RFQ_EA-133M-18-RQ-01428.pdf

Page - 1

Emergency Dry Dock for Z-Drive Repairs for the

NOAA Ship NANCY FOSTER

NOTICE DATE: 05/01/2018 NOTICE TYPE: REQUEST FOR QUOTATION (RFQ)

NAICS: 336611 – Shipbuilding and Repair

Contracting Office:

Department of Commerce, National Oceanic and Atmospheric Administration (NOAA), Eastern Region Acquisition Division, 200 Granby Street, Suite 815, Norfolk, VA 23510

Solicitation Number

EA-133M-18-RQ-01428

Response Due May 4, 2018, No Later Than 12:00 pm, EST

Period of Performance

Tentative period of performance May 7, 2018 through May 13, 2018.

Start date shall be no earlier than May 5, 2018 and no later than May 11, 2018, based on ship’s schedule and dry dock availability.

This RFQ is for full and open competition. This is a combined synopsis/solicitation for commercial items prepared in accordance with the format at FAR Subpart 12.6, as supplemented with additional information included in this notice, and is being conducted pursuant to FAR Part 12 and Subpart 13.5. This announcement constitutes the only solicitation. This RFQ incorporates provisions and clauses in effect through Federal Acquisition Circular No. 2005-96 dated 11/06/2017. At time of issue, this order will be a firm fixed-price purchase order for services in the form of a written offer to the contractor and shall require the contractor’s acceptance by notification to the Government, in writing, as defined at FAR 2.101.

The National Oceanic and Atmospheric Administration (NOAA), Eastern Region Acquisition Division, 200 Granby Street, Norfolk, Virginia 23510, on behalf of the Office of Marine and Aviation Operations (OMAO) is soliciting quotes for Emergency Dry Dock for Z-Drive Repairs on the NOAA Ship NANCY FOSTER. The contractor is responsible for providing all supervision, labor, services, and materials in accordance with the specifications and additional references attached with this announcement.

NOTE: Due to the ship’s current location, there will NOT be a vessel site visit. Only dry dock facilities on the Gulf Coast will be considered for award.

Page - 2

Pricing

Provide pricing for the following contract line item numbers (CLINs):

CLIN Work Item Unit Price 0001 DRY DOCK for Z-DRIVE REPAIRS as detailed in the attached Specifications

JB __________

ADDITIONAL ITEM REQUIREMENTS (AIRs): These items relate to Growth Work. The Unit Price column will be used throughout the life of the contract if growth work is added to the scope of the contract [reference Commerce Acquisition Regulation (CAR) clause 1352.271-72]. If AIRs are issued, these items will be awarded at the quantities needed via a contract modification. The quantity shown is an estimate only and may be exceeded at the unit prices offered.

0002 AIRS/Growth (estimated)

**Provide breakdown, as follows:

AIRs/Growth Labor Rate Unit Price: $_____; Quantity: 305 ; Unit of Issue:

Hour; Extended Price: $______

AIRs/Growth Material Markup/Handling Fee Unit Price: $10,000; Quantity: 1; Unit of Issue:

Percent _____%;

Extended Price: [$10,000.00 X percentage]

LT

LT

Total Price:

Attachments:

Specifications: Z-Drive Repairs, Item No. 12351

References:

a. Item No. 1101 General Requirements

b. Item No. 10021 Emergency Dry Docking Basic Spec Requirements

c. AMC-000-1F General Requirements for Ship Repair

d. AMC-000-2C Temporary Services at Contractor Facilities

e. MOC-300-3 General Requirements for Electrical/Electronic Items

f. MOC-631-2D Coating Systems for Steel Surfaces

g. AMC-997-1A Drydocking and Routine Drydock Work

h. Technical Manual for Z-Drive, Model 260/370-H

i. NF-505-6501097 Standard Piping Details

j. NF085001 Drawing

k. NF085002_F, Docking Plan

Page - 3

Federal Acquisition Regulation (FAR), and Commerce Acquisition Regulation (CAR) provisions and clauses that are included in this solicitation are denoted by the applicable acronyms.

FAR CONTRACT CLAUSES

(1) 52.212-5 CONTRACT TERMS AND CONDITINOS REQUIRED TO IMPLEMENT

STATUES OR EXECUTIVE ORDERS—COMMERCIAL ITEMS (JAN 2017)

Contract Terms and Conditions Required To Implement Statutes or Executive Orders—Commercial Items (Nov 2017) ((a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015)

(3) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(4) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77, 108- 78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.] XX (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009).

X (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-282) (31 U.S.C. 6101 note).

___ (5) [Reserved] ___ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

___ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

XX (8) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note).

XX (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313).

___ (10) [Reserved] ___ (11) (i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C.

657a).

___ (ii) Alternate I (Nov 2011) of 52.219-3.

___ (12) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C.

657a).

___ (ii) Alternate I (Jan 2011) of 52.219-4.

https://www.acquisition.gov/far/html/52_200_206.html#wp1141649 http://uscode.house.gov/ https://www.acquisition.gov/far/html/52_207_211.html#wp1140926 https://www.acquisition.gov/far/html/52_207_211.html#wp1145644

Page - 4

___ (13) [Reserved] ___ (14) (i) 52.219-6, Notice of Total Small Business Aside (Nov 2011) (15 U.S.C. 644).

___ (ii) Alternate I (Nov 2011).

___ (iii) Alternate II (Nov 2011).

___ (15) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).

___ (ii) Alternate I (Oct 1995) of 52.219-7.

___ (iii) Alternate II (Mar 2004) of 52.219-7.

___ (16) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)).

___ (17) (i) 52.219-9, Small Business Subcontracting Plan (Jan 2017) (15 U.S.C. 637 (d)(4)).

___ (ii) Alternate I (Nov 2016) of 52.219-9.

___ (iii) Alternate II (Nov 2016) of 52.219-9.

___ (iv) Alternate III (Nov 2016) of 52.219-9.

___ (v) Alternate IV (Nov 2016) of 52.219-9.

___ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)).

___ (19) 52.219-14, Limitations on Subcontracting (Jan 2017) (15 U.S.C. 637(a)(14)).

___ (20) 52.219-16, Liquidated Damages—Subcontracting Plan (Jan 1999) (15 U.S.C.

637(d)(4)(F)(i)).

___ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657f).

XX(22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C.

632(a)(2)).

___ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)).

___ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)).

XX (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

XX (26) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126).

XX (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

XX (28) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246).

XX (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015)(38 U.S.C. 4212).

XX (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

XX (31) 52.222-37, Employment Reports on Veterans (FEB 2016) (38 U.S.C. 4212).

XX (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

XX(33)(i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627).

(ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

XX (34) 52.222-54, Employment Eligibility Verification (OCT 2015). (Executive Order 12989).

(Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

___ (35) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

___ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

___ (36) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O.13693).

https://www.acquisition.gov/far/html/52_217_221.html#wp1139913 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/far/html/52_222.html#wp1147479 https://www.acquisition.gov/far/html/52_222.html#wp1147630 https://www.acquisition.gov/far/html/52_222.html#wp1147656 https://www.acquisition.gov/far/html/52_222.html#wp1147711 https://www.acquisition.gov/far/html/52_222.html#wp1158632 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/far/html/52_222.html#wp1162802 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t29t32+2+78++%2829%29%20%20AND%20%28%2829%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/far/html/52_222.html#wp1148123 https://www.acquisition.gov/far/html/52_222.html#wp1160019 https://www.acquisition.gov/far/html/52_222.html#wp1151848 http://uscode.house.gov/ https://www.acquisition.gov/far/html/52_222.html#wp1151848 http://uscode.house.gov/ https://www.acquisition.gov/far/html/52_222.html#wp1156645 https://www.acquisition.gov/far/html/Subpart%2022_18.html#wp1089948

Page - 5

___ (37) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693).

___ (38) (i) 52.223-13, Acquisition of EPEAT® -Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514 ___ (ii) Alternate I (Oct 2015) of 52.223-13.

___ (39) (i) 52.223-14, Acquisition of EPEAT® -Registered Television (Jun 2014) (E.O.s 13423 and 13514).

___ (ii) Alternate I (Jun 2014) of 52.223-14.

___ (40) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C.

8259b).

___ (41) (i) 52.223-16, Acquisition of EPEAT® -Registered Personal Computer Products (Oct 2015) (E.O.s 13423 and 13514).

___ (ii) Alternate I (Jun 2014) of 52.223-16.

XX (42) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving (Aug 2011) (E.O. 13513).

___ (43) 52.223-20, Aerosols (Jun 2016) (E.O. 13693).

___ (44) 52.223-21, Foams (Jun 2016) (E.O. 13696).

___ (45) (i) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

___ (ii) Alternate I (Jan 2017) of 52.224-3.

___ (46) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83).

___ (47) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112- 41, 112-42, and 112-43).

___ (ii) Alternate I (May 2014) of 52.225-3.

___ (iii) Alternate II (May 2014) of 52.225-3.

___ (iv) Alternate III (May 2014) of 52.225-3.

___ (48) 52.225-5, Trade Agreements (Oct 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

XX (49) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

___ (50) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

___ (51) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

___ (52) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).

___ (53) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C.

4505), 10 U.S.C. 2307(f)).

___ (54) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

XX (55) 52.232-33, Payment by Electronic Funds Transfer— System for Award Management (Jul 2013) (31 U.S.C. 3332).

___ (56) 52.232-34, Payment by Electronic Funds Transfer—Other Than System for Award Management (Jul 2013) (31 U.S.C. 3332).

___ (57) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

___ (58) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

___ (59) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C. 637(d)(12)).

___ (60) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631).

Page - 6

___ (ii) Alternate I (Apr 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.] ___ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495) ___ (2) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67.).

___ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

___ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (Multiple Year and Option Contracts) (May 2014) (29 U.S.C.206 and 41 U.S.C. chapter 67).

___ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

___ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67).

___ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67).

___ (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (E.O. 13658).

___ (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

___ (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792).

___ (11) 52.237-11, Accepting and Dispensing of $1 Coin (Sep 2008) (31 U.S.C. 5112(p)(1)).

(d) Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records -- Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e)

(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c) and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause—

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

Page - 7

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(iv) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in accordance with paragraph (1) of FAR clause 52.222-17.

(v) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(vi) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246).

(vii) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

(viii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

(ix) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212).

(x) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xi) 52.222-41, Service Contract Labor Standards (May 2014), (41 U.S.C. chapter 67).

(xii) (A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O.

13627).

(B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 E.O. 13627).

(xiii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C.

chapter 67.)

(xiv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67)

(xv) 52.222-54, Employment Eligibility Verification (Oct 2015) (E. O. 12989).

(xvi) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015).

(xvii) 52.222-62, Paid sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

(xviii) (A) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

(B) Alternate I (Jan 2017) of 52.224-3.

(xix) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xx) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C.

1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxi) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

(End of Clause)

(2) FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (Feb 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available.

Also, the full text of a clause may be accessed electronically at this/these address:

http://farsite.hill.af.mil/

(End of clause) http://farsite.hill.af.mil/

Page - 8

(3) FAR 52.211-11 LIQUIDATED DAMAGES--SUPPLIES, SERVICES, OR RESEARCH

AND DEVELOPMENT (SEP 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $9,019.59 per calendar day of delay.

(b) If the Government terminates this contract in whole or in part under the Default-Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract.

(End of clause)

FAR CLAUSES BY REFERENCE

(1) FAR 52.203-3 GRATUITIES (APR 1984)

(2) FAR 52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND

REQUIREMENT TO INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS.

(3) FAR 52.204-13, SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (OCT 2016)

(4) FAR 52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND

CERTIFICATIONS (DEC 2014)

(5) FAR 52.212-4 CONTRACT TERMS AND CONDITIONS – COMMERCIAL ITEMS (JAN

2017)

(6) FAR 52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUN 2013)

(7) FAR 52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS

SUBCONTRACTORS (DEC 2013)

(8) FAR 52.233-3 PROTEST AFTER AWARD (AUG 1996)

(9) FAR 52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

(10) FAR 52.244-6 SUBCONTRACTS FOR COMMERCIAL ITEMS (NOV 2017)

(11) FAR 52.245-1 GOVERNMENT PROPERTY (JAN 2017)

(12) FAR 52.245-9 USE AND CHARGES (APR 2012)

(13) FAR 52.246.-2 INSPECTION OF SUPPLIES—FIXED-PRICE (AUG 1996)

(14) FAR 52.246-16 RESPONSIBILITY FOR SUPPLIES (APR 1984)

(15) FAR 52.247-34 F.O.B. DESTINATION (NOV 1991)

Page - 9

CAR CONTRACT CLAUSES

(1) CAR 1352.201-72 CONTRACTING OFFICER'S REPRESENTATIVE (COR) (APR 2010)

(a) Mr. Jamie LeCompte is hereby designated as the Contracting Officer's Representative (COR). The COR may be changed at any time by the Government without prior notice to the contractor by a unilateral modification to the contract. The COR is located at:

NOAA Ship Nancy Foster Attn: Jamie LeCompte Charleston Marine Support Facility 1050 Register Street Charleston, SC 29405 Phone Number: (843) 566-9191 jamie.a.lecompte@noaa.gov

(b) The responsibilities and limitations of the COR are as follows:

(1) The COR is responsible for the technical aspects of the contract and serves as technical liaison with the contractor. The COR is also responsible for the final inspection and acceptance of all deliverables and such other responsibilities as may be specified in the contract.

(2) The COR is not authorized to make any commitments or otherwise obligate the Government or authorize any changes which affect the contract price, terms or conditions. Any contractor request for changes shall be referred to the Contracting Officer directly or through the COR. No such changes shall be made without the express written prior authorization of the Contracting Officer. The Contracting Officer may designate assistant or alternate COR(s) to act for the COR by naming such assistant/alternate(s) in writing and transmitting a copy of such designation to the contractor.

(End of clause)

(2) CAR 1352.246-70 PLACE OF ACCEPTANCE (APR 2010)

The contractor’s facility.

(End of clause)

(3) CAR 1352.270-70 PERIOD OF PERFORMANCE (APR 2010)

The period of performance for this contract shall May 7, 2018 through May 13, 2018.

(4) 1352.271-71 METHOD OF PAYMENT AND INVOICING INSTRUCTIONS FOR SHIP

REPAIR (APR 2010)

(a) The Government will make payment under this contract based on a percentage of completion.

The contractor may invoice for the percentage completed for each work item as work progresses. The amount invoiced shall be calculated based on prices stated in the Schedule, as follows: A work item may not be invoiced until the percentage complete reaches 25 percent. Future invoices for that work item have no limitation as to the percentage of completion required before invoicing, but in no event may invoices be submitted more frequently than every 2 weeks, or for amounts less than $10,000, mailto:jamie.a.lecompte@noaa.gov

Page - 10 unless it is the final payment. The minimum percentage of completion (25%) to be reached prior to billing each work item may be waived by the Contracting Officer for large dollar work items on a case-by-case basis.

(b) Invoices submitted by the contractor which are deemed not proper, in accordance with FAR 52.232–25, will be returned. Invoices shall include:

(1) Name and Address of the contractor;

(2) DUNS Number;

(3) Invoice Date;

(4) Contract Number/Modification Number;

(5) CLIN/Work Item Number, to include: Description, Quantity, Unit of Measure, Unit Price and Extended Price;

(6) Shipping and Payment Terms; and,

(7) Contractor Point of Contact, including: Name, Title, Phone Number, and Mailing Address;

(8) The percentage of completion for each CLIN/work item identified;

(9) Name of the Contracting Officer ;

(10) Ship name;

(11) The overall percentage and dollar amount previously billed, currently billed and unbilled.

(c) When invoicing for changed work, the contractor shall identify it as a contract change and shall identify the modification authorizing the change, and the CLIN/Work Item associated with the change.

(d) All items of work invoiced under this contract will be verified and confirmed by the Contracting Officer's Representative as accurate and complete and approved by the designated billing office before payment will be made.

(e) Mail the original invoice to both:

1. NOAA Ship Nancy Foster Charleston Marine Support Facility 1050 Register Street Charleston, SC 29405 Attn: Jamie LeCompte Phone Number: (843) 566-9191 jamie.a.lecompte@noaa.gov

2. NOAA Acquisitions Division Attn: Alexander Cooper 200 Granby Street, Suite 815 Norfolk, VA 23510 Alexander.cooper@noaa.gov

Attn: Kenyon Zitzka Kenyon.zitzka@noaa.gov Phone Number: (757) 619-0744

(f) The contractor's final invoice submitted under the contract must be marked as follows: “THIS

INVOICE CONSTITUTES THE FINAL INVOICE—UPON PAYMENT OF THIS INVOICE NO

OTHER MONIES ARE DUE UNDER CONTRACT NUMBER ________.” (To be assigned at contract award)

(5) CAR 1352.271-75 DELIVERY AND SHIFTING OF THE VESSEL (APR 2010)

mailto:jamie.a.lecompte@noaa.gov mailto:Alexander.cooper@noaa.gov mailto:Kenyon.zitzka@noaa.gov

Page - 11

(a) The Government shall deliver the vessel to the contractor, at the location specified in the contract.

(b) Whether the specified location of performance is the contractor's own facility or any other authorized facility, it shall be understood to mean the fairway of the facility. The contractor shall provide necessary tugs and pilot services to move the vessel from the fairway to the pier or dock, and, upon completion of all work, from the pier or dock to the fairway of the facility.

(c) While the vessel is in the possession of the contractor, any necessary movement of the vessel incidental to the work specified in the contract shall be furnished by the contractor without additional charge to the Government.

(6) CAR 1352.271-88 GUARANTEES (APR 2010)

(a) In the event any work performed or materials furnished by the contractor under this contract prove defective or deficient within 90 days from the date of redelivery of the vessel, the contractor, as directed by the Contracting Officer and at its own expense, shall correct and repair the deficiency to the satisfaction of the Contracting Officer.

(b) The Government shall be entitled to rely upon any guarantee secured by the contractor or any sub-contractor covering work done or materials furnished which exceeds the 90 day period until its expiration.

(c) With respect to any individual work item identified and listed as incomplete at the redelivery of the vessel, the guarantee period shall run from the date of completion of such item.

(d) If and when practicable, the Government shall afford the contractor an opportunity to effect such corrections and repairs.

(1) If the Contracting Officer determines it is impracticable or is otherwise not advisable to return the vessel to the contractor, or the contractor fails to proceed promptly with any such repairs as directed by the Contracting Officer, the Contracting Officer may direct that the repairs be performed elsewhere, at the contractor's expense.

(2) Where corrections and repairs are to be made by other than the contractor due to nonreturn of the vessel to the contractor, the contractor's liability may be discharged by an equitable deduction in the price of the contract.

(e) The contractor's liability shall only extend for an additional 90 day guarantee period on those defects or deficiencies which it corrected. However, this clause does not limit the responsibility or relieve the liability of the contractor under the Liability and Insurance clause.

(f) At the Contracting Officer's option, defects and deficiencies may be left in their uncorrected condition. In that event, the contractor and the Contracting Officer shall agree on an equitable deduction in the contract price. Failure to agree upon an equitable reduction shall constitute a dispute under the Disputes clause of this contract.

Page - 12

(g) The rights and remedies of the Government provided in this clause are in addition to and do not limit any rights afforded to the Government by any other clause of the contract. If a defect or deficiency that exists at the time of redelivery of the vessel was not discovered by a reasonable inspection and is discovered after the expiration of the time frame stated in this clause, it is not subject to the time limitations stated in this clause.

(End of clause)

(7) CAR 1352.271-90 INSURANCE REQUIREMENTS (APR 2010)

(a) The contractor shall procure and thereafter maintain the following insurance:

(1) Ship contractor's legal liability insurance to insure the risks described in paragraph (b) of clause 1352.271–79. This insurance shall be for $1,000,000.00.

(2) Comprehensive general liability insurance and automobile insurance to insure the risks described in paragraph (c) of clause 1352.271–79. This insurance shall be for $1,000,000.00 on account of any one accident or occurrence with respect to each vessel, boat, and/or barge upon which work is performed. The contractor shall cause the Government to be named as an additional insured under any and all liability insurance policies.

(3) Full coverage in accordance with the State Worker's Compensation law; and

(4) Full coverage in accordance with the United States Longshoremen's and Harbor Worker's Act.

(b) As evidence that it has obtained the insurance specified in paragraph (a) of this clause, the contractor shall furnish the Contracting Officer with a certificate or certificates executed by an agent of the insurer authorized to execute such certificates. Such certificates shall be furnished prior to commencement of the work. Each certificate shall state that (name of insurer) has insured (name of contractor) awarded contract number ______ for repair/alteration of the NOAA Ship Nancy Foster in accordance with the Liability and Insurance clause and the Insurance Requirements clause contained herein. Each certificate shall set forth that each policy of insurance represented thereby will expire on (APR 2010) and that each such policy contains the following clause:

“It is agreed that in the event of cancellation or any material change in the policy adversely affecting the interest of the Government in this insurance, 30 days prior written notice will be given to the Contracting Officer.”

(End of clause)

CAR CLAUSES BY REFERENCE

(1) CAR 1352.201-70 CONTRACTING OFFICER'S AUTHORITY (APR 2010)

(2) CAR 1352.209-73 COMPLIANCE WITH THE LAWS (APR 2010)

(3) CAR 1352.209-74 ORGANIZATIONAL CONFLICT OF INTEREST (APR 2010)

(4) CAR 1352.271-70 INSPECTION AND MANNER OF DOING WORK (APR 2010)

(5) CAR 1352.271-72 ADDITIONAL ITEM REQUIREMENTS (AIR)—GROWTH WORK (APR

2010)

(6) CAR 1352.271-73 SCHEDULE OF WORK (APR 2010)

(7) CAR 1252.271-76 PERFORMANCE (APR 2010)

Page - 13

(8) CAR 1352.271-77 DELAYS (APR 2010)

(9) CAR 1352.271-78 MINIMIZATION OF DELAY DUE TO GOVERNMENT FURNISHED

PROPERTY (APR 2010)

(10) CAR 1352.271-79 LIABILITY AND INSURANCE (APR 2010)

(11) CAR 1352.271-80 TITLE (APR 2010)

(12) CAR 1352.271.81 DISCHARGE OF LEINS (APR 2010)

(13) CAR 1352.271.83 GOVERNMENT REVIEW, COMMENT, ACCEPTANCE AND

APPROVAL (APR 2010)

(14) CAR 1352.271.84 ACCESS TO THE VESSEL (APR 2010)

(15) CAR 1352.271.85 DOCUMENTATION FOR REQUESTS OF EQUITABLE ADJUSTMENT

(APR 2010)

(16) CAR 1352.271.86 LAY DAYS (APR 2010)

(17) CAR 1352.271.87 CHANGES – SHIP REPAIR (APR 2010)

(18) CAR 1352.271.89 TEMPRORARY SERVICES (APR 2010)

NOAA Acquisition Manual (NAM) Clauses

(1) NAM 1330-52.242.70 SUBMITTAL OF INVOICES

The Contractor shall prepare and submit an invoice to the COR for approval [with a copy to the contracting officer for information]. All invoices shall be submitted by the 10th day of the subsequent month.

To constitute a proper invoice, the contractor’s invoice shall be prepared in accordance with, and contain all elements specified in, the paragraph titled, “Contractor’s Invoice,” of the applicable prompt payment provision of the contract (e.g., FAR 52.232-25, Prompt Payment; FAR 52.232-26, Prompt Payment for Fixed-Price Architect Engineer Contracts; or FAR 52.232-27, Prompt Payment for Construction Contracts). For contracts and orders for commercial items and services, paragraph

(g) of FAR 52.212-4, titled, “Invoices,” applies.

If the invoice does not comply with the applicable prompt payment provision of the contract, the COR will return it to the contractor within seven days after the date the designated office received the invoice along with a statement as to the reasons why it is not a proper invoice.

(2) NAM 1330-52.270-304 NOAA ACQUISITION AND GRANTS OFFICE OMBUDSMAN

a. The NOAA Acquisition and Grants Office (AGO) Ombudsman is available to organizations to promote responsible and meaningful exchanges of information. Generally, the purpose of these exchanges will be to:

1. Allow contractors to better prepare for and propose on business opportunities.

Page - 14

2. Advise as to technologies and solutions within the marketplace that the Government may not be aware of, or is not fully benefiting from.

3. Identify constraints in transparency and process.

b. The AGO Ombudsman will objectively, reasonably, and responsibly collaborate with parties and recommend fair, impartial, and constructive solutions to the matters presented to him/her.

Further, the AGO Ombudsman will maintain the reasonable and responsible confidentiality of the source of a concern, when such a request has been formally made by an authorized officer of an organization seeking to do business with, or already doing business with NOAA.

c. Before consulting with the AGO Ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations with the respective contracting officer for resolution. However, direct access to the AGO Ombudsman may be sought when an interested party questions the objectivity or equity of a contracting officer’s decision, or when there is a bona fide reason to believe that reasonable, responsible, and objective consideration will not be received from an assigned contracting officer.

d. There are several constraints to the scope of the AGO Ombudsman’s authority, for instance:

1. Consulting with the AGO Ombudsman does not alter or postpone the timelines of any formal process (e.g., protests, claims, debriefings, employee employer actions, activities involving A76 competition performance decisions, judicial or congressional hearings, or proposal, amendment, modification or deliverable due dates, etc.).

2. The AGO Ombudsman cannot participate in the evaluation of proposals, source selection processes, or the adjudication of protests or formal contract disputes.

3. The AGO Ombudsman is not authorized to generate or alter laws, judicial decisions, rules, policies, or formal guidance.

4. The AGO Ombudsman is not authorized to develop or alter opportunity announcements, solicitations, contracts, or their terms or conditions.

5. The AGO Ombudsman cannot overrule the authorized decisions or determinations of the contracting officer.

6. The AGO Ombudsman has no authority to render a decision that binds AGO, NOAA, the Department of Commerce, or the U.S. Government.

7. The AGO Ombudsman is not NOAA’s agent relative to the service of magistrate or judicial process and cannot be used to extend service of process to another party (whether federal, public, or a private entity).

e. After review and analysis of a filed concern or recommendation, the AGO Ombudsman may refer the interested party to another more suitable federal official for consideration. Moreover, concerns, disagreements, and/or recommendations that cannot be resolved by the AGO Ombudsman will need to be pursued through more formal venues.

f. The AGO Ombudsman is not to be contacted to request copies of forms and/or documents under the purview of a contracting officer. Such documents include Requests for Information, solicitations, amendments, contracts, modifications, or conference materials.

g. Questions regarding this solicitation and contract language shall be directed to Rafael Roman, NOAA AGO Ombudsman, at Rafael.Roman@noaa.gov.

mailto:Rafael.Roman@noaa.gov

Page - 15

FAR SOLICITATION PROVISIONS

(1) FAR 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JUL 2013)

(a) Definitions. As used in this provision— “Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceeding at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

“Federal contracts and grants with total value greater than $10,000,000” means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

“Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror [_] has [_] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

(End of provision)

(2) FAR 52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law (Feb 2016) https://www.acquisition.gov/

Page - 16

(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that--

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that—

(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

(End of provision)

(3) U.S. DEPARTMENT OF COMMERCE (DOC) PROVISION ENTITLED

“REPRESENTATION BY CORPORATIONS REGARDING AN UNPAID DELINQUENT

TAX LIABILITY OR A FELONY CONVICTION UNDER ANY FEDERAL LAW (CLASS

DEVIATION) (MARCH 2015)” is incorporated herein in full text, as follows:

(1) In accordance with Sections 744 and 745 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113- 235), none of the funds made available by the Consolidated and Further Continuing Appropriations Act, 2015 funding may be used to enter into a contract with any corporation that-

(a) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where an awarding agency is aware of the conviction, unless the agency has considered suspension or debarment of the corporation and has made a determination that this further action is not necessary to protect the interests of the Government, or

(b) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless the agency has considered suspension or debarment of the corporation and made a determination that this further action is not necessary to protect the interests of the Government.

(2) The Offeror represents that, as of the date of this offer -

Page - 17

(a) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

(b) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability.

(4) FAR 52.212-1 INSTRUCTIONS TO OFFERORS--COMMERCIAL ITEMS (JAN 2017)

ADDENDUM TO FAR 52.212-1 INSTRUCTIONS TO OFFERORS--COMMERCIAL ITEMS

(JAN 2017)

Complete and return one (1) copy of this RFQ no later than May 4, at 12:00 pm EST via email to the following Contract Specialists:

Alexander Cooper at Alexander.cooper@noaa.gov

Inquires regarding this requirement are due by 5:00 PM ET on May 2, 2018. Inquiries regarding this RFQ shall be addressed to the following Contract Specialist:

Alexander Cooper at Alexander.cooper@noaa.gov

1) Quote Preparation

The following instructions apply for the submission of quotes:

a. Quotes shall be submitted in three separate volumes:

Volume I – Past Performance Volume II - Price

b. The Government will evaluate quotes in accordance with the evaluation criteria set forth in FAR 52.212-2 of this RFQ.

2) Quote Instructions

a. Past Performance:

Past performance will be used as a means of evaluating the relative capability of the vendor to successfully meet the requirements of this solicitation. Vendors are required to provide information on no more than three (3) of the firm’s most recently completed contracts/orders (not to exceed three (3) years since completion) for like or similar work. Vendors may submit performance data regarding current contract performance as long as a minimum of one year of performance has been completed as of the closing date of this solicitation.

The Government may consider this information, as well as information obtained from any other sources, when evaluating the offeror’s past performance. The vendor is further reminded that the source selection authority shall determine the relevance of similar past performance information (PPI).

Page - 18

The offeror is requested to provide this information in the following format for each contract:

1. Contract Number and Client point of contact (including 2 points of contact with telephone numbers)

2. Ship Name, Hull Number

3. Dollar Value of the contract (Original: $ __________and Final: $

4. Contract performance period at the end of the contract (actual performance dates upon completion): Start: ___________ End: ___________

Vendors shall assume that the Government has no prior knowledge of them and that it will base its evaluation on the information presented in the Past Performance Proposal; as such, Past Performance Proposals must be fully self-sufficient and provide all necessary information. Failure to submit the Past Performance Proposal by the date and time cited above may be cause for rejection and the proposal receiving no further consideration.

b. Price: Pricing shall be submitted for all line items included in this solicitation. The vendor provided pricing for each CLIN will be added together to derive the overall evaluated price. Price will be evaluated for reasonableness.

(End of provision/addendum)

(5) FAR 52.212-2 -- Evaluation -- Commercial Items. (Oct 2014)

(a…