19T0094_Released.pdf

SEE ADDENDUM

(No Collect Calls)

W9098S19T0094 19-Jul-2019

b. TELEPHONE NUMBER

(309) 782-8543

8. OFFER DUE DATE/LOCAL TIME

08:00 AM 12 Aug 2019

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W9098S9. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

DEBBIE L TRAINOR

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

0 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

ROCK ISLAND ARSENAL (ACC-RI)

JOINT MANUFACTURING & TECHNOLOGY CENTER

BLDG 211 RODMAN AVENUE

1 ROCK ISLAND ARSENAL

ROCK ISLAND IL 61299-5000

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS AX

13b. RATING

DO-C9

CODE15. DELIVER TO CODE 16. ADMINISTERED BY

SEE SCHEDULE

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

FAX:

TEL: SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

NAICS:

337124

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF58

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

W9098S19T0094

Section SF 1449 - CONTINUATION SHEET

SOLICITATION NARRATIVE

ADDENDUM TO 52.212-1, INSTRUCTIONS TO OFFERORS – COMMERCIAL

1. The Army Contracting Command - Rock Island (ACC-RI) hereby issues solicitation W9098S19T0094 for the procurement of Type I and Type II Cabinet Sets in support of the Metal Working and Machine Shop Set (MWMSS) program at the Rock Island Arsenal, Joint Manufacturing and Technology Center (RIA-JMTC). The solicitation is issued in accordance with FAR Part 12 (Acquisition of Commercial Items) and FAR Part 13.5 (Simplified Procedures for Certain Commercial Items). The result of this solicitation will be a Firm Fixed Price (FFP), 5-year Indefinite Delivery/Indefinite Quantity (IDIQ) contract. Award will be based on the lowest priced, responsive, responsible vendor quote whose offer conforms to the solicitation requirement to include delivery schedule and represents the lowest total evaluated price. Contractor responsibility will be determined as outlined by FAR 9.104-1.

The IDIQ will include five, 1-year evaluated ordering periods as follows:

Ordering Period One: Date of Contract to 365 calendar day Ordering Period Two: 366 calendar day to 731 calendar day Ordering Period Three: 732 calendar day to 1,096 calendar day Ordering Period Four: 1,097 calendar day to 1,462 calendar day Ordering Period Five: 1,463 calendar day to 1,827 calendar day

*Actual dates will be clarified at the time of award.

*Any offeror submitting a quote agrees by submission that their quote and the prices contained therein will be valid for 90 days after receipt of proposals.

Evaluation of Offers – All or None. Vendors must quote all items to be eligible for award.

2. The total minimum and maximum quantities for each CLIN are listed in the table below. These guaranteed minimum quantities are the only guaranteed quantities to be awarded under this solicitation. The Government is under no further obligation to order additional quantities on any CLIN. Except for the minimum guaranteed quantity, all quantities are estimates and do not bind the Government in any way.

CLIN DRAWING NUMBER MINIMUM QTY MAXIMUM QTY

0001 See CLIN 0001 Type I

Cabinet Set drawings 1 120

0002 See CLIN 0002 Type II Cabinet Set drawings

1 120

3. Deliveries:

Deliveries must begin within 60 days of issuance of a delivery order. Firm delivery dates will be expressed on the delivery order(s).

Delivery will be FOB Destination to:

TRANSPORTATION OFFICER, W52H1C

BLDG 299, BECK AND GILESPIE

EAST END, RECG DOOR 16A

ROCK ISLAND IL 61299-5000

*On time delivery is very critical. Therefore, the contractor must adhere to the delivery requirements indicated in each individual delivery order issued under the awarded IDIQ contract. Failure to comply with the contractual delivery schedule after issuance of a delivery order may result in termination of the order or require consideration if the Government elects to extend the schedule. The Government is not required to extend your delivery should you encounter delays. The non-availability of raw materials, subcontractor issues, scheduling conflicts, etc., are not considered acceptable delays/excuses for failing to meet the contractual delivery schedule. If there is going to be a delay in delivery, the contractor is required to notify the Contract Specialist/Contracting Officer designated in the delivery order prior to being late. The contractors notice shall include the contractor’s complete reasons for delay(s), corrective action(s) taken or to be taken, and the contractor’s offered consideration for the identified delay for Government consideration. It is the responsibility of the contractor to ensure that they are providing quality product(s) that conform to the Contract/Delivery Order terms and conditions as well as meet the required delivery dates. Delivery of nonconforming products results in delivery/acceptance delays and increased cost to the Government. Early delivery is acceptable.

4. Warranty: A commercial standard warranty (to include parts and labor) is required for all CLINS. All warranties will begin upon final acceptance by the United States Government (USG). Contractor shall provide the product warranty information IAW CDRL 0003 (Attachment 0004_CDRL 0003) upon award.

5. Payment: Payment will be made 100% upon final acceptance by USG. Payments will be processed through Defense Finance and Accounting Systems (DFAS) via Wide Area Workflow (WAWF). Only Electronic invoices, submitted through WAWF, will be accepted. All other formats will be rejected.

6. Pricing:

Offerors shall complete the Price Matrix (Attachment 0001). Pricing provided at the CLIN level is not acceptable.

Each cell that requires the Offeror’s input on the Price Matrix has been highlighted in blue. The offeror shall enter firm fixed prices for each CLIN, Ordering Period, and Quantity Ranges on the applicable Price Matrix (Attachment 0001).

Proposed unit prices must be submitted on an FOB Destination basis. Ship to location is Rock Island, IL 61299- 5000. The quantity ranges on the Price Matrix are provided solely for the purpose of establishing reasonable ranges of quantities against which to provide prices in the event all delivery orders are executed. In order to be acceptable, an offer must include firm fixed unit prices for all CLINs, all ordering periods and quantity ranges listed on the Price Matrix. Any order placed against the resulting contract will be at the unit price offered by the contractor for the applicable quantity range and ordering period. Failure to complete the Price Matrix in its entirety may deem an offeror as non-responsive.

No other information is to be added to the Price Matrix, nor shall Offerors make any changes to the Price Matrix. All proposed unit prices are limited to two decimal places and shall be stated in current U.S. dollars. All unit prices proposed will be binding. The Government reserves the right to require the submission of any data (i.e. certified cost or pricing data or data other than certified cost or pricing data) necessary to validate the reasonableness of an offer.

Award will be made to the Offeror whose quote represents the lowest total evaluated price. Therefore, the contractor’s initial quote should contain the contractor’s best terms. Any order placed against the resulting contract will be at the unit price offered by the contractor for the applicable quantity range and ordering period based on the date the delivery order is issued. All delivery orders will be issued unilaterally by the Government. Upon award, Delivery Order 0001 will be placed for at least the guaranteed minimum quantity.

7. Evaluation:

Award will be based on the lowest priced, responsive, responsible vendor quote whose offer conforms to the solicitation requirement to include delivery schedule and represents the lowest total evaluated price.

a. The Government will evaluate offers based on prices proposed for all Ordering Periods and any other price related factors required by the solicitation. Prices will be determined fair and reasonable IAW FAR 13.106-2.

b. For each quote, the Government will calculate a weighted average price for each CLIN by multiplying the proposed unit prices for each Quantity Range and Ordering Period by their respective weight. Note that the weight associated with each range represents the likelihood that an order, if placed, would be placed within that range. The weighted average unit price is then multiplied by the estimated annual quantity for each ordering period to calculate an estimated annual total price. Note that the annual estimated quantity is just an estimate for evaluation purposes only and does not bind the Government to purchase those quantities in any ordering period.

c. The Total Evaluated Price is the sum of the evaluated price for each CLIN.

d. If an offeror fails to submit unit prices for all quantity ranges and Ordering Periods listed on the Price Evaluation Sheet, its proposal may be considered unacceptable and the Government may reject the quote.

8. All offerors must complete the following. Failure to comply may result in your firm being considered non-compliant.

FAR 52.223-22 - Public Disclosure of Greenhouse Gas Emissions and Reduction Goals-- Representation is included in this solicitation.

Did your firm receive $7.5 million or more in Federal contract awards in the prior Federal fiscal year? Please place an "X" next to the appropriate answer.

Yes_____ Completion of 52.223-22, located in the Addendum to 52.212-1 below is required.

No_____ No further action for this provision is required.

9. The following is a list of documents incorporated as attachments to this solicitation:

Attachment 0001 Price Matrix Attachment 0002 CDRL_0001_CommercialManuals-Copyright Release Attachment 0003 CDRL_0002_ ProductWarrantyInformation

10. Only ACC-RI (CCRI-AH) is authorized to issue delivery orders under this IDIQ contract.

11. Government Points of contact for this solicitation are as follows:

Title Name Phone Number Email Contract Specialist Debbie Trainor 309-782-8543 debbie.l.trainor.civ@mail.mil Procuring Contracting Officer

Cathy Mendoza 309-782-1258 cathy.k.mendoza.civ@mail.mil

12. Accessing Rock Island Arsenal:

Rock Island Arsenal (RIA) Visitor Access Passes are issued to individuals, not companies or groups. All visitors, to include transportation and freight services, official and unofficial, are highly suggested to pre-register at least three

(3) business days prior to their visit. Pre-registration of visitors allows for the National Crime Information Center NCIC-III background check to be conducted prior to the individual arriving at RIA, reducing their wait time upon arrival.

It is the responsibility of the prime contractor to ensure that this information is passed along to any subcontractor or transportation provider used during the performance of this purchase order. DRIVERS WHO DO NOT MEET

THE INSTALLATION ACCESS REQUIREMENTS WILL NOT BE ALLOWED ON THE

INSTALLLATION AND WILL BE TURNED AWAY.

NOTE: As of 31 Dec 2015, Department of Defense and Department of the Army has directed that Driver Licenses and ID cards from Minnesota, Missouri and Washington are not compliant with the standards of the REAL ID Act and cannot be used on their own as a primary means of identification to apply for access to Rock Island Arsenal.

Driver’s Licenses that have written on the top of them “NOT FOR FEDERAL IDENTIFICATION PURPOSES” are also non-compliant. These non-compliant driver’s license or state issued identification cards may still be presented at the Rock Island Visitor Control Center, but they must be accompanied by one of the following secondary forms of identification before a records check is conducted and installation access is granted:

*Current vehicle registration showing name and address *Social Security card *US passport or passport card *US Military or Draft Record (DD-214 or Selective Service Registration Card) *Veteran Health Identification Card issued by the US Department of Veterans Affairs *Transportation Worker Identification Credential *Personal Identification Verification card issued by the Federal Government *Personal Identification Verification 0 Interoperable card issued by the Federal Government *US Certificate of Naturalization or certificate of citizenship (Form N-550) *US Department of Homeland Security “Trusted Traveler” card (Global Entry, NEXUS, SENTRI, or

FAST)

*Driver’s license issued by the US Department of State *US Military Identification Card for military members, dependents and retirees *US Permanent Resident/Alien Registration Receipt Card (Form 1-551) *US Coast Guard or Department of Homeland Security Merchant Mariner card *Native American Tribal Photo Identification card

Visitor Access Request Forms and a complete list of acceptable identification can be found at https://home.army.mil/ria/ (click on Menu, then Visitor Information, and then under How to Visit Rock Island Arsenal click on the second bullet “How to obtain a visitor pass”. Then on the right side of the screen click on “Access Request Process”) or call 309-782-0551.

Forms may be emailed for faxed.

All visitors must process through the Moline Visitor Center Gate (I-74) off of River Drive in Moline, IL.

Visitors (to include transportation and freight providers) will require proper identification to access RIA

POC for this Policy are: RIA Visitor Center, Phone 309-782-0551, FAX 309-782-5029, email:

usarmy.ria.imcom.mbx.usag-access-request@mail.mil

13. RECEIVING HOURS OF OPERATION:

Monday – Friday, 6:30am to 2:00pm CST Deliveries before or after the above stated hours will be turned away. Appointments are not necessary.

For Directions call: 309-782-8539 (Automated)

END OF ADDENDUM TO 52.212-1, INSTRUCTIONS TO OFFERORS – COMMERCIAL

SUPPLEMENTAL INFORMATION

ADDENDUM TO 52.212-4, CONTRACT TERMS AND CONDITIONS – COMMERCIAL

1. SHIPPING/DELIVERY INSTRUCTIONS AND INFORMATION

A. The complete purchase order number (starts with W9098S----) MUST be on the outside of the shipping container(s). This number must also appear on all packing slips, invoices, bills, or any communications regarding this order.

B. A Packing List must be included with each shipment.

C. Shipment or delivery to any address other than the "ship to" address designated in the purchase order, Block 15 of the SF1449, may result in a delay in payment.

D. Any change in the "ship to" address must be approved by a written contract modification from the Contracting Officer.

(End of Notice)

2. ROCK ISLAND ARSENAL SAFETY REQUIREMENTS

A. All Contractors and Contractor personnel coming on to Arsenal Island must comply with the Rock Island Arsenal/Joint Manufacturing and Technology Center (RIA-JMTC), other Arsenal Island safety requirements and all federal, state, and local safety laws and regulations.

B. Contractors must provide their employees with, and the employees must use, all required safety equipment necessary for the work they are performing and/or the areas they are in.

C. This includes safety glasses, safety shoes, proper clothing, proper protective equipment and rigging.

D. All drivers on Arsenal Island must use seatbelts at all times when driving a motor vehicle.

E. If in doubt about any safety requirements, contact the Rock Island Safety Office Phone: 309-782-2579.

(End of Notice)

3. ROCK ISLAND ARSENAL LAW ENFORCEMENT, SECURITY, AND FIRE PREVENTION

REQUIREMENTS

A. Any contractor personnel entering Rock Island Arsenal (RIA) as a result of this order/contract are required to adhere to all regulations governing safety, law enforcement, security, and fire prevention in effect at the time of entrance. Failure to comply with said regulations may result in immediate removal from RIA. The contractor shall bear full responsibility of the consequences of said removal. Further clarifications of RIA regulations are available from the Contracting Officer of this order/contract.

B. BADGING: ALL contractors who are performing services within the confines of Rock Island Arsenal are required to obtain a visitor badge. Contractors shall coordinate with Contracting Officer/Specialist and (if applicable) the Contracting Officer’s Representative (COR) designated for the contract/order.

C. Contractors are required to display provided visitor badges above the waist in a conspicuous place on the upper part of the body. Badges are accountable and are required by the recipient to be safeguarded at all times to prevent theft, loss of misuse by unauthorized personnel.

D. PARKING: All parking is on a first come, first served basis, provided the parking space is not posted with a reserved, visitor, or Handicapped parking sign. Parking is allowed in “marked” spaces only. All valid spaces are clearly marked with white lines on both sides of the space. Vehicles parked in other than valid spaces are subject to being issued parking tickets.

E. Contractors will not be allowed in restricted areas of the Arsenal without proper identification and authorization.

F. INSEPCTIONS: All contractor employee’s vehicles, equipment, and packages are subject to inspection or examination at entry/exit of the Arsenal.

G. SMOKING POLICY: Indoor smoking is not permitted. Outside smoking must occur at least 50 feet from any building entrance and exit.

4. PHOTOGRAPHIC EQUIPMENT RESTRICTIONS

There are restrictions on the use of photographic devices in all non-public areas of Arsenal Island. This includes digital cameras, cell phones and PDAs with cameras. You must get permission to use any type of photographic device in any non-public area on Arsenal Island. All requests must be coordinated with the Contracting Officer’s Representative (COR) or designated Contracting Officer for this effort prior to using any photographic device.

5. RECEIVING HOURS OF OPERATION

RECEIVING HOURS OF OPERATION:

Monday - Friday, 6:30 am to 2:00 pm CST Deliveries before or after the above stated hours will be turned away.

Appointments are not required.

For directions call: 309-782-8539 (Automated)

(End of notice)

6. CONCEALED CARRY RESTRICTIONS

Concealed carry permits do not apply on military installations. Contractors and delivery drivers shall ensure there are NO weapons or ammunition in their vehicles prior to entering the installation; a K-9 unit will find and alert if any prohibited items are detected.

END ADDENDUM TO 52.212-4, CONTRACT TERMS AND CONDITIONS – COMMERCIAL

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 120 Each MWMSST1CABS Type I Cabinet Set

FFP

MWMSST1CABS consist of: Cabinet "A" Assembly IAW Drawing 11B5040003RIA, Cabinet "B" Top Cabinet Assembly IAW Drawing 11B5091067RIA, Cabinet "B" Bottom Cabinet Assembly IAW Drawing 11B5091047RIA, Cabinet "C" Top Cabinet Assembly IAW Drawing 11B5091020RIA, Cabinet "C" Bottom Cabinet Assembly IAW Drawing 11B5091048RIA, Cabinet "D" Assembly IAW Drawing 11B5040012RIA, Cabinet "E" Assembly IAW Drawing 11B5040015RIA, Cabinet "W" Assembly IAW Drawing 11B5040018RIA, Cabinet "X" Assembly IAW Drawing

11B5040021RIA.

CERTIFICATE OF CONFORMANCE (CoC) IS REQUIRED FOR THIS

MATERIAL PER FAR 52.246-15.

FOR RIA INTERNAL USE ONLY:

LMP PR #

Project Code # D25

QA: 120_335

FOB: Destination

PSC CD: 7125

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0002 120 Each MWMSST2CABS Type II Cabinet Sets

FFP

MWMSST2CABS consists of: Cabinet "F" Assembly IAW Drawing 11B5190645RIA, Cabinet "G" Assembly IAW Drawing 11B5190652RIA, Cabinet "F-G" Counter Top IAW Drawing 11B5190656RIA, and Cabinet "I-J" Assembly IAW Drawing 11B5140006RIA.

CERTIFICATE OF CONFORMANCE (CoC) IS REQUIRED FOR THIS

MATERIAL PER FAR 52.246-15.

FOR RIA INTERNAL USE ONLY:

LMP PR #

Project Code # D25

QA: 120_345

FOB: Destination

PSC CD: 7125

NET AMT

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.203-3 Gratuities APR 1984 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

252.203-7000 Requirements Relating to Compensation of Former DoD Officials

SEP 2011

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV 2011

252.204-7008 Compliance With Safeguarding Covered Defense Information Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.215-7008 Only One Offer OCT 2013 252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7001 Buy American And Balance Of Payments Program-- Basic DEC 2017 252.225-7012 Preference For Certain Domestic Commodities DEC 2017 252.226-7001 Utilization of Indian Organizations and Indian-Owned

Economic Enterprises, and Native Hawaiian Small Business Concerns

APR 2019

252.227-7015 Technical Data--Commercial Items FEB 2014 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.244-7000 Subcontracts for Commercial Items JUN 2013 252.247-7023 Transportation of Supplies by Sea FEB 2019

CLAUSES INCORPORATED BY FULL TEXT

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

(End of provision)

52.212-1 INSTRUCTIONS TO OFFERORS--COMMERCIAL ITEMS (OCT 2018)

(a) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code and small business size standard for this acquisition appear in Block 10 of the solicitation cover sheet (SF 1449). However, the small business size standard for a concern which submits an offer in its own name, but which proposes to furnish an item which it did not itself manufacture, is 500 employees.

(b) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show--

(1) The solicitation number;

(2) The time specified in the solicitation for receipt of offers;

(3) The name, address, and telephone number of the offeror;

(4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary;

(5) Terms of any express warranty;

(6) Price and any discount terms;

(7) "Remit to" address, if different than mailing address;

(8) A completed copy of the representations and certifications at FAR 52.212-3 (see FAR 52.212-3(b) for those representations and certifications that the offeror shall complete electronically);

(9) Acknowledgment of Solicitation Amendments;

(10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and

(11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration.

(c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 30 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation.

(d) Product samples. When required by the solicitation, product samples shall be submitted at or prior to the time specified for receipt of offers. Unless otherwise specified in this solicitation, these samples shall be submitted at no expense to the Government, and returned at the sender's request and expense, unless they are destroyed during preaward testing.

(e) Multiple offers. Offerors are encouraged to submit multiple offers presenting alternative terms and conditions, including alternative line items (provided that the alternative line items are consistent with subpart 4.10 of the Federal Acquisition Regulation), or alternative commercial items for satisfying the requirements of this solicitation.

Each offer submitted will be evaluated separately.

(f) Late submissions, modifications, revisions, and withdrawals of offers:

(1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that offers or revisions are due.

(2)(i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and--

(A) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of offers; or

(B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or

(C) If this solicitation is a request for proposals, it was the only proposal received.

(ii) However, a late modification of an otherwise successful offer, that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(3) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the offer wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(4) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(5) Offers may be withdrawn by written notice received at any time before the exact time set for receipt of offers.

Oral offers in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile offers, offers may be withdrawn via facsimile received at any time before the exact time set for receipt of offers, subject to the conditions specified in the solicitation concerning facsimile offers. An offer may be withdrawn in person by an offeror or its authorized representative if, before the exact time set for receipt of offers, the identity of the person requesting withdrawal is established and the person signs a receipt for the offer.

(g) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with offerors. Therefore, the offeror's initial offer should contain the offeror's best terms from a price and technical standpoint. However, the Government reserves the right to conduct discussions if later determined by the Contracting Officer to be necessary. The Government may reject any or all offers if such action is in the public interest; accept other than the lowest offer; and waive informalities and minor irregularities in offers received.

(h) Multiple awards. The Government may accept any item or group of items of an offer, unless the offeror qualifies the offer by specific limitations. Unless otherwise provided in the Schedule, offers may not be submitted for quantities less than those specified. The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit prices offered, unless the offeror specifies otherwise in the offer.

(i) Availability of requirements documents cited in the solicitation. (1)(i) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to--GSA Federal Supply Service Specifications Section, Suite 8100, 470 East L'Enfant Plaza, SW, Washington, DC 20407, Telephone (202) 619-8925, Facsimile (202) 619-8978.

(ii) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (i)(1)(i) of this provision.

Additional copies will be issued for a fee.

(2) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites:

(i) ASSIST (https://assist.dla.mil/online/start/).

(ii) Quick Search (http://quicksearch.dla.mil/).

(iii) ASSISTdocs.com (http://assistdocs.com).

(3) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by--

(i) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm);

(ii) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or

(iii) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone

(215) 697-2667/2179, Facsimile (215) 697-1462.

(4) Nongovernment (voluntary) standards must be obtained from the organization responsible for their preparation, publication, or maintenance.

(j) Unique entity identifier. (Applies to all offers exceeding $3,500, and offers of $3,500 or less if the solicitation requires the Contractor to be registered in the System for Award Management (SAM).) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation ``Unique Entity Identifier'' followed by the unique entity identifier that identifies the Offeror's name and address. The Offeror also shall enter its Electronic Funds Transfer (EFT) indicator, if applicable. The EFT indicator is a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the Offeror to establish additional SAM records for identifying alternative EFT accounts (see subpart 32.11) for the same entity. If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for unique entity identifier establishment directly to obtain one. The Offeror should indicate that it is an offeror for a Government contract when contacting the entity designated at www.sam.gov for establishing the unique entity identifier.

(k) Reserved.

(l) Debriefing. If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(1) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer.

(2) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

(3) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(4) A summary of the rationale for award;

(5) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.

(6) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

(End of provision)

ADDENDUM TO 52.212-1, INSTRUCTIONS TO OFFERORS - COMMERCIAL

PROVISIONS INCORPORATED BY REFERENCE

52.203-11 Certification and Disclosure Regarding Payments to Influence

Certain Federal Transactions

SEP 2007

52.203-18 Prohibition on Contracting with Entities that require Certain Internal Confidentiality Agreements of Statements – Representation.

JAN 2017

52.204-7 System for Award Management JUL 2013 52.204-22 Alternative Line Item Proposal JAN 2017 52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

DEC 2012

52.215-20 Requirements for Certified Cost or Pricing Data OCT 2010

PROVISIONS INCORPORATED BY FULL TEXT

52.204-17 OWNERSHIP OR CONTROL OF OFFEROR (JUL 2016)

(a) Definitions. As used in this provision--

Commercial and Government Entity (CAGE) code means—

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity;

or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

Highest-level owner means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

Immediate owner means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

(b) The Offeror represents that it [ ___ ] has or [ ___ ] does not have an immediate owner. If the Offeror has more than one immediate owner (such as a joint venture), then the Offeror shall respond to paragraph (c) and if applicable, paragraph (d) of this provision for each participant in the joint venture.

(c) If the Offeror indicates ``has'' in paragraph (b) of this provision, enter the following information:

Immediate owner CAGE code:

Immediate owner legal name: ___

(Do not use a ``doing business as'' name)

Is the immediate owner owned or controlled by another entity?:

[ ___ ] Yes or [ ___ ] No.

(d) If the Offeror indicates ``yes'' in paragraph (c) of this provision, indicating that the immediate owner is owned or controlled by another entity, then enter the following information:

Highest-level owner CAGE code:

Highest-level owner legal name:

(Do not use a ``doing business as'' name)

(End of provision)

52.209-5 CERTIFICATION REGARDING RESPONSIBILITY MATTERS (OCT 2015)

(a)(1) The Offeror certifies, to the best of its knowledge and belief, that-

(i) The Offeror and/or any of its Principals-

(A) Are ( ) are not ( ) presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(B) Have ( ) have not ( ), within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) contract or subcontract; violation of Federal or State antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property (if offeror checks “have”, the offeror shall also see 52.209-7, if included in this solicitation); and

(C) Are ( ) are not ( ) presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in paragraph (a)(1)(i)(B) of this provision.;

and

(D) Have , have not , within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied.

(1) Federal taxes are considered delinquent if both of the following criteria apply:

(i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(ii) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(2) Examples. (i) The taxpayer has received a statutory notice of deficiency, under I.R.C. Sec. 6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(ii) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. Sec. 6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(iii) The taxpayer has entered into an installment agreement pursuant to I.R.C. Sec. 6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(iv) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. 362 (the Bankruptcy Code).

(ii) The Offeror has ( ) has not ( ), within a three-year period preceding this offer, had one or more contracts terminated for default by any Federal agency.

(2) Principal, for the purposes of this certification, means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager;

head of a division or business segment; and similar positions).

(b) The Offeror shall provide immediate written notice to the Contracting Officer if, at any time prior to contract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.

(c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this solicitation. However, the certification will be considered in connection with a determination of the Offeror's responsibility. Failure of the Offeror to furnish a certification or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible.

(d) Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render, in good faith, the certification required by paragraph (a) of this provision. The knowledge and information of an Offeror is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.

(e) The certification in paragraph (a) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous certification, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation for default.

(End of provision)

52.204-20 Predecessor of Offeror (JUL 2016)

(a) Definitions. As used in this provision--

Commercial and Government Entity (CAGE) code means--

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity;

or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

Predecessor means an entity that is replaced by a successor and includes any predecessors of the predecessor.

Successor means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

(b) The Offeror represents that it [____] is or [____] is not a successor to a predecessor that held a Federal contract or grant within the last three years.

(c) If the Offeror has indicated “is” in paragraph (b) of this provision, enter the following information for all predecessors that held a Federal contract or grant within the last three years (if more than one predecessor, list in reverse chronological order):

Predecessor CAGE code: ____ (or mark “Unknown”).

Predecessor legal name: ____.

(Do not use a “doing business as” name).

(End of provision)

52.211-14 NOTICE OF PRIORITY RATING FOR NATIONAL DEFENSE, EMERGENCY PREPAREDNESS, AND ENERGY PROGRAM USE (APR 2008)

Any contract awarded as a result of this solicitation will be DX rated order; X DO rated order certified for national defense, emergency preparedness, and energy program use under the Defense Priorities and Allocations System (DPAS) (15 CFR 700), and the Contractor will be required to follow all of the requirements of this regulation.

(End of provision)

52.223-22 PUBLIC DISCLOSURE OF GREENHOUSE GAS EMISSIONS AND REDUCTION GOALS--

REPRESENTATION (DEC 2016)

(a) This representation shall be completed if the Offeror received $7.5 million or more in Federal contract awards in the prior Federal fiscal year. The representation is optional if the Offeror received less than $7.5 million in Federal contract awards in the prior Federal fiscal year.

(b) Representation. [Offeror is to check applicable blocks in paragraphs (b)(1) and (2).]

(1) The Offeror (itself or through its immediate owner or highest-level owner) [ ___ ] does, [ ___ ] does not publicly disclose greenhouse gas emissions, i.e., make available on a publicly accessible Web site the results of a greenhouse…