Solicitation_W912DW-17-B-0008_Aug_23,_2017.pdf

IFB No. W912DW-17-B-0008

Seattle District

FY17 DLA Warehouse 9670 Remodel Project, JBLM, WA

Construction Remodel Solicitation and Specifications

This is a 100% Set-Aside for Service Disabled Veteran Owned Small Business (SDVOSB)

August 23, 2017

This page is intentionally left blank as a back side to the cover page.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

W912DW-17-B-0008

2. TYPE OF SOLICITATION 3. DATE ISSUED

23-Aug-2017

PAGE OF PAGES

X SEALED BID (IFB)

NEGOTIATED (RFP)

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

442995

7. ISSUED BY CODE W912DW 8. ADDRESS OFFER TO (If Other Than Item 7) CODE

USA ENGINEER DISTRICT, SEATTLE

ATTN: CENWS-CT

4735 EAST MARGINAL WAY SOUTH, BLDG. 1202

SEATTLE WA 98134-2388

TEL: FAX:

See Item 7

TEL: FAX:

9. FOR INFORMATION

CALL:

A. NAME

DEBBIE A KNICKERBOCKER

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

206-764-6804

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date):

DLA Warehouse 9670 Remodel, JBLM

The Contractor w ill f urnish all labor, materials, and equipment to perform all w ork for the DLA Warehouse 9670 Remodel Project, PN 442995, at Joint Base Lew is McChord (JBLM), WA in accordance w ith the attached Contract Clauses, Provisions, Special Clauses, Technical Specif ications and Draw ings.

This project is 100% Set-aside for Service Disabled Veteran Ow ned Small Business (SDVOSB) f irms.

Magnitude of w ork: Betw een $5,000,000 and $10,000,000.

11. The Contractor shall begin perf ormance w ithin 10 calendar days and complete it w ithin 365 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See * 00 73 00 .)

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

12B. CALENDAR DAYS

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed of fers in original and 0 copies to perf orm the w ork required are due at the place specified in Item 8 by 2:00 PM (hour) local time 22 Sep 2017 (date). If this is a sealed bid solicitation, off ers must be publicly opened at that time. Sealed envelopes containing of fers shall be marked to show the of feror's name and address, the solicitation number, and the date and time off ers are due.

B. An of fer guarantee X is, is not required.

C. All off ers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than 90 calendar days for Government acceptance af ter the date off ers are due w ill not be considered and w ill be rejected.

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA FAR (48 CFR) 53.236-1(e)

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

OFFER (M ust be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14)

See Item 14

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specified below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY: CODE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this 29. AWARD (Contractor is not required to sign this document.)

document and return _ copies to issuing office.) Contractor agrees to f urnish and deliv er all items or perf orm all work, requisitions identif ied on this f orm and any continuation sheets f or the consideration stated in this contract. The rights and obligations of the parties to this contract shall be gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

Y our of f er on this solicitation, is hereby accepted as to the items listed. This award con-summates the contract, which consists of (a) the Gov ernment solicitation and y our of f er, and (b) this contract award. No f urther contractual document is necessary .

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED

TO SIGN (Type or print)

31A. NAME OF CONTRACTING OFFICER (Type or print)

TEL: EMAIL: 30B. SIGNATURE 30C. DATE

31B. UNITED STATES OF AMERICA

BY

31C. AWARD DATE

NSN 7540-01-155-3212 STANDARD FORM 1442 BACK (REV. 4-85)

TABLE OF CONTENTS

CAUTION TO BIDDERS

SECTION TITLE

SF1442 Pages 00 11 00-1 thru 00 11 00-6 (00 11 00-3 is reserved for use at a later time)

00 21 00 Instructions, Conditions and Notice to Offerors

00 45 00 Representations and Certifications and other Statements of Offerors, and Pre-Award Information

1 72 00 Contract Clauses

2 73 00 Special Clauses, which include the following:

a) Special Clauses Pages 00 73 00-1 thru 00 73 00-14

b) Davis-Bacon General Wage Decision No.

WA170038

3 00 00 Technical Specifications: 01 14 10 thru 33 82 00

! ! ! C A U T I O N TO B I D D E R S ! ! !

1. TELEPHONES: There are no public telephones at the Seattle District Corps of Engineers.

2. BUSINESS HOURS: For the Seattle District Corps of Engineers are from 7:30 A.M. to 4:00 P.M., Monday through Friday.

3. AVAILABILITY OF FUNDS: Funds are not currently available for this acquisition. No contract award will be made until appropriated funds are made available from which payment for contract purposes can be made.

BEFORE SIGNING AND MAILING THIS OFFER, PLEASE TAKE NOTE OF THE FOLLOWING, AS

FAILURE TO PERFORM ANY ONE OF THESE ACTIONS MAY CAUSE YOUR OFFER TO BE REJECTED

4. AMENDMENTS: Have you acknowledged receipt of ALL amendments? If in doubt as to the number of amendments issued, please contact the representative listed on the Information Page.

5. AMENDED SECTIONS: If any of the amendments furnished amended sections, the amended sections must be used in submitting your offer.

6. MISTAKE IN OFFER: Have you reviewed your offer price for possible errors in calculation or work left out?

7. OFFER ACCEPTANCE PERIOD: The offer acceptance period is specified in block 13D of SF1442, page 00 11 00 -1, Solicitation, Offer and Award. Please ensure that you allow at least the stated number of calendar days for the Government to accept your offer.

8. SYSTEM FOR AWARD MANAGEMENT: Before receipt of contract award, Contractors are required to ensure that their firm is registered in the government web site entitled System for Award Management (SAM) and that all information required is current and up to date. https://www.sam.gov/portal/public/SAM/

9. Far 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper (May 2011) The Contractor is asked to submit paper documents, such as offers, letters, or reports that are printed or copied double-sided on paper containing at least 30 percent postconsumer fiber, whenever practicable, when not using electronic commerce methods to submit information or data to the Government.

10. ATTENTION: Due to heightened security, the method of Hand Delivery has changed, and it takes longer than the previous method of arriving at the Federal Center South building lobby to deliver your bid.

Please allow sufficient time to allow for heightened security at Government installations and to get to Building #1202.

Allow time to park, pass through a metal detector, sign in, and receive a building pass at the Federal Center South Building. From there, you will be directed to the USACE Oxbow Building (#1202) which sits behind the Federal Center South Building. Allow additional time.

Report to the Security Desk in the lobby of the USACE Oxbow Building (#1202) and you will be directed to the bid opening room. This room will be available 30 minutes prior to the bid opening. If you do not wish to be present when bids are opened and would like to drop off your bid, contact the following persons upon reporting to the Security Desk:

Sonia Frees, Procurement Technician, at 206-764-3516, or Debbie Knickerbocker, the Contracting Specialist, at 206- 764-6804. A Contracting representative will come down and accept your bid.

A bid is not received by the Government until it is in the physical possession of a representative of the Contracting office.

Security guards and other non-contracting personnel are NOT authorized to accept proposals on behalf of the Government.

Note that official receipt of a proposal shall be in accordance with FAR 52.215-1.

Note: If delivery is by any means other than Hand Delivery, please check prior to the due date and time to ensure that your bid has arrived on time.

W912DW-17-B-0008

THIS PROCUREMENT IS:

100% set-aside for Service Disabled Veteran-Owned Small Business (SDVOSB)

SITE VISIT: A SITE VISIT IS SCHEDULED FOR THURSDAY, 7 SEPTEMBER 2017;

Meeting time will be 1:00pm Local Time; Location will be at Building 9671, JBLM.

POC’s: Robert Burrell, Area Manager; DLA Disposition Services Lewis; 253 966 3182 and Keeley Brown, Project Manager; USACE Seattle District; 206 764-3434.

Contractors who don’t already have access to JBLM will need a Visitor’s Pass. You may take Exit 120 off Interstate 5 to visit the Pass and ID building. To receive a Visitor Pass, you will be required to show ID, Vehicle Registration and proof of Insurance. To get to Bldg. 9671 on JBLM go to I-5 and take Exit 123. If you are coming from North, turn left, go for ¾ mile to Logistics Center Gate; turn left onto Rainier Ave. and go ¾ mile to the corner of Rainier and O Street, turn right onto O Street; destination is there. If you are coming from the South turn right, go for ¾ mile to Logistics Center Gate; turn left onto Rainier Ave. and go ¾ mile to the corner of Rainier and O Street, turn right onto O Street; destination is there.

Advanced registration for all attendees is required. Please provide the following information to Debbie Knickerbocker at debbie.a.knickerbocker@usace.army.mil NO LATER THAN 3 business days before the site visit. All attendees must present valid I.D. All vehicles must have valid vehicle registration and valid proof of insurance. Without these items, the person and/or vehicle will not be allowed to attend the site tour. Please arrive about 15 minutes early to begin the check-in process.

BIDDING DOCUMENTS: Register for solicitations at the Internet site: http://www.fedbizopps.gov/

Please see Section 00 21 00 of this Solicitation.

FOR INQUIRIES AND ADMINISTRATIVE MATTERS: Contact the following individual Monday through Friday between the hours of 8:00 a.m. and 3:30 p.m.:

Debbie Knickerbocker, debbie.a.knickerbocker@usace.army.mil Susan Newby, susan.f.newby@usace.army.mil

(Mail) Seattle District, U.S. Army Corps of Engineers, P.O. Box 3755, CECT-NWS, Bldg 1202, Seattle, WA 98124-3755

(Street) 4735 E. Marginal Way S., Bldg 1202, Seattle, WA 98134-2388

TECHNICAL QUESTIONS:

All inquiries regarding this solicitation are to be submitted via ProjNet-Bidsm. Telephone and email inquiries will not be accepted. ProjNet-Bidsm is a web-based program that allows bidders to post questions regarding the solicitation and to view all questions by other bidders and answers by USACE. ProjNet-Bidsm can be accessed through ProjNetsm at https://www.projnet.org To access the ProjNet-Bidsm website the first time:

1) Click the Bid tab

2) Click Bidder Inquiry. (The Agency is USACE.)

3.a) Enter the following information for access:

1. The Bidder Inquiry Key GVE6VF-MTB3Y4

2. Valid business contact information (e.g. company name, contact person, business address, phone number and email address). (required on first project only)

3. Establish Secret Question and Answer which will be used as a password (required on first project only) 3.b) For subsequent access use your email address, the Bid Inquiry Key, and response to the Secret Question to access the ProjNet-Bidsm Module.

4) Submit technical questions. When an answer is posted to a question, the question and answer is then available for all other bidders to review.

5) For questions about the ProjNet-Bidsm, please contact the Call Center help desk toll free at 1-800- 428-HELP (4357), which operates from 8AM to 5PM (Central US time zone).

No response will be posted to inquiries after the Close of Business on the fifth business day preceding the solicitation due date. All bidders will be held to have reviewed the questions and responses in ProjNet-Bidsm prior to bid submission. Nothing in the solicitation is changed unless an amendment is sent out.

IF THE CONTRACTOR IS A CORPORATION OR PARTNERSHIP, THE APPLICABLE PORTION

OF THE FORM LISTED BELOW MUST BE COMPLETED. IN THE ALTERNATIVE, OTHER

EVIDENCE MUST BE SUBMITTED TO SUBSTANTIATE THE AUTHORITY OF THE PERSON

SIGNING THE CONTRACT. IF A CORPORATION, THE SAME OFFICER SHALL NOT

EXECUTE BOTH THE CONTRACT AND THE CERTIFICATE.

CORPORATE CERTIFICATE

I, , certify that I am the

Secretary of the Corporation named as Contractor herein; that , who signed this contract on behalf of the Contractor was then of said corporation; that said contract was duly signed for and on behalf of said corporation by authority of its governing body and is within the scope of its corporate powers.

(CORPORATE

(Secretary) SEAL)

AUTHORITY TO BIND PARTNERSHIP

This is to certify that the names and signatures of all partners are listed below and that the person signing the contract has authority actually to bind the partnership pursuant to its partnership agreements.

Each of the partners individually has full authority to enter into and execute contractual instruments on behalf of said partnership with the United States of America, except as follows: (state "none" or describe limitations, if any)

This authority shall remain in full force and effect until such time as the revocation of authority by any cause whatsoever has been furnished in writing to, and acknowledged by, the Contracting Officer.

(Names and Signatures of all Partners)

NAME SIGNATURE

W912DW-17-B-0008 00 11 00 - 4

This page was intentionally left blank for duplex printing.

FY15 P2 442995 DLA Warehouse Bldg #9670 15013 Joint Base Lewis-McChord, WA W912DW-17-B-0008

00 11 00

BID SCHEDULE

CLIN

Item # Description of Item Quantity Unit

Unit Price Amount

BASE ITEMS

0001 Site preparation, including demolition of

Building #9686 and existing loading dock, and construction of site work, site utilities, and paved areas from the construction limits to the building.

1 JOB N/A $________________

0002 Repairs of warehouse including all work as delineated in the drawings and specifications except those items specifically included in Item #0003.

1 JOB N/A $________________

0003 Provision of new storage racks and associated equipment including concrete floor preparation and polishing as described in detail in Section 01 22 01 MEASUREMENT AND PAYMENT, Paragraph WORK INCLUDED IN

ITEM 0003.

1 JOB N/A $________________

0004 All work for O&M manuals as specified in Section 01 78 23 OPERATIONS AND MAINTENANCE MANUALS from preparation to final approval.

1 JOB N/A $20,000

0005 All work for As-Built drawings as specified in Section 01 78 00 CLOSEOUT SUBMITTALS from preparation to final approval.

1 JOB N/A $10,000

All Work for DD Form 1354 Checklist and Equipment-in-Place List as specified in Section 01 78 00 CLOSEOUT SUBMITTALS from Preparation to Final Approval.

1 JOB N/A $10,000

TOTAL ALL ITEMS 0001-0006 $_____________________

NOTES:

1) 100% Design Projects cannot be altered, changed, or re-designed in any way. No alternate proposals will be accepted.

2) To better facilitate the receipt and proposal process, all modifications to proposals shall be submitted on copies of the latest Bid Schedule as published in the solicitation or the

FY15 P2 442995 DLA Warehouse Bldg #9670 15013 Joint Base Lewis-McChord, WA W912DW-17-B-0008

00 11 00 latest amendment thereto. In lieu of indicating additions/deductions to line items, all Offerors should state their revised prices for each item.

3) Offerors must insert a price on all entry amount lines of numbered items of the Bid Schedule. Failure to do so will result in the offer being unacceptable.

4) The dollar amount established in Item Nos. 0004, 0005, and 0006 shall not be revised by Offerors.

END BID SCHEDULE

SECTION 00 21 00

CLAUSES/PROVISIONS INCORPORATED BY REFERENCE

52.204-7 System for Award Management (OCT 2016) 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.232-14 Notice Of Availability Of Progress Payments Exclusively For APR 1984

Small Business Concerns 52.232-18 Availability Of Funds APR 1984

CLAUSES/PROVISIONS INCORPORATED BY FULL TEXT

52.214-15 PERIOD FOR ACCEPTANCE OF BIDS (APR 1984)

In compliance with the solicitation, the bidder agrees, if this bid is accepted within 90 calendar days from the date specified in the solicitation for receipt of bids, to furnish any or all items upon which prices are bid at the price set opposite each item, delivered at the designated point(s), within the time specified in the Schedule.

(End of clause)

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

(End of provision)

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK (MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

(End of provision)

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

6.2% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Joint Base Lewis-McChord (JBLM), Pierce County, Fort Lewis, Washington

(End of provision)

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT--CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American --Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

(End of provision)

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3,000,000.00, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of provision)

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

R. Dave Williams, Chief of Contracting US Army Corps of Engineers – Seattle District PO Box 3755 Seattle, WA 98124-3755

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://www.farsite.hill.af.mil http://www.dtic.mil/dfars

(End of provision)

52.252-3 ALTERATIONS IN SOLICITATION (APR 1984)

Portions of this solicitation are altered as follows:

Alterations, if necessary, will be via Amendment.

Section 00 45 00 - Representations & Certifications

The following representations and certifications apply to this solicitation. Offerors submitting proposals in response to this solicitation shall fill in the appropriate information and/or check the appropriate boxes for each provision listed below and complete the Pre-Award Information sheet provided as Attachment A at the end of this Section. This information shall be submitted with the offeror’s price proposal.

In addition, a complete FAR and DFARS Representations and Certifications will be retrieved from the System For Award Management (SAM). The website for SAM is www.SAM.gov.

Failure to complete and submit the provisions listed herein as well as the Pre-Award Information sheet may result in delay of contract award. Failure to complete and/or update the SAM Registration by the time proposals are due may also result in delay of contract award.

CLAUSES INCORPORATED BY FULL TEXT

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2017)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 236220.

(2) The small business size standard is $36,500,000.00.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

X

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.222-57, Representation Regarding Compliance with Labor Laws (Executive Order 13673). This provision applies to solicitations expected to exceed $50 million which are issued from October 25, 2016 through April 24, 2017, and solicitations expected to exceed $500,000, which are issued after April 24, 2017.

Note to paragraph (c)(1)(xvi): By a court order issued on October 24, 2016, 52.222-57 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(xvii) 2.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,533, the provision with its Alternate II applies.

(D) If the acquisition value is $77,533 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) ) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2015)

Substitute the following paragraphs (d) and (e) for paragraph (d) of the provision at FAR 52.204-8:

(d)(1) The following representations or certifications in the System for Award Management (SAM) database are applicable to this solicitation as indicated:

(i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.222-7007, Representation Regarding Combating Trafficking in Persons, as prescribed in 222.1771. Applies to solicitations with a value expected to exceed the simplified acquisition threshold.

(iv) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(v) 252.225-7049, Prohibition on Acquisition of Commercial Satellite Services from Certain Foreign Entities-- Representations. Applies to solicitations for the acquisition of commercial satellite services.

(vi) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vii) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(viii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(ix) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

(i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

(ii) 252.225-7000, Buy American--Balance of Payments Program Certificate.

(iii) 252.225-7020, Trade Agreements Certificate.

Use with Alternate I.

(iv) 252.225-7031, Secondary Arab Boycott of Israel.

(v) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate.

Use with Alternate I.

Use with Alternate II.

Use with Alternate III.

Use with Alternate IV.

Use with Alternate V.

(e) The offeror has completed the annual representations and certifications electronically via the SAM Web site at https://www.acquisition.gov/. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

SUBMIT THE FOLLOWING INFORMATION WITH YOUR BID

NOTICE TO BIDDERS REGARDING PRE-AWARD INFORMATION

1. Company Name and Address:

2. Point of Contact Name:

Telephone Number: Fax Number:

Email address:

3. Electronic Transfer Payments will now be required for all new contracts. Do you currently receive Electronic Transfer Payments from this agency? (agency codes 00005524/00006482) Yes No

4. Name of Bank and Branch:

Personal Banker:

Telephone Number: Fax Number:

Email address:

5. Name of Bonding Agent Company:

Agents Name:

Telephone Number: Fax Number:

Email address:

6. Contractors are required, before receipt of contract award to ensure that their firm is registered in the government web site entitled System for Award Management (SAM) and that all information required is current and up to date.

https://www.sam.gov/portal/public/SAM/

Ensure that your company’s information is updated for the following areas:

CORE DATA: Ensure that your business types are correctly filled in:

(Examples of Business types: Small Business (SB), Small Disadvantaged Business (SDB), Woman-Owned Small Business (WOSB), Historically Underutilized Business Zone (HUBZone), Veteran-Owned Small Business (VOSB), Service-Disabled Veteran-Owned Small Business (SDVOSB), and SBA 8(a)).

What is your business type?

DUNS Number:

CAGE Code:

TAX ID:

REPS & CERTS: Ensure that you have certified the FAR and DFARs provisions (clauses) listed on the Reps & Certs pages.

CORE DATA – Business Types updated: Yes Date:

REPS & CERTS – Certified Yes Date:

7. Please provide the following information; it will not be used to evaluate or rank bids. It will be used solely as a reference check for our internal files. List no more than three projects that are substantially complete or have been completed

W912DW-17-B-0008 00 45 00 - A

within the last ten years that are similar to this project. Projects should be listed in the following order: Federal projects, state projects, city/county projects, and then commercial projects. Use the following format:

a) Title & Location of Project:

Agency/Company:

Point of Contact (Name &Title):

Email address:

Telephone Number: Award Amount: $ Yr of Completion:

b) Title & Location of Project:

Agency/Company:

Point of Contact (Name &Title):

Email address:

Telephone Number: Award Amount: $ Yr of Completion:

c) Title & Location of Project:

Agency/Company:

Point of Contact (Name &Title):

Email address:

Telephone Number: Award Amount: $ Yr of Completion:

8. List all outstanding uncompleted projects, in the following format:

a) Title of Project:

Agency/Company:

Award Amount: $ Est. Completion Date:

b) Title of Project:

Agency/Company:

Award Amount: $ Est. Completion Date:

c) Title of Project:

Agency/Company:

Award Amount: $ Est. Completion Date:

W912DW-17-B-0008 00 45 00 - B

Section 00 72 00 - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal MAY 2014

Or Improper Activity 52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-17 Contractor Employee Whistleblower Rights and Requirement APR 2014 To Inform Employees of Whistleblower Rights

52.204-2 Alt II Security Requirements (Aug 1996) - Alternate II APR 1984 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52…