d.Appendix_B_Shelter_Scaled.doc

Contract Name: Shelter Stewardship

APPENDIX B

STEWARDSHIP CONTRACT TIMBER REMOVAL SPECIFICATIONS

*B.0 CONTRACT AREA

*B.2 Claims

*C.0 TIMBER SPECIFICATIONS

*C.1 Included Timber

*C.1.1 Standard Timber

*C.1.2 Substandard Timber

*C.1.3 Damaged Timber

*C.1.3.1 Damaged by Contractor

*C.1.3.2 Negligent or Willful Damage

*C.1.3.4 Minor Damage by Natural Causes

*C.1.4 Unintentionally Cut Timber

*C.1.6 Other Material

*C.2 Utilization and Removal of Included Timber

*C.3 Timber Designations

C.3.2 Construction Clearing

*C.3.2.2 Other Authorized Clearings

C.3.5 Individual Trees

*C.3.7 Minor Changes

*C.4 Volume Estimate

*D.0 RATES OF PAYMENT

*D.1 Current Contract Rates

*D.4 Other Payment Rates

*D.4.1 Material and Quantities Not in Division A

*D.4.2 Timber Cut Through Mistake

*D.4.2.1 Designated Timber Cut But Not Removed

*D.4.3 Undesignated Timber Damaged Without Negligence

*D.4.4 Undesignated Timber Unnecessarily Damaged or Negligently or Willfully Cut

*D.4.5 Liquidated Damages

*D.4.7 Defect Caused by Abnormal Delay

*E.0 PAYMENTS

*E.1 Amount Payable for Timber

*E.2 Integrated Resource Account

*E.3 Deposits When Payment Guaranteed

*G.0 OPERATIONS

*G.4 Conduct of Logging

*G.4.1 Felling and Bucking

*G.4.1.1 Felling in Clearings

*G.4.1.2 Stump Heights

*G.4.1.3 Bucking Lengths *G.4.1.4 Limbing

*G.4.2 Skidding and Yarding

G.4.2.1 Rigging

*G.4.2.2 Landings and Skid Trails

*G.4.2.3 Skidding on Roads

*G.6.3 Temporary Roads

*G.6.4 Landings

*G.6.5 Skid Trails and Fire Lines

*G.6.6 Current Operating Areas

*G.6.7 Erosion Control Structure Maintenance

*G.7 Slash Disposal

*G.8 Scaling

*G.8.1 Scaling Services

*G.8.1.1Sclaing Location

*G.8.1.2 Scaling Adjustments

*G.8.1.3 Delayed or Interrupted Scaling Services

*G.8.1.4 Weighing Services

*G.8.2 Presentation for Scaling

*G.8.3 Scaling Other Products

*G.8.4 Accountability

*G.8.4.1 Route of Haul

**G.8.4.2 Product Identification

I.0 OTHER CONDITIONS

*I.1 Title and Liability

*I.1.1 Title Passage

*I.1.2 Liability for Loss

*I.5 Sale of Other Materials

K-G.3.5.7# Individual Tree Designation (Option 1) (06/08) K-G.4.7# Abnormal Delay (05/05)

K-F.1.0.1# Temporary Road and Landing Construction (Option 1) (06/10)

K-F.1.3# Road Completion Date (09/04) K-F.2.2.1# Material Sources (09/04)

K-G.3.1.5# Project Operation Schedule (05/05)

K-G.4.0.5 Alternate Removal of Included Timber (05/05)

K-G.4.1# Specific Requirements (05/05)

K-G.4.2# Yarding/ Skidding Requirements (05/05)

K-G.6.0# Erosion Control and Soil Treatment By Contractor (04/14)

K-G.6.4.2 Constructed Landings (05/05)

K-G.7 Slash Disposal (06/08)

K-G.7.4.1# Slash Treatment Requirements (Option 1) (06/08)

K-G.8.1.5 Third Party Scaling Services (9/04) K-G.8.4 Use of Paint by Contractor (Option 1) (06/06)

K-G.8.5.1 Weight of Lost Loads (04/14)

K-H.1 Plans (05/05)

K-H.2 Specific Fire Precautions (05/05) K-H.2.0.1 Burning by Contractor (06/06)

K-H.2.2 Emergency Fire Precautions (05/05)

K-I.1.0 Disclaimer of Expressed or Implied Warranty (05/05) K-I.3.1# Contract Changes (Option 1) (05/05) K-I.6.8# Use of Timber (Option 1) (9/04)

Division A Location and Area:

T. 28 N., R. 12 W., Sections 1, 2, 11 and 12, W.M.

Volume Estimate and Utilization Standards

Quantity * Unit of

Measure Minimum Specifications

Diameter Breast High (d.b.h.)

(inches) Number of Minimum Pieces per Tree Length (feet) Diameter Inside Bark at Small End (inches) Net Scale in % if Gross Scale

Douglas-fir

Western Hemlock and other species Sawtimber Sawtimber 12583

Tons Tons 8.0 8.0 6.0 6.0

Total Quantity

21515

Timber Designations, acres are approximate:

Number

Acres

Clearcutting Units (C.3.1)

Overstory Removal Units (C.3.3)

Understory Removal Units (C.3.4)

Individual Trees (C.3.5)

Incompletely Measured (C.3)

Designation by Description or Prescription (K-C.3)

High Stumps

(inches)

Roads

Construction of Roads and Bridges and Federal Highway Projects (2003) -english

Class Approx.

Length (mi./km.)

Sheet Numbers and Approval Date Performance Responsibility

Staking1/

06/16/2015

(M.P. 0.00-0.42)

06/16/2015

06/16/2015

1/ Indicate timing, i.e., before clearing (BC) or after clearing (AC).

Specification sheets with itemized construction codes also attached

Scaling Instructions and Specifications

Fiber scaling rules apply to non-sawtimber products. Check scaling will be performed at individual scaling locations.

Scaling Specifications

Scaling Length (feet) Trim Allowance

Diameter Range (inches) Length Range (feet) Trim Allowance (inches)

Scaling Services

Unit of Measure

Estimated Cost per Unit

Site per G.8.1.1 and G.8.1.4

APPLICABLE REGIONAL CLAUSES MAY BE ADDED

UNITED STATES DEPARTMENT OF AGRICULTURE

Forest Service

TIMBER REMOVAL SPECIFICATIONS

CALUSES FOR SCALED TIMBER REMOVAL CONTRACTS

(Applicable to Contracts to be Measured After Felling) This Division is organized into Parts, Sections, Subsections, and Items. These are numbered in accordance with the following scheme: Part Bl.0, Section Bl.1, Subsection Bl.11, and Item Bl.111. References to a Part include all Sections, Subsections, and Items within that Part; references to a Section include all Subsections and Items within that Section; and references to a Subsection include all Items within that Subsection. Cross references within this contract cite the reference number of the applicable Division, Part, Section, Subsection, and Item. Descriptive headings used are not to be considered in determining the rights and obligations of the parties hereunder. The Standard Clauses in this Division are subject to Specific Conditions of the contract stated in Division A. Wherever appropriate, Specific Conditions established in Division A are herein cited by reference number. References to Standard Clauses also apply to Special K Clauses with the same numbers. These clauses are applicable only to the timber removal portion of the Shelter Stewardship Contract except where otherwise specifically referenced. “Timber” when used in this appendix includes timber and other products.

B.0—CONTRACT AREA

B.2 Claims. Valid claims are excluded from Contract Area, except those on which timber cutting is authorized in writing by the claimant and except mining claims on which cutting is authorized by the Act of July 23, 1955 (30 USC 614). Claims that limit Contractor’s rights to operate under this contract and that Forest Service has been able to identify are shown on Contract Area Map. Contractor is not obligated to operate contrary to existing claim limitations. Forest Service shall designate boundaries of claims on the ground to the extent necessary to identify Included Timber.

C.0—TIMBER SPECIFICATIONS

C.1 Included Timber. “Included Timber” consists of:

C.1.1 Standard Timber. Live and dead trees and portions thereof that meet Utilization Standards and are designated for cutting.

C.1.2 Substandard Timber. Live and dead trees that:

(a) Do not meet Utilization Standards and

(b) Are located in Clearcutting Units or construction clearings or are otherwise designated for cutting.

C.1.3 Damaged Timber.

C.1.3.1 Damaged by Contractor. Undesignated live trees meeting Utilization Standards (a) within 200 feet slope distance from centerline of roads constructed hereunder which are damaged by Contractor's construction to the extent that considerable deterioration or mortality is imminent and are designated by Forest Service for felling before the nearest road segment is substantially completed; or (b) which are damaged by Contractor in logging and are subsequently Marked before Contractor has completed skidding or yarding operations in the immediate area. By agreement, such trees may be left without charge if their removal would cause undue damage or be grossly uneconomic.

C.1.3.2 Negligent or Willful Damage. Undesignated timber meeting Utilization Standards and unnecessarily damaged or negligently or willfully cut by Contractor, if included by Forest Service.

C.1.3.4 Minor Damage by Natural Causes. Undesignated trees within Contract Area and meeting Utilization Standards, that become insect infested, windthrown, suffer serious damage, or die, as designated by agreement.

C.1.4 Unintentionally Cut Timber. Trees within or immediately adjacent to Contract Area or to road construction or other authorized clearing outside Contract Area, not designated for cutting but that are cut through mistake by Contractor, when included by Forest Service.

C.1.6 Other Material. Species or products not listed in the contract, upon written approval of Forest Service.

C.2 Utilization and Removal of Included Timber. “Utilization Standards” for trees and minimum pieces are stated in Division A. To meet minimum tree specifications, trees must equal or exceed tree diameters listed in Division A and contain at least one minimum piece. Except for timber required or authorized to be left, Contractor shall fell and buck such trees and shall remove from Contract Area all pieces that:

(a) Meet minimum piece standards in Division A or,

(b) Do not meet such standards, but would have qualified as part of minimum pieces if bucking lengths were varied to include such material.

C.3 Timber Designations. Timber designated for cutting shall be confined to Contract Area, except as otherwise provided. Contract Area Map indicates subdivisions, if any, where Marking is to be done after solicitation, except for construction clearing, minor changes, and damaged timber. The boundaries of cutting units were plainly marked on ground before solicitation and are shown on Contract Area Map. The number of units and approximate acreage of timber designations are stated in Division A.

C.3.2 Construction Clearing. All timber is designated for cutting that is within the clearing limits of roads constructed hereunder or is in other authorized clearings. All dead or unstable live trees are designated for cutting that are sufficiently tall to reach Contractor’s landings, work areas, or the roadbed of Specified and Temporary Roads when Marked in advance of work in the immediate area. Pieces meeting Utilization Standards from such dead or un-stable live trees shall be removed, unless there is agreement that to do so could damage the road. Such designation may be revised as part of agreed changes in road locations.

C.3.2.2 Other Authorized Clearings. Timber within authorized clearings for Temporary Roads, landings, or other construction clearings is designated for cutting. Quantities of such timber are not included in Division A.

C.3.5 Individual Trees. All trees to be cut, other than in the units described in C.3.1, C.3.2, C.3.3, and C.3.4, are Marked or designated by description. Trees are “Marked” when individually designated by Forest Service with paint marks above and below stump height.

Contract Area Map indicates areas plainly identified on the ground where leave trees are Marked to be left uncut.

C.3.7 Minor Changes. Within Contract Area, minor adjustments may be made in boundaries of cutting units or in the timber individually Marked for cutting when acceptable to Contractor and Forest Service.

C.4 Volume Estimate. The estimated volumes of timber by species designated for cutting and expected to be cut under Utilization Standards are listed in Division A. The estimated volumes stated are not to be construed as guarantees or limitations of the timber volumes to be designated for cutting under the terms of this contract.

D.0—RATES OF PAYMENT

D.1 Current Contract Rates. Included Timber that is removed by Contractor and presented for scaling shall be paid for at Current Contract Rates determined under this Section. “Current Contract Rates” shall be Flat Rates. Flat Rates shall be those listed in Division AT or B2 of the Schedule of Items. In the event contract time is adjusted, Current Contract Rates shall be continued in the same manner as immediately prior to the adjustment period.

D.4 Other Payment Rates.

D.4.1 Material and Quantities Not in Division A. Incidental amounts of products or portions of trees of species that do not meet Utilization Standards may be removed without charge. Such material from Clearcutting Units and construction clearings may be purposely removed in more than incidental amounts without charge subject to agreement on deposits for road maintenance and use. Such material from other than Clearcutting Units and construction clearings may be purposely removed in more than incidental amounts without charge upon written approval of Contracting Officer, and subject to agreement on deposits if needed for road maintenance and use. Other species or products not listed may, upon written approval of Contracting Officer, be cut and removed subject to agreement on rates of payment. Timber for which the quantity is not included in the estimate, shall be paid for at Current Contract Rates and Required Deposits.

D.4.2 Timber Cut Through Mistake. Undesignated timber meeting Utilization Standards, cut by Contractor through mistake and included by the Forest Service, shall be removed and paid for at Current Contract Rates and Required Deposits, unless such material is not listed. In such event, Forest Service, in accord with standard Forest Service methods, shall establish rates to be paid.

D.4.2.1 Designated Timber Cut But Not Removed. Standard timber shall be removed prior to acceptance of a Subdivision for completion of logging. There shall be no charge when (a) leaving the incidental material is justified under existing conditions, or (b) Cut timber is left by option or requirement.

D.4.3 Undesignated Timber Damaged Without Negligence. Undesignated timber meeting Utilization Standards, damaged without negligence by Contractor and designated by Forest Service, shall be cut, removed, and paid for at Current Contract Rates and Required Deposits.

D.4.4 Undesignated Timber Unnecessarily Damaged or Negligently or Willfully Cut. Undesignated timber meeting Utilization Standards and unnecessarily damaged or negligently or willfully cut by Contractor, if included by Forest Service shall be cut, removed, and paid for at Current Contract Rates and Required Deposits that are in addition to liquidated damages. If such timber is of a species or size not listed in Division A or is of a quality different from designated timber, Contracting Officer shall establish payment rates in accord with standard Forest Service methods.

D.4.5 Liquidated Damages. Unnecessary damage to or negligent or willful cutting of undesignated timber, on portions of Contract Area cut over under this contract is likely to cause substantial silvicultural or other damage to the National Forest. It will be difficult, if not impossible, to determine the amount of such damage. Therefore, Contractor shall pay as fixed, agreed, and liquidated damages an amount equivalent to the amount payable at Current Contract Rates. If designated by the Forest Service, Contractor shall remove such damaged timber.

D.4.7 Defect Caused by Abnormal Delay. Scaling deductions made for rot, check, or other defect resulting from abnormal delay in Scaling caused by Contractor shall be recorded separately and charged to Integrated Resource Account at Current Contract Rates and applicable deposits.

E.0—PAYMENTS

E.1 Amount Payable for Timber. Current Contract Rates and Required Deposits in effect when the timber is Scaled shall be applied to the Scaled volume to determine the amount Contractor shall pay.

E.2 Stewardship Account

“Stewardship Account” is an account of all Contractor’s deposits, credits, Payment Guarantees, and the charges for:

a. Timber, or other Products at rates specified in contract

b. Slash disposal and road maintenance at Required Deposit rates,

c. Stewardship Credits established,

d. Contract Scaling Deposits, and

e. Other Charges provided in this contract.

Cash deposits and Stewardship Credits earned shall be recorded currently in such account.

Charges for timber cut shall be made when Forest Service prepares and furnishes to Contractor periodic statements of volume and value of such timber cut and scaled. Charges against Stewardship Credits shall be limited to timber value in excess of Required Deposits. Required Deposits and Other Charges shall be paid in cash.

Contractor shall make cash deposits to meet Contractor’s obligations within 15 days of billing by the Forest Service. Deposits shall be made to Forest Service, USDA, by mail or delivery to the address shown on the bill for collection.

E.3 - Deposits When Payment Guaranteed. (05/10) To the extent payment guarantee is provided under Clause entitled, “PRODUCT PAYMENT GUARANTEE” requirements for advance cash deposits shall be waived for the value of Product on contract area that is cut, but not removed, and for the value of Products removed from contract area, up to limit of remaining stewardship credits to be earned and exchanged for value of included product except for Required Deposits and Associated Charges. Associated charges shall be waived for not more than one monthly billing period.

G.0—OPERATIONS

G.4 Conduct of Logging. Unless otherwise specifically provided herein, Contractor shall fell trees designated for cutting and shall remove the portions which meet Utilization Standards, except for occasional trees inadvertently not cut or trees or pieces not removed for good reason, including possible damage to forest resources or gross economic impracticability at the time of removal of other timber. Logging shall be conducted in accordance with the following, unless other clauses set forth requirements to meet special or unusual logging conditions:

G.4.1 Felling and Bucking. Felling shall be done to minimize breakage of Included Timber and damage to residual timber. Unless agreed otherwise, felling shall be done by saws or shears. Bucking shall be done to permit removal of all minimum pieces set forth in Division A. Contractor may buck out cull material when necessary to produce pieces meeting Utilization Standards. Such bucked out material shall contain a minimum amount of sound wood, not in excess of the net Measure in percentage of gross Measure, or based on the merchantability factor, whichever is stated in Division A. If necessary to assess extent of defect, Contractor shall make sample saw cuts or wedges.

G.4.1.1 Felling in Clearings. Insofar as ground conditions, tree lean and shape of clearings permit, trees shall be felled so that their tops do not extend outside construction clearings and areas of regeneration cutting.

G.4.1.2 Stump Heights. Stumps shall not exceed, on the side adjacent to the highest ground, the maximum heights set forth in Division A, except that occasional stumps of greater heights shall be acceptable when necessary for safe and efficient conduct of logging. Except for acceptable high stumps stated above, Contractor shall re-cut high stumps so they will not exceed heights specified in Division A and shall dispose of severed portions in the same manner as other logging debris or as otherwise agreed. The stump heights shown in Division A were selected with the objective of maximum reasonable utilization of the timber unless Contract Area Map shows special areas where stump heights are lower for aesthetic, land treatment or silvicultural reasons.

G.4.1.3 Bucking Lengths. Trees shall be bucked in various lengths to obtain the greatest utilization of material meeting Utilization Standards.

G.4.1.4 Limbing. When Forest Service determines it is necessary to minimize damage to the residual stand during skidding, Contractor shall cut exposed limbs from products prior to skidding. Contractor may leave uncut those limbs that cannot be cut with reasonable safety.

G.4.2 Skidding and Yarding. Methods of skidding or yarding specified for particular areas, if any, are indicated on Contract Area Map. Outside Clearcutting Units and construction clearings, insofar as ground conditions permit, products shall not be skidded against reserve trees or groups of reproduction and tractors shall be equipped with a winch to facilitate skidding.

G.4.2.1 Rigging. Insofar as practicable, needed rigging shall be slung on stumps or trees designated for cutting.

G.4.2.2 Landings and Skid Trails. Location of all landings, tractor roads, and skid trails shall be agreed upon prior to their construction. The cleared or excavated size of landings shall not exceed that needed for efficient skidding and loading operations.

G.4.2.3 Skidding on Roads. Products may be skidded on permanent roads authorized for hauling only by prior written agreement.

G.6.3 Temporary Roads. As necessary to attain stabilization of roadbed and fill slopes of Temporary Roads, Contractor shall employ such measures as outsloping, drainage dips, and water-spreading ditches.

After a Temporary Road has served Contractor’s purpose, Contractor shall give notice to Forest Service and shall remove bridges and culverts, eliminate ditches, outslope roadbed, remove ruts and berms, effectively block the road to normal vehicular traffic where feasible under existing terrain conditions, and build cross ditches and water bars, as staked or otherwise marked on the ground by Forest Service. When bridges and culverts are removed, associated fills shall also be removed to the extent necessary to permit normal maximum flow of water.

G.6.4 Landings. After landings have served Contractor’s purpose, Contractor shall ditch and slope them to permit water to drain or spread. Unless agreed otherwise, cut and fill banks around landings shall be sloped to remove overhangs and otherwise minimize erosion.

G.6.5 Skid Trails and Fire Lines. Contractor shall construct cross ditches and water-spreading ditches on tractor roads and skid trails, where staked or otherwise marked on the ground by Forest Service. Forest Service shall designate cross ditching on Contractor-built fire lines prior to or during construction. By agreement, Contractor may use other comparable erosion control measures, such as backblading skid trails, in lieu of cross ditching.

G.6.6 Current Operating Areas. Where logging, road construction, or other stewardship project work is in progress but not completed, unless agreed otherwise, Contractor shall, before operations cease annually, remove all temporary log culverts and construct temporary cross drains, drainage ditches, dips, berms, culverts, or other facilities needed to control erosion.

Such protection shall be provided, prior to end of February 28, for all disturbed, unprotected ground that is not to be disturbed further prior to end of operations each year, including roads and associated fills, tractor roads, skid trails, and fire lines. When weather permits operations during March 1 to June 1, inclusive Contractor shall keep such work on any additional disturbed areas as up to date as practicable.

G.6.7 Erosion Control Structure Maintenance. During the period of this contract, Contractor shall provide maintenance of soil erosion control structures constructed by Contractor until they become stabilized, but not for more than 1 year after their construction. Contractor shall not be responsible for repair of such structures damaged by other National Forest users whose activities are not a part of Contractor’s Operations.

G.7 Slash Disposal. Contractor’s timing of product removal and preparatory work shall not unnecessarily delay slash disposal. Specific slash disposal measures to be employed by Contractor are stated elsewhere herein and are in addition to Required Deposits for slash disposal.

G.8 Scaling. “Scaling,” as used herein, involves:

(a) Various volume determination methods, such as log rule, sampling, measuring, linear measuring, counting, weighing, or another method or combination of methods;

(b) Various sites, such as truck Scaling stations, rollways, weighing stations, woods landings, water Scaling stations, or other sites; and

(c) Various geographic locations.

G.8.1 Scaling Services. Scaling services shall be performed by Forest Service personnel or parties under contract to Forest Service, except that weighing services may be performed by personnel or parties approved by Forest Service. Scaling shall be provided in accordance with the instructions and specifications in Division A. Scalers shall be currently certified to perform accurate Scaling services. The Scaling services provided shall be selected exclusively by Forest Service. Scaling services may be Continuous, Intermittent, or Extended. “Continuous Scaling Services” is Scaling at one site five (5) 8-hour shifts a week, exclusive of Sundays and Federal holidays. “Intermittent Scaling Services” are non-continuous Scaling services. “Extended Scaling Services” are Scaling services exceeding Continuous Scaling Services and may include Sundays and designated Federal holidays. Upon written request of Contractor and approval of Contracting Officer, Forest Service may provide other services, such as but not limited to grading, tagging, or marking of Scaled logs.

G.8.1.1 Scaling Location. Forest Service shall provide Scaling services at the Scaling site(s) shown in Division A. The Scaling site(s) shown in Division A normally will be a non-exclusive site where more than one National Forest contractor may be served. Contractor may request, in writing, an alternate Scaling site, such as at a private mill yard, private truck ramp, or a privately operated log transfer facility. Contracting Officer may approve an alternate Scaling site, when Contracting Officer determines that Scaling conditions at an alternate site are acceptable. Such conditions shall include at a minimum: (a) Scaler safety and comfort, (b) Product accountability and security, (c) Facilities and practices conducive to accurate and independent Scaling, and (d) The ability to provide for remote check Scaling. Upon approval of an alternate Scaling site, Forest Service and Contractor shall enter into a written memorandum of agreement governing Scaling at that alternate location. Contractor agrees that Forest Service personnel or persons under contract with Forest Service shall perform Scaling services at an alternative Scaling site. In no instance shall Contractor or employees of Contractor perform Scaling services.

G.8.1.2 Scaling Adjustments. Forest Service shall check the accuracy of the Scaling performed on National Forest logs. Scaling will be satisfactory if performed within the accuracy standards stated in governing instructions identified in Division A. In the event Forest Service check Scale(s) shows a variance in net Scale in excess of the allowable variance, an adjustment to volume reported Scaled may be made by Forest Service. Such adjustment will be based on the difference between Forest Service check Scale(s) and original Scale for contract volume Scaled within the adjustment period. The volume to which this difference will be applied will be: (a) One-half of the volume Scaled between the last satisfactory check Scale and the first unsatisfactory check Scale or, if a period of 120 days or more occurs without Scaling National Forest timber for stumpage, the adjustment will be applied to 100 percent of the volume Scaled after this period and (b) 100 percent of the volume Scaled between unsatisfactory check Scales and (c) One-half of the volume Scaled between the last unsatisfactory check Scale and the next satisfactory check Scale, or if no satisfactory check Scale is completed and a period of 120 days or more occurs without Scaling of National Forest timber for stumpage, the adjustment will be applied to 100 percent of the volume Scaled since the last unsatisfactory check Scale. Adjustments may increase or decrease the original Scaled volume. Adjustments will be applied to Integrated Re-source Account to correct charges for Included Timber, plus deposits, Scaled during the adjustment period.

G.8.1.3 Delayed or Interrupted Scaling Services. In the event Scaling services are delayed or interrupted, Contractor shall discontinue hauling. Contractor further agrees that no logs will be presented for Scaling outside agreed upon Scaling services schedule.

G.8.1.4 Weighing Services. Weighing services for stumpage payment purposes may be provided by either public or privately owned and operated weighing facilities. A “Weighing Services Agreement,” approved by the Forest Supervisor, must be executed at each weighing facility providing weighing services. Scales used to weigh National Forest products for payment purposes must be a currently certified scale in accordance with State law and be capable of weighing the entire load of logs in a single operation. The weighing of less than the entire load or weighing two loads at once is prohibited. Unless otherwise agreed, the minimum sized weighing facility shall be a 60-ton capacity scale with a 10 foot by 70 foot platform or larger. The weighmaster must work in a position where it is possible to verify that the truck wheels are on or off the scales.

Weighing facilities shall meet the following minimum requirements:

(a) Be an electronic design,

(b) Use electronic load cells or have a fully enclosed and sealed weigh-beam,

(c) Have digital weight meters sealed with a seal approved by the State,

(d) Have a zero interlocking device on the printer,

(e) Have an automatic zero-setting mechanism,

(f) Have an automatic motion-detecting device,

(g) Be shielded against radio or electromagnetic interference, and

(h) Have a date and time stamp and gross and tare weights that print electronically with each weighing. Contracting Officer may waive electronic printing for public or third party weighing facilities.

Contractor shall bear all charges or fees for weighing services.

G.8.2 Presentation for Scaling. Contractor shall present products so that they may be Scaled in an economical and safe manner. If prior to Scaling, Included Timber is to be mixed with other timber, Contractor shall, prior to mixing, provide for distinguishing, by means approved by Forest Service, each product included in this contract.

Trees or pieces presented for Scaling that have not been bucked to separate material meeting minimum piece standards from material not meeting minimum piece standards due to diameter, shall be Scaled as though such bucking had been done.

Deductions made for rot, check, or other defects resulting from abnormal delay in Scaling caused by Contractor shall be recorded separately and charged to Integrated Resource Account under D.4.7.

Any timber that has been removed from Contract Area during the period of this contract, but remains unscaled after contract termination, shall be Scaled at the earliest reasonable date.

G.8.3 Scaling Other Products. The Scaled volume of material presented for Scaling in forms other than those stated in Division A., when appropriate, shall be converted to the Division A unit of measure by the application of standard converting factors and procedures in effect at the time the contract was sold. Other converting factors may be used by written agreement.

G.8.4 Accountability. When Scaling is performed away from Contract Area, products shall be accounted for in accordance with Forest Service written instructions or an Accountability Agreement between Forest Service and Contractor and as follows:

(a) Contractor shall plainly mark or otherwise identify products prior to hauling in accordance with G.8.4.2;

(b) Forest Service shall issue removal receipts to Contractor;

(c) Contractor shall assign a competent individual at the landing to complete removal receipts and attach them to each load of products removed from Contract Area;

(d) Removal receipts shall be returned to Forest Service at periodic intervals;

(e) When products are in transit, the truck driver shall possess or display removal receipt and show it upon request as evidence of authority to move products;

(f) The scaler’s portion of removal receipt shall be surrendered at point of Scaling, the unloading point, or as requested by Forest Service; and

(g) Contractor shall notify Forest Service of lost or off-loaded logs and their location within 12 hours of such loss.

Contractor shall not place products in storage for deferred Scaling until an accountability system has been agreed to in writing for a stated period.

G.8.4.1 Route of Haul. Contractor shall furnish a map showing the route of haul over which unscaled products will be transported from Contract Area to the approved Scaling location. Such route of haul shall be the shortest, most economical haul route available between the points.

Upon advance written agreement, other routes may be approved. All unscaled products removed from Contract Area shall be transported over the designated routes of haul. Contractor shall notify Forest Service when a load of products, after leaving Contract Area, will be delayed for more than 12 hours in reaching Scaling location.

Contractor shall require truck drivers to stop, if requested by Forest Service, for the following reasons:

(a) For accountability checks when products are in transit from Contract Area to the designated Scaling location or

(b) For a remote check Scale when products are in transit after being truck Scaled at the designated Scaling location.

Contractor and Forest Service shall agree to locations for accountability checks and remote check Scales in advance of haul. Such locations shall be established only in areas where it is safe to stop trucks.

Forest Service shall notify Contractor of the methods to be used to alert truck drivers of an impending stop.

G.8.4.2 Product Identification. For contracts west of the 100th meridian, before removal from Contract Area, unless Contracting Officer determines that circumstances warrant a written waiver or adjustment, Contractor shall:

(a) Hammer brand all products that are eight (8) feet or more in length and one-third (1/3) or more sound, on each end that is seven (7) inches or more in diameter

(b) West of the 100th meridian, paint with a spot of highway-yellow paint all domestic processing products that are eight (8) feet or more in length and one-third (1/3) or more sound, on each end that is seven (7) inches or more in diameter. Each paint spot must be not less than three (3) square inches in size.

Contracting Officer shall assign brands and, if Contract Area is within a State that maintains a log brand register, brands shall be registered with the State. Contractor shall use assigned brand exclusively on logs from this contract until Contracting Officer releases brand. Contractor shall furnish and apply highway-yellow paint of a lasting quality (oil-base or equivalent).

All hammer brands and/or highway-yellow paint must remain on logs until they are domestically processed. Contractor shall replace identifying marks if they are lost, removed, or become unreadable. Contractor may remanufacture products into different log lengths. Except for logs remanufactured as part of the mill in-feed process immediately before processing, remanufactured products must be rebranded with the assigned contract brand and repainted with highway-yellow paint, unless otherwise agreed to in writing by Contracting Officer. For such remanufactured products, Contracting Officer may approve use of a brand to be used exclusively as a catch brand, in lieu of the assigned contract brand.

I.0—OTHER CONDITIONS

I.1 Title and Liability.

I.1.1 Title Passage. All right, title, and interest in and to any Included Timber shall remain in Forest Service until it has been cut, scaled, and removed from Contract Area or other authorized cutting area, and paid for, at which time title shall vest in Contractor. Timber cut under the terms of clause titled Product Payment Guarantee, shall be considered to be paid for. Title to any Included Timber that has been cut, scaled and paid for, but not removed from Contract Area or other authorized cutting area by Contractor on or prior to contract termination, shall remain in Forest Service.

I.1.2 Liability for Loss. If Included Timber is destroyed or damaged by an unexpected event that significantly changes the nature of the Included Timber, such as fire, wind, flood, insects, disease, or similar cause, the party holding title shall bear the timber value loss resulting from such destruction or damage; except that such losses caused by insect or disease after felling of timber shall be borne by Contractor, unless Contractor is prevented from removing such timber by the Forest Service. Deterioration or loss of value of salvage timber is not an unexpected event. In the event Included Timber to which Forest Service holds title is destroyed, Contractor will not be obligated to remove and pay for such timber. In the event Included Timber to which Forest Service holds title is damaged, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the value loss and the appraised unit value of timber after the loss. Current Contract Rates in effect at the time of the value loss shall be adjusted by said differences to become the redetermined rates.

There shall be no obligation for Forest Service to supply, or for Contractor to accept and pay for, other timber in lieu of that destroyed or damaged. This Subsection shall not be construed to relieve either party of liability for negligence.

I.5 Sale of Other Materials. Forest Service reserves the right to sell from Contract Area during the period of this contract any materials or products not subject to its terms, but shall not permit removal, possession or use thereof which will materially interfere with Contractor's Operations. Contractor shall not be obligated to do any work made necessary by the action of others.

K-C.3.5.7# - INDIVIDUAL TREE DESIGNATION (OPTION 1). (6/08) All trees meeting the attached designation by description which meet the minimum tree diameter stated in A.2 are designated for cutting. Additional timber to be cut, if any, will be designated for cutting in accordance with C.3.7.

Leave trees, Marked with orange paint above and below stump height, or identified by boundary tags and in the attached description table as “ghost trees” are not to be cut, unless designated by the Forest Service.

DESCRIPTION PURSUANT TO K-C.3.5.7# INDIVIDUAL TREE DISGNATION (Option 1) (06/08)

All live trees, except as excluded below, in all Subdivisions except as stated below, are designated for cutting if they are within see below of a live tree with a larger stump diameter.

ALL SUBDIVISIONS

Cut Trees: Cut tree species will vary by subdivisions, gaps, and heavy thin areas. All other species are ghost trees. (see K-C.3.5.7# Specifications Table)

No western redcedar, hardwoods, or orange painted trees will be cut unless designated by the Forest Service.

Stump Diameters: Minimum and maximum stump diameters vary for each cut tree species by subdivision

(see K-C.3.5.7# Specifications Table).

Stump diameter is measured at 10 inches perpendicular to the bole of the tree.

Minimum stump height is 10 inches above ground level on the uphill side of the tree.

Spacing Distance: Regardless of maximum stump diameter, all cut tree species will be used for the purpose of determining spacing distance (see K-C.3.5.7# Specifications Table).

All distances are measured slope distance, outside bark stump height to outside bark stump height.

Ghost Trees: Boundary trees (marked with tags and orange paint), as well as all species not designated as cut tree species for the subdivision are ghost trees (see K-C.3.5.7# Specifications Table). Ghost trees are not to be used for spacing and are not to be cut or used to cut other trees.

Gaps: Center trees are marked with an orange band and the letter “G.” Trees larger than the maximum stump diameter, smaller than the minimum stump diameter, ghost tree species stated for the subdivision, and orange painted trees will not be cut (see K-C.3.5.7# Specifications Table).

Heavy thin (HT): Boundaries are marked with pink tags facing toward the heavy thin, blue boundary tags facing out, orange paint, and a combination of blue and pink ribbon. Trees larger than the maximum stump diameter, smaller than the minimum stump diameter, ghost tree species stated for the subdivision, and orange painted trees will not be cut (see K-C.3.5.7# Specifications Table).

Skips (No Cut Areas): Boundaries are marked with blue boundary tags facing away from the skip, orange paint, and a combination of blue and pink ribbon.

Windthrown Trees: No windthrown trees will be removed unless designated by the Forest Service. Windthrown trees are those with the root wad either exposed or partially exposed.

Individual boles of forked trees are considered to be seperate trees if they fork below 10 inches above ground level and are to be measured individually with a diameter tape at that height. They are considered to be a single tree if a diameter tape cannot be passed between them at 10 inches above ground level.

All temporary roads, skid trails, yarding corridors, and landing clearing limits shall be identified and approved per K-G.4.2# before this provision is implemented.

Species Abbreviations

DF- Douglas-fir

WH- Western Hemlock

PSF- Pacific Silver Fir

RA – Red Alder

WRC – Western Red Cedar

K-C.3.5.7# Individual Tree Desigantaion (Option 1) (6/08)

Table

(inches) Upper Stump Diameter (inches)

4A, 4B

HT

9-23 inches.

7, 7A

HT

HT

SS 26

53B, 53D

HT

SS 26

K-D.4.7# - ABNORMAL DELAY. (5/05) Unless otherwise agreed, felled timber meeting Utilization Standards shall be removed by Contractor pursuant to C.2 and shall be presented for Scaling within the time period indicated in the following removal schedule. The number of days shown are consecutive calendar days.

Failure to remove and present such timber for Scaling within the required time limits will be considered abnormal delay, subject to D.4.7.

REMOVAL SCHEDULE

K-F.1.0.1# - TEMPORARY ROAD AND LANDING CONSTRUCTION (OPTION 1). (6/10) In addition to the requirements of F.1 and G.6.3, Contractor and Forest Service will agree to the design, construction, maintenance, closure, and obliteration of all Temporary Roads.

Construction of Temporary Roads in areas shown on Contract Area Map shall be in accordance with the attached plans or criteria.

Unless otherwise agreed, if Contractor 's Operations require more than 0 cubic yards of rock for Temporary Roads, landings, or other temporary uses, such rock shall be obtained from commercial sources.

PLANS AND CRITERIA PURSUANT TO K-F.1.0.1# (OPTION 1) - TEMPORARY ROAD AND LANDING CONSTRUCTION (06/10) General. Temporary roads shall facilitate the removal of Included Timber with minimum land impact during anticipated weather and soil conditions pursuant to K-G.3.1.5#.

Contractor may elect not to build all or segments of proposed Temporary Roads if contractor can otherwise log Included Timber in accordance with contract provisions. Contractor may also propose alternate locations and/or additional Temporary Roads. Such proposals must be submitted to Forest Service in writing and approved prior to the start of construction. Forest Service makes no guarantee regarding agreement to alternate locations and/or additional Temporary Roads.

Contractor retains the final responsibility for determining the location, extent, feasibility, and suitability of all Temporary Roads. Forest Service shall not be liable for any variation in quantity, extent, location, materials, or specifications with regard to temporary roads.

Material Sources. All rock will be from a commercial source and certified weed free. Potential borrow source areas shall be identified by the Contractor and approved on the ground by Forest Service prior to development.

Borrow sources must be ripped and blasting is not allowed unless approved by the Forest Service.

Design. Temporary Roads shall be single lane with a maximum surface width necessary to accommodate logging equipment. Clearing widths shall be agreed to prior to construction and shall be 16 feet excluding curve widening and turnouts unless otherwise designated by Forest Service. Turnouts do not need to be inter-visible, but shall be of sufficient quantity on longer roads to provide safe access.

Temporary Roads shall be planned for self-balance. Full bench construction is required on slopes greater than 40 percent.

Surfacing shall be applied as necessary to provide for erosion control and to allow safe and reasonable access pursuant to K-G.3.1.5#, K-G.6.0#.

Road surface drainage shall be sufficient to control water flow and provide erosion control. Drainage management may consist of ditches, ditch relief and cross drain culverts, insloping or outsloping, surfacing, drainage dips, water bars, silt fencing, sediment traps, or a combination of methods as needed or as directed by Forest Service in writing.

Right-Of-Way. All merchantable timber within clearing limits of Temporary Roads shall be designated by Forest Service prior to felling. Timber meeting Utilization Standards shall be utilized in accordance with C.1 and C.2.

Right-of-way timber shall be felled into right-of-way clearings whenever possible. Controlled felling shall be used to ensure the direction of fall when necessary to prevent damage to property, improvements, trees designated to remain, and/or traffic.

PLANS AND CRITERIA PURSUANT TO K-F.1.0.1# (OPTION 1) - TEMPORARY ROAD AND LANDING CONSTRUCTION (06/10) (continued)

If needed for safety, Forest Service shall authorize the falling of snags and hazard trees outside of clearing limits. Felled snags and hazard trees shall not be removed unless Forest Service agrees to removal in writing.

Branches of remaining trees or shrubs inside designated clearing limits shall be limbed to a height of 14 feet above the roadbed.

Construction. All suitable material excavated within designated clearing limits shall be utilized in the construction of embankments, subgrades, shoulders, slopes, bedding, surfacing, and backfill for structures.

Excess excavation material shall be disposed of at locations designated on the Contract Area Map, or as agreed to in writing.

Woody debris from clearing and grubbing shall be disposed of in accordance with K-G.7.4.1# or according to alternate methods agreed to in writing. Such debris shall not be disposed of or scattered in such a manner that the debris could enter stream courses.

Roller compaction is not required on Temporary Roads. Contractor may elect to do so at their own expense.

Stream Crossings.

Drainages and stream channels shall be crossed by the use of culverts or bridges. Log puncheons and/or brush crossings are not permitted. Culverts or bridges shall be designed, installed and maintained to pass all anticipated stream flows, sediment, and wood likely to be encountered at the crossing during the period the structure will be in place.

Every effort shall be made to avoid crossing the stream channel with heavy equipment. Single round-trip equipment crossings of the stream channel shall be allowed for both installation and removal, if necessary.

The timing of in-stream work shall be in accordance with K-G.3.1.5#.

De-watering is required prior to work in live streams. A written de-watering plan shall be prepared prior to the start of the in-stream work that describes the method of bypass, location and construction of any coffer dams or diversion dams, the number and size of pumps to be used, and backup plans in place in case of mechanical failure or unanticipated storm events.

The de-watering system shall be designed and installed to minimize erosion and sediment delivery to watercourses and to withstand all streamflows anticipated during the construction period.