower tier supplier with this clause. After award of the contract and upon request of the

Contracting Officer, the Prime Contractor shall deliver a written statement acknowledging that this clause has been included in contracts with all subcontractors and suppliers.

52.203-S0004 Advertising of Award Smithsonian Institution

The Contractor shall not refer to the Smithsonian or to any of its museums, organizations, or facilities in any manner or through any medium, whether written, oral or visual, for any purpose whatsoever, including advertising, marketing, and promotion.

52.215-S0008 Contracting Officer's Technical Representative (Apr 1988)

Contracting Officer's Technical Representative (herein referred to as the COTR) will be the Contracting

Officer's (CO) exclusive representative to the Contractor with respect to the Project during construction and until Final Payment and Release of Claims. The term COTR is referred to throughout the Contract

Documents as if singular in number and masculine in gender. The Smithsonian Institution's communications with the Contractor shall be exclusively through the COTR, who will have full authority to act on behalf of the C.O. with regard to all aspects of the Project except that the C.O. must approve all

Modifications and payments to the Contractor and is the final authority for all disputes under any Clause of this Contract. All of the Contractor's communications to the S.I. shall be exclusively through the COTR.

All of the COTR's actions with regard to this Project will be as the representative of the C.O.

52.215-S0009 Information, Services and Rights of the Smithsonian (Apr 1988)

(a) The S.I., through the C.O. and COTR, will provide administration of the contract as hereinafter described.

(b) The S.I. or its authorized representatives shall at all times have access to the Work whenever it is in preparation or progress. The Contractor shall provide safe facilities for such access.

(c) The S.I. or its authorized representatives shall not be responsible for or have control or charge of the construction means, methods, techniques, sequences, or procedures, or for safety precautions and program in connection with the Work, and will not be responsible for the Contractor's failure to carry out the Work in accordance with the Contract Documents.

(d) The COTR shall have authority to reject Work when in his opinion, the Work does not conform to the

Contract Documents.

(e) Whenever in the COTR's reasonable opinion it is considered necessary or advisable for the implementation of the intent of the Contract Documents, the COTR will have authority to require special inspection or testing of the Work in accordance with the provisions of the Contract Documents whether or not such Work be then fabricated, installed or completed.

(f) The COTR shall have the authority and discretion to call, schedule, and conduct job meetings to be attended by the Contractor, representatives of his Subcontractors, and the Architect to discuss such matters as procedures, progress, problems, payments and scheduling.

(g) The COTR will establish procedures to be followed for processing all Shop Drawings, catalogs, and other project reports and other documentation, test reports, and maintenance manuals.

(h) The COTR will review all requests for changes and shall implement the processing of Change Orders, including applications for extension of the Contract Time.

(1) The COTR will review and process all Progress Payments including the Final Payment.

(2) The Smithsonian Institution or its authorized representatives shall not be responsible or liable to the

Contractor for the acts, errors or omissions of the Contractor, any separate Subcontractor, any separate contractor or any contractor's or subcontractor's agents or employees, or any other persons performing any of the Work.

(k) Unless otherwise provided in the Contract Documents, the Contractor will be furnished, free of charge, ten copies of full size Drawings and Specifications reasonably necessary for the execution of the Work.

(l) The foregoing rights are in addition to other rights of the S.I. enumerated herein and those provided by law.

52.223-S0070 Dissemination of Information

There shall be no dissemination or publication of information, except between the Contractor and any subcontractors, of information developed under this contract or any task orders awarded under the terms of this contract or contained in reports to be furnished pursuant to this contract without the prior written approval of the Contracting Officer.

52.236-S0030 Availability and Use of Utility Services (Jun 2000)

(a) The Government shall make all reasonably required amounts of utilities available to the Contractor from existing outlets and supplies, as specified in the contract. These services shall be furnished without charge to the Contractor. The Contractor shall carefully conserve any utilities furnished without charge.

(b) The Contractor, at its expense and in a workmanlike manner satisfactory to the Contracting Officer, shall install and maintain all necessary temporary connections and distribution lines. Before final acceptance of the work by the Government, the Contractor shall remove all the temporary connections, distribution lines, and associated paraphernalia.

52.236-S0031 Use of Site (Jun 2000)

The Contractor shall confine operations at the site to areas permitted by law,…