C-Labor_Performance_Bonds.pdf

<Project Title> 2024 Form PAYMENT BOND <Project Number> Page 3

Payment Bond

Town of Los Gatos (“Town”) and ________________________ (“Contractor”) have entered into a contract for work on the _________________________________________________ Project

(“Project”). The Contract is incorporated by reference into this Payment Bond (“Bond”).

1. General. Under this Bond, Contractor as principal and ____________________________, its surety (“Surety”), are bound to City as obligee in an amount not less than $_________________, under California Civil Code § 9550 et seq., to ensure payment to authorized claimants. This Bond is binding on the respective successors, assigns, owners, heirs, or executors of Surety and Contractor.

2. Surety’s Obligation. If Contractor or any of its Subcontractors fails to pay a person authorized in California Civil Code § 9100 to assert a claim against a payment bond, any amounts due under the Unemployment Insurance Code with respect to work or labor performed under the Contract, or any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of Contractor and its Subcontractors under California Unemployment Insurance Code § 13020 with respect to the work and labor, then Surety will pay the obligation.

3. Beneficiaries. This Bond inures to the benefit of any of the persons named in California

Civil Code § 9100, so as to give a right of action to those persons or their assigns in any suit brought upon this Bond. Contractor must promptly provide a copy of this Bond upon request by any person with legal rights under this Bond.

4. Duration. If Contractor promptly makes payment of all sums for all labor, materials, and equipment furnished for use in the performance of the Work required by the Contract, in conformance with the time requirements set forth in the Contract and as required by California law, Surety’s obligations under this Bond will be null and void. Otherwise, Surety’s obligations will remain in full force and effect.

5. Waivers. Surety waives any requirement to be notified of alterations to the Contract or extensions of time for performance of the Work under the Contract. Surety waives the provisions of Civil Code §§ 2819 and 2845. City waives the requirement of a new bond for any supplemental contract under Civil Code § 9550. Any notice to Surety may be given in the manner specified in the Contract and sent to Surety as follows:

Attn: _____________________________________________________ Address: _________________________________________________ City/State/Zip: _____________________________________________ Phone: ___________________________________________________ Email: ___________________________________________________

6. Law and Venue. This Bond will be governed by California law, and venue for any dispute pursuant to this Bond will be in the Santa Clara County Superior Court, and no other place.

Surety will be responsible for City’s attorneys’ fees and costs in any action to enforce the provisions of this Bond.

[Signatures are on the following page.]

<Project Title> 2024 Form PAYMENT BOND <Project Number> Page 4

7. Effective Date; Execution. This Bond is entered into and is effective on __________, 20__.

SURETY:

Business Name s/__________________________________ ______________________________ Date

Name, Title

(Attach Acknowledgment with Notary Seal and Power of Attorney)

CONTRACTOR:

Business Name s/__________________________________ ______________________________ Date

APPROVED BY TOWN:

s/ __________________________________ ______________________________ Date

END OF PAYMENT BOND

<Project Title> 2024 Form PERFORMANCE BOND <Project Number> Page 5

Performance Bond

Town of Los Gatos (“Town”) and __________________________ (“Contractor”) have entered into a contract for work on the _______________________________________________ Project

(“Project”). The Contract is incorporated by reference into this Performance Bond (“Bond”).

1. General. Under this Bond, Contractor as principal and ___________________________, its surety (“Surety”), are bound to City as obligee for an amount not less than $__________________ to ensure Contractor’s faithful performance of its obligations under the Contract. This Bond is binding on the respective successors, assigns, owners, heirs, or executors of Surety and Contractor.

2. Surety’s Obligations. Surety’s obligations are co-extensive with Contractor’s obligations under the Contract. If Contractor fully performs its obligations under the Contract, including its warranty obligations under the Contract, Surety’s obligations under this Bond will become null and void. Otherwise, Surety’s obligations will remain in full force and effect.

3. Waiver. Surety waives any requirement to be notified of and further consents to any alterations to the Contract made under the applicable provisions of the Contract Documents, including changes to the scope of Work or extensions of time for performance of Work under the Contract. Surety waives the provisions of Civil Code §§ 2819 and 2845.

4. Application of Contract Balance. Upon making a demand on this Bond for completion of the Work prior to acceptance of the Project, City will make the Contract Balance available to Surety for completion of the Work under the Contract. For purposes of this provision, the Contract Balance is defined as the total amount payable by City to Contractor as the Contract Price minus amounts already paid to Contractor, and minus any liquidated damages, credits, or backcharges to which City is entitled under the terms of the Contract.

5. Contractor Default. Upon written notification from City of Contractor’s termination for default under Article 13 of the Contract General Conditions, time being of the essence, Surety must act within the time specified in Article 13 to remedy the default through one of the following courses of action:

5.1 Arrange for completion of the Work under the Contract by Contractor, with City’s consent, but only if Contractor is in default solely due to its financial inability to complete the Work;

5.2 Arrange for completion of the Work under the Contract by a qualified contractor acceptable to City, and secured by performance and payment bonds issued by an admitted surety as required by the Contract Documents, at Surety’s expense;

or

5.3 Waive its right to complete the Work under the Contract and reimburse City the amount of City’s costs to have the remaining Work completed.

6. Surety Default. If Surety defaults on its obligations under the Bond, City will be entitled to recover all costs it incurs due to Surety’s default, including legal, design professional, or delay costs.

7. Notice. Any notice to Surety may be given in the manner specified in the Contract and sent to Surety as follows:

<Project Title> 2024 Form PERFORMANCE BOND <Project Number> Page 6

Attn: _____________________________________________________ Address: _________________________________________________ City/State/Zip: _____________________________________________ Phone: ___________________________________________________ Fax: _____________________________________________________ Email: ___________________________________________________

8. Law and Venue. This Bond will be governed by California law, and venue for any dispute pursuant to this Bond will be in the Santa Clara County Superior Court, and no other place.

Surety will be responsible for City’s attorneys’ fees and costs in any action to enforce the provisions of this Bond.

9. Effective Date; Execution. This Bond is entered into and effective on

____________________, 20___.

SURETY:

Business Name s/__________________________________ ______________________________ Date

(Attach Acknowledgment with Notary Seal and Power of Attorney)

CONTRACTOR:

Business Name s/__________________________________ ______________________________ Date

APPROVED BY TOWN:

s/ __________________________________ ______________________________ Date

END OF PERFORMANCE BOND