A_01_PANG_Alert_Hgr_Type_B3_Final_Spec_Book_20140321.pdf

Project Manual

For

Portland Air National Guard Base

Construct Alert Hangar Bay

Project No. TQKD129072

Mead & Hunt, Inc.

3142100-121766.01

Prepared for:

Portland National Guard Base Portland, Oregon

Prepared by:

Type B3 FINAL

March 21, 2014

Portland Air National Guard Base 21 March 2014 Construct Alert Hangar Bay - Type B3 Final

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 14 00 WORK RESTRICTIONS

01 30 00 ADMINISTRATIVE REQUIREMENTS

01 32 01.00 10 PROJECT SCHEDULE

01 32 16.00 20 CONSTRUCTION PROGRESS DOCUMENTATION

01 33 00 SUBMITTAL PROCEDURES

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.10 20 QUALITY CONTROL FOR MINOR CONSTRUCTION

01 45 35 SPECIAL INSPECTIONS

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 57 20.00 10 ENVIRONMENTAL PROTECTION

01 57 23 TEMPORARY STORM WATER POLLUTION CONTROL

01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT

01 78 00 CLOSEOUT SUBMITTALS

01 78 23 OPERATION AND MAINTENANCE DATA

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION

DIVISION 03 - CONCRETE

03 11 13.00 10 STRUCTURAL CAST-IN-PLACE CONCRETE FORMING

03 15 00.00 10 CONCRETE ACCESSORIES

03 20 00.00 10 CONCRETE REINFORCING

03 30 00.00 10 CAST-IN-PLACE CONCRETE

03 39 00.00 10 CONCRETE CURING

DIVISION 05 - METALS

05 12 00 STRUCTURAL STEEL

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 41 13 METAL ROOF PANELS

07 42 13 METAL WALL PANELS

07 92 00 JOINT SEALANTS

DIVISION 08 - OPENINGS

08 11 00 HOLLOW METAL DOORS AND FRAMES

08 34 16.20 VERTICAL LIFT FABRIC DOORS

08 71 00 DOOR HARDWARE

DIVISION 09 - FINISHES

09 06 90 COLOR SCHEDULE

09 67 23 RESINOUS FLOORING

09 90 00 PAINTS AND COATINGS

DIVISION 10 - SPECIALTIES

10 14 00.20 INTERIOR SIGNAGE

10 81 13 BIRD CONTROL BARRIER AND DEVICES

PROJECT TABLE OF CONTENTS Page 1

DIVISION 13 - SPECIAL CONSTRUCTION

13 34 19 METAL BUILDING SYSTEMS

DIVISION 21 - FIRE SUPPRESSION

21 13 00 FIRE SUPPRESSION SPRINKLER SYSTEM

21 13 40 HEF FOAM FIRE PROTECTION

DIVISION 26 - ELECTRICAL

26 05 00.00 40 COMMON WORK RESULTS FOR ELECTRICAL

26 41 01.00 10 LIGHTNING PROTECTION SYSTEM

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 16 00.00 20 BASIC INTRUSION DETECTION SYSTEMS (IDS)

28 31 00 FIRE ALARM FOR HEF RELEASING

28 50 05 ALERTING SYSTEM

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 01 11.51 PAINT REMOVAL FROM AIRFIELD PAVEMENTS

32 01 16.17 COLD MILLING OF BITUMINOUS PAVEMENTS

32 11 33 CEMENT STABILIZED BASE COURSE AT AIRFIELDS AND ROADS

32 12 10 BITUMINOUS TACK AND PRIME COATS

32 12 15.13 HOT-MIX ASPHALT AIRFIELD PAVING

32 17 23.00 20 PAVEMENT MARKINGS

32 31 13.53 HIGH-SECURITY CHAIN LINK FENCES AND GATES

DIVISION 33 - UTILITIES

33 11 00 WATER DISTRIBUTION

33 40 00 STORM DRAINAGE UTILITIES

33 51 15 NATURAL-GAS / GAS DISTRIBUTION

DIVISION 34 - TRANSPORTATION

34 43 00.00 20 AIRFIELD LIGHTING

DIVISION 49 -

49 00 00 APPENDIX A - GEOTECHNICAL REPORT

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 2

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00

SUMMARY OF WORK

08/11

PART 1 GENERAL

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

1.1.2 Location

1.2 OCCUPANCY OF PREMISES

1.3 EXISTING WORK

1.4 ON-SITE PERMITS

1.5 LOCATION OF UNDERGROUND UTILITIES

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

SECTION 01 11 00 Page 1

SECTION 01 11 00

SUMMARY OF WORK

08/11

PART 1 GENERAL

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

The work includes but is not limited to: a pre-engineered metal building, reinforced concrete foundations, ashpalt and concrete pavement, airfield and other site lighitng, electrical, fire protection, a high expansion foam system, vertical lift fabric door and utility work. and incidental related work.

1.1.2 Location

The work shall be located at the Portland Air National Guard Base in Portland, Oregon, approximately as indicated. The exact location will be shown by the Contracting Officer.

1.2 OCCUPANCY OF PREMISES

Adjacent building(s) and Site will be occupied during performance of work under this Contract.

Before work is started, the Contractor shall arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.3 EXISTING WORK

In addition to "FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements":

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work shall be in a condition equal to or better than that which existed before new work started.

1.4 ON-SITE PERMITS

Notify the Contracting Officer at least 72 hours prior to starting excavation work. The Contractor must obtain from the Contracting Officer a completed AF 103 Form. The Contractor must retain this form until completion of work. Contractor is responsible for marking and verifying all utilities not marked.

1.5 LOCATION OF UNDERGROUND UTILITIES

The Contractor shall scan the construction site with electromagnetic or

SECTION 01 11 00 Page 2 sonic equipment, and mark the surface of the ground or paved surface where existing underground utilities are discovered. Verify the elevations of existing piping, utilities,and any type of underground or encased obstruction not indicated to be specified or removed but indicated or discovered during scanning in locations to be traversed by piping, ducts, and other work to be conducted or installed. Verify elevations before installing new work closer than nearest manhole or other structure at which an adjustment in grade can be made.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

SECTION 01 11 00 Page 3

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 14 00

WORK RESTRICTIONS

11/11

PART 1 GENERAL

1.1 SPECIAL SCHEDULING REQUIREMENTS

1.2 CONTRACTOR ACCESS AND USE OF PREMISES

1.2.1 Installation Regulations

1.2.1.1 Subcontractors and Personnel Contacts

1.2.1.2 Identification Badges and Installation Access

1.2.1.3 Personnel Entry Approval

1.2.1.4 No Smoking Policy

1.2.2 Working Hours

1.2.3 Work Outside Regular Hours

1.2.4 Occupied Buildings

1.2.5 Utility Cutovers and Interruptions

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 14 00 Page 1

SECTION 01 14 00

WORK RESTRICTIONS

11/11

PART 1 GENERAL

1.1 SPECIAL SCHEDULING REQUIREMENTS

c. The non-hangar portions of the adjacent Building 210 will remain in operation during the entire construction period. The Contractor must conduct his operations so as to cause the least possible interference with normal operations of the adjacent Buidings.

d. Permission to interrupt any roads, taxiways and/or utility service must be requested in writing a minimum of 21 calendar days prior to the desired date of interruption.

1.2 CONTRACTOR ACCESS AND USE OF PREMISES

1.2.1 Installation Regulations

Ensure that Contractor personnel employed on the Installation become familiar with and obey regulations including safety, fire, traffic and security regulations. Keep within the limits of the work and avenues of ingress and egress. Wear hard hats in designated areas. Do not enter any restricted areas unless required to do so and until cleared for such entry. Mark Contractor equipment for identification.

1.2.1.1 Subcontractors and Personnel Contacts

Provide a list of contact personnel of the Contractor and subcontractors including addresses and telephone numbers for use in the event of an emergency. As changes occur and additional information becomes available, correct and change the information contained in previous lists.

1.2.1.2 Identification Badges and Installation Access

Application for and use of badges will be as directed.

1.2.1.3 Personnel Entry Approval

Failure to obtain entry approval will not affect the contract price or time of completion.

1.2.1.4 No Smoking Policy

Smoking is prohibited within and outside of all buildings except in designated smoking areas in accordance with installation regulations..

This applies to existing buildings, buildings under construction and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer will identify designated smoking areas.

1.2.2 Working Hours

Regular working hours are between the hours of 7:00a.m. and 4:00p.m., SECTION 01 14 00 Page 2

Monday through Friday, excluding Government holidays.

1.2.3 Work Outside Regular Hours

Work outside regular working hours requires Contracting Officer approval.

The Contractor shall provide justification for this work outside of regular working hours. If approved by the Contracting Officer, the contractor may be required to compensate the government for all additional personnel or services it must perform to accommodate such work, unless such work is requried for utility cutovers. Make application 15 calendar days prior to such work to allow arrangements to be made by the Government for inspecting the work in progress

1.2.4 Occupied Buildings

The Contractor shall be working around existing buildings which are occupied. Do not enter the buildings without prior approval of the Contracting Officer.

The existing buildings and their contents must be kept secure at all times. Provide temporary closures as required to maintain security as directed by the Contracting Officer.

1.2.5 Utility Cutovers and Interruptions

a. Coordinate utility cutovers and interruptions with the Contracting Officer. This may require work after normal working hours or on Saturdays, Sundays, and Government holidays. Conform to procedures required in the paragraph "Work Outside Regular Hours."

b. Ensure that new utility lines are complete, except for the connection, before interrupting existing service.

c. Interruption to water, sanitary sewer, storm sewer, telephone service, electric service, air conditioning, heating, and fire alarm, are considered utility cutovers pursuant to the paragraph entitled "Work Outside Regular Hours."

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 14 00 Page 3

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 30 00

ADMINISTRATIVE REQUIREMENTS

11/11

PART 1 GENERAL

1.1 SUBMITTALS

1.2 PROGRESS AND COMPLETION PICTURES

1.3 MINIMUM INSURANCE REQUIREMENTS

1.4 SUPERVISION

1.5 PRECONSTRUCTION CONFERENCE

1.6 AVAILABILITY OF CADD DRAWING FILES

1.7 ELECTRONIC MAIL (E-MAIL) ADDRESS

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 30 00 Page 1

SECTION 01 30 00

ADMINISTRATIVE REQUIREMENTS

11/11

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Progress and completion pictures; G Project Schedule; CPM and AF3064 and AF 3065; G Demolition Plan; G AF66, Material Submittal Log with completion dates; G Requests for substitution; G List of subcontractors; G Schedule of Values; G Insurance and Performance Payment Bonds; G Quality Control Plan; G Waste Management Plan; G MSDS Sheets Initial Base Access List

1.2 PROGRESS AND COMPLETION PICTURES

Photographically document site conditions prior to start of construction operations. Provide monthly, and within one month of the completion of work, digital photographs, showing the sequence and progress of work.

Take a minimum of 20 digital photographs each week throughout the entire project from a minimum of ten views. Submit a view location sketch indicating points of view. Submit with the monthly invoice on a CD-R, cumulative of all photos to date. Indicate photographs demonstrating environmental procedures. Photographs for each month shall be in a separate monthly directory and each file shall be named to indicate its location on the view location sketch. The view location sketch shall also be provided on the CD as digital file. All file names shall include a date designator. Cross reference submittals in the appropriate daily report.

Photographs shall be provided for unrestricted use by the Government.

1.3 MINIMUM INSURANCE REQUIREMENTS

Procure and maintain during the entire period of performance under this contract the following minimum insurance coverage:

a. Comprehensive general liability: $500,000 per occurrence

b. Automobile liability: $200,000 per person, $500,000 per occurrence for bodily injury, $20,000 per occurrence for property damage

SECTION 01 30 00 Page 2

c. Workmen's compensation as required by Federal and State workers' compensation and occupational disease laws.

d. Employer's liability coverage of $100,000, except in States where workers compensation may not be written by private carriers,

e. Others as required by Solicitation.

1.4 SUPERVISION

Have at least one qualified supervisor capable of reading, writing, and conversing fluently in the English language on the job site during working hours. In addition, if a Quality Control (QC) representative is required on the contract, then that individual shall also have fluent English communication skills.

1.5 PRECONSTRUCTION CONFERENCE

After award of the contract but prior to commencement of any work at the site, meet with the Contracting Officer to discuss and develop a mutual understanding relative to the administration of the safety program, preparation of the schedule of prices or earned value report, shop drawings, and other submittals, scheduling programming, prosecution of the work, and clear expectations of the "Interim DD Form 1354" Submittal.

Major subcontractors who will engage in the work shall also attend.

Preconstruction conference shall comply with FAR 52.236-26

At a minimum, the Contractor shall submit for government review and comment all of the preconstruction submittals noted above at the preconstruction conference, except for progress and completion photos (if required).

Initial base access list shall include the name, company, driver's license number and last four digits of social security number for those personnel that will initially require base access

1.6 AVAILABILITY OF CADD DRAWING FILES

After award and upon request, the electronic "Computer-Aided Drafting and Design (CADD)" drawing files will only be made available to the Contractor for use in preparation of construction data related to the referenced contract subject to the following terms and conditions.

Data contained on these electronic files shall not be used for any purpose other than as a convenience in the preparation of construction data for the referenced project. Any other use or reuse shall be at the sole risk of the Contractor and without liability or legal exposure to the Government.

The Contractor shall make no claim and waives to the fullest extent permitted by law, any claim or cause of action of any nature against the Government, its agents or sub consultants that may arise out of or in connection with the use of these electronic files. The Contractor shall, to the fullest extent permitted by law, indemnify and hold the Government harmless against all damages, liabilities or costs, including reasonable attorney's fees and defense costs, arising out of or resulting from the use of these electronic files.

These electronic CADD drawing files are not construction documents.

Differences may exist between the CADD files and the corresponding construction documents. The Government makes no representation regarding

SECTION 01 30 00 Page 3 the accuracy or completeness of the electronic CADD files, nor does it make representation to the compatibility of these files with the Contractors hardware or software. In the event that a conflict arises between the signed and sealed construction documents prepared by the Government and the furnished CADD files, the signed and sealed construction documents shall govern. The Contractor is responsible for determining if any conflict exists. Use of these CADD files does not relieve the Contractor of duty to fully comply with the contract documents, including and without limitation, the need to check, confirm and coordinate the work of all contractors for the project.

If the Contractor uses, duplicates and/or modifies these electronic CADD files for use in producing construction drawings and data related to this contract, all previous indicia of ownership (seals, logos, signatures, initials and dates) shall be removed.

1.7 ELECTRONIC MAIL (E-MAIL) ADDRESS

The Contractor shall establish and maintain electronic mail (e-mail) capability along with the capability to open various electronic attachments in Microsoft, Adobe Acrobat, and other similar formats. Within 10 days after contract award, the Contractor shall provide the Contracting Officer a single (only one) e-mail address for electronic communications from the Contracting Officer related to this contract including, but not limited to contract documents, invoice information, request for proposals, and other correspondence. The Contracting Officer may also use email to notify the Contractor of base access conditions when emergency conditions warrant, such as hurricanes, terrorist threats, etc. Multiple email address will not allowed.

It is the Contractor's responsibility to make timely distribution of all Contracting Officer initiated e-mail with its own organization including field office(s). The Contractor shall promptly notify the Contracting Officer, in writing, of any changes to this email address.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 30 00 Page 4

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 32 01.00 10

PROJECT SCHEDULE

08/08

PART 1 GENERAL

1.1 SUBMITTALS

PART 2 PRODUCTS

PART 3 EXECUTION

3.1 GENERAL REQUIREMENTS

3.1.1 Approved Project Schedule

3.1.2 Schedule Status Reports

3.1.3 Default Terms

3.2 BASIS FOR PAYMENT AND COST LOADING

3.3 PROJECT SCHEDULE DETAILED REQUIREMENTS

3.3.1 Critical Path Method

3.3.2 Level of Detail Required

3.3.2.1 Activity Durations

3.3.2.2 Procurement Activities

3.4 REQUESTS FOR TIME EXTENSIONS

3.4.1 Justification of Delay

3.5 PROGRESS MEETINGS

SECTION 01 32 01.00 10 Page 1

SECTION 01 32 01.00 10

PROJECT SCHEDULE

08/08

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Project Schedule; G

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

3.1 GENERAL REQUIREMENTS

Prepare for approval a Project Schedule, as specified herein, pursuant to the Contract Clause, SCHEDULE FOR CONSTRUCTION CONTRACTS. Show in the schedule the sequence in which the Contractor proposes to perform the work and dates on which the Contractor contemplates starting and completing all schedule activities. The scheduling of the entire project is required.

Contractor management personnel shall actively participate in its development. Subcontractors and suppliers working on the project shall also contribute in developing and maintaining an accurate Project Schedule. Provide a schedule that is a forward planning as well as a project monitoring tool.

3.1.1 Approved Project Schedule

Use the approved Project Schedule to measure the progress of the work and to aid in evaluating time extensions. Make the schedule cost loaded and activity coded. The schedule will provide the basis for all progress payments. If the Contractor fails to submit any schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

3.1.2 Schedule Status Reports

Provide a Schedule Status Report on at least a monthly basis. If, in the opinion of the Contracting Officer, the Contractor falls behind the approved schedule, take steps necessary to improve its progress including those that may be required by the Contracting Officer, without additional cost to the Government. In this circumstance, the Contracting Officer may require the Contractor to increase the number of shifts, overtime operations, days of work, and/or the amount of construction plant, and to

SECTION 01 32 01.00 10 Page 2 submit for approval any supplementary schedule or schedules as the Contracting Officer deems necessary to demonstrate how the approved rate of progress will be regained.

3.1.3 Default Terms

Failure of the Contractor to comply with the requirements of the Contracting Officer shall be grounds for a determination, by the Contracting Officer, that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the Contracting Officer may terminate the Contractor's right to proceed with the work, or any separable part of it, in accordance with the default terms of the contract.

3.2 BASIS FOR PAYMENT AND COST LOADING

Use the schedule as the basis for determining contract earnings during each update period and therefore the amount of each progress payment. Lack of an approved schedule update, or qualified scheduling personnel, will result in the inability of the Contracting Officer to evaluate contract earned value for the purposes of payment. Failure of the Contractor to provide all required information will result in the disapproval of the preliminary, initial and subsequent schedule updates. In the event schedule revisions are directed by the Contracting Officer and those revisions have not been included in subsequent revisions or updates, the Contracting Officer may hold retainage up to the maximum allowed by contract, each payment period, until such revisions to the Project Schedule have been made. Activity cost loading shall be reasonable, as determined by the Contracting Officer. The aggregate value of all activities coded to a contract CLIN shall equal the value of the CLIN on the Schedule.

3.3 PROJECT SCHEDULE DETAILED REQUIREMENTS

The computer software system utilized to produce and update the Project Schedule shall be capable of meeting all requirements of this specification.

3.3.1 Critical Path Method

Use the Critical Path Method (CPM) of network calculation to generate the Project Schedule.

3.3.2 Level of Detail Required

Develop the Project Schedule to an appropriate level of detail. Failure to develop the Project Schedule to an appropriate level of detail, as determined by the Contracting Officer, will result in its disapproval. The Contracting Officer will consider, but is not limited to, the following characteristics and requirements to determine appropriate level of detail:

3.3.2.1 Activity Durations

Reasonable activity durations are those that allow the progress of ongoing activities to be accurately determined between update periods. Less than 2 percent of all non-procurement activities shall have Original Durations (OD) greater than 20 work days or 30 calendar days. Procurement activities are defined herein.

SECTION 01 32 01.00 10 Page 3

3.3.2.2 Procurement Activities

The schedule must include activities associated with the submittal, approval, procurement, fabrication and delivery of long lead materials, equipment, fabricated assemblies and supplies. Long lead procurement activities are those with an anticipated procurement sequence of over 90 calendar days. A typical procurement sequence includes the string of activities: submit, approve, procure, fabricate, and deliver.

3.4 REQUESTS FOR TIME EXTENSIONS

In the event the Contractor believes it is entitled to an extension of the contract performance period, completion date, or any interim milestone date, furnish the following for a determination by the Contracting Officer: justification, project schedule data, and supporting evidence as the Contracting Officer may deem necessary. Submission of proof of excusable delay, based on revised activity logic, duration, and costs (updated to the specific date that the delay occurred) is a condition precedent to any approvals by the Government. In response to each Request For Proposal issued by the Government, submit a schedule impact analysis demonstrating whether or not the change contemplated by the Government impacts the critical path.

3.4.1 Justification of Delay

The project schedule shall clearly display that the Contractor has used, in full, all the float time available for the work involved with this request. The Contracting Officer's determination as to the number of allowable days of contract extension shall be based upon the project schedule updates in effect for the time period in question, and other factual information. Actual delays that are found to be caused by the Contractor's own actions, which result in a calculated schedule delay, will not be a cause for an extension to the performance period, completion date, or any interim milestone date.

3.5 PROGRESS MEETINGS

a. Meet bi-weekly with the Government (or as otherwise mutually agreed to) for the purpose of jointly reviewing the actual progress of the project as compared to the as planned progress and to review planned activities for the upcoming two weeks. The then current and approved schedule update shall be used for the purposes of this meeting and for the production and review of reports. The Contractor's Project Manager and the Authorized Representative of the Contracting Officer shall attend.

The progress meeting will address the status of RFI's, RFP's and Submittals.

c. The Government and the Contractor shall jointly review the reports. If it appears that activities on the longest path(s) which are currently driving the calculated completion date (driving activities), are not progressing satisfactorily and therefore could jeopardize timely project completion, corrective action must be taken immediately.

Corrective action includes but is not limited to: increasing the number of work crews; increasing the number of work shifts; increasing the number of hours worked per shift; and determining if Government responsibility coded activities require Government corrective action.

SECTION 01 32 01.00 10 Page 4

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

CONSTRUCTION PROGRESS DOCUMENTATION

11/09

PART 1 GENERAL

1.1 SUBMITTALS

1.2 ACCEPTANCE

1.3 UPDATED SCHEDULES

1.4 3-WEEK LOOK AHEAD SCHEDULE

1.5 CORRESPONDENCE AND TEST REPORTS:

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 32 16.00 20 Page 1

SECTION 01 32 16.00 20

CONSTRUCTION PROGRESS DOCUMENTATION

11/09

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor Quality Control approval. The following shall be submitted in accordance with Section

01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Construction schedule; G

1.2 ACCEPTANCE

Prior to the start of work, prepare and submit to the Contracting Officer for acceptance a construction schedule in the form of a in accordance with the terms in Contract Clause "FAR 52.236-15, Schedules for Construction Contracts," except as modified in this contract. Acceptance of an error free Baseline Schedule and updates is a condition precedent to processing the Contractor's pay request.

1.3 UPDATED SCHEDULES

Update the Construction schedule at monthly intervals or when the schedule has been revised. The updated schedule shall be kept current, reflecting actual activity progress and plan for completing the remaining work. Submit copies of purchase orders and confirmation of delivery dates as directed.

1.4 3-WEEK LOOK AHEAD SCHEDULE

The Contractor shall prepare and issue a 3-Week Look Ahead schedule to provide a more detailed day-to-day plan of upcoming work identified on the Construction Schedule. The work plans shall be keyed to activity numbers when a NAS is required and updated each week to show the planned work for the current and following two-week period. Additionally, include upcoming outages, closures, preparatory meetings, and initial meetings. Identify critical path activities on the Three-Week Look Ahead Schedule. The detail work plans are to be bar chart type schedules, maintained separately from the Construction Schedule on an electronic spreadsheet program and printed on 8 ½ by 11 sheets as directed by the Contracting Officer. Activities shall not exceed 5 working days in duration and have sufficient level of detail to assign crews, tools and equipment required to complete the work.

Three hard copies and one electronic file of the 3-Week Look Ahead Schedule shall be delivered to the Contracting Officer no later than 8 a.m. each Monday and reviewed during the weekly CQC Coordination Meeting.

1.5 CORRESPONDENCE AND TEST REPORTS:

All correspondence (e.g., letters, Requests for Information (RFIs), e-mails, meeting minute items, Production and QC Daily Reports, material delivery tickets, photographs, etc.) shall reference Schedule activities

SECTION 01 32 16.00 20 Page 2 that are being addressed. All test reports (e.g., concrete, soil compaction, weld, pressure, etc.) shall reference schedule activities that are being addressed.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

SECTION 01 32 16.00 20 Page 3

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 33 00

SUBMITTAL PROCEDURES

05/11

PART 1 GENERAL

1.1 SUMMARY

1.2 DEFINITIONS

1.2.1 Submittal Descriptions (SD)

1.2.2 Approving Authority

1.2.3 Work

1.3 SUBMITTALS

1.4 SUBMITTAL CLASSIFICATION

1.4.1 Government Approved G

1.4.2 Information Only

1.5 FORWARDING SUBMITTALS REQUIRING GOVERNMENT APPROVAL

1.5.1 Submittals Required from the Contractor

1.5.1.1 O&M Data

1.6 PREPARATION

1.6.1 Transmittal Form

1.6.2 Identifying Submittals

1.6.3 Format for SD-02 Shop Drawings

1.6.4 Format of SD-03 Product Data and SD-08 Manufacturer's

Instructions

1.6.5 Format of SD-04 Samples

1.6.6 Format of SD-05 Design Data and SD-07 Certificates

1.6.7 Format of SD-06 Test Reports and SD-09 Manufacturer's Field

Reports

1.6.8 Format of SD-10 Operation and Maintenance Data (O&M)

1.6.9 Format of SD-01 Preconstruction Submittals and SD-11 Closeout

Submittals

1.7 QUANTITY OF SUBMITTALS

1.7.1 Number of Copies of SD-02 Shop Drawings

1.7.2 Number of Copies of SD-03 Product Data and SD-08

Manufacturer's Instructions

1.7.3 Number of Samples SD-04 Samples

1.7.4 Number of Copies SD-05 Design Data and SD-07 Certificates

1.7.5 Number of Copies SD-06 Test Reports and SD-09 Manufacturer's

Field Reports

1.7.6 Number of Copies of SD-10 Operation and Maintenance Data

1.7.7 Number of Copies of SD-01 Preconstruction Submittals and SD-11

Closeout Submittals

1.8 INFORMATION ONLY SUBMITTALS

1.9 VARIATIONS

1.9.1 Considering Variations

1.9.2 Proposing Variations

1.9.3 Warranting That Variations Are Compatible

1.9.4 Review Schedule Is Modified

1.10 SUBMITTAL REGISTER

1.10.1 Use of Submittal Register

SECTION 01 33 00 Page 1

1.10.2 Contractor Use of Submittal Register

1.10.3 Approving Authority Use of Submittal Register

1.10.4 GOVERNMENT REVIEW ACTION CODES

1.10.5 Copies Delivered to the Government

1.11 SCHEDULING

1.11.1 Constraints

1.12 GOVERNMENT APPROVING AUTHORITY

1.13 DISAPPROVED OR REJECTED SUBMITTALS

1.14 APPROVED/ACCEPTED SUBMITTALS

1.15 WITHHOLDING OF PAYMENT

1.16 APPROVED SAMPLES

1.17 STAMPS

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 33 00 Page 2

SECTION 01 33 00

SUBMITTAL PROCEDURES

05/11

PART 1 GENERAL

1.1 SUMMARY

The Contracting Officer may request submittals in addition to those specified when deemed necessary to adequately describe the work covered in the respective sections.

Units of weights and measures used on all submittals are to be the same as those used in the contract drawings.

Each submittal is to be complete and in sufficient detail to allow ready determination of compliance with contract requirements.

Contractor to check and approve all items prior to submittal and stamp, sign, and date indicating action taken. Proposed deviations from the contract requirements are to be clearly identified. Include within submittals items such as: Contractor's, manufacturer's, or fabricator's drawings; descriptive literature including (but not limited to) catalog cuts, diagrams, operating charts or curves; test reports; test cylinders;

samples; O&M manuals (including parts list); certifications; warranties;

and other such required submittals.

Submittals requiring Government approval are to be scheduled and made prior to the acquisition of the material or equipment covered thereby. Pick up and dispose of samples not incorporated into the work in accordance with manufacturer's Material Safety Data Sheets (MSDS) and in compliance with existing laws and regulations.

1.2 DEFINITIONS

1.2.1 Submittal Descriptions (SD)

Submittals requirements are specified in the technical sections.

Submittals are identified by Submittal Description (SD) numbers and titles as follows:

SD-01 Preconstruction Submittals

Submittals which are required prior to the start of construction or the next major phase of the construction on a multi-phase contract. They include:

Certificates of insurance

Surety bonds

List of proposed Subcontractors

List of proposed products

Construction progress schedule

SECTION 01 33 00 Page 3

Submittal register

Schedule of prices

Health and safety plan

Work plan

Quality Control(QC) plan

Environmental protection plan

SD-02 Shop Drawings

Drawings, diagrams and schedules specifically prepared to illustrate some portion of the work.

Diagrams and instructions from a manufacturer or fabricator for use in producing the product and as aids to the Contractor for integrating the product or system into the project.

Drawings prepared by or for the Contractor to show how multiple systems and interdisciplinary work will be coordinated.

SD-03 Product Data

Catalog cuts, illustrations, schedules, diagrams, performance charts, instructions and brochures illustrating size, physical appearance and other characteristics of materials, systems or equipment for some portion of the work.

Samples of warranty language when the contract requires extended product warranties.

SD-04 Samples

Fabricated or unfabricated physical examples of materials, equipment or workmanship that illustrate functional and aesthetic characteristics of a material or product and establish standards by which the work can be judged.

Color samples from the manufacturer's standard line (or custom color samples if specified) to be used in selecting or approving colors for the project.

Field samples and mock-ups constructed on the project site establish standards by which the ensuring work can be judged. Includes assemblies or portions of assemblies which are to be incorporated into the project and those which will be removed at conclusion of the work.

SD-05 Design Data

Design calculations, mix designs, analyses or other data pertaining to a part of work.

SD-06 Test Reports

Report signed by authorized official of testing laboratory that a

SECTION 01 33 00 Page 4 material, product or system identical to the material, product or system to be provided has been tested in accord with specified requirements. (Testing must have been within three years of date of contract award for the project.)

Report which includes findings of a test required to be performed by the Contractor on an actual portion of the work or prototype prepared for the project before shipment to job site.

Report which includes finding of a test made at the job site or on sample taken from the job site, on portion of work during or after installation.

Investigation reports.

Daily logs and checklists.

Final acceptance test and operational test procedure.

SD-07 Certificates

Statements printed on the manufacturer's letterhead and signed by responsible officials of manufacturer of product, system or material attesting that product, system or material meets specification requirements. Must be dated after award of project contract and clearly name the project.

Document required of Contractor, or of a manufacturer, supplier, installer or Subcontractor through Contractor, the purpose of which is to further quality of orderly progression of a portion of the work by documenting procedures, acceptability of methods or personnel qualifications.

SD-08 Manufacturer's Instructions

Preprinted material describing installation of a product, system or material, including special notices and (MSDS)concerning impedances, hazards and safety precautions.

SD-09 Manufacturer's Field Reports

Documentation of the testing and verification actions taken by manufacturer's representative at the job site, in the vicinity of the job site, or on a sample taken from the job site, on a portion of the work, during or after installation, to confirm compliance with manufacturer's standards or instructions. The documentation must be signed by an authorized official of a testing laboratory or agency and must state the test results; and indicate whether the material, product, or system has passed or failed the test.

SD-10 Operation and Maintenance Data

Data that is furnished by the manufacturer, or the system provider, to the equipment operating and maintenance personnel, including manufacturer's help and product line documentation necessary to maintain and install equipment. This data is needed by operating and maintenance personnel for the safe and efficient operation, maintenance and repair of the item.

SECTION 01 33 00 Page 5

This data is intended to be incorporated in an operations and maintenance manual or control system.

SD-11 Closeout Submittals

Documentation to record compliance with technical or administrative requirements or to establish an administrative mechanism.

Special requirements necessary to properly close out a construction contract. For example, Record Drawings and as-built drawings. Also, submittal requirements necessary to properly close out a major phase of construction on a multi-phase contract.

Interim "DD Form 1354" with cost breakout for all assets 30 days prior to facility turnover.

1.2.2 Approving Authority

Office or designated person authorized to approve submittal.

1.2.3 Work

As used in this section, on- and off-site construction required by contract documents, including labor necessary to produce submittals, construction, materials, products, equipment, and systems incorporated or to be incorporated in such construction.

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with this section.

SD-01 Preconstruction Submittals

Submittal Register; G

1.4 SUBMITTAL CLASSIFICATION

Submittals are classified as follows:

1.4.1 Government Approved G

Government approval is required for extensions of design, critical materials, deviations, equipment whose compatibility with the entire system must be checked, and other items as designated by the Contracting Officer.

Within the terms of the Contract Clause entitled, "Specifications and Drawings for Construction," they are considered to be "shop drawings."

1.4.2 Information Only

Submittals not requiring Government approval will be for information only.

They are not considered to be "shop drawings" within the terms of the Contract Clause referred to above.

SECTION 01 33 00 Page 6

1.5 FORWARDING SUBMITTALS REQUIRING GOVERNMENT APPROVAL

1.5.1 Submittals Required from the Contractor

As soon as practicable after award of contract, and before procurement of fabrication, forward to the CO submittals required in the technical sections of this specification, including shop drawings, product data and samples.

1.5.1.1 O&M Data

Submit data specified for a given item within 30 calendar days after the item is delivered to the contract site.

In the event the Contractor fails to deliver O&M Data within the time limits specified, the Contracting Officer may withhold from progress payments 50 percent of the price of the item with which such O&M Data are applicable.

1.6 PREPARATION

1.6.1 Transmittal Form

Transmit each submittal, except sample installations and sample panels, to office of approving authority. Transmit submittals with transmittal form prescribed by Contracting Officer and standard for project. On the transmittal form identify Contractor, indicate date of submittal, and include information prescribed by transmittal form and required in paragraph entitled, "Identifying Submittals," of this section. Process transmittal forms to record actions regarding sample installations or panels, if included in project.

Use AF Form 3000 for submitting both Government approved and information only submittals in accordance with the instructions on the reverse side of the form. These forms will be furnished to the Contractor. Properly complete this form by filling out all the heading blank spaces and identifying each item submitted. Exercise special care to ensure proper listing of the specification paragraph and sheet number of the contract drawings pertinent to the data submitted for each item.

1.6.2 Identifying Submittals

When submittals are provided by a Subcontractor, the Prime Contractor is to prepare, review and stamp with Contractor's approval all specified submittals prior to submitting for Government approval.

Identify submittals, except sample installations and sample panels, with the following information permanently adhered to or noted on each separate component of each submittal and noted on transmittal form. Mark each copy of each submittal identically, with the following:

a. Project title and location.

b. Construction contract number.

c. Date of the drawings and revisions.

d. Name, address, and telephone number of subcontractor, supplier, manufacturer and any other subcontractor associated with the submittal.

SECTION 01 33 00 Page 7

e. Section number of the specification section by which submittal is required.

f. Submittal description (SD) number of each component of submittal.

g. When a resubmission, add alphabetic suffix on submittal description, for example, submittal 18 would become 18A, to indicate resubmission.

h. Product identification and location in project.

1.6.3 Format for SD-02 Shop Drawings

Shop drawings are not to be less than 8 1/2 by 11 inches nor more than 30 by 42 inches, except for full size patterns or templates. Prepare drawings to accurate size, with scale indicated, unless other form is required.

Drawings are to be suitable for reproduction and be of a quality to produce clear, distinct lines and letters with dark lines on a white background.

Present 8 1/2 by 11 inches sized shop drawings as part of the bound volume for submittals required by section. Present larger drawings in sets.

Include on each drawing the drawing title, number, date, and revision numbers and dates, in addition to information required in paragraph entitled, "Identifying Submittals," of this section.

Number drawings in a logical sequence. Each drawing is to bear the number of the submittal in a uniform location adjacent to the title block. Place the Government contract number in the margin, immediately below the title block, for each drawing.

Reserve a blank space on the right hand side of each sheet for the Government disposition stamp.

Dimension drawings, except diagrams and schematic drawings; prepare drawings demonstrating interface with other trades to scale. Use the same unit of measure for shop drawings as indicated on the contract drawings.

Identify materials and products for work shown.

Include the nameplate data, size and capacity on drawings. Also include applicable federal, military, industry and technical society publication references.

1.6.4 Format of SD-03 Product Data and SD-08 Manufacturer's Instructions

Present product data submittals for each section as a complete, bound volume. Include table of contents, listing page and catalog item numbers for product data.

Indicate, by prominent notation, each product which is being submitted;

indicate specification section number and paragraph number to which it pertains.

Supplement product data with material prepared for project to satisfy submittal requirements for which product data does not exist. Identify this material as developed specifically for project, with information and format as required for submission of SD-07 Certificates.

Include the manufacturer's name, trade name, place of manufacture, and

SECTION 01 33 00 Page 8 catalog model or number on product data. Also include applicable federal, military, industry and technical society publication references. Should manufacturer's data require supplemental information for clarification, submit as specified for SD-07 Certificates.

Where equipment or materials are specified to conform to industry and technical society reference standards of the organizations such as American National Standards Institute (ANSI), ASTM International (ASTM), National Electrical Manufacturer's Association (NEMA), Underwriters Laboratories (UL), and Association of Edison Illuminating Companies (AEIC), submit proof of such compliance. The label or listing by the specified organization will be acceptable evidence of compliance. In lieu of the label or listing, submit a certificate from an independent testing organization, competent to perform testing, and approved by the Contracting Officer.

State on the certificate that the item has been tested in accordance with the specified organization's test methods and that the item complies with the specified organization's reference standard.

Collect required data submittals for each specific material, product, unit of work, or system into a single submittal and marked for choices, options, and portions applicable to the submittal. Mark each copy of the product data identically. Partial submittals will not be accepted for expedition of construction effort.

Submit manufacturer's instructions prior to installation.

1.6.5 Format of SD-04 Samples

Furnish samples in sizes below, unless otherwise specified or unless the manufacturer has prepackaged samples of approximately same size as specified:

a. Sample of Equipment or Device: Full size.

b. Sample of Materials Less Than 2 by 3 inches: Built up to 8 1/2 by 11 inches.

c. Sample of Materials Exceeding 8 1/2 by 11 inches: Cut down to 8 1/2 by 11 inches and adequate to indicate color, texture, and material variations.

d. Sample of Linear Devices or Materials: 10 inch length or length to be supplied, if less than 10 inches. Examples of linear devices or materials are conduit and handrails.

e. Sample of Non-Solid Materials: Pint. Examples of non-solid materials are sand and paint.

f. Color Selection Samples: 2 by 4 inches. Where samples are specified for selection of color, finish, pattern, or texture, submit the full set of available choices for the material or product specified. Sizes and quantities of samples are to represent their respective standard unit.

g. Sample Panel: 4 by 4 feet.

h. Sample Installation: 100 square feet.

Samples Showing Range of Variation: Where variations in color, finish, SECTION 01 33 00 Page 9 pattern, or texture are unavoidable due to nature of the materials, submit sets of samples of not less than three units showing extremes and middle of range. Mark each unit to describe its relation to the range of the variation.

Reusable Samples: Incorporate returned samples into work only if so specified or indicated. Incorporated samples are to be in undamaged condition at time of use.

Recording of Sample Installation: Note and preserve the notation of area constituting sample installation but remove notation at final clean up of project.

When color, texture or pattern is specified by naming a particular manufacturer and style, include one sample of that manufacturer and style, for comparison.

1.6.6 Format of SD-05 Design Data and SD-07 Certificates

Provide design data and certificates on 8 1/2 by 11 inches paper. Provide a bound volume for submittals containing numerous pages.

1.6.7 Format of SD-06 Test Reports and SD-09 Manufacturer's Field Reports

Provide reports on 8 1/2 by 11 inches paper in a complete bound volume.

Indicate by prominent notation, each report in the submittal. Indicate specification number and paragraph number to which it pertains.

1.6.8 Format of SD-10 Operation and Maintenance Data (O&M)

Comply with the requirements specified in Section 01 78 23 OPERATION AND MAINTENANCE DATA for O&M Data format.

1.6.9 Format of SD-01 Preconstruction Submittals and SD-11 Closeout Submittals

When submittal includes a document which is to be used in project or become part of project record, other than as a submittal, do not apply Contractor's approval stamp to document, but to a separate sheet accompanying document.

1.7 QUANTITY OF SUBMITTALS

1.7.1 Number of Copies of SD-02 Shop Drawings

Submit shop drawings in digital format with the exception of larger scale drawings that would be more appropriately reviewed with hard copies. When hard copies are submitted, provide six copies of submittals of shop drawings requiring review and approval.

1.7.2 Number of Copies of SD-03 Product Data and SD-08 Manufacturer's Instructions

Submit in compliance with quantity requirements specified for shop drawings.

1.7.3 Number of Samples SD-04 Samples

a. Submit two samples, or two sets of samples showing range of variation, SECTION 01 33 00 Page 10 of each required item. One approved sample or set of samples will be retained by approving authority and one will be returned to Contractor.

b. Submit one sample panel or provide one sample installation where directed. Include components listed in technical section or as directed.

c. Submit one sample installation, where directed.

d. Submit one sample of non-solid materials.

1.7.4 Number of Copies SD-05 Design Data and SD-07 Certificates

Submit in compliance with quantity requirements specified for shop drawings.

1.7.5 Number of Copies SD-06 Test Reports and SD-09 Manufacturer's Field Reports

Submit…