Atch_2_Supplemental_Contract_Requirements.pdf
PDF 85 KB Posted
- Attached to
- Live Fire Exercise Shoothouse at Camp W. G. Williams, Utah Federal contract opportunity
- Solicitation number
- W91238-17-S-0679
About this file
Atch 2 Supplemental Contract Requirements
View the file
Other files for this federal contract opportunity
Show all 31
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Attachment 2 – Supplemental Contract Requirements Live Fire Exercise Shoothouse Camp Williams, UT June 9, 2017
SUPPLEMENTAL CONTRACT REQUIREMENTS
1. Performance Period. Refer to FAR 52.211-10, Commencement, Prosecution, And Completion of Work. The time duration of performance period is 540 calendar days after Notice to Proceed date.
2. Liquidated Damages. Refer to FAR 52.211-12, Liquidated Damages-Construction.
Liquidated damages for this work is $1,686.00 for each day of delay.
3. Authorities. Only a warranted Contracting Officer (either PCO or ACO) acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer. The Government Contracting Officer/Administrative Contracting Officer has the authority to make any changes to this contract action that impact cost or schedule. Authority from the Contracting Officer/Administrative Contracting Officer to the contractor to make changes that impact cost or schedule will be in the form of an official, signed modification.
4. Wage Determination. General Decision Number UT170108, 2/03/2017 (Building), Utah County, Utah, or its most current modification at the time of award is hereby applicable to work performed under this contract. The most current decisions or their modifications can be found by clicking on hyperlink https://www.wdol.gov/wdol/scafiles/davisbacon/UT108.dvb?v=3 for such information.
5. Time Extensions For Unusually Severe Weather. Refer to FAR 52.249-10, Default (Fixed- Priced Construction). All weather delays will need to be submitted and approved by the Contracting Officer Representative.
MONTHLY ANTICIPATED ADVERSE WEATHER DELAY
WORK DAYS BASED ON (5) DAY WORK WEEK
JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC
(20) (16) (14) (08) (05) (03) (02) (02) (02) (05) (13) (21)
File details come from the government source that posted it.