Amendment 01-RFP SP4701-22-R-0029.pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment your desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICITATION

NO.

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO.

IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

NSN 7540-01-152-8070

Previous edition unusable

SP4709

The subject RFP is amended as follows:

1. Please see the updated PWS based upon the Question and Answers received from industry.

2. Please see the "Amendment 01-SP4701-22-R-0029- Q&A's" for responses to questions received from industry.

3. The solicitation closing date has been extended until November 14, 2022 at 4 PM EST.

SP4701

DLA CONTRACTING SERVICES OFFICE - PHILADELPHIA

700 Robbins Avenue Philadelphia, PA 19111

SEE BLOCK 6.

SP4701-22-R-0029

11/08/2022

Combined Synopsis/Solicitation

This is a combined synopsis/solicitation for commercial products or commercial services prepared in accordance with the format in FAR subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; proposals are being requested and a written solicitation will not be issued.

(1) Date: November 2, 2022

(2) Contracting Office Address:

DLA Contracting Services Office Philadelphia 700 Robbins Avenue, Building # 26/2, North Side Philadelphia, PA 19111

(3) Subject: Defense Logistics Agency (DLA) Troop Support Medical Freight Transportation (MFT) Indefinite Delivery, Indefinite Quantity (IDIQ) Solicitation

(4) Proposed Solicitation Number: SP4701-22-R-0029

(5) Questions Due Date: November 4, 2022 at 12:00PM EST

(6) Closing Response Date: November14, 2022 at 4:00PM EST

(7) Contact Point:

Contracting Officer: Irv Farmer (Irvin.Farmer2@dla.mil; 215-737-2876) Contracting Specialist: Maxwell Day (Maxwell.Day@dla.mil; 215-737-0503)

(8) Submission: Please email proposals on or before closing response date/time to Irvin.Farmer2@dla.mil and Maxwell.Day@dla.mil

(9) Set Aside: NA

(10) NAICS Code: 481112

(11) Description: DLA Contracting Services Office Philadelphia (DCSO-P) intends to award multiple, multiple-award firm-fixed-price IDIQ MFT contracts to Commercial Airlift Review Board (CARB) approved, Federal Aviation Administration (FAA) certified air carriers participating in the Civil Reserve Air Fleet (CRAF) program. MFT IDIQ contract awardees will provide door-to-door delivery services for worldwide, heavyweight shipments of medical freight over 300 pounds, in support of DLA Troop Support-Medical Supply Chain requirements. Each multiple-award IDIQ contract will serve a distinct theater (EUCOM, PACOM, CENTCOM, or NORTHCOM) and/or distinct origin destination lane(s) in one or multiple theaters and may include multiple, individual transportation lanes and accessorials. The services required include the movement of Ambient (general medical cargo) and HAZMAT shipments for customers located Outside the Continental United States (OCONUS).

(12) Performance Work Statement:

mailto:Irvin.Farmer2@dla.mil mailto:Maxwell.Day@dla.mil

Section 1: Schedule of Supplies

Base Period: January 1, 2023 through December 31, 2023

CLIN DESCRIPTION U/I QTY UNIT PRICE TOTAL

Medical Freight Transportation

FFP

Domestic and International Transportation Services FOB: Origin

V111 LOT 1

Total

Option Period 1: January 1, 2024 through December 31, 2024

CLIN DESCRIPTION U/I QTY UNIT PRICE TOTAL

Medical Freight Transportation FFP

Domestic and International Transportation

Option Period 2: January 1, 2025 through December 31, 2025

CLIN DESCRIPTION U/I QTY UNIT PRICE TOTAL

Medical Freight Transportation FFP

Domestic and International Transportation

Total Price (Base, Option Period 1, and Option Period 2)

Section 2: PERFORMANCE WORK STATEMENT

WHO MAY SUBMIT PROPOSALS?

Only Commercial Airlift Review Board-approved, Federal Aviation Administration-certified air carriers participating in the CRAF program, as authorized by Title 10, Chapter 961, the Civil Reserve Air Fleet and/or the Defense Production Act, 50 United States Code (USC) § 4511, and not in a suspended non-use status should submit proposals and will be eligible to receive an IDIQ contract award.

SCOPE

Contractors shall provide air transportation services in support of DLA Troop Support-Medical Supply Chain requirements in accordance with this Performance Work Statement (PWS). The services required include door-to-door delivery services for worldwide, heavyweight shipments of Ambient (general medical cargo) and HAZMAT medical freight to customers located Outside of the Continental United States (OCONUS), including customers in Hawaii and Alaska, as well as several U.S. territories. All shipments will be for medical freight weighing over 300 lbs.

DESCRIPTION OF SERVICE REQUIREMENTS

The DLA Troop Support Medical Supply Chain requires international commercial air transportation services for medical materiel. The services required will include time-definite, door-to-door pick-up and delivery, transportation, In transit Visibility (ITV), Government-Approved Third-Party Payment System participation, expedited customs processing, and clearance of less than full planeloads. The service includes movement of Ambient (general medical cargo) and HAZMAT shipments to OCONUS customers.

On high volume lanes, a second carrier will be selected to allow for options of moving cargo.

Basic Service: The contractor shall provide international commercial air transportation door-to-door services for less than full planeloads of medical material, to and from locations documented in this PWS. Service is required Monday through Friday, except holidays, including those holidays specific to international countries, as applicable. Pick-up shall be within 24-hours of notification except as otherwise stated in subsequent paragraphs. Required delivery times are noted in the table under the Section titled RDD/Transit Time Requirements.

• The contractor shall provide safe transportation, protection, accountability, and timely delivery of U.S.

Government cargo in accordance with applicable Federal Aviation Regulations and the provisions of this contract.

• The contractor shall be responsible for aircraft load planning, weight and balance, aircraft loading/off loading, secure fastening, and any required special handling. Cargo may include hazardous material (HAZMAT) Classes 1 through 9 as defined in the International Air Transportation Association (IATA)

• Dangerous Goods Regulation. At locations where the US Government has operational responsibilities and representatives to load/unload the aircraft, the US Government or its contracted agency will be responsible for loading/unloading the aircraft.

• At pickup, the shipper’s agent may load the carrier’s vehicle and at delivery, the consignee/customer may unload the carrier’s vehicle. At a minimum, the shipper’s agent or consignee must be available for pickup and delivery of the cargo.

• The contractor shall assign account numbers to all Prime Vendor shipping locations, if one does not already exist.

• Prepayment or collect charges from the consignee is not allowed.

DLA Troop Support, Medical Supply Chain (shipper)

• “Shipper” refers to the DLA Troop Support Medical Transportation office.

• “Shipping locations” refers to the various Prime Vendor (PV) distribution centers. The PVs are agents acting on the government’s behalf, preparing the shipments. They represent multiple “shipping locations.”

• “Customers” refers to any number of military depots, medical treatment facilities, clinics, or hospitals around the world. There is a Major Class VIII Medical Depot located in Germany; as well as critical Class VIII depots serving European Command, Africa Command, Central Command, and Indo-Pacific Command. Commonly used destinations are listed later in this document.

• Pharmaceutical Prime Vendors: ABC Pharmacy Primary; DMS Secondary (shipper’s agents) These prime vendors are the only distributer of brand pharmaceutical supplies who pick, pack, and offer these shipments to the government-supplied carrier(s). The examples provided below are incomplete lists. Supplies and cargo will not be limited to what is described below.

o Examples of pharmaceuticals: drugs for heart disease, cholesterol, acid reflux, asthma, mental health, diabetes, anemia, arthritis, cancer, pain, supplements, aspirins, ointments, prescription drugs, antidepressants, antacids, diuretics, vaccines, laxatives, etc.

o Examples of Pharmaceutical HAZMAT Cargo: Medical Lab Reagents.

• Medical/Surgical Prime Vendors: Cardinal Healthcare; Owens & Minor Secondary (shipper’s agents) These prime vendors are the only distributers of brand-specific medical surgical supplies who pick, pack, and offer these shipments to the government-supplied carrier(s). The examples provided below are incomplete lists.

Supplies and cargo will not be limited to what’s described below.

o Examples of Medical/Surgical supplies: tourniquet cuffs, quad-shaping drills, wound-contact dressing, ointments, face shields, cervical supports, diluting solution, ECG electrodes, forceps, kit (sexual assault), disposable face mask, circuit ventilator, kit (resuscitation), laryngoscope, refrigerated blood cooling, laboratory bottles, kit (poliovirus VAC), reagent blood, heat pack (instant), potassium iodide tablets, mouthpiece, dental (pro-root cement), needles, tongue depressors, water-jell tactical burn blanket, valve expiration, clamp fixation, stabilizing ankle support, kit (OB emergency), saliva ejector, CO2 airway adapters (single patient use), sked-EVAC patient litter strap, cable blood pressure critical care, stiff-necked extrication, collar, crutches, gloves (black nitrile), etc.

o Examples of Medical/Surgical HAZMAT Cargo: Wound control, antiseptic, and infection control material.

Cargo Pick-up Requirements.

• The contractor shall be responsible for the door-to-door pick-up and delivery of pharmaceutical and medical/surgical supplies from DLA-designated medical prime vendor locations. Prime Vendors will notify the pickup carrier by 1400 local time, outlining the daily volume, to enable same day pickup. Awarded Carriers shall pickup same day if notified by the cut-off time.

o Pick-up Locations include but are not limited to:

– Bethlehem, PA

– Baltimore, MD

– Ontario, CA

– Sacramento, CA

– Richmond, VA

– Park Ridge, IL

• The contractor shall provide staged trailers at high volume sites bolded above.

• Transit time clock starts at pick-up.

• During a contingency/surge, the contractor may be required to support two to three times the normal

Government traffic flow and at the same level of service prior to the contingency/surge. For volume information, please reference Attachment number 3, Expeditious Routing Matrix, Historical Volumes tab.

• The contractor shall provide DLA Troop Support Medical a dedicated 24-hour point of contact to include name, telephone number, fax number, and e-mail address.

• The contractor shall provide an automated system to print airway bills or provide each Prime Vendor shipping location with pre-printed airway bills for each customer.

• In accordance with the contractor’s commercial procedures, the contractor shall provide to the government, at no additional cost, a shipping system for qualified users under this contract to prepare labels and preprinted airway bills when requested by the shipper. The shipping system shall be capable of printing shipping labels with a TCN bar-coded format and in clear text.

Supply Chain Security/Handling

• The contractor shall follow their commercial security and customs procedures to safeguard cargo against theft, loss, tampering, or damage.

• The contractor shall not place any medical supplies in direct sunlight.

In transit Visibility/Tracking

• The contractor shall provide, via their website, near real-time ITV for all shipments from the date and time of pickup to the date and time of delivery.

• Near real-time ITV means that updates shall be provided within 4 hours of any event, and the contractor shall update ITV shipment status information each day at least the same number of times as required for commercial customers, and upon request by the Government.

• The contractor shall continue to provide ITV information when shipments are transported by their subcontractors or partners. In addition, electronic feedback upon receipt shall be visible to the shipper and customers.

• ITV information shall include as a minimum: Government-furnished Transportation Control Number (TCN) if provided, shipper’s reference number, contractor’s unique identifying Commercial Bill of Lading (CBL) number, dates and times for shipment origin departure, trans-shipment points, destination arrival, proof of delivery with consignee’s name (if applicable), and delay codes (if applicable). When shipments are delivered without obtaining a signature, the ITV system shall record the exact location where the shipment was left.

• The contractor shall provide consignee pre-alert notification at least 24 hours in advance of delivery. If delays in transit occur, a revised pre-alert notice will be sent at least 24 hours in advance of delivery to the consignee (or as soon as delay is known if less than 24 hours). The pre-alert is intended to assure access to dock space and availability of government personnel and material handling equipment. The pre-alert should provide, at a minimum, the following information: TCN, number of pallets, weight of pallets and pieces to be delivered, date and time to be delivered, and identification of any pallet(s) containing perishable items, medical priority shipments, or other cargo requiring special handling.

• The contractor shall notify the consignee of misrouted shipments.

• The contractor shall notify the shipper and consignee within 24 hours if government shipments are detained in customs.

IDE/GTN (Integrated Development Environment/Global Transportation Network) Global Convergence (IGC) (formerly Global Transportation Network (GTN)) Interface.

• The contractor shall provide interface with the DoD’s IGC as required. The contractor shall provide this information without restriction.

• Development and execution of Electronic Data Interchange (EDI) transaction sets within the scope of the contract shall be agreed upon by the IGC Program Office, detailed and documented in the standard Military Surface Deployment and Distribution Command (SDDC) Trading Partner Agreement (TPA) prior to contract performance. All questions regarding TPA must be addressed to usarmy.scott.sddc.mbx.g6-edi-support@army.mil.

• The contractor shall be capable of providing an accurate data feed to IGC prior to starting performance.

Contingency/Redirection/Surges.

• In the event of a contingency/state of war (declared or not), where the shipments are undeliverable to a location/country, the contractor shall contact the shipping office for possible redirection of shipments. The shipping office will coordinate with the appropriate government offices, agencies, and contractor to ensure proper receipt and ultimate delivery of redirected shipment to the consignees. If any such redirection causes an increase or decrease in the cost of performance, the contractor shall notify the Contracting Officer in writing as soon as practicable. During a contingency/surge, the contractor may be required to support two to three times the normal Government traffic flow and at the same level of service prior to the contingency/surge. For volume information, please reference Attachment number 3, Expeditious Routing Matrix, Historical Volumes tab.

Reduction/Cancellation of Service.

• The government reserves the right to reduce and/or cancel service over specific lanes due to withdrawal of forces or other mission necessity.

RDD/Transit Time Requirements

• Transit time requirements are established by origin/destination pairing and type of cargo.

• Transit time requirements are established to meet the expectations of our medical customers as indicated in the tables below.

Dest.

Theater From Commonly Used

Origins Commonly Used

Destinations Dest.

Country CLIN TYPE Transit (Days) ACCESSORIAL USAGE

P A C O M

HAZ 7 HMA, HAZ, HMI, 520, 665, 670, 675, LDS, Z13, Z14

Ambient 5 520, 665, 670, 675, LDS, Z13, Z14

OKAH

7 HMA, HAZ, HMI, 520, 665, 670, 675, LDS, Z13, Z14

CONUS

(Not including

AK & HI)

Ontario, CA; City of Industry, CA;

Sacramento, CA;

Park Ridge, IL

Camp Foster, Kadena AB, Camp

Kinser Okinawa

OKAA

HAZ

Ambient 5 520, 665, 670, 675, LDS, Z13, Z14

HAZ 5 HMA, HAZ, HMI, 520, 665, 670, 675, LDS, Z13, Z14

CONUS

(Not including

AK & HI)

Ontario, CA; City of Industry, CA;

Sacramento, CA;

Park Ridge, IL

Camp Carroll, Kunsan AB, Osan

AB

Korea

KORA

Ambient 4 520, 665, 670, 675, LDS, Z13, Z14

JAPH

HMA, HAZ, HMI, 520, 665, 670, 675, LDS, Z13, Z14

CONUS

(Not including

AK & HI)

Ontario, CA; City of Industry, CA;

Sacramento, CA;

Park Ridge, IL

Yokosuka, Yokota AB, Misawa AB Japan

JAPA

5 520, 665, 670, 675, LDS, Z13, Z14

GUMH HAZ 9

AmbientCONUS (Not including

AK & HI)

Ontario, CA; City of Industry, CA;

Sacramento, CA;

Park Ridge, IL

Santa Rita, Yigo, Agana Guam

GUMA

KORH

520, 665, 670, 675, LDS, Z13, Z14

TURH HAZ 9 HMA, HAZ, HMI, 520, 665, 670, 675, LDS, Z13, Z14

Ambient 8

HAZ 6 HMA, HAZ, HMI, 520, 665, 670, 675, LDS, Z13, Z14

CONUS

(Not including

AK & HI)

Bethlehem, PA;

Park Ridge, IL;

Baltimore, MD;

Hanover, MD

Incirlik AB Turkey

TURA

Ambient 4 520, 665, 670, 675, LDS, Z13, Z14

GBRH

7 HMA, HAZ, HMI, 520, 665, 670, 675, LDS, Z13, Z14

CONUS

(Not including

AK & HI)

Bethlehem, PA;

Park Ridge, IL;

Baltimore, MD;

Hanover, MD

Lakenheath Great Britain

GBRA

HAZ

Ambient 5 520, 665, 670, 675, LDS, Z13, Z14

HAZ 6 HMA, HAZ, HMI, 520, 665, 670, 675, LDS, Z13, Z14

CONUS

(Not including

AK & HI)

Bethlehem, PA;

Park Ridge, IL;

Baltimore, MD

Rota Spain

ESPA

Ambient 5 520, 665, 670, 675, LDS, Z13, Z14

ITAH

HMA, HAZ, HMI, 520, 665, 670, 675, LDS, Z13, Z14

CONUS

(Not including

AK & HI)

Bethlehem, PA;

Park Ridge, IL;

Baltimore, MD

Aviano Sigonella Naples

Italy

ITAA

3 520, 665, 670, 675, LDS, Z13, Z14

DEUH HAZ 6

Ambient

E U C O M

CONUS

(Not including

AK & HI)

Bethlehem, PA;

Park Ridge, IL;

Baltimore, MD

Kaiserslautern, Dulmen, Ramstein, Landstul, Spangdahlem

Germany

DEUA

ESPH

Cargo Delivery Requirements

• The contractor shall notify the customer within 24 hours in the event a shipping delay occurs in excess of the required transit times specified above and provide daily updates until delivery is completed.

• Shipments for medical supplies that are contained on one Bill of Lading (House Airway bill) but split over several

Master Airway bills (e.g., 1 of 10), must be delivered as one unit at the same time, once all House Airway bill pieces of the shipment are in the destination country.

Delivery Attempt or Refusal.

• Attempted Delivery. The contractor shall attempt to deliver a shipment three times before contacting the shipper for disposition instructions. Each delivery attempt shall be made on the next consignee business day following the contractor’s initial delivery attempt.

• The contractor shall leave a conspicuous notice of attempted delivery at the point of delivery for each delivery attempt. For purposes of contract performance, delivery shall be considered accomplished on the date of the first delivery attempt. The cost of any further disposition, or additional deliveries requested by the shipper, is the responsibility of the shipper (DLA).

• Refusal by Consignee. If a consignee refuses to accept a delivery, the contractor shall annotate refusal on the order with date, time, and name of person who refused and contact the shipper for disposition instructions. For purposes of contract performance, delivery shall be considered accomplished on the date of the first delivery attempt.

Changes in address for delivery is the responsibility of the shipper and billed accordingly.

• When authorized by the shipper on the Commercial Bill of Lading (CBL), Electronic Commercial Forms and Procedures (CF&P), Government Bill of Lading (GBL), or other government documents as approved by the Contracting Officer, the shipment shall be considered delivered when the shipment is left without signature at the front door/loading dock (i.e., point of delivery approved by shipper) of the consignee’s address.

HAZMAT Shipments (Cargo Aircraft ONLY)

• Examples of “Cargo Aircraft Only” HAZMAT include, but are not limited to, the following United Nation (UN) numbers: UN2924, UN1230, and UN1037.

Customs. The contractor shall provide duty-free customs clearance for all shipments. In the event that a shipment is not duty free, the contractor shall process in the same manner provided for its commercial customers and shall submit a linked eBill in addition to their Government-Approved Third-Party Payment System invoice.

• Customs clearance procedures and updates can be reviewed in the Defense Transportation Regulation (DTR) Part

V, Department of Defense Customs/Border Clearance Policies and Procedures, which is available on the public web page at https://www.ustranscom.mil/dtr/dtrp5.cfm.

• Any additional customs fees or reductions arising during the contract performance period will be substantiated with the Department of State (Embassy) and/or the foreign government involved. Upon receipt of documentation the Contracting Officer will review and make a determination on a case-by-case basis whether a rate adjustment is warranted.

• The contractor shall serve as an agent and appoint sub-agents, as may be necessary, to act directly or through such re-delegation, appointment, or designation to other customs brokers, persons, or business concerns as it deems necessary for performance of customs clearance and shall provide all customs forms necessary for customs clearance.

• The contractor shall notify the shipper and consignee within 24 hours if government shipments are detained in customs.

• The contractor shall be responsible for all destination airport facility storage charges in the event of any customs clearing delays that are attributable to the contractor. In some countries, pre-clearance protocols are required to avoid excessive storage charges; other countries require storage charges while awaiting customs clearance.

• The contractor shall participate in the development and testing of DoD automated customs clearance systems by providing user feedback to the Government and by inputting manifest and other shipping data to the system(s) as necessary. Upon implementation of these systems in various destination countries, the contractor shall begin using electronic customs procedures to clear cargo as indicated in DTR Part V or interim instructions issued by

USTRANSCOM.

Cargo Acceptability and Special Cargo.

The contractor shall transport general medical merchandise, goods, wares, and products of all kinds, unless otherwise excluded by contractor's regulations provided:

• The shipper or shipper’s agent timely provides all documentation and information required for the shipment.

• Shipments are packed in a manner suitable for carriage by aircraft.

• Shipments are accompanied by the requisite shipping documents, and they are not likely to endanger aircraft, persons or property, or cause annoyance to passengers or crew.

Goods Acceptable Only Under Prescribed Conditions. The following goods are acceptable for carriage:

• Hazardous Cargo Shipments. All hazardous materials will be in air authorized packaging and meet the type and/or quantity restrictions for cargo only aircraft and packaged, prepared, marked/labeled, and certified in accordance with the International Air Transport Association (IATA), Dangerous Goods Regulations. The contractor shall ensure that Hazardous items are properly packed prior to air movement.

If packages are not properly marked the carrier shall return the shipment to the shipper for corrections.

• Oversized Cargo. Air cargo exceeding the usable dimensions of a commercial unit load device (e.g., 125” L x 88” W x 96” H pallet). The dimensions may vary based on the type of cargo and usually requires the use of multiple pallet positions.

• Unusual Shipments. With Contracting Officer approval, contractor may refuse cargo of extreme length, unusual shape or excessive weight for transportation unless handling arrangements have been previously made.

Damage or Loss.

• The contractor shall be liable for loss, damaged, or misrouted shipments. The contractor’s liability shall be limited to the lower dollar amount of $50,000 or $9.07 per pound or the actual amount of the cargo.

• The contractor shall provide notification to the shipper of any incident (e.g., hard landing or crash) within

24 hours and shall provide a copy of the manifest to shippers within 48 hours if available.

• Claims shall be filed by the shipper within 30 days of receipt of the manifest (or ship date if no manifest is provided) unless the contractor’s commercial practice allows for a longer period for shippers to file claims, in which case the contractor’s commercial claim filing deadline will apply

Billing.

• International Shipments: The contractor shall charge the greater amount of the total actual weight of all pieces combined, or the total dimensional weight of all pieces combined, per shipment. Dimensional weight shall be calculated Length x Width x Height divided by 139, rounded to the next whole number.

• Domestic Shipments (CONUS to Alaska, Hawaii, and Puerto Rico): The contractor shall charge the greater amount of the total actual weight of all pieces combined, or the total dimensional weight of all pieces combined, per shipment. Dimensional weight shall be calculated Length x Width x Height divided by 166, rounded to the next whole number.

• If the shipper does not indicate the shipping weight, the contractor shall weigh the item and annotate the weight. If the shipment weight listed on the order is different from the actual weight (e.g., as a result of reweigh or dimensional weight, or no weight was initially identified), the contractor shall indicate on the billing documents submitted to the paying activity those shipments that have been adjusted.

• All weights and measures in the contract shall be in pounds and inches.

• Any proposed contractor accessorial charges not identified on the Schedule of Services/Supplies shall be submitted and approved by the shipper’s office prior to accepting cargo for shipment. In the event of a dispute between the shipper’s office and the contractor regarding an accessorial charge, the Contracting Officer will review the situation and render a Contracting Officer's decision. Further, unless otherwise stated, it is presumed all accessorial service not specifically identified and priced separately on the Schedule of Services/Supplies are included in the basic service contract price.

Invoicing/Billing/Payment - Government-Approved Third-Party Payment System (TPPS).

• The Deputy Secretary of Defense directed the implementation of TPPS system to pay for transportation services. DoD contracts and voluntary tenders require the use of TPPS, and all DoD cargo movements must be offered only to commercial carriers who utilize TPPS as their billing and payment system.

• The Government-Approved TPPS is an automated on-line payment processing and transaction tracking system that supports logistical transactions. The Government-Approved TPPS receives a transaction processing fee for every paid transaction. It consists of five primary functions: (1) electronic data transmission, (2) payment approval process, (3) electronic payment and billing, (4) communication for dispute resolution, and (5) customized data analysis.

• The contractor shall have a signed Government-Approved TPPS Trading Partner Agreement in place before moving freight. Providing a signed copy of the Trading Partner Agreement or formal notification in writing/email to the Contracting Officer shall constitute verification.

• The contractor shall coordinate with U.S. Bank, shipper, and service representative to facilitate to the maximum extent possible Government Approved TPPS implementation. The contractor shall work with each service representative and military installation to develop TPPS Trading Partner Agreements. This process shall commence once contacted by the installation and/or the service representative to begin testing for accurate Government Approved TPPS billing EDI interfaces.

• Transportation Service Providers (TSPs) are required to submit the shipments’ contract number via EDI.

In the event TSPs need assistance configuring their EDI file to include the contract number, the TSP can call the U.S. Bank customer service help desk or e-mail the customer service e-mail box and a representative will open a Service Request to assign a U.S. Bank EDI analyst for assistance. TSPs who do not transmit EDI, shall provide the contract number when entering invoices in the U.S. Bank Freight Payment web-based user interface.

• Invoices must be sent NLT 5 business days after confirmation of shipment delivery.

Administrative

• The contractor shall provide weekly reporting in the format prescribed in Attachment 4, Weekly

Shipment detail report, to enable DLA Troop Support to proactively follow up on shipments which are potentially delayed.

• The contractor shall develop a relationship with the Medical PVs and customers and will be expected to attend meetings with both parties. The purpose of the meetings will be to discuss delivery timeframes, contract performance, and address contractor/customer concerns.

Carrier Selection Criteria

• DLA Troop Support Medical requires unencumbered carrier evaluations to include the consideration of carrier routings with the goal of maximum efficiency and reliability and minimal delays.

• DLA Troop Support evaluation criteria should include but not be limited to the following:

o Routing – carriers should submit their planned routings. Minimized routing reduces trucking and number of touches o Past Performance o Price

Period of Performance

The Period of Performance (POP) shall be for a period of twelve (12) months with an anticipated start date of 1 January 2023 through 31 December 2023. There will be two 12-month option periods.

Quality Assurance Surveillance Plan (QASP)

The contractor shall submit Attachment 4 - Weekly Shipment Detail Report in a timely and accurate manner to the Contracting Officer Representative (COR) on a weekly basis. This report will be used to surveil the On-Time Percent (OTP) and Quality (lack of loss or damage) of the carriers’ shipment performance.

Overall Performance Ratings

Satisfactory – Performance meets or exceeds contractual requirements. The contractual performance reflects some minor problem(s) for which corrective actions taken by the contractor appear or were satisfactory. The COR recommends and the Contracting Officer will make a determination to pay the contractor 100% of the invoice amount.

Unsatisfactory – Performance does not meet most contractual requirements and recovery is not likely in a timely manner. The contractual performance contains a serious problem(s) for which the contractor’s corrective actions appear or were ineffective.

Payment will be withheld pending resolution of cure notice(s). Termination for default or cause may result.

On-Time Percent (OTP)

Using the Weekly Shipment Detail Report, Contractor Performance in regard to timeliness will be considered on two bases: a lane specific OTP and an average overall OTP.

In order to keep a lane-specific or overall Satisfactory rating, carriers must maintain an OTP of 95% or greater. Any 4-week trajectory below 95% OTP may put the carrier in jeopardy, as described below.

LANE SPECIFIC OTP

• Carriers shall maintain a minimum 95% OTP rating on each awarded lane, with a target of delivering 100% of the shipments on time.

• If a carrier's single lane average OTP (an average over the 4 most recent weekly reports) falls below 75%, the carrier may be declared unsatisfactory on that lane, along with all cures noted in the unsatisfactory category.

AVERAGE OVERALL OTP

• Carriers shall maintain a minimum 95% average overall OTP across all awarded lanes, with a target of delivering 100% of the shipments on time.

• If a carrier's average OTP across all of their awarded lanes (an average over the 4 most recent weekly reports) falls below 80%, the carrier may be declared unsatisfactory for inclusion on the contract, along with all cures noted in the unsatisfactory category.

Timeliness

Satisfactory Meets or exceeds contractual requirements in terms of timeliness of delivery. The timeliness of contractual performance reflects some minor problem(s) for which corrective actions taken by the contractor appear or were satisfactory.

Unsatisfactory Does not meet most contractual requirements in terms of timeliness of delivery and recovery is not likely in a timely manner. The timeliness of contractual performance contains a serious problem(s) for which the contractor’s corrective actions appear or were ineffective.

Quality (lack of loss or damage)

Quality

Satisfactory Meets or exceeds contractual requirements in terms of quality of work performed. The quality of contractual performance reflects some minor problem(s) for which corrective actions taken by the contractor appear or were satisfactory.

Unsatisfactory Does not meet most contractual requirements in terms of quality and recovery is not likely in a timely manner. The quality of contractual performance contains a serious problem(s) for which the contractor’s corrective actions appear or were ineffective.

Disincentives are applied for ratings of “Unsatisfactory” as follows:

Satisfactory = 100% payment

Unsatisfactory = Payment will be withheld pending resolution of cure notice(s). Termination for default or cause may result.

Section 3: Instructions to Contractors and Evaluation of Offers

3.1 OFFER SUBMISSION INSTRUCTIONS

Contractors shall submit their proposal documents electronically by email to the following email addresses:

Irvin.Farmer2@dla.mil ; Maxwell.Day@dla.mil

Email responses shall have the subject line "RFQ: SP4701-22-R-0029 [Company Name]"

Proposals shall be submitted on or before November 14, 2022 at4:00PM Eastern Time. All email submissions shall be less than 10 MB. If needed, you may submit multiple emails if the total file size exceeds 10 MB. Offerors are encouraged to confirm Government receipt of their proposal documents.

Late proposals will be handled in accordance with the requirement of FAR 15.208

3.2 SUBMISSION OF QUESTIONS

Should contractors have any questions with respect to this RFP, they should submit them, via email, to the contracting officer AND contract specialist Irvin Farmer III at Irvin.Farmer2@dla.mil AND Maxwell Day at Maxwell.Day@dla.mil. Any technical questions, requests for clarification or requests for data in connection with this RFP must be submitted in writing on or before November 4, 2022_at 12:00PM Eastern Time to allow DLA adequate time to provide answers to the questions submitted and to prevent any delays in the closing date of the RFP.

Contractors are strongly urged to follow-up the submission of any questions with a phone call to the Contracting Officer to ensure that questions have been received.

3.3 CONTRACT TYPE

The Government anticipates awarding multiple, multiple-award firm-fixed-price IDIQ MFT contracts to CARB-approved, FAA-certified air carriers participating in the CRAF program.

3.4 AWARD WITHOUT DISCUSSION

The Government intends to make an award based on initial offers; however, the Government reserves the right to conduct discussions, if necessary. The contractor is encouraged to submit their “best proposal” in response to this solicitation.

3.5 NO AWARD

The Government reserves the right not to issue an award as a result of this RFP if such award is determined contrary to the best interest of the Government.

mailto:Irvin%20Farmer%20III%20at%20Irvin.Farmer2@dla.mil

3.6 PROPOSAL PREPARATION COSTS

The Government shall not be responsible or liable for any costs incurred by any parties in the preparation and submission of any proposals submitted in response to this RFP.

3.7 SECTION 508 COMPLIANCE REQUIREMENTS

In accordance with L29 Section 508 Requirements JUL 2019, offerors shall comply with the Section 508 accessibility requirements. By submission of a proposal, the offeror affirms that its Electronic Information Technology (EIT) supplies and services are accessible as outlined in the law, the standard, and FAR Subpart 39.2.

Offerors shall complete Attachment Z - Voluntary Product Accessible Template (VPAT) Version 2.3 document in the solicitation. If applicable, offerors shall indicate where their Section 508 EIT compliance information is available for review (e.g., offeror’s website or other location the contracting officer can access). The contracting officer may require a demonstration of Section 508 compliance prior to award.

3.8 ON RAMP

Consistent with FAR 16.504(c)(1)(ii)(A), the Contracting Officer has determined that it is in the Government’s best interest that at all times during the terms of the basic contracts, there remain an adequate number of MFT IDIQ contract holders capable of satisfying all DLA Troop Support-Medical air transportation requirements.

All U.S. flag air carriers have the opportunity to join the CRAF program at any time. Recognizing this, DLA reserves the right to periodically review the total number of MFT IDIQ contract holders participating in the MFT Ordering Process and determine whether it would be in the Government’s best interest to initiate an open season to solicit proposals from new or additional CRAF carriers for the purpose of awarding IDIQ contracts to successful offerors and including additional CRAF carriers in the existing MFT multiple-award IDIQ contracts.

Open Season Procedures

If DLA determines that it would be in the Government’s best interest to open a new solicitation to solicit proposals from new or additional CRAF carriers, the Contracting Officer may do so at any time provided that:

(a) The solicitation is issued under then-applicable federal procurement law;

(b) The solicitation identifies the total approximate number of new awards that the Contracting Officer intends to make. The Contracting Officer may decide to award more or fewer MFT IDIQ Contracts than the number anticipated in the solicitation depending upon the overall quality of the offers received;

(c) Any Contractor that meets the eligibility requirements set forth in the new solicitation submits a proposal in response to the solicitation;

(d) The award decision under any solicitation is based upon substantially the same evaluation factors/sub-factors as the original solicitation;

(e) The terms and conditions of any resulting awards from a new solicitation are materially identical to the existing version of the Basic Contract;

(f) The term for any such new awards from a solicitation is co-terminus with the existing term for all other MFT IDIQ contract holders, including option periods (if applicable);

(g) The award of any new MFT IDIQ Contract(s) does not increase the overall ceiling of the existing MFT IDIQ Contracts.

3.9 EVALUATION OF OFFERS

BASIS FOR AWARD

This requirement will be solicited on SAM.gov as unrestricted and is open to all eligible contractors. To be eligible for award, offerors must be CARB-approved, FAA-certified air carriers participating in the CRAF program who are not in a suspended non-use status.

DCSO-P intends to award multiple, multiple-award firm-fixed-price IDIQ MFT contracts. Each multiple-award IDIQ contract will serve a distinct theater (EUCOM, PACOM, CENTCOM, or NORTHCOM) and/or distinct origin destination lane(s) in one or multiple theaters and may include multiple, individual transportation lanes and accessorials. This will provide Government shippers competition, flexibility of choice, and service coverage. Awards will be made utilizing a best value trade-off approach with evaluation of price and non-price factors. The Non-Price Factors that will be evaluated are Business Proposal, Technical Proposal, and Past Performance. Technical Proposal is the most important factor and considered significantly more important than Past Performance. All Technical Proposal subfactors are of equal importance. Past Performance is considered more important than Business Proposal and Price Proposal. All Business Proposal subfactors are of equal importance. Price is the least important factor.

Business Proposals will be evaluated on an Acceptable/Unacceptable basis. Price Proposals will be evaluated for fair and reasonableness but will not be rated. Contracts will be awarded to responsible offerors whose proposals do not take exception to the solicitation requirements, whose proposed prices have been determined fair and reasonable, and whose proposals represent the best value to the Government.

The Government will utilize FAR Part 15 and the provisions contained within this RFP to evaluate offers and determine the best value at the IDIQ level. With submission of its proposal, the offeror accedes to the terms and conditions included in this solicitation and agrees to comply in all material respects with the requirements of law and regulation to perform all requirements included in the PWS. Failure to meet a solicitation requirement may result in a proposal being determined unacceptable and therefore will result in the offeror being eliminated from further consideration.

Instructions to Contractors:

Volume I: Business Proposal

• Subfactor 1: Completion of Attachment number 1, Authorized Negotiator Letter: Letter signed by the offeror (a CRAF representative) identifying the individuals authorized to negotiate with the Government and obligate their company contractually. The letter shall also include the name, phone, and email of the Program Manager for this program that is an employee of the prime contractor. This person will serve as the primary point of contact for the government for all matters related to the IDIQ contract.

• Subfactor 2: Completion of Attachment number 2, Point of Contact (POC) Listing: The offeror will provide a POC listing of all individuals who will work under this IDIQ contract administratively and their responsibilities. The listing shall include the name, phone, email, and position of each individual.

• Subfactor 3: Statement acknowledging the requirements to maintain CRAF status for the duration of the contract.

• Subfactor 4: Provide offeror’s street address, CAGE code, Unique Entity Identifier (UEI), and Standard Carrier Alpha Code (SCAC). The SCAC shall represent the CRAF carrier. If offeror is proposing on the HAZ, HMA, and HMI accessorials, the offeror shall provide its current and valid Department of Transportation Hazardous Material Certificate.

• Subfactor 5: Small Business Subcontracting Plan

Volume II: Technical Proposal

• Subfactor 1: Completion of Attachment 3, Expeditious Routing Matrix. The offeror shall provide a detailed plan to accomplish the shipment of general medical cargo, hazardous medical cargo, and commercial aircraft only cargo, within the transit time allotted for each origin destination lane, in the format provided.

• Subfactor 2: Shipment Execution. The offeror shall provide its technical approach for using the government-provided Government Bill of Lading/Commercial Bill of Lading (GBL/CBL) in conjunction with the carrier’s Air Waybill number to execute an order. The approach shall describe how the offeror will successfully execute a shipment using a government provided GBL/CBL and the carrier provided Air Waybill number.

• Subfactor 3: Bill of Lading Invoicing. The offeror shall provide its technical approach for using the government provided GBL/CBL in conjunction with the carrier’s Air Waybill number to send clear and concise invoice transactions to Syncada in accordance with PWS section “Invoicing/Billing/Payment.” The approach shall demonstrate the offeror’s ability to send invoice transactions in accordance with PWS section “Carrier Invoicing Data Requirements.

• Subfactor 4: Weekly Shipment Reports. The offeror shall provide its technical approach for the required weekly shipment detail reports. The approach shall demonstrate the offeror’s ability to provide complete, detailed reports in accordance with Attachment 4, Weekly Shipment detail report.

• Subfactor 5: Tracking. The offeror shall provide a web address for their tracking system, as well as describe its technical approach for providing shipment tracking information, within 4 hours of any event, 24-hours a day, seven days a week, even for its subcontracted partners. The approach shall demonstrate the tracking IT infrastructure exists and the offeror’s ability to accurately track shipments in accordance with PWS section “In Transit Visibility/Tracking”.

• Subfactor 6: Delivery Pre-alert to consignee. The offeror shall describe its technical approach for providing the required pre-alerts at least 24 hours in advance of delivery, in accordance with PWS section “In Transit Visibility/Tracking”.

Volume III: Past Performance

The Government will consider the contractor’s past performance/experience under U.S. Government contracts or other contracts/projects within 3 years of the issuance date of this RFQ. Any contracts/projects submitted in reference to past performance that are outside of the 3-year recency period will not be considered for evaluation.

Contractors/Awardees shall submit at least one past performance example, but not more than two examples.

Note: In the case of a contractor without a record of relevant past performance or for whom information on past performance is not available, the contractor will not be evaluated favorably or unfavorably on past performance and will receive a Neutral rating.

For each past performance project, the contractor shall fill out Attachment 7– “Past Performance Template” and return the document with its offer. In addition, the contractor shall provide a corresponding CPARS for the past performance example(s) provided.

Volume IV: Price Proposal

• Subfactor 1: Lane Rates (Firm-Fixed-Price Rates). Completion of Attachment 5, Pricing Structure Template. Offerors shall insert a proposed all-inclusive price-per-pound rate, for every weight break, and for each country-to-country pairing (lane) listed in the template, in which they wish to be considered for award. Cell inputs shall only be numeric and rounded to the nearest two decimal positions. If an offeror chooses to bid on an ambient lane, they must bid on all ambient lanes (and weight breaks) for that destination theater. If an offeror chooses to bid on a hazardous lane, they must bid on all hazardous lanes (and weight breaks) for that destination theater. These rates will be for the Base Period of Performance – 1 Jan 23 - 31 Dec '23.

• Subfactor 2: Accessorials. Completion of Attachment 5, Pricing Structure Template. Offerors shall indicate in the pricing structure template, on the accessorial charges tab, whether or not each international accessorial listed is offered. If the offeror provides the international accessorial, the offeror shall insert a proposed FFP rate based on the business rule in column D of the accessorial charges tab, or indicate if there is no charge for the service. Cell inputs shall only be numeric and rounded to the nearest two decimal positions. These rates will be for FY2023.

• Subfactor 3: Annual Escalation Rates. Completion of Attachment 6, Escalation Rate Template.

The offeror shall propose its escalation rates in attachment number 6. These rates will be for FY2024 through FY2025.

Evaluation for Award:

Factor I – Business Proposal

The offeror’s Business Proposal will be…