B08_140L4024R0004_Continuation_Document_0002.docx

140L4024R0004 Pecos District Fencing Project

Type of Contract: Construction, Firm Fixed Priced (FFP), Single Award Contract Area of Requirement: Chaves and Eddy County, Pecos District Office, New Mexico Type of Construction: Heavy/Highway

Proposal Submittal Information:

Site Visit: A site visit shall take place on August 19, 2024, at 0900MST. Perspective vendors shall report to BLM Carlsbad Field Office, 620 E. Greene St., Carlsbad, NM 88220. Vendors shall report to the front lobby and be met by a BLM employee. Perspective vendors are responsible for their own transportation to the BLM Carlsbad Field Office and out to the sites. Attendance is highly encouraged.

Questions Due Date: August 19, 2024, at 2:00 PM Mountain Time All questions must be submitted in writing via email to rshumate@blm.gov with subject line: RFP 140L4024R0004 – Pecos District Fencing Project. No questions will be accepted via phone calls. (See Section L below)

Proposal Due Date: September 12, 2024, at 0900AM Mountain Time (See Section L – Instructions to Offerors)

Award Selection:

Low Price Technically Acceptable (LPTA) with a tiered socio-economical evaluation preference. (See Section M – Basis for Award)

Bonds:

Electronic copy of bid bond required with proposal. No other form of bid guarantee will be accepted. (See FAR 52.228-1 and section L below for more details) Performance and payment bond required within 10 calendar days after the award (See FAR 52.228-15).

Table of Contents

SOLICITATION NO: 140L4024R0004

PROJECT DESCRIPTION: Pecos District Fencing Project

PART I – THE SCHEDULE

SECTION A: SOLICITATION / CONTRACT FORM

Refer to pages 1-3 of this solicitation package (SF1442 - Solicitation, Offer, and Award)

(END OF SECTION)

SECTION B: BID SCHEDULE

CONTRACT PRICE SCHEDULE

See Bid Schedule – listed in Section J as well

PERFORMANCE PERIOD: See clause 52.211-10 in Section I.

THIS SOLICITATION IS SET ASIDE FOR TOTAL SMALL BUSINESS.

SECTION C: SPECIFICATIONS/DRAWINGS

Specifications and drawings are attached in Section J and incorporated herein by reference.

MAPS

SECTION D: PACKAGING AND MARKING

Section Does Not Apply

SECTION E: INSPECTION AND ACCEPTANCE

CLAUSES INCORPORATED BY REFERENCE

SECTION F: DELIVERIES OR PERFORMANCE

CLAUSES INCORPORATED BY REFERENCE

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (April 1984) The Contractor shall be required to

(a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed,

(b) prosecute the work diligently, and

(c) complete the entire work ready for use not later than 126 calendar days after receipt of the notice to proceed. The time stated for completion shall include final cleanup of the premises.

(End of Clause)

SECTION G: CONTRACT ADMINISTRATION DATA

DIARS 1452.201-70 AUTHORITIES AND DELEGATIONS (September 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

(End of clause)

G-1 ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INVOICE PROCESSING PLATFORM (IPP)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

1. Invoice date and Government Contract Number

2. Billing period specified with beginning and ending dates. The beginning date must not be later than the completion date or within any previous billing dates.

3. The accounting must follow the approved schedule of values as described in the specification attachment.

4. Total amount due for the billing period

5. Certification of Progress Payment

6. Payrolls (Mail weekly)

7. Substantiation of Subcontractor Payment

8. Limitations on Subcontracting Worksheet with final payment request

9. 52.223-9 Certification with final payment request.

10. A Release of Claims (See 1452.204-70) with a request for final payment.

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

G-2 LOCAL INTERNET PAYMENT PLATFORM (IPP) HOTLINE

To check payment status, contact the Payment Hotline at 877-480-9724 or 303-236-2850. You will need to leave a message with the following information:

1. Company Name

2. Contract Number

3. Invoice Number

4. Invoice Amount

5. A brief description of why you are calling

6. Your contact information

If you do not receive a callback from the Payment Hotline within 72 hours, please contact the Contract Officer with the day and time you contacted the Payment Hotline.

G-3 GOVERNMENT POINTS OF CONTACT

Contracting Officer (Primary POC):

Ronald Dean Shumate BLM – New Mexico State Office 301 Dinosaur Trail Santa Fe, NM 87508 rshumate@blm.gov

G-5 CONSTRUCTION CONTRACT ADMINISTRATION

FAR 36.211(b) requires agencies provide description of policies and procedures that apply to definitization of equitable adjustments for change orders under construction contracts and data on the time required to definitize equitable adjustments for change orders under construction contracts. This information can be found at: https://www.doi.gov/pam/acquisition/policy/constructioncontract.

SECTION H: SPECIAL CONTRACT REQUIREMENTS

H-1 WORK HOURS

The performance period established for this contract is based upon all work being conducted during regular office hours which are 7:00 am to 6:00 pm, Monday through Friday, excluding government holidays. If the contractor desires to carry on work outside regular hours (Saturdays, Sundays, government holidays), a written request must be submitted to the contracting officer in sufficient time allow satisfactory arrangements to be made by the government for access to the work site and inspection.

H-2 FIRE DANGER SEASON

If the contracting officer representative (COR) allows the contractor to continue work during periods of declared fire danger or season, the contractor shall comply with all applicable state laws relating to fire prevention and with all special conditions of work as directed by the COR.

H-3 DRAWINGS

(a) Typical Drawings. Any drawings titled typical are general only and dimensions of each structure will be fixed by the contracting officer to adapt the design to existing conditions at the structure location.

(b) Reduced Size Drawings. Any drawings identified as "REDUCED SIZE DRAWINGS" appearing in the solicitation are photographically reduced in size. Accordingly, measurements and dimensions should not be taken or be based on any numerical scales shown. Prospective offerors desiring to review a copy of the full-size drawings may contact the primary contracting office point-of-contact contracting identified in the solicitation.

H-4 PRESERVATION OF HISTORICAL AND ARCHEOLOGICAL DATA

(a) The Historic and Archeological Data Preservation Act of 1974, provides for the preservation of historical and archeological data that might otherwise be lost as the result of alterations to the terrain caused by a federal or federally licensed activity or program.

(b) If, in connection with operations under this contract, the contractor, subcontractors, or the employees of any of them, discovers, encounters or becomes aware of any possible historical or archeological data, objects or sites of cultural value on the project area, such as historical ruins, graves or grave markers, fossils, or artifacts, the contractor shall immediately suspend all operations in the vicinity of the cultural value and shall notify the contracting officer in writing, giving the location and nature of the findings. No objects of cultural resource value may be removed.

(c) Where appropriate by reason of discovery, the contracting officer may order delays in the time of performance and/or changes in the work. If such delays and/or changes are ordered, the time of performance and contract price shall be adjusted in accordance with the Changes clause.

(d) The contractor will be responsible for protecting the cultural resources within the affected area from damage. In addition, the contractor will be liable for all damage to the identified cultural resources caused by their actions or the actions of their agents or representatives. The contractor shall immediately notify the contracting officer or his representative if any damage occurs to any cultural resource and immediately suspend work in the area in which damage has occurred until authorized to proceed.

H-5 SAFETY AND QUALITY CONTROL PLAN

If requested, within 10-days following contract award, the contractor shall provide effective quality control and safety plans for acceptance by the government.

H-6 FEDERAL HOLIDAYS

The following federal holidays are observed, to include those proclaimed by executive order:

Christmas Day

H-7 LIMITATIONS ON SUBCONTRACTING REPORTING

In accordance with 52.219-14 Limitations on Subcontracting, the prime contractor must perform at least 15% of the cost of the contract, excluding the cost of materials with its own employees and employees of a similarly situated subcontractor. A similarly situated subcontractor is a small business concern subcontractor that is a participant of the same SBA program that qualified the prime contractor as an eligible offeror and awardee of the contract. The contractor is responsible for ensuring compliance with the Limitations on Subcontracting clause.

At the conclusion of the period of performance and prior to final payment, the contractor shall submit a limitations on subcontracting report directly to the contracting officer. The following information is required as part of the report:

1) The total amount paid to the prime during the performance period broken out by labor and materials

2) List of similarly situated subcontractors and the amounts paid to each during the performance period broken out by labor and materials 3) List of any other subcontractors and the amounts paid to each during the performance period broken out by labor and materials

If the contracting officer review of the report finds that the contractor is not in compliance for the period of performance, the contractor will be notified in writing. Penalties for failure to comply are described in 13 CFR 125.6(h) which states:

Whoever violates the requirements set forth in paragraph (a) of this section shall be subject to the penalties prescribed in 15 U.S.C. 645(d), except that the fine shall be treated as the greater of $500,000 or the dollar amount spent, in excess of permitted levels, by the entity on subcontractors. A party's failure to comply with the spirit and intent of a subcontract with a similarly situated entity may be considered a basis for debarment on the grounds, including but not limited to, that the parties have violated the terms of a government contract or subcontract pursuant to FAR 9.406-2(b)(1)(i) (48 CFR 9.406-2(b)(1)(i)).

H-8 UNAUTHORIZED PERSONNEL

The contractor shall inform all personnel working under his jurisdiction (including subcontractor and visiting supplier personnel) that access to restricted areas outside of the immediate work area; excluding direct haul and access routes, contracting and Civil Engineering offices and points of supply and storage; is prohibited. Circulation of said personnel will be limited to official business only. Persons in violation of the above will be apprehended and appropriately disciplined.

H-9 HAZARDOUS MATERIALS

Any material suspected of being hazardous that is encountered during performance of a project shall immediately be brought to the attention of the Contracting Officer, at which time a determination will be made as to whether hazardous material testing shall be performed. If the Contracting Officer directs the contractor to perform tests, and/or the material is found to be of a hazardous nature requiring additional protective measures, a contract modification may be required, subject to equitable adjustment under the terms of the contract. The contractor is advised that friable and/or non-friable asbestos-containing material may be encountered in project areas. Friable asbestos-containing material is any material that contains more than one percent asbestos by weight, and that hand pressure can crumble, pulverize or reduce to powder when dry. Non-friable asbestos containing materials are materials in which asbestos fibers are bound by a matrix material, saturation, impregnation or coating.

Non-friable asbestos-containing materials do not normally release airborne asbestos fiber during routine handling and end-use. However, excessive fiber concentrations may be produced during uncontrolled abrading, sanding, drilling, cutting, machining, removal, demolition, or other similar activities. 29 CFR 1910.1001 shall be referenced in the event asbestos-containing materials are encountered. Friable asbestos-containing materials are not authorized for use in new construction or maintenance projects.

H-10 CONSTRUCTION WAGE RATES APPLICABLE TO TRUCK DRIVERS

29 CFR 5.2(j) limits coverage of construction contractor or subcontractor employees performing as truck drivers under the Davis-Bacon Act (FAR 52.222-6) to only their time spent directly upon the "site of the work" or when hauling between the site of the work and a facility which is dedicated to and located in the proximity of the actual construction location. Other transportation of materials or supplies to or from the site of work by employees of the construction contractor or subcontractor is not “construction” at the site of work and accordingly is not subject to the Davis-Bacon Act.

(END OF SECTION & PART I)

PART II – CONTRACT CLAUSES

SECTION I: CONTRACT CLAUSES

CLAUSES INCORPORATED BY REFERENCE

52.252-2 CLAUSES INCORPORATED BY REFERENCE (February 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address (es): FAR | Acquisition.GOV and DIAR | Acquisition.GOV.

Debarred, Suspended, or Proposed for Debarment November 2021

October 2018

or Pricing Data – Modifications November 2021

April 2015

Contracts

August 2018

January 1997

December 1991

April 1984

September 1996

52.204-25 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE SERVICES OR EQUIPEMENT (November 2021)

(a) Definitions. As used in this clause— Backhaul means intermediate links between the core network, or backbone network, and the small subnetworks at the edge of the network (e.g., connecting cell phones/towers to the core telephone network). Backhaul can be wireless (e.g., microwave) or wired (e.g., fiber optic, coaxial cable, Ethernet).

Covered foreign country means The People’s Republic of China.

Covered telecommunications equipment or services means–

(1) Telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities);

(2) For the purpose of public safety, security of Government facilities, physical security surveillance of critical infrastructure, and other national security purposes, video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities);

(3) Telecommunications or video surveillance services provided by such entities or using such equipment; or

(4) Telecommunications or video surveillance equipment or services produced or provided by an entity that the Secretary of Defense, in consultation with the Director of National Intelligence or the Director of the Federal Bureau of Investigation, reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country.

Critical technology means–

(1) Defense articles or defense services included on the United States Munitions List set forth in the International Traffic in Arms Regulations under subchapter M of chapter I of title 22, Code of Federal Regulations;

(2) Items included on the Commerce Control List set forth in Supplement No. 1 to part 774 of the Export Administration Regulations under subchapter C of chapter VII of title 15, Code of Federal Regulations, and controlled-

(i) Pursuant to multilateral regimes, including for reasons relating to national security, chemical and biological weapons proliferation, nuclear nonproliferation, or missile technology; or

(ii) For reasons relating to regional stability or surreptitious listening;

(3) Specially designed and prepared nuclear equipment, parts and components, materials, software, and technology covered by part 810 of title 10, Code of Federal Regulations (relating to assistance to foreign atomic energy activities);

(4) Nuclear facilities, equipment, and material covered by part 110 of title 10, Code of Federal Regulations (relating to export and import of nuclear equipment and material);

(5) Select agents and toxins covered by part 331 of title 7, Code of Federal Regulations, part 121 of title 9 of such Code, or part 73 of title 42 of such Code; or

(6) Emerging and foundational technologies controlled pursuant to section 1758 of the Export Control Reform Act of 2018 (50 U.S.C. 4817).

Interconnection arrangements means arrangements governing the physical connection of two or more networks to allow the use of another's network to hand off traffic where it is ultimately delivered (e.g., connection of a customer of telephone provider A to a customer of telephone company B) or sharing data and other information resources.

Reasonable inquiry means an inquiry designed to uncover any information in the entity's possession about the identity of the producer or provider of covered telecommunications equipment or services used by the entity that excludes the need to include an internal or third-party audit.

Roaming means cellular communications services (e.g., voice, video, data) received from a visited network when unable to connect to the facilities of the home network either because signal coverage is too weak or because traffic is too high.

Substantial or essential component means any component necessary for the proper function or performance of a piece of equipment, system, or service.

(b) Prohibition. (1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. The Contractor is prohibited from providing to the Government any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract, or extending or renewing a contract, with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract.

(c) Exceptions. This clause does not prohibit contractors from providing—

(1) A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(2) Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(d) Reporting requirement. (1) In the event the Contractor identifies covered telecommunications equipment or services used as a substantial or essential component of any system, or as critical technology as part of any system, during contract performance, or the Contractor is notified of such by a subcontractor at any tier or by any other source, the Contractor shall report the information in paragraph (d)(2) of this clause to the Contracting Officer, unless elsewhere in this contract are established procedures for reporting the information; in the case of the Department of Defense, the Contractor shall report to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (d)(1) of this clause

(i) Within one business day from the date of such identification or notification: the contract number; the order number(s), if applicable; supplier name; supplier unique entity identifier (if known); supplier Commercial and Government Entity (CAGE) code (if known); brand; model number (original equipment manufacturer number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the information in paragraph (d)(2)(i) of this clause: any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of covered telecommunications equipment or services, and any additional efforts that will be incorporated to prevent future use or submission of covered telecommunications equipment or services.

(e) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (e) and excluding paragraph (b)(2), in all subcontracts and other contractual instruments, including subcontracts for the acquisition of commercial products or commercial services.

52.211-12 LIQUIDATED DAMAGES-CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of 198.80 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause) 52.211-18 VARIATION IN ESTIMATED QUANTITY (April 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

52.219-14 LIMITATIONS ON SUBCONTRACTING (October 2022) (DEVIATION OCT 2022)

(a) This clause does not apply to the unrestricted portion of a partial set-aside.

(b) Definition. Similarly situated entity, as used in this clause, means a first-tier subcontractor, including an independent contractor, that—

(1) Has the same small business program status as that which qualified the prime contractor for the award (e.g., for a small business set-aside contract, any small business concern, without regard to its socioeconomic status); and

(2) Is considered small for the size standard under the North American Industry Classification System (NAICS) code the prime contractor assigned to the subcontract.

(c) Applicability. This clause applies only to—

(1) Contracts that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(2) Part or parts of a multiple-award contract that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(3) Contracts that have been awarded on a sole-source basis in accordance with subparts 19.8, 19.13, 19.14, and 19.15;

(4) Orders expected to exceed the simplified acquisition threshold and that are—

(i) Set aside for small business concerns under multiple-award contracts, as described in 8.405-5 and 16.505(b)(2)(i)(F); or

(ii) Issued directly to small business concerns under multiple-award contracts as described in 19.504(c)(1)(ii);

(5) Orders, regardless of dollar value, that are—

(i) Set aside in accordance with subparts 19.8, 19.13, 19.14, or 19.15 under multiple-award contracts, as described in 8.405-5 and 16.505(b)(2)(i)(F); or

(ii) Issued directly to concerns that qualify for the programs described in subparts 19.8, 19.13, 19.14, or 19.15 under multiple-award contracts, as described in 19.504(c)(1)(ii); and

(6) Contracts using the HUBZone price evaluation preference to award to a HUBZone small business concern unless the concern waived the evaluation preference.

(d) Independent contractors. An independent contractor shall be considered a subcontractor.

(e) Limitations on subcontracting. By submission of an offer and execution of a contract, the Contractor agrees to the following requirements in the performance of a contract assigned a North American Industry Classification System (NAICS) code applicable to this contract:

(1) Services (except construction). It will not pay more than 50 percent of the amount paid by the Government for contract performance, excluding certain other direct costs and certain work performed outside the United States (see paragraph (e)(1)(i)), to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor’s 50 percent subcontract amount that cannot be exceeded. When a contract includes both services and supplies, the 50 percent limitation shall apply only to the service portion of the contract.

(i) The following services may be excluded from the 50 percent limitation:

(A) Other direct costs, to the extent they are not the principal purpose of the acquisition and small business concerns do not provide the service. Examples include airline travel, work performed by a transportation or disposal entity under a contract assigned the environmental remediation NAICS code (562910), cloud computing services, or mass media purchases.

(B) Work performed outside the United States on awards made pursuant to the Foreign Assistance Act of 1961, or work performed outside the United States required to be performed by a local contractor.

(2) Supplies (other than procurement from a nonmanufacturer of such supplies). It will not pay more than 50 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor’s 50 percent subcontract amount that cannot be exceeded. When a contract includes both supplies and services, the 50 percent limitation shall apply only to the supply portion of the contract.

(3) General construction. It will not pay more than 85 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor’s 85 percent subcontract amount that cannot be exceeded.

(4) Construction by special trade contractors. It will not pay more than 75 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor’s 75 percent subcontract amount that cannot be exceeded.

(f) The Contractor shall comply with the limitations on subcontracting as follows:

(1) For contracts, in accordance with paragraphs (c)(1), (2), (3) and (6) of this clause – [Contracting Officer check as appropriate.] X By the end of the base term of the contract and then by the end of each subsequent option period; or __ By the end of the performance period for each order issued under the contract.

(2) For orders, in accordance with paragraphs (c)(4) and (5) of this clause, by the end of the performance period for the order.

(g) A joint venture agrees that, in the performance of the contract, the applicable percentage specified in paragraph (e) of this clause will be performed by the aggregate of the joint venture participants.

52.225-9 BUY AMERICAN - CONSTRUCTION MATERIALS (October 2022)

(a) Definitions. As used in this clause— Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is–

(i) A commercial product (as defined in paragraph (1) of the definition of “commercial product” at Federal Acquisition Regulation (FAR) 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

"Construction material" means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means—

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Domestic construction material means—

(1) For construction material that does not consist wholly or predominantly of iron or steel or a combination of both-

(i) An unmanufactured construction material mined or produced in the United States; or

(ii) A construction material manufactured in the United States, if–

(A) The cost of its components mined, produced, or manufactured in the United States exceeds 55 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic. Components of unknown origin are treated as foreign; or

(B) The construction material is a COTS item; or

(2) For construction material that consists wholly or predominantly of iron or steel or a combination of both, a construction material manufactured in the United States if the cost of foreign iron and steel constitutes less than 5 percent of the cost of all components used in such construction material. The cost of foreign iron and steel includes but is not limited to the cost of foreign iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the construction material and a good faith estimate of the cost of all foreign iron or steel components excluding COTS fasteners. Iron or steel components of unknown origin are treated as foreign. If the construction material contains multiple components, the cost of all the materials used in such construction material is calculated in accordance with the definition of "cost of components".

Fastener means a hardware device that mechanically joins or affixes two or more objects together. Examples of fasteners are nuts, bolts, pins, rivets, nails, clips, and screws.

Foreign construction material means a construction material other than a domestic construction material.

Foreign iron and steel means iron or steel products not produced in the United States. Produced in the United States means that all manufacturing processes of the iron or steel must take place in the United States, from the initial melting stage through the application of coatings, except metallurgical processes involving refinement of steel additives. The origin of the elements of the iron or steel is not relevant to the determination of whether it is domestic or foreign.

Predominantly of iron or steel or a combination of both means that the cost of the iron and steel content exceeds 50 percent of the total cost of all its components. The cost of iron and steel is the cost of the iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the product and a good faith estimate of the cost of iron or steel components excluding COTS fasteners.

Steel means an alloy that includes at least 50 percent iron, between 0.02 and 2 percent carbon, and may include other elements.

"United States" means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference. (1) This clause implements 41 U.S.C.chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the domestic content test of the Buy American statute is waived for construction material that is a COTS item, except that for construction material that consists wholly or predominantly of iron or steel or a combination of both, the domestic content test is applied only to the iron and steel content of the construction materials, excluding COTS fasteners. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial product or to the construction materials or components listed by the Government as follows: none

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that-

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 20 percent;

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute. (1) (i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including-

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination…