FA5004-12-R-C005-0001.pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment your desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICITATION

NO.

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO.

IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

NSN 7540-01-152-8070

Previous edition unusable

The purpose of this amendment is to make the following changes:

1. To revise the liquidated damages rate. See FAR Clause 52-211-12 for additional details.

2. To revise Section 15699 of the specification. Please note that all changes are in bold text.

3. To answer questions which have arisen based on the RFP; see attachment labeled "Questions and Answers Amendment 0001". All questions are now closed.

4. To provide access to attachment JA-6. See **Notice to Offerors** on page 2 for additional information.

5. The offer due date has been extended from 4:00PM AST on 20 July 2012 to 4:00PM AST on 26 July 2012.

POC for this amendment is TSgt Nicholas Bastiani at (907) 377-3485 or nicholas.bastiani@us.af.mil.

354 CONTRACTING SQUADRON ISSUING OFFICE

2310 CENTRAL AVE, BLDG 2258

LGCA - CONSTRUCTION

EIELSON AFB, AK 99702-1801

See Item 6

J

FA5004-12-R-C005

FTQW 12-1015

07/12/2012

06/20/2012

07/12/2012

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

**NOTICE TO OFFERORS** Due to the size of the files associated with Attachment JA-6 - Structural Drawings, it has been brought to the Governments attention that the files on www.fbo.gov were not uploaded properly. As a result, the Government is utilizing a U.S. Army, automated document distribution system called ARMDEC Safe File

Exchange to distribute copies of this document. Interested offerors should email TSgt Nicholas Bastiani at nicholas.bastiani@us.af.mil NOT LATER THAN TUESDAY, 17 JULY 2012 AT 4:00PM, to request access to

Attachment JA-6. Offerors who request attachment JA-6 after 17 July 2012 will be granted access to the document but no additional offer due date extensions will be granted based on this information.

SECTION A – SOLICITATION/ CONTRACT FORM

The required response date/time for receipt of proposals has changed

FROM:

20 July 2012 4:00PM AST

TO:

26 July 2012 4:00PM AST

SECTION F – DELIVERIES OR PERFORMANCE

The following clause has changed from:

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $214.00 for the first calendar day and $190.22 for each subsequent calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

TO:

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $214.00 for the first calendar day and $190.22 for each subsequent calendar day of delay until the work is completed or accepted.

(b) Additionally, for each hour beyond the Contract Completion Date that Turbine-Generator #5 is not available to produce power because of the Contractor’s failure to complete the work of the contract, the Contractor shall pay

Type 2 liquidated damages in the amount of $253.00 per hour/ $6,072.00 per 24 hour period. This charge is based on the difference between the cost of coal needed to generate power with Turbine #5 and the cost of generating power using Turbine-Generators #1 and #2, which are significantly less efficient machines than Turbine #5.

mailto:nicholas.bastiani@us.af.mil

(c) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

(End Summary of Changes)