Atch_2_BU_Power_Systems_(B533).pdf

PATRICK AIR FORCE BASE

Technical Specifications

For

SXHT 14-1046

Consolidate Backup Power Systems, Comm Ctr B533

100% Submittal

DATE: January 2018

RRAAEEIISS

Range Architect-Engineer Inspection Services

Consolidate Backup Power Systems, Comm Ctr B533 SXHT 14-1046

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00.00 30 SUMMARY OF WORK

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS

01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT

01 78 00 CLOSEOUT SUBMITTALS

DIVISION 26 - ELECTRICAL

26 20 00 INTERIOR DISTRIBUTION SYSTEM

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 1 1/16/2018

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00.00 30

SUMMARY OF WORK

10/14

PART 1 GENERAL

1.1 SUMMARY

1.2 PROJECT DESCRIPTION

1.2.1 Electrical

1.3 REFERENCES

1.4 SUBMITTALS

1.5 CONTRACT DRAWINGS

1.5.1 Layout of Work and Elevations

1.6 WORK SCHEDULING

1.6.1 Requirements

1.7 OCCUPANCY OF PREMISES/ACCESS REQUIREMENTS

1.7.1 Facility Contents

1.7.1.1 Responsibilities

1.7.1.2 Maintain Clean Work Areas

1.7.1.3 Damage To Existing Equipment

1.7.1.4 New Material and Construction Equipment

1.7.2 Construction Area Access And Control

1.7.2.1 Access and Control Requirements

1.7.3 Vehicle Parking

1.7.3.1 Requirements

1.8 STORAGE, TRANSPORTATION AND PROTECTION

1.8.1 Storage

1.8.2 Protection

1.8.3 Transportation

1.8.4 Hazardous Materials

1.8.5 Site Protection Plan

1.9 GOVERNMENT-FURNISHED EQUIPMENT - None

1.10 ON-SITE PERMITS

1.10.1 Utility Outage Requests And Connection Requests

1.10.1.1 Requirements

1.10.2 Protection of Work

1.10.3 Burn Permits

1.11 SALVAGE AND DISPOSAL OF MATERIAL AND EQUIPMENT

1.11.1 Removal

1.11.2 Housekeeping

1.11.3 Salvage of Material And Equipment

1.11.3.1 Salvage Items

1.11.4 Waste Disposal

1.11.5 Cleanup

1.11.6 Salvage And Disposal Record Keeping

1.12 RADIO FREQUENCY MANAGEMENT PROCEDURES

1.13 COMMUNICATION SECURITY

PART 2 PRODUCTS

SECTION 01 11 00.00 30 Page 1

PART 3 EXECUTION

3.1 ACCESS REQUIREMENTS

3.1.1 Construction Site Requirement

3.2 PAFB VEHICLE INSPECTION

3.3 PAFB DELIVERIES

3.3.1 Non-Hazardous Deliveries

3.3.2 Hazardous Deliveries

3.4 RESPONSIBILITIES

3.5 EXCAVATION

3.5.1 Dig/Utility Locate Permit Requirements

3.5.1.1 Location of Buried Structures and Utility Lines

3.5.1.2 Excavation, Trenching, and Backfilling

3.5.1.3 Cutting of Roads, Streets, Driveways, and Paved Areas

3.5.2 Restrictions

3.5.3 Temporary Shoring, Bracing And Supports

3.5.4 Barricades

3.6 WELDER QUALIFICATION REQUIREMENTS

3.7 QUALITY CONTROL

3.7.1 Licenses

3.7.2 Government Inspection/Approval

3.7.3 Inspection Files

3.8 SUPERINTENDENT

3.9 CONSTRUCTION SCHEDULING REQUIREMENTS

3.9.1 Contractor Coordination Meetings

3.9.2 On-Site Construction Sequence

-- End of Section Table of Contents --

SECTION 01 11 00.00 30 Page 2

SECTION 01 11 00.00 30

SUMMARY OF WORK

10/14

PART 1 GENERAL

1.1 SUMMARY

The work to be performed under this project is located at Patrick Air Force Base. Patrick Air Force Base is located approximately three miles south of Cocoa Beach on State Road A1A.

The work to be performed under this project consists of providing the labor, equipment and materials to remove critical loads from an existing 350 kW generator and connect them to an existing 600 kW generator.

1.2 PROJECT DESCRIPTION

1.2.1 Electrical

Install new breaker in existing switchboard DP-1.

Disconnect critical loads from existing 350 kW generator.

Install new conduit and wire to connect existing critical loads to existing switchboard DP-1.

Disconnect and remove existing 350 kW generator and associated automatic transfer switch and turn over to the Government.

Remove existing diesel fuel tank and turn over the government.

During outages provide portable generators as indicated on the drawings.

Location and connection of portable generators shall be coordinated with 45 CES and the 45th Comm Squadron.

1.3 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

AMERICAN WELDING SOCIETY (AWS)

AWS B2.1/B2.1M (2014; Errata 2015) Specification for Welding Procedure and Performance Qualification

AWS D1.1/D1.1M (2015; Errata 1 2015; Errata 2 2016) Structural Welding Code - Steel

ASME INTERNATIONAL (ASME)

ASME BPVC SEC IX (2010) BPVC Section IX-Welding and Brazing Qualifications

SECTION 01 11 00.00 30 Page 3

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 101 (2015; ERTA 2015) Life Safety Code

U.S. AIR FORCE (USAF)

AFI 33-580 (2013) Spectrum Management

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety and Health Requirements Manual

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

29 CFR 1910 Occupational Safety and Health Standards

29 CFR 1926 Safety and Health Regulations for Construction

1.4 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor Quality Control information only. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES in sufficient detail to show full compliance with the specification:

SD-01 Preconstruction Submittals

Submit the following items to the Contracting Officer:

Utility Outage Requests;G

Connection Requests;G

Air Force Form 3952 (AF 3952), Chemical/Hazardous Material Request Authorization;G (including all paint)

SOLID WASTE DISPOSAL DIVERSION TRACKING;G

Premises/Access Plan;G

Storage Area Request;G

Superintendent Contact and Qualifications;G

1.5 CONTRACT DRAWINGS

See Drawing Index for list of project drawings.

Contract drawings, maps, and specifications will be furnished to the Contractor either hard copy or electronic at the Government's discretion.

Reference publications will not be furnished.

Contractor shall immediately check furnished drawings and notify the Contracting Officer of any discrepancies.

The drawings indicate the general location and arrangement of existing

SECTION 01 11 00.00 30 Page 4 conditions. Field measurements may be necessary to determine the size and quantity of materials. Conditions which are obvious/visible or which should be reasonably anticipated by the Contractor on inspection will not be considered under the Differing Site Conditions clause of this contract.

1.5.1 Layout of Work and Elevations

Dimensions and elevations indicated in the layout of work shall be verified by the Contractor. Discrepancies between the drawings, specifications and/or existing conditions shall be referred to the Contracting Officer in writing, for review, before the affected work is performed. Failure to make notification shall place the responsibility upon the Contractor to carry out the work in a satisfactory and workmanlike manner.

1.6 WORK SCHEDULING

Work Schedules for all on-site activities must be reviewed and approved by the Contracting Officer prior to start of the project; and all activities coordinated with the Contracting Officer once work has begun. Due to the critical nature of the work location, all work pertaining to this contract shall be completed with minimal disruption to the operation of Building 533.

Contractor shall allow for non-access days where construction activity is prohibited due to hazardous operations or launch activity. When possible, the Government will provide 24 hour notification each time the restrictions are invoked.

1.6.1 Requirements

Working hours will normally range between the hours of 7:30 AM and 4:00 PM (0730-1600) excluding Saturdays, Sundays and Federal Holidays. If work must be done during periods other than above, additional Government inspection and Range Support personnel may be required. Notification must be given to the Contracting Officer five working days in advance of intention to work during other periods to allow assignment of additional inspection forces when the Contracting Officer determines that they are reasonably available. If such support is reasonably available, the Contracting Officer may authorize work to be performed during periods other than normal duty hours/days. Work beyond normal hours/days may be required for major utility outages. It is the Government's discretion to request copies of contractor inspection records for periods worked on holidays and weekends (FAR 52.246-12 Inspection of Construction).

No construction work shall take place over the Christmas/New Year holiday period. This period will start one full work day before the Federal Christmas holiday and end the first work day after the Federal New Year Holiday. The Contractor may request to work during this time at the discretion of the Contracting Officer; however no base support will be available.

1.7 OCCUPANCY OF PREMISES/ACCESS REQUIREMENTS

Various building(s) will be occupied during performance of work under this Contract. Occupancy notifications will be posted in a prominent location in the work area. Contractor shall post warning signs in accordance with OSHA requirements.

Before work is started, the Contractor shall submit a Premises/Access Plan to the Contracting Officer or Representative for approval. The plan shall

SECTION 01 11 00.00 30 Page 5 include a sequence of procedures, means of access, space plan for storage of materials and equipment, and use of approaches, corridors, and stairways.

This plan must comply with NFPA 101 requirements that all exits and exit access must be maintained at all times. Base Fire Department is required to approve any deviations which affect the exiting or exit access from the building.

1.7.1 Facility Contents

1.7.1.1 Responsibilities

The schedule of work shall be closely coordinated with the Contracting Officer. Unless otherwise stated, remove all furniture, equipment, curtains, drapes, pictures, blackboards, etc., as required to perform the work. Any movable or fixed furniture, equipment, carpet, etc., remaining in the work area shall be covered and protected from damage. All relocated items shall also be protected from damage throughout the construction period. After completion of work and prior to final acceptance, replace removed items in their original location.

Demolition of critical facility systems mechanical, electrical, etc. shall not be started until replacement equipment is on site.

1.7.1.2 Maintain Clean Work Areas

All work areas shall be kept clean at all times. Contractor shall prevent introduction of dirt or dust into areas adjacent to the work areas. All materials, tools and equipment shall be thoroughly cleaned prior to being brought into the work areas or adjacent areas.

1.7.1.3 Damage To Existing Equipment

Any damage must be reported to the Contracting Officer immediately. Damage to existing materials, equipments, systems, or properties occurring from Contractor activities or neglect, shall, at the sole discretion of the Contracting Officer, be repaired or replaced by the Contractor at no cost to the Federal Government.

1.7.1.4 New Material and Construction Equipment

Only material and construction equipment designated for performance of contract work may be stored at the construction site or located in Government-controlled warehouses or shop facilities.

1.7.2 Construction Area Access And Control

1.7.2.1 Access and Control Requirements

Exclusive use or control of any area will not be allowed as the Government must have access to all areas at all times. All work must be scheduled around operational constraints.

1.7.3 Vehicle Parking

1.7.3.1 Requirements

Job and support vehicles for workers will be parked in designated parking areas within reasonable access to the worksite. All vehicle operators must

SECTION 01 11 00.00 30 Page 6 comply with all traffic laws including mandatory seat belt usage, speed limits and hauling restrictions. Contractor shall be responsible for repairing or replacing any facility/grounds damaged areas.

1.8 STORAGE, TRANSPORTATION AND PROTECTION

1.8.1 Storage

At Government discretion, Contractor may be assigned a storage area upon submitting written Storage Area Request to the Contracting Officer.

Contractor's Storage Area Request shall indicate dimensions of trailer, size of storage area, and utilities required. All trailers shall be in good and safe condition. Storage space is normally co-located with construction site, at the Contracting Officer's discretion. Storage areas may require fence and screening as required by Government. Contractor shall secure storage areas during inclement weather situation.

Office trailers and long term (longer than one year) storage trailers shall be painted to match the base approved color", as noted in the base Facilities Sustainment guide. Trailers located on site for short term storage, less than one year, will not need to meet this requirement. In addition, all office trailers and long term storage trailers shall be skirted along the entire perimeter with a wood lattice material. This skirting shall be painted to match the same trailer color as described above. Contractor shall be responsible for the storage and protection of all of their materials and equipment, whether incorporated into the job or not.

Portable/mobile structures, such as job shacks, material storage containers, and trailers remaining in position for longer than 24 hours, shall be anchored and stabilized.

1.8.2 Protection

Store and protect products in accordance with manufacturer's instructions.

Store products with seals, labels intact and legible. Store sensitive products in weather tight, climate controlled, enclosures in an environment favorable to the product. Products acceptable for exterior storage shall be on sloped supports above ground. Contractor shall not use swales, drainage ditches, or any other storm water permitted area to store materials or equipment. If swales, drainage ditches or any other storm water permitted areas must be used for storage, Contractor must get special permission from Contracting Officer.

1.8.3 Transportation

Transport and handle products in accordance with manufacturer's instructions. Promptly inspect shipments to ensure the products comply with requirements, quantities are correct, and products are undamaged.

Protect products subject to deterioration with impervious sheet covering.

Provide ventilation to prevent condensation and degradation of products.

Store loose granular materials on solid flat surfaces in a well drained area. Prevent mixing with foreign materials.

1.8.4 Hazardous Materials

Submit an Air Force Form 3952 (AF 3952), Chemical/Hazardous Material Request Authorization if hazardous materials & petroleum product will used on site. Hazardous Materials & petroleum product containers shall be stored

SECTION 01 11 00.00 30 Page 7 on an impervious surface with containment. Incompatible materials shall be segregated and have separate containment systems. Additional HAZMAT requirements are provided in Section 01 57 19 TEMPORARY ENVIRONMENTAL

CONTROLS.

1.8.5 Site Protection Plan

Structures, utilities, sidewalks, pavements, and other facilities immediately adjacent to excavations shall be protected against damage.

Contractor shall comply with "FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements" and is required to protect areas adjacent to the construction site.

1.9 GOVERNMENT-FURNISHED EQUIPMENT - None

1.10 ON-SITE PERMITS

1.10.1 Utility Outage Requests And Connection Requests

Work shall be scheduled to hold outages to a minimum.

Utility outages and Connection Requests required during the execution of work that affect existing systems shall be arranged at the convenience of the Government, which may require scheduling outside of the regular working hours or on weekends, at no additional cost to the Government.

Each Utility Outage and Connection Requests shall state the system involved, area involved, approximate duration of outage, and the nature of work involved.

1.10.1.1 Requirements

A written request for a utilities outage (electricity, communication, water, compressed air, gas, steam, air conditioning, fire detection and suppression systems, etc.) must be submitted to the Contracting Officer at least 14 calendar days in advance of the desired outage. Approval is required prior to scheduling any outage. All limitations noted on the approved outage authorization shall be carefully observed. A utilities outage without prior approval and coordination is prohibited.

Utility outages affecting fire alarm, fire detection, fire suppression, fire pumps and water supplies to fire protection systems greater than 4 hours will require a fire watch.

Since many systems are critical to facility operations, the number and duration of utility outages shall be kept to an absolute minimum. All work effort shall be coordinated and sufficient manpower, materials, and equipment shall be provided to complete the work within the authorized outage window.

Existing utility services may be interrupted only when approved by the Contracting Officer. The interruption shall be scheduled at a time of minimum demand on the utility, convenient to the Government. Outages on weekends, holidays, or evenings shall be performed at no additional cost to the Government.

Contractor shall make all necessary arrangements to schedule and provide connections to existing utilities and to cause minimum interruption to system operation. All temporary utility hook-ups and disconnects shall be

SECTION 01 11 00.00 30 Page 8 made by the Contractor.

If the Contractor fails to comply with a scheduled outage, the cost to reschedule the outage will be deducted from the final contract payment.

1.10.2 Protection of Work

Contractor shall obtain (from technical representative), prepare, and properly complete "Base Civil Engineering Work Clearance Request" AF Form

103. Prior to submitting 103 for review and approval, contractor shall mark in white paint all locations requiring utility locates and a commercial utility locate ticket number must be obtained by calling SUNSHINE at 1-800-432-4770. Contractor shall provide coordination for location of buried structures and utility lines before beginning any work involving digging/excavation. Contact the Government Technical Representative to schedule locates prior to any excavation. The Technical representative shall be the first and the last to coordinate on the AF Form 103.

After excavation permit has been obtained and prior to any excavating, verify with Cape Support (853-5211) that there are no "Critical Days" that would prevent excavation.

Contractor shall temporarily halt any machine excavation work or other surface penetration when approaching within 5 feet of the existing utility line until the Contractor has exposed the utility line by hand excavation to fix its location.

1.10.3 Burn Permits

Burn permits are required for any spark,flame, or welding activity. Burn Permits shall be obtained thru PAFB Fire Department (494-7642).

Permits shall be posted at a conspicuous location in the construction area.

Burning of trash or rubbish is not permitted on any USAF facility.

1.11 SALVAGE AND DISPOSAL OF MATERIAL AND EQUIPMENT

1.11.1 Removal

Remove and/or relocate only those materials or items of equipment specifically indicated in the drawings and specifications. Removal operations shall be performed in such a manner that adjacent areas, installed equipment, or existing utilities are not damaged. Repair all openings that occur due to removal or demolition operations to match adjacent, existing surfaces. Any damage incurred during removal operations shall be repaired at no additional cost to the Government.

1.11.2 Housekeeping

Sufficient personnel and equipment shall be provided to ensure compliance with all housekeeping requirements. Work will not be allowed in those areas that do not comply with the requirements of Section 14.C of EM 385-1-1.

Job sites are to be kept clean on an ongoing, daily basis. All areas are to be thoroughly cleaned prior to leaving the jobsite at completion of project work.

SECTION 01 11 00.00 30 Page 9

1.11.3 Salvage of Material And Equipment

All salvageable materials or items to be removed shall remain the property of the Federal Government. Salvageable items are listed below in the paragraph entitled, "Salvage Items". Salvageable items shall be transported to and deposited at the Defense Logistics Agency Office - Disposition Services (DLA) at Jacksonville, FL at the contractor's expense.

Salvageable material must be segregated and separated into categories before transport. Material shall be palletized or moveable by forklift (maximum 10,000 lbs). For material that is not palletized, it will be the responsibility of the Contractor to provide labor support for material removal.

Deliveries to DLA shall be scheduled through the Contracting Officer a minimum of 72 hours in advance. All salvageable items delivered to DLA shall be accompanied by a properly prepared DD Form 1348. This form will be furnished by the Contracting Officer. A signed copy by DLA reflecting the turn in materials shall be furnished to the Contracting Officer.

Contractor shall maintain property control records for material or equipment designated as salvage. Contractor's system of property control may be used if approved by the Contracting Officer. Contractor shall be responsible for storage and protection of salvaged materials and equipment until disposition by the Contracting Officer.

Material to be salvaged and reinstalled by the Contractor shall be protected during removal and stored to prevent damage.

For reference purposes salvageable is defined as: items, material, equipment which can be refitted, reworked, and restored and put to use or sold. The Contracting Officer shall have sole discretion as to determining whether any particular item is salvageable.

1.11.3.1 Salvage Items

- 350 kW generator

- Automatic transfer switch

- Diesel fuel tank

1.11.4 Waste Disposal

Non-salvageable material and debris shall be removed from work areas and disposed of daily. Contractor shall dispose of C&D at a State approved disposal site.

Refer to Section 01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS for further waste disposal and record keeping requirements.

1.11.5 Cleanup

All waste materials, except indicated salvaged items, generated by the construction shall be hauled off U.S. Government property at the end of each work day and deposited at a disposal site selected by the Contractor.

Disposal shall be in accordance with federal, state, county and city ordinances and at the expense of the Contractor.

Upon completion of the construction each day, the Contractor shall leave the work premises in a clean, neat and workmanlike condition, satisfactory

SECTION 01 11 00.00 30 Page 10 to the Contracting Officer.

1.11.6 Salvage And Disposal Record Keeping

Contractor shall maintain and submit quarterly and at the completion of the project the SOLID WASTE DISPOSAL DIVERSION TRACKING form to the Contracting Officer of all materials removed from the job site. This inventory shall include waste materials disposed in landfills and materials reused on the job, sold for salvage and recycled.

1.12 RADIO FREQUENCY MANAGEMENT PROCEDURES

The following procedures shall be followed in obtaining radio frequency authorization:

The policy and procedures contained in AFI 33-580 shall be followed to obtain frequency allocation approval of electronic devices and USAF Radio Frequency Assignment.

1.13 COMMUNICATION SECURITY

Government telecommunications networks are continually subject to interception by hostile/unfriendly intelligent organizations. Therefore, the DOD has authorized the military departments to conduct COMSEC monitoring and recording of telephone calls from, or terminating at, DOD organizations. Contractor shall assume the responsibility for ensuring frequent dissemination of this information to all employees dealing with official DOD information.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

3.1 ACCESS REQUIREMENTS

3.1.1 Construction Site Requirement

All on-site project work is confined to non-restricted areas. That is, no restricted area badge shall be necessary to accomplish the on-site work.

However, normal access requirements into PAFB must still be accomplished.

3.2 PAFB VEHICLE INSPECTION

The Oversized Vehicle Search Area is located on State Road A1A approximately 1 mile north of Pineda Causeway. Manned Operating hours are scheduled from 0600-1700. For after hours access, call PAFB Security Forces at (321) 494-2000 to co-ordinate entry. Mandatory inspection is required for all: Commercial Vehicles, Tractor Trailers, Trailers, RVs and Boats. All other passenger vehicles will be turned away from this gate and are required to enter at either the Main Gate or South Gate. Allow ample time for inspections, especially for the critical delivery period of mixed concrete. The government will not be responsible for rejected batches, caused by Contractor delays. Advance coordination is highly recommended.

SECTION 01 11 00.00 30 Page 11

3.3 PAFB DELIVERIES

3.3.1 Non-Hazardous Deliveries

All deliveries of construction material and equipment to job sites (including cement trucks) shall use the PAFB Oversized Vehicle Search Area (located on State Road A1A approximately 1 mile north of Pineda Causeway) for access. The operating hours for the Oversized Vehicle Search Area are 0600-1700. After hours access shall be through the South Gate. The driver of each delivery vehicle and their passengers must have the following:

a. A valid photo ID; and

b. A valid bill of lading; and

c. A known delivery point on PAFB; and

d. An on-base or local phone number and POC to vouch for delivery

Only deliveries that can be verified will be allowed to proceed. Special deliveries, deliveries after normal business hours, or deliveries that cannot negotiate through the barricades must be coordinated in advance.

All delivery vehicles shall be inspected by Security Forces personnel prior to being allowed to proceed onto the installation.

3.3.2 Hazardous Deliveries

Deliveries of fuel, large volume of chemicals, or other hazardous materials shall comply with this section. All hazardous deliveries shall enter through the same gates as non-hazardous delivers and have the information required for non-hazardous deliveries (see subpart entitled "Non-Hazardous Deliveries" of this section). Only deliveries that can be verified will be allowed to proceed. In addition, hazardous deliveries must be scheduled a minimum of 48 hours in advance for escort by Security Forces to and from job site. Contractors shall contact the PAFB Security Forces at 321-494-2000 to arrange for hazardous delivery escorts. Deliveries that have not arranged in advance for Security Forces escorts will be turned away and must be re-scheduled.

3.4 RESPONSIBILITIES

The Government reserves the right to revoke badging authority, escort authority and/or base access privileges for any person, at any time and for any reason. Contractor understands that the Government has made every attempt to identify potential delays associated with background checks and badging requirements and those delays have been considered in the construction schedule. Delays resulting from the Contractor's failure to follow the badging guidelines above shall not be considered grounds for contract extension or compensation.

3.5 EXCAVATION

3.5.1 Dig/Utility Locate Permit Requirements

Excavation shall be accomplished only after the Dig permit is received and utility locates accomplished and then with extreme caution to prevent damage to the existing buried utilities in the area. All open trenches must comply with OSHA regulations. All excavation must be further approved

SECTION 01 11 00.00 30 Page 12 by daily contact with Cape Support (321-853-5211).

3.5.1.1 Location of Buried Structures and Utility Lines

Accurately locate and paint structures and utility lines indicated by the Government provided Utility Locators on PAFB. If unidentified underground utilities are encountered during excavation, notify the Contracting Officer and cease operations until they are properly identified.

3.5.1.2 Excavation, Trenching, and Backfilling

Open only those trenches for which material is ready to be placed. As soon as approved by the Technical Representative, trenches shall be backfilled and tamped as required by the drawings and specifications. As a minimum, the topsoil shall be replaced and the disturbed area shall be grassed by seeding, watered and maintained for a minimum of 60 calendar days. All excavation shall be in compliance with OSHA regulations. Mark or barricade construction work which may present a hazard.

3.5.1.3 Cutting of Roads, Streets, Driveways, and Paved Areas

Repair roads, streets, and paved parking areas which require surface cutting under this project within 10 calendar days after initial cutting.

The topping shall be a minimum of 2 inches of asphalt and match existing (concrete topping on asphalt areas is not allowed). Mark, barricade, and illuminate construction work on or near roads or streets which may present a traffic hazard per OSHA 29 CFR 1910. Contractor shall provide signaling, lighting, and barricades in the construction area conforming to the Manual on Uniform Traffic Control Devices, OSHA 29 CFR 1926.201 and 1926.202.

Closures of Streets, parking lots, and other traffic areas will not be permitted unless approved by the Contracting Officer after written request 14 calendar days before the scheduled closure.

3.5.2 Restrictions

All excavation at the work site must be accomplished by hand only.

Excavating machinery is prohibited.

Hand digging is required within five feet of located underground utilities.

3.5.3 Temporary Shoring, Bracing And Supports

All new excavation and trenching work shall be securely and safely supported during installation with temporary, but substantial, shoring, bracing, hangers and other supports as required by OSHA regulations. After new work is completed and completely cured (if required) and all permanent fasteners, anchors and supports are properly installed, the temporary supports shall be removed.

3.5.4 Barricades

Guardrails, fences or other suitable barricades and warning lights shall be placed at all open excavations/trenches which are adjacent to paths, walkways, sidewalks, vehicle parking areas, and other pedestrian or vehicle thoroughfares. Coordinate with 45 CE Environmental prior to placing warning lights.

SECTION 01 11 00.00 30 Page 13

3.6 WELDER QUALIFICATION REQUIREMENTS

Before assigning any welder/brazer to work in pipe and/or structural fabrication on this project, names shall be provided to the Contracting Officer of all welders/solderers together with written certification that these welders/brazers have passed Qualification Tests as prescribed by AWS D1.1/D1.1M, AWS B2.1/B2.1M, and/or ASME BPVC SEC IX, as applicable.

All piping and/or structural welds shall be performed by persons holding current certifications. If testing is required, the test and certification shall be by an independent organization regularly engaged in the testing and certification of welders. Date of certification for each welder/brazer shall not be over one year prior to date of contract award.

3.7 QUALITY CONTROL

It is the Contractor's responsibility to provide, inspect and document the level of quality that has been established by all applicable standards, codes and guidelines. The Contractor shall use skilled workers, an adequate number of which are thoroughly trained and have a minimum of 3 years experience in the necessary crafts and who are completely familiar with the specified requirements and the methods needed for the proper performance of the work in each section of these specifications. Contractor shall submit Superintendent Contact and Qualifications to the Contracting Officer.

3.7.1 Licenses

Contractor or their subcontractors shall be licensed by the State of Florida or have an equivalent out-of-state license in all areas applicable to this contract or as otherwise stated elsewhere in this contract. Copies of licenses and certificates shall be provided to the Contracting Officer.

Asbestos Abatement Contractor shall be licensed by the State of Florida.

3.7.2 Government Inspection/Approval

When the Contractor considers that the work is acceptable to the Government and is complete, he/she shall inform the Contracting Officer, or designated representative, and the Government Project Manager that the work is complete and ready for inspections. In the event that the work is not acceptable, the Contractor shall record a list of items noted by the Government Project Manager, A subsequent inspection may take place in order to review the corrected items. The Government is not required to inspect all work.

3.7.3 Inspection Files

The Contractor shall be responsible for keeping inspection files for all projects. Files shall include on site records of all inspections conducted by the Contractor and the necessary corrective actions taken. Daily Reports shall be kept and made available to the Government throughout the contract performance period and for the period after completion until final settlement of any claims made under this contract.

3.8 SUPERINTENDENT

Provide name and qualifications and past experience for review. Designate a competent superintendent who shall have full authority to act for the Contractor and who shall be the primary contact with the Government until acceptance. Contractor's superintendent shall be at the job site at all times when work is taking place and shall have full authority to act for

SECTION 01 11 00.00 30 Page 14 the Contractor.

3.9 CONSTRUCTION SCHEDULING REQUIREMENTS

3.9.1 Contractor Coordination Meetings

Contractor shall attend weekly project meetings, not to exceed 3 hours, scheduled by the Government. Subcontractor representatives shall attend as required.

Discussion shall address the progress schedule, potential factors of delay, deficiencies, material delivery schedules, submittals, and safety issues.

3.9.2 On-Site Construction Sequence

The required work shall be performed in a sequence to minimize the time when fire alarm systems, panelboards, transformers, power supply, etc. are inoperative or out-of-service. Remove a single item of equipment, install the new replacement item, tie in required utilities, test, and restore the new item of equipment to fully operational status before removing subsequent equipment.

-- End of Section --

SECTION 01 11 00.00 30 Page 15

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 33 00

SUBMITTAL PROCEDURES

05/11

PART 1 GENERAL

1.1 DEFINITIONS

1.1.1 Submittal Descriptions (SD)

1.1.2 Approving Authority

1.1.3 Work

1.2 SUBMITTALS

1.3 SUBMITTAL CLASSIFICATION

1.3.1 Government Approved (G)

1.4 PREPARATION

1.4.1 Transmittal Form

1.4.2 Source Drawings for Shop Drawings

1.4.2.1 Terms and Conditions

1.5 QUANTITY OF SUBMITTALS

1.5.1 Number of Copies of SD-02 Shop Drawings

1.5.2 Number of Copies of SD-03 Product Data and SD-08

Manufacturer's Instructions

1.5.3 Number of Samples SD-04 Samples

1.5.4 Number of Copies SD-06 Test Reports and SD-09 Manufacturer's

Field Reports

1.5.5 Number of Copies of SD-10 Operation and Maintenance Data

1.5.6 Number of Copies of SD-01 Preconstruction Submittals and SD-11

Closeout Submittals

1.6 SUBMITTAL REGISTER

1.6.1 Use of Submittal Register

1.6.2 Contractor Use of Submittal Register

1.6.3 Approving Authority Use of Submittal Register

1.6.4 Copies Delivered to the Government

1.7 SCHEDULING

1.8 GOVERNMENT APPROVING AUTHORITY

1.8.1 Review Notations

1.9 DISAPPROVED SUBMITTALS

1.10 APPROVED SUBMITTALS

1.11 APPROVED SAMPLES

1.12 PROGRESS SCHEDULE

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

SECTION 01 33 00 Page 1

SECTION 01 33 00

SUBMITTAL PROCEDURES

05/11

PART 1 GENERAL

1.1 DEFINITIONS

1.1.1 Submittal Descriptions (SD)

Submittals requirements are specified in the technical sections.

Submittals are identified by Submittal Description (SD) numbers and titles as follows:

SD-01 Preconstruction Submittals

Submittals which are required prior to start of construction work.

Certificates of insurance

Surety bonds

List of proposed Subcontractors

List of proposed products

Construction progress schedule

Network Analysis Schedule (NAS)

Submittal register

Schedule of prices or Earned Value Report

Health and safety plan

Work plan

Quality Control(QC) plan

Environmental protection plan

SD-03 Product Data

Catalog cuts, illustrations, schedules, diagrams, performance charts, instructions and brochures illustrating size, physical appearance and other characteristics of materials, systems or equipment for some portion of the work.

Samples of warranty language when the contract requires extended product warranties.

SD-06 Test Reports

Report signed by authorized official of testing laboratory that a material, product or system identical to the material, product or

SECTION 01 33 00 Page 2 system to be provided has been tested in accord with specified requirements. Unless specified in another section, testing must have been within three years of date of contract award for the project.

Report which includes findings of a test required to be performed by the Contractor on an actual portion of the work or prototype prepared for the project before shipment to job site.

Report which includes finding of a test made at the job site or on sample taken from the job site, on portion of work during or after installation.

Investigation reports.

Daily logs and checklists.

Final acceptance test and operational test procedure.

SD-07 Certificates

Statements printed on the manufacturer's letterhead and signed by responsible officials of manufacturer of product, system or material attesting that the product, system, or material meets specification requirements. Must be dated after award of project contract and clearly name the project.

Document required of Contractor, or of a manufacturer, supplier, installer or Subcontractor through Contractor. The document purpose is to further promote the orderly progression of a portion of the work by documenting procedures, acceptability of methods, or personnel qualifications.

Confined space entry permits.

Text of posted operating instructions.

SD-08 Manufacturer's Instructions

Preprinted material describing installation of a product, system or material, including special notices and (SDS) concerning impedances, hazards and safety precautions.

SD-10 Operation and Maintenance Data

Data that is furnished by the manufacturer, or the system provider, to the equipment operating and maintenance personnel, including manufacturer's help and product line documentation necessary to maintain and install equipment. This data is needed by operating and maintenance personnel for the safe and efficient operation, maintenance and repair of the item.

This data is intended to be incorporated in an operations and maintenance manual or control system.

SD-11 Closeout Submittals

Documentation to record compliance with technical or administrative requirements or to establish an administrative mechanism.

SECTION 01 33 00 Page 3

Submittals required for Guiding Principle Validation (GPV) or Third Party Certification (TPC).

Special requirements necessary to properly close out a construction contract. For example, Record Drawings and as-built drawings. Also, submittal requirements necessary to properly close out a major phase of construction on a multi-phase contract.

1.1.2 Approving Authority

Office or designated person authorized to approve submittal.

1.1.3 Work

As used in this section, on- and off-site construction required by contract documents, including labor necessary to produce submittals, construction, materials, products, equipment, and systems incorporated or to be incorporated in such construction.

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor QC approval.

Submit the following in accordance with this section.

SD-01 Preconstruction Submittals

Submittal Register; G

1.3 SUBMITTAL CLASSIFICATION

Submittals are classified as follows:

1.3.1 Government Approved (G)

Government approval is required for extensions of design, critical materials, deviations, equipment whose compatibility with the entire system must be checked, and other items as designated by the Contracting Officer.

Within the terms of the Contract Clause SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION, they are considered to be "shop drawings."

1.4 PREPARATION

1.4.1 Transmittal Form

Transmit each submittal, except sample installation and sample panels to office of Contracting Officer.

1.4.2 Source Drawings for Shop Drawings

The entire set of Source Drawing files (DWG) will not be provided to the Contractor. Only those requested by the Contractor to prepare shop drawings may be provided. Request the specific Drawing Number only for the preparation of Shop Drawings. These drawings may only be provided after award.

1.4.2.1 Terms and Conditions

Data contained on these electronic files must not be used for any purpose

SECTION 01 33 00 Page 4 other than as a convenience in the preparation of construction data for the referenced project. Any other use or reuse shall be at the sole risk of the Contractor and without liability or legal exposure to the Government.

The Contractor must make no claim and waives to the fullest extent permitted by law, any claim or cause of action of any nature against the Government, its agents or sub consultants that may arise out of or in connection with the use of these electronic files. The Contractor must, to the fullest extent permitted by law, indemnify and hold the Government harmless against all damages, liabilities or costs, including reasonable attorney's fees and defense costs, arising out of or resulting from the use of these electronic files.

These electronic Source Drawing files are not construction documents.

Differences may exist between the Source Drawing files and the corresponding construction documents. The Government makes no representation regarding the accuracy or completeness of the electronic Source Drawing files, nor does it make representation to the compatibility of these files with the Contractor hardware or software. In the event that a conflict arises between the signed and sealed construction documents prepared by the Government and the furnished Source Drawing files, the signed and sealed construction documents govern. The Contractor is responsible for determining if any conflict exists. Use of these Source Drawing files does not relieve the Contractor of duty to fully comply with the contract documents, including and without limitation, the need to check, confirm and coordinate the work of all contractors for the project.

If the Contractor uses, duplicates or modifies these electronic Source Drawing files for use in producing construction data related to this contract, remove all previous indicia of ownership (seals, logos, signatures, initials and dates).

1.5 QUANTITY OF SUBMITTALS

1.5.1 Number of Copies of SD-02 Shop Drawings

Submit six copies of submittals of shop drawings requiring review and approval by Contracting Officer.

1.5.2 Number of Copies of SD-03 Product Data and SD-08 Manufacturer's Instructions

Submit in compliance with quantity requirements specified for shop drawings.

1.5.3 Number of Samples SD-04 Samples

a. Submit two samples, or two sets of samples showing range of variation, of each required item. One approved sample or set of samples will be retained by approving authority and one will be returned to Contractor.

1.5.4 Number of Copies SD-06 Test Reports and SD-09 Manufacturer's Field Reports

Submit in compliance with quantity and quality requirements specified for shop drawings other than field test results that will be submitted with QC reports.

1.5.5 Number of Copies of SD-10 Operation and Maintenance Data

Submit five copies of O&M Data to the Contracting Officer for review and approval.

SECTION 01 33 00 Page 5

1.5.6 Number of Copies of SD-01 Preconstruction Submittals and SD-11 Closeout Submittals

Unless otherwise specified, submit two sets of administrative submittals.

1.6 SUBMITTAL REGISTER

Prepare and maintain submittal register, as the work progresses. Do not change data which is output in columns (c), (d), (e), and (f) as delivered by Government; retain data which is output in columns (a), (g), (h), and

(i) as approved. A submittal register showing items of equipment and materials for which submittals are required by the specifications is provided as an attachment. This list may not be all inclusive and additional submittals may be required.

Column (c): Lists specification section in which submittal is required.

Column (d): Lists each submittal description (SD No. and type, e.g. SD-02 Shop Drawings) required in each specification section.

Column (e): Lists one principal paragraph in specification section where a material or product is specified. This listing is only to facilitate locating submitted requirements. Do not consider entries in column (e) as limiting project requirements.

1.6.1 Use of Submittal Register

Submit submittal register. Submit with QC plan and project schedule.

Verify that all submittals required for project are listed and add missing submittals. Coordinate and complete the following fields on the register submitted with the QC plan and the project schedule:

Column (a) Activity Number: Activity number from the project schedule.

Column (g) Contractor Submit Date: Scheduled date for approving authority to receive submittals.

Column (h) Contractor Approval Date: Date Contractor needs approval of submittal.

Column (i) Contractor Material: Date that Contractor needs material delivered to Contractor control.

1.6.2 Contractor Use of Submittal Register

Update the following fields throughout contract.

Column (b) Transmittal Number: Contractor assigned list of consecutive numbers.

Column (j) Action Code (k): Date of action used to record Contractor's review when forwarding submittals to QC.

Column (l) List date of submittal transmission.

Column (q) List date approval received.

SECTION 01 33 00 Page 6

1.6.3 Approving Authority Use of Submittal Register

Update the following fields.

Column (b) Transmittal Number: Contractor assigned list of consecutive numbers.

Column (l) List date of submittal receipt.

Column (m) through (p) List Date related to review actions.

Column (q) List date returned to Contractor.

1.6.4 Copies Delivered to the Government

Deliver one copy of submittal register updated by Contractor to Government with each invoice request.

1.7 SCHEDULING

Schedule and submit concurrently submittals covering component items forming a system or items that are interrelated. Include certifications to be submitted with the pertinent drawings at the same time. No delay damages or time extensions will be allowed for time lost in late submittals.

a. Coordinate scheduling, sequencing, preparing and processing of submittals with performance of work so that work will not be delayed by submittal processing. Allow for potential resubmittal of requirements.

b. Submittals called for by the contract documents will be listed on the register. If a submittal is called for but does not pertain to the contract work, the Contractor is to include the submittal in the register and annotate it "N/A" with a brief explanation. Approval by the Contracting Officer does not relieve the Contractor of supplying submittals required by the contract documents but which have been omitted from the register or marked "N/A."

c. Re-submit register and annotate monthly by the Contractor with actual submission and approval dates. When all items on the register have been fully approved, no further re-submittal is required.

d. Carefully control procurement operations to ensure that each individual submittal is made on or before the Contractor scheduled submittal date shown on the approved "Submittal Register."

1.8 GOVERNMENT APPROVING AUTHORITY

When approving authority is Contracting Officer, the Government will:

a. Note date on which submittal was received.

b. Review submittals for approval within scheduling period specified and only for conformance with project design concepts and compliance with contract documents.

c. Identify returned submittals with one of the actions defined in paragraph REVIEW NOTATIONS and with markings appropriate for action indicated.

SECTION 01 33 00 Page 7

Upon completion of review of submittals requiring Government approval, stamp and date submittals.

1.8.1 Review Notations

Submittals will be returned to the Contractor with the following notations:

a. Submittals marked "approved" or "accepted" authorize the Contractor to proceed with the work covered.

b. Submittals marked "approved as noted" or "approved, except as noted, resubmittal not required," authorize the Contractor to proceed with the work covered provided he takes no exception to the corrections.

c. Submittals marked "not approved" or "disapproved," or "revise and resubmit," indicate noncompliance with the contract requirements or design concept, or that submittal is incomplete. Resubmit with appropriate changes. No work shall proceed for this item until resubmittal is approved.

d. Submittals marked "not reviewed" will indicate submittal has been previously reviewed and approved, is not required, does not have evidence of being reviewed and approved by Contractor, or is not complete. A submittal marked "not reviewed" will be returned with an explanation of the reason it is not reviewed. Resubmit submittals returned for lack of review by Contractor or for being incomplete, with appropriate action, coordination, or change.

1.9 DISAPPROVED SUBMITTALS

Contractor shall make corrections required by the Contracting Officer. If the Contractor considers any correction or notation on the returned submittals to constitute a change to the contract drawings or specifications; notice as required under the Contract clause entitled CHANGES, is to be given to the Contracting Officer. Contractor is responsible for the dimensions and design of connection details and construction of work. Failure to point out deviations may result in the Government requiring rejection and removal of such work at the Contractor's expense.

If changes are necessary to submittals, make such revisions and submission of the submittals in accordance with the procedures above.