A.07.23_18-B-0003_Solicitation_with_Specifications.pdf

CODE

(Hour)

PAGE(S)

until 02:00 PM local time 07 Nov 2017

A

X B

X C

D

EX

X

G

F 31 - 37

38 - 44 X H

Kent.R.Bernard@usace.army .mil

RATING PAGE OF PAGES

7. ISSUED BY

(Date)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

Previous Edition is Unusable 33-134 STANDARD FORM 33 (REV. 9-97)

Prescribed by GSA

FAR (48 CFR) 53.214(c)

1 44

(If other than Item 7)

15A. NAME 16. NAME AND TITLE OF PERSON AUTHORIZED TO

AND

ADDRESS

SIGN OFFER (Type or print)

OF

OFFEROR

AMENDMENT NO. DATE

15B. TELEPHONE NO (Include area code) 17. SIGNATURE15C. CHECK IF REMITTANCE ADDRESS

IS DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

18. OFFER DATE

1. THIS CONTRACT IS A RATED ORDER

UNDER DPAS (15 CFR 700)

2. CONTRACT NO.

W912EF 8. ADDRESS OFFER TO

See Item 7

9. Sealed offers in original and 1 copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 8, or if handcarried, in the depository located in

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and conditions contained in this solicitation.

10. FOR INFORMATION

CALL:

A. NAME (NO COLLECT CALLS)

KENT R. BERNARD 509-527-7205

11. TABLE OF CONTENTS

SOLICITATION/ CONTRACT FORM

SUPPLIES OR SERVICES AND PRICES/ COSTS

X I CONTRACT CLAUSES

DESCRIPTION/ SPECS./ WORK STATEMENT X

PACKAGING AND MARKING

46 J LIST OF ATTACHMENTS

INSPECTION AND ACCEPTANCE

DELIVERIES OR PERFORMANCE

X K

REPRESENTATIONS, CERTIFICATIONS AND

OTHER STATEMENTS OF OFFERORS

CONTRACT ADMINISTRATION DATA X

SPECIAL CONTRACT REQUIREMENTS

OFFER (Must be fully completed by offeror) 6 - 8 M

L INSTRS., CONDS., AND NOTICES TO OFFERORS

EVALUATION FACTORS FOR AWARD

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause No. 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments

AMENDMENT NO. DATE

to the SOLICITATION for offerors and related documents numbered and dated):

FACILITY

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period

SOLICITATION, OFFER AND AWARD

X

(X) SEC. DESCRIPTION (X) SEC. DESCRIPTION PAGE(S)

PART I - THE SCHEDULE

26. NAME OF CONTRACTING OFFICER (Type or print) 27. UNITED STATES OF AMERICA 28. AWARD DATE

EMAIL:TEL: (Signature of Contracting Officer)

CODE CODE

B. TELEPHONE (Include area code) C. E-MAIL ADDRESS

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

23. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

24. ADMINISTERED BY (If other than Item 7) CODE 25. PAYMENT WILL BE MADE BY CODE

PART IV - REPRESENTATIO NS AND INSTRUCTIO NS

PART III - LIST O F DO CUMENTS, EXHIBITS AND O THER ATTACHMENTS

9 - 29

PART II - CO NTRACT CLAUSES

USAED, WALLA WALLA - CONTRACTING DIV.

KENT R. BERNARD 201 N. THIRD AVENUE

WALLA WALLA WA 99362-1876

509-527-7205

509-527-7802FAX:

TEL:

FAX:

TEL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

6. REQUISITION/PURCHASE NO.5. DATE ISSUED

04 Oct 2017

4. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

[ X ]

3. SOLICITATION NO.

W912EF-18-B-0003

Section B - Supplies or Services and Prices

BID SCHEDULE

Walla Walla District Corps of Engineers Lower Monumental Drainage and Unwatering Pumps System Replacement

100% Small Business Set Aside

ITEM DESCRIPTION

QUANTITY

U/M U/P AMOUNT

Supply CLINs

Supply Low Voltage Motor Control Center

1 EA

Supply Medium Voltage Motor Control Center

1 EA

Supply Low Voltage Drainage Pumps

2 EA

Supply Medium Voltage Unwatering Pumps

2 EA

Supply Low Voltage Unwatering Pump (safety pool)

1 EA

Construction CLINs

Removal of Existing, and Installation of New Motor Control Centers

1 JOB XXXXXXXX

Removal of Existing, and Installation of New Drainage Pumps

1 JOB XXXXXXXX

Removal of Existing, and Installation of New Unwatering Pumps

1 JOB XXXXXXXX

Installation of New Oil Water Separator System

1 JOB XXXXXXXX

Schedule Total $_________________

IMPORTANT See Section 01 22 00.00 28; MEASUREMENT AND PAYMENT; Paragraph; Retainage of Payment, for withholding of payment for final deliverables.

Section C - Descriptions and Specifications

TECHNICAL SPECIFICATIONS

Technical Plans and Specifications will be attached separately.

Section E - Inspection and Acceptance

SUPPLY CLAUSES

CLAUSES INCORPORATED BY REFERENCE

52.246-2 Inspection Of Supplies--Fixed Price AUG 1996

52.246-16 Responsibility For Supplies APR 1984

CONSTRUCTION CLAUSES

52.246-12 Inspection of Construction AUG 1996

Section F - Deliveries or Performance

CONSTRUCTION CLAUSES

CLAUSES INCORPORATED BY REFERENCE

52.242-15 Stop-Work Order AUG 1989

52.242-17 Government Delay Of Work APR 1984

52.247-34 F.O.B. Destination NOV 1991

CLAUSES INCORPORATED BY FULL TEXT

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,858.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least 75 percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting

Officer determines that the reduction would be to the advantage of the Government.

(End of clause)

Section H - Special Contract Requirements

SPECIAL CONTRACT REQUIREMENTS

Invoices/Payment Requests

Invoices/payment requests must be submitted to Walla Walla District, Corps of Engineers, Attention: Construction

Branch, 201 N. Third Ave., Walla Walla, WA 99362.

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with CLAUSE: DEFAULT (FIXED-PRICE CONSTRUCTION) of the CONTRACT CLAUSES. In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and

Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. A weather delay day is any day when the maximum temperature does not exceed

32 degrees Fahrenheit or when 0.10 inch or more of precipitation occurs. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

Monthly Anticipated Adverse Weather Delay Work Days Based on (7) Day Work Week

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

9 3 4 4 3 3 1 1 1 3 4 7

Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor shall record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work.

Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled workday. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number “Anticipated Adverse Weather Delay Work Days”, above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days and issue a modification in accordance with the CLAUSE: DEFAULT (FIXED PRICE CONSTRUCTION) of the

CONTRACT CLAUSES.

(End of Clause)

U.S. ARMY CORPS OF ENGINEERS SAFETY AND HEALTH REQUIREMENTS MANUAL, EM 385-1-1

This contract/purchase order requires the contractor to comply with EM 385-1-1. EM 385-1-1 and its changes are available at: http://www.usace.army.mil/SafetyandOccupationalHealth.aspx

The Contractor shall be responsible for complying with the current edition and all changes posted on the web as of the effective date of this solicitation.

ACCESS FOR FOREIGN NATIONALS:

CONTRACT WORK: Security clearance for foreign nationals to perform onsite work requires a minimum of 4 weeks. Please send documentation by email (.pdf files are preferred) to Kent.R.Bernard@usace.army.mil and

Jani.C.Long@usace.army.mil

Acceptable forms of documentation include:

A US passport, Certificate of US citizenship (INS Form N-560 or N-561),Certificate of Naturalization (INS

Form N-550 or N-570), foreign passport with I-551 stamp or attached INS Form I-94 indicating employment authorization, Alien Registration Receipt Card with photograph (INS Form I-151 or I-551), Temporary

Resident Card (INS Form I-688), Employment Authorization Card (INS Form I-688A), Reentry Permit (INS

Form I-327), Refugee Travel Document (INS Form I-571), Employment Authorization Document issued by the

INS which contains a photograph (INS Form I-688B).

Foreign nationals must have received clearance prior to being granted access to the project site.

PROFIT

Alternate structured approach for construction contracts. [UDG 5115.404-73-1]

Weighted guidelines method of determining profit shall be used on any equitable adjustment change order or modification issued under this contract. The profit factors shall be as stated below.

(a) The following alternate structured approach shall be used for all fixed-price construction contract actions.

(b) Based on the circumstances of the procurement action, each of the above factors shall be weighted from .03 to

.12 as indicated below. "Value" shall be obtained by multiplying the rate by the weight. The Value column when totaled indicates the fair and reasonable profit percentage under the circumstances of the particular procurement.

Factor Rate

Weight Value

Degree of risk 20

Relative difficulty of work

Size of job 15

Period of performance

Contractor's investment

Assistance by

Government

Subcontracting 25

TOTAL 100%

mailto:Kent.R.Bernard@usace.army.mil mailto:Jani.C.Long@usace.army.mil

(1) Degree of risk. Where the work involves no risk or the degree of risk is very small, the weighting should be .03;

as the degree of risk increases, the weighting should be increased up to a maximum of .12. Lump sum items shall generally have a higher weight than unit price items. Consider the nature of the work and where it is to be performed.

Also consider the portion of the work to be done by subcontractors, amount and type of labor included in costs and whether the negotiation is before or after performance of the work. Modifications settled before the fact have much greater risk than those settled after the fact. A weight of .03 is appropriate for after the fact equitable adjustments and/or settlements.

(2) Relative Difficulty of Work. If the work is difficult and complex, the weight should be .12 and should be proportionately reduced to .03 on the simplest of jobs. This factor is tied in to some extent with the degree of risk. Other things to consider are the nature of the work, by whom it is to be done (i.e., subcontractors, consultants), etc.

(3) Size of Job. Work of $100,000 shall be weighted at .12. Work estimated between $100,000 and $5,000,000 shall be proportionately weighted from .12 to .05. Work from $5,000,000 to $10,000,000 shall be weighted at .04. Work in excess of $10,000,000 shall be weighted at .03. It should be noted that control of fixed expenses generally improves with increased job magnitude.

(4) Period of Performance. Work not to exceed 1 month is to be proportionately weighted at .03. Durations between

1 and 24 months are to be proportionately weighted between .03 and .12. Work in excess of 24 months is to be weighted at .12.

(5) Contractor's Investment. To be weighted from .03 to .12 on the basis of below average, average and above average. Consider the amount of subcontracting, Government-furnished property or data such as surveys, method of making progress payments, and any mobilization payment items.

(6) Assistance by Government. To be weighted from .12 to .03 on the basis of average to above average. Consider use of Government-owned property, equipment and facilities, expediting assistance, etc.

(7) Subcontracting. To be weighed inversely proportional to the amount of subcontracting. Where 80% or more of the work is to be subcontracted use .03. The weighting should be increased proportionately to .12 where all the work is performed by the contractor's own forces.

LISTING OF GOVERNMENT-FURNISHED PROPERTY

(a) The following items will be made available to the Contractor. The Contractor will verify the condition of the property and acknowledge receipt in writing to the Contracting Officer. The Contractor shall provide the

Government a minimum 48-hour notice prior to the date that receipt of Government Furnished Property is required.

The following will be made available to the Contractor to use during the performance of this job. The Contractor is responsible to ensure this property is returned to the Government in the same condition as prior to use.

Item

No.

Description Quantity Unit Acquisition

Cost

Total

Acquisition

Cost

1 Lower Monumental Bridge Crane 1 $4,000,000 $4,000,000

(b) The above estimated acquisition cost is applicable to accounting for Government-furnished property. This cost shall not be included by the Contractor in the proposal price. (52.245-1, Government Property)

Section I - Contract Clauses

SUPPLY CLAUSES

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013

52.203-3 Gratuities APR 1984

52.203-5 Covenant Against Contingent Fees MAY 2014

52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006

52.203-7 Anti-Kickback Procedures MAY 2014

52.203-7 Anti-Kickback Procedures MAY 2014

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

APR 2014

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-7 System for Award Management JUL 2013

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-13 System for Award Management Maintenance OCT 2016

52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for

Debarment

OCT 2015

52.209-9 Updates of Publicly Available Information Regarding

Responsibility Matters

JUL 2013

52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.211-5 Material Requirements AUG 2000

52.215-21 Requirements for Certified Cost or Pricing Data and Data

Other Than Certified Cost or Pricing Data -- Modifications

OCT 2010

52.219-6 Notice Of Total Small Business Set-Aside NOV 2011

52.219-8 Utilization of Small Business Concerns OCT 2014

52.219-14 Limitations On Subcontracting JAN 2017

52.222-3 Convict Labor JUN 2003

52.222-4 Contract Work Hours and Safety Standards- Overtime

Compensation

MAY 2014

52.222-19 Child Labor -- Cooperation with Authorities and Remedies FEB 2016

52.222-20 Contracts for Materials, Supplies, Articles, and Equipment

Exceeding $15,000

MAY 2014

52.222-21 Prohibition Of Segregated Facilities APR 2015

52.222-26 Equal Opportunity SEP 2016

52.222-35 Equal Opportunity for Veterans OCT 2015

52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014

52.222-37 Employment Reports on Veterans FEB 2016

52.222-50 Combating Trafficking in Persons MAR 2015

52.222-54 Employment Eligibility Verification OCT 2015

52.222-59 Compliance with Labor Laws (Executive Order 13673) DEC 2016

52.222-60 Paycheck Transparency (Executive Order 13673) OCT 2016

52.222-61 Arbitration of Contractor Employee Claims (Executive Order

13673)

DEC 2016

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011

52.223-6 Drug-Free Workplace MAY 2001

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008

52.227-1 Authorization and Consent DEC 2007

52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.229-3 Federal, State And Local Taxes FEB 2013

52.232-1 Payments APR 1984

52.232-8 Discounts For Prompt Payment FEB 2002

52.232-9 Limitation On Withholding Of Payments APR 1984

52.232-11 Extras APR 1984

52.232-17 Interest MAY 2014

52.232-23 Alt I Assignment of Claims (May 2014) - Alternate I APR 1984

52.232-25 Prompt Payment JUL 2013

52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013

52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014

52.233-3 Protest After Award AUG 1996

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.242-13 Bankruptcy JUL 1995

52.243-1 Changes--Fixed Price AUG 1987

52.244-6 Subcontracts for Commercial Items SEP 2016

52.245-1 Government Property JAN 2017

52.245-9 Use And Charges APR 2012

52.246-24 Limitation Of Liability--High-Value Items FEB 1997

52.248-1 Value Engineering OCT 2010

52.249-2 Termination For Convenience Of The Government (Fixed-

Price)

APR 2012

52.249-8 Default (Fixed-Price Supply & Service) APR 1984

52.253-1 Computer Generated Forms JAN 1991

252.201-7000 Contracting Officer's Representative DEC 1991

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense-

Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.204-7005 Oral Attestation of Security Responsibilities NOV 2001

252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of

Terrorism

OCT 2015

252.215-7000 Pricing Adjustments DEC 2012

252.223-7001 Hazard Warning Labels DEC 1991

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.225-7002 Qualifying Country Sources As Subcontractors AUG 2016

252.225-7006 Acquisition of the AmericanFlag AUG 2015

252.225-7012 Preference For Certain Domestic Commodities AUG 2016

252.225-7021 Trade Agreements--Basic SEP 2016

252.225-7030 Restriction On Acquisition Of Carbon, Alloy, And Armor

Steel Plate

DEC 2006

252.226-7001 Utilization of Indian Organizations and Indian-Owned

Economic Enterprises, and Native Hawaiian Small Business

Concerns

SEP 2004

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.243-7002 Requests for Equitable Adjustment DEC 2012

252.244-7000 Subcontracts for Commercial Items JUN 2013

252.245-7001 Tagging, Labeling, and Marking of Government-Furnished

Property

APR 2012

252.245-7002 Reporting Loss of Government Property APR 2012

252.245-7003 Contractor Property Management System Administration APR 2012

252.245-7004 Reporting, Reutilization, and Disposal SEP 2016

252.247-7023 Transportation of Supplies by Sea APR 2014

252.247-7024 Notification Of Transportation Of Supplies By Sea MAR 2000

CLAUSES INCORPORATED BY FULL TEXT

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The

Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the

Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in

SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code 333911- assigned to contract number .

(Contractor to sign and date and insert authorized signer's name and title).

(End of clause)

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3,000,000.00, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of provision)

52.246-17 WARRANTY OF SUPPLIES OF A NONCOMPLEX NATURE (JUN 2003)

(a) Definitions. As used in this clause --

Acceptance means the act of an authorized representative of the Government by which the Government assumes for itself, or as an agent of another, ownership of existing supplies, or approves specific services as partial or complete performance of the contract.

Supplies means the end items furnished by the Contractor and related services required under this contract. The word does not include ``data.''

(b) Contractor's obligations.

(1) Notwithstanding inspection and acceptance by the Government of supplies furnished under this contract, or any condition of this contract concerning the conclusiveness thereof, the Contractor warrants that for

VFDs – 3 Years

Motor Control Centers – 2 Years

Pumps – 1 Year

Motors & Inverters – 3 Years

(i) All supplies furnished under this contract will be free from defects in material or workmanship and will conform with all requirements of this contract; and

(ii) The preservation, packaging, packing, and marking, and the preparation for, and method of, shipment of such supplies will conform with the requirements of this contract.

(2) When return, correction, or replacement is required, transportation charges and responsibility for the supplies while in transit shall be borne by the Contractor. However, the Contractor's liability for the transportation charges shall not exceed an amount equal to the cost of transportation by the usual commercial method of shipment between the place of delivery specified in this contract and the Contractor's plant, and return.

(3) Any supplies or parts thereof, corrected or furnished in replacement under this clause, shall also be subject to the terms of this clause to the same extent as supplies initially delivered. The warranty, with respect to supplies or parts thereof, shall be equal in duration to that in paragraph (b)(1) of this clause and shall run from the date of delivery of the corrected or replaced supplies.

(4) All implied warranties of merchantability and "fitness for a particular purpose" are excluded from any obligation contained in this contract.

(c) Remedies available to the Government.

(1) The Contracting Officer shall give written notice to the Contractor of any breach of warranties in paragraph

(b)(1) of this clause within 45 days of the last delivery under this contract,” or “45 days after discovery of the defect.

(2) Within a reasonable time after the notice, the Contracting Officer may either--

(i) Require, by written notice, the prompt correction or replacement of any supplies or parts thereof (including preservation, packaging, packing, and marking) that do not conform with the requirements of this contract within the meaning of paragraph (b)(1) of this clause; or

(ii) Retain such supplies and reduce the contract price by an amount equitable under the circumstances.

(3) (i) If the contract provides for inspection of supplies by sampling procedures, conformance of suppliers or components subject to warranty action shall be determined by the applicable sampling procedures in the contract.

The Contracting Officer--

(A) May, for sampling purposes, group any supplies delivered under this contract;

(B) Shall require the size of the sample to be that required by sampling procedures specified in the contract for the quantity of supplies on which warranty action is proposed;

(C) May project warranty sampling results over supplies in the same shipment or other supplies contained in other shipments even though all of such supplies are not present at the point of reinspection; provided, that the supplies remaining are reasonably representative of the quantity on which warranty action is proposed; and

(D) Need not use the same lot size as on original inspection or reconstitute the original inspection lots.

(ii) Within a reasonable time after notice of any breach of the warranties specified in paragraph (b)(1) of this clause, the Contracting Officer may exercise one or more of the following options:

(A) Require an equitable adjustment in the contract price for any group of supplies.

(B) Screen the supplies grouped for warranty action under this clause at the Contractor's expense and return all nonconforming supplies to the Contractor for correction or replacement.

(C) Require the Contractor to screen the supplies at locations designated by the Government within the contiguous

United States and to correct or replace all nonconforming supplies.

(D) Return the supplies grouped for warranty action under this clause to the Contractor (irrespective of the f.o.b.

point or the point of acceptance) for screening and correction or replacement.

(4) (i) The Contracting Officer may, by contract or otherwise, correct or replace the nonconforming supplies with similar supplies from another source and charge to the Contractor the cost occasioned to the Government thereby if the Contractor--

(A) Fails to make redelivery of the corrected or replaced supplies within the time established for their return; or

(B) Fails either to accept return of the nonconforming supplies or fails to make progress after their return to correct or replace them so as to endanger performance of the delivery schedule, and in either of these circumstances does not cure such failure within a period of 10 days (or such longer period as the Contracting Officer may authorize in writing) after receipt of notice from the Contracting Officer specifying such failure.

(ii) Instead of correction or replacement by the Government, the Contracting Officer may require an equitable adjustment of the contract price. In addition, if the Contractor fails to furnish timely disposition instructions, the

Contracting Officer may dispose of the nonconforming supplies for the Contractor's account in a reasonable manner.

The Government is entitled to reimbursement from the Contractor, or from the proceeds of such disposal, for the reasonable expenses of the care and disposition of the nonconforming supplies, as well as for excess costs incurred or to be incurred.

(5) The rights and remedies of the Government provided in this clause are in addition to and do not limit any rights afforded to the Government by any other clause of this contract.

(End of clause)

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/

(End of clause)

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any Defense Federal Acquisition Regulation Supplement (48 CFR

Chapter 2) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

CONSTRUCTION CLAUSES

Section I - Contract Clauses – applicable only to construction (CLINs 0006 – 0009)

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions JAN 2012

52.203-3 Gratuities APR 1984

52.203-5 Covenant Against Contingent Fees APR 1984

52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006

52.203-7 Anti-Kickback Procedures OCT 2010

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

JAN 1997

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity JAN 1997

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

APR 2014

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-13 System of Award Management Maintenance

OCT 2016

52.204-18 Commercial and Government Entity Code Maintenance

JUL 2016

http://farsite.hill.af.mil/

52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for

Debarment

DEC 2010

52.209-9 Updates of Publicly Available Information Regarding

Responsibility Matters

JUL 2013

52.209-10 Prohibition on ContractingWith Inverted Domestic

Corporations

NOV 2015

52.211-13 Time Extensions SEP 2000

52.214-27 Price Reduction for Defective Certified Cost or Pricing Data –

Modifications – Sealed Bidding

AUG 2011

52.214-28 Subcontractor Certified Cost or Pricing Data – Modifications-

Sealed Bidding

OCT 2010

52.215-21 Requirements for Certified Cost or Pricing Data or

Information Other Than Certified Cost or Pricing Data--

Modifications

OCT 2010

52.219-6 Notice of Total Small Business Set-Aside NOV 2011

52.219-8 Utilization of Small Business Concerns JAN 2011

52.219-14 Limitations on Subcontracting JAN 2017

52.222-3 Convict Labor JUN 2003

52.222-4 Contract Work Hours and Safety Standards Act - Overtime

Compensation

JUL 2005

52.222-6 Davis Bacon Act JUL 2005

52.222-7 Withholding of Funds FEB 1988

52.222-8 Payrolls and Basic Records JUN 2010

52.222-9 Apprentices and Trainees JUL 2005

52.222-10 Compliance with Copeland Act Requirements FEB 1988

52.222-11 Subcontracts (Labor Standards) JUL 2005

52.222-12 Contract Termination-Debarment FEB 1988

52.222-13 Compliance with Davis-Bacon and Related Act Regulations. FEB 1988

52.222-14 Disputes Concerning Labor Standards FEB 1988

52.222-15 Certificate of Eligibility FEB 1988

52.222-21 Prohibition Of Segregated Facilities FEB 1999

52.222-26 Equal Opportunity MAR 2007

52.222-27 Affirmative Action Compliance Requirements for

Construction

FEB 1999

52.222-35 Equal Opportunity for Veterans SEP 2010

52.222-36 Affirmative Action For Workers With Disabilities OCT 2010

52.222-37 Employment Reports on Veterans SEP 2010

52.222-38 Compliance with Veterans’ Employment Reporting

Requirements

FEB 2016

52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons FEB 2009

52.222-54 Employment Eligibility Verification JUL 2012

52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015

52.222-59 Compliance with Labor Laws (Executive Order 13673) DEC 2016

52.222-60 Paycheck Transparency (Executive Order 13673) OCT 2016

52.222-61 Arbitration of Contractor Employee Claim (Executive Order

13673)

DEC 2016

52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2017

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011

52.223-6 Drug-Free Workplace MAY 2001

52.223-9 Estimate of Percentage of Recovered Material Content for

EPA-Designated Items

MAY 2008

52.223-10 Waste Reduction Program MAY 2011

52.223-16 Acquisition of EPEAT (R) - Registered Personal Computer

Products

OCT 2015

52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies to Ban Text Messaging

While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008

52.227-1 Authorization and Consent DEC 2007

52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007

52.228-2 Additional Bond Security OCT 1997

52.228-5 Insurance - Work On A Government Installation JAN 1997

52.228-11 Pledges of Assets JAN 2012

52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014

52.228-14 Irrevocable Letter of Credit NOV 2014

52.228-15 Performance and Payment Bonds – Construction OCT 2010

52.229-3 Federal, State And Local Taxes FEB 2013

52.232-5 Payments under Fixed-Price Construction Contracts SEP 2002

52.232-17 Interest OCT 2010

52.232-23 Alt I Assignment of Claims (Jan 1986) - Alternate I APR 1984

52.232-27 Prompt Payment for Construction Contracts OCT 2008

52.232-33 Payment by Electronic Funds Transfer-Central Contractor

Registration

OCT 2003

52.233-1 Disputes JUL 2002

52.233-3 Protest After Award AUG 1996

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.236-2 Differing Site Conditions APR 1984

52.236-3 Site Investigation and Conditions Affecting the Work APR 1984

52.236-4 Physical Data APR 1984

52.236-5 Material and Workmanship APR 1984

52.236-6 Superintendence by the Contractor APR 1984

52.236-7 Permits and Responsibilities NOV 1991

52.236-8 Other Contracts APR 1984

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984

52.236-11 Use and Possession Prior to Completion APR 1984

52.236-12 Cleaning Up APR 1984

52.236-13 Alt I Accident Prevention (Nov 1991) - Alternate I NOV 1991

52.236-15 Schedules for Construction Contracts APR 1984

52.236-17 Layout of Work APR 1984

52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997) -

Alternate I

APR 1984

52.236-26 Preconstruction Conference FEB 1995

52.242-13 Bankruptcy JUL 1995

52.242-14 Suspension of Work APR 1984

52.243-4 Changes JUN 2007

52.244-6 Subcontracts for Commercial Items DEC 2010

52.245-1 Government Property JAN 2017

52.245-9 Use and Charges APR 2012

52.246-12 Inspection of Construction AUG 1996

52.246-21 Warranty of Construction MAR 1994

52.248-3 Value Engineering-Construction OCT 2010

52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984

52.253-1 Computer Generated Forms JAN 1991

252.201-7000 Contracting Officer's Representative DEC 1991

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense-

Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights JAN 2009

252.204-7003 Control of a Government Personnel Work Product APR 1992

252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident

OCT 2016

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Terrorist Country

DEC 2006

252.215-7000 Pricing Adjustments DEC 1991

252.223-7001 Hazard Warning Labels DEC 1991

252.223-7006 Prohibition On Storage And Disposal Of Toxic And

Hazardous Materials

APR 2012

252.225-7012 Preference For Certain Domestic Commodities FEB 2013

252.227-7033 Rights in Shop Drawings APR 1966

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006

252.236-7000 Modification Proposals-Price Breakdown DEC 1991

252.243-7001 Pricing of Contract Modification DEC 1991

252.243-7002 Requests for Equitable Adjustment MAR 1998

252.244-7000 Subcontracts for Commercial Items and Commercial

Components (DoD Contracts)

MAR 2013

252.245-7001 Tagging, Labeling, and Marking of Government – Furnished

Property

APR 2012

252.245-7002 Reporting Loss of Government Property APR 2012

252.245-7003 Contractor Property Management System Administration APR 2012

252.245-7004 Reporting, Reutilization, and Disposal SEP 2016

252.247-7023 Transportation of Supplies by Sea MAY 2002

CLAUSES INCORPORATED BY FULL TEXT

52.225-9 BUY AMERICAN ACT—CONSTRUCTION MATERIALS (SEP 2010)

(a) Definitions. As used in this clause--

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in section 3 of the Shipping Act of 1984 (46 U.S.C. App. 1702), such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Domestic construction material means--

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if--

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

Foreign construction material means a construction material other than a domestic construction material.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements the Buy American Act (41 U.S.C. 10a-10d) by providing a preference for domestic construction material. In accordance with 41 U.S.C. 431, the component test of the Buy American Act is waived for construction material that is a COTS item (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows: NONE

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American Act. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph

(b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American Act applies and the

Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American Act applies, use of foreign construction material is noncompliant with the Buy American Act.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the

Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison

Construction material description Unit of measure Quantity Price (dollars) \1\

Item 1

Foreign construction material

Domestic construction material

Item 2

Foreign construction material

Domestic construction material

Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).

List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.

Include other applicable supporting information.

(End of clause)

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address:

http://farsite.hill.af.mil

(End of clause)

252.236-7001 CONTRACT DRAWINGS, MAPS, AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2)…