Solicitation FA665620B0001.pdf

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

9. FOR INFORMATION

CALL:

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See ).

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and copies to perform the work required are due at the place specified in Item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

b. An offer guarantee is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

12b. CALENDAR DAYS

YES NO

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

AMOUNTS

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

FA665620B0001

Section A - Solicitation/Contract Form

Section B - Supplies or Services and Prices/Cost

Additional Information/Notes

Sustain Airfield Marking and Rubber Removal Project ZQEL 20-0001.

The work specified herein consists of furnishing all labor, equipment, tools, appliances, transportation, and materials required to remove 95% of the rubber buildup from 100% of designated area on the Youngstown ARS Assault (asphalt covered) Runway. The rubber removal is to be completed without damage to the pavement surface, joints, and joint and crack seals, or any other government property. Destruction of any runway or other pavement markings as a result of the rubber removal process will be restored, repainted as necessary. All LZ Markings, Controlled Apron and Non-Controlled Apron Markings shall be repainted as per specifications and as shown on plans dated 17 Mar 2020. See Solicitation Section J for drawings and specifications.

Manufacturer's Part Number: Null Product Service Code: 3825 Firm Fixed Price

Item Supplies/Service Quantity Unit Unit Price Amount

FY20 F6240 3A4421 910CER FM9 ZQEL

20-0001 Sustain Airfield Markings & Rubber Removal Manufacturer's Part Number: Null Product Service Code: 9999

CIN: 00000000000005161896

1.0 Each

Section C - Description/Specifications/Statement of Work

Requirements: The work specified herein consists of furnishing all labor, equipment, tools, appliances, transportation, and materials required to remove 95% of the rubber buildup from 100% of designated area on the Youngstown ARS Assault (asphalt covered) Runway. The rubber removal is to be completed without damage to the pavement surface, joints, and joint and crack seals, or any other government property. Destruction of any runway or other pavement markings as a result of the rubber removal process will be restored, repainted as necessary. All LZ Markings, Controlled Apron and Non-Controlled Apron Markings shall be repainted as per specifications and as shown on plans dated 17 Mar 2020. See Solicitation Section J for drawings and specifications.

Requirements Project ZQEL 20-0001 Sustain Airfield Marking and Rubber Removal.

Requirements FY20 F6240 3A4421 910CER FM9 ZQEL 20-0001 Sustain Airfield Markings and Rubber Removal USAF Reserves ZQEL 20-0001 - Sustain Airfield Marking and Rubber Removal Project Special Award Provision:

This solicitation will be awarded as a result of a total 100% HUBZone small business set-aside. NAICS code:

237310 MUST BE registered in System for Award Management at time of bid opening to be considered technically acceptable and responsive. See Solicitation Section J for details in regard to Drawings and Specifications. Location: 910th Airlift Wing AFRC, Youngstown Air Reserve Station, 3976 King Graves Road, Vienna OH 44473 (Trumbull County). Special Note: Hand carried offers SHALL BE delivered to the Contracting Officer in Bldg 504, not later than the time specified for receipt of proposal. Facsimile (FAX) offers or modifications of offers WILL NOT be considered, nor will FAX acknowledgment of amendments be authorized. Notice to Offerors: Funds are not presently available for this project. No award will be made until funds are available. The government reserves the right to cancel this solicitation, either before or after bid opening/RFP closing, with no obligation to the offeror by the government. Magnitude of Construction: The estimated cost of this project is between $100,000 and $250,000.

Section D - Packaging and Marking

Section E - Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.246-12 Inspection of Construction. 1996-08

Section F - Deliveries or Performance

Delivery Schedule Ship To Address

Delivery Requested By

21 FEB 2020

1.0 Each

Ship To DoDAAC: F5Q345 Cage:

DunsNumber:

Duns4Number:

CountryCode:

USAF:910 AW MSS

910 AW MSS AF BPN NO MILSBILLS

PROCESSES 3976 KING GRAVES RD UNIT 45

BLG 128 YOUNGSTOWN OH 44473

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.242-17 Government Delay of Work. 1984-04 52.247-34 F.o.b. Destination. 1991-11

Section G - Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.201-7000 Contracting Officer's Representative 1991-12 252.204-7006 Billing Instructions. 2005-10 252.231-7000 Supplemental Cost Principles 1991-12 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. 2018-12 252.236-7000 Modification Proposals--Price Breakdown 1991-12

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. 2018-12

As prescribed in 232.7004(b), use the following clause:

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) As used in this clause- Definitions.

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as Electronic invoicing.

authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) To access WAWF, the Contractor shall- WAWF access.

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice WAWF training.

Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) Document submissions may be via web entry, Electronic Data Interchange, or File Transfer WAWF methods of document submission.

Protocol.

(f) The Contractor shall use the following information when submitting payment requests and receiving reports WAWF payment instructions.

in WAWF for this contract or task or delivery order:

(1) The Contractor shall submit payment requests using the following document type(s): Document type.

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

combo

(Contracting Officer: Insert either "Invoice 2in1" or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

(f) [Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in Document routing.

WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC F87700

Issue By DoDAAC FA6656

Admin DoDAAC FA6656

Inspect By DoDAAC F5Q337

Ship To Code F5Q337

Ship From Code n/a

Mark For Code n/a

Service Approver (DoDAAC) F5Q337

Service Acceptor (DoDAAC) F5Q337

Accept at Other DoDAAC n/a

LPO DoDAAC n/a

DCAA Auditor DoDAAC n/a

Other DoDAAC(s) n/a

(*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert "See Schedule" or "Not applicable.")

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in Payment request.

accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F. Receiving report.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

Ashley Senich, ashleysenich@us.af.mil

(Contracting Officer: Insert applicable information or "Not applicable.")

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

Section H - Special Contract Requirements

Section I - Contract Clauses

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.203-12 Limitation on Payments to Influence Certain Federal Transactions. 2010-10

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights.

2014-04

52.203-18 Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation.

2017-01

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements. 2017-01 52.204-9 Personal Identity Verification of Contractor Personnel. 2011-01 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. 2018-10 52.204-13 System for Award Management Maintenance. 2018-10 52.204-18 Commercial and Government Entity Code Maintenance. 2016-07

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities.

2018-07

52.209-6 Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment.

2015-10

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. 2015-11 52.211-13 Time Extensions. 2000-09 52.214-29 Order of Precedence-Sealed Bidding. 1986-01 52.219-3 Notice of HUBZone Set-Aside or Sole Source Award. 2020-03 52.219-6 Notice of Total Small Business Set-Aside. 2020-03 52.219-13 Notice of Set-Aside of Orders. 2020-03 52.219-27 Notice of Service-Disabled Veteran-Owned Small Business Set-Aside. 2020-03 52.222-1 Notice to the Government of Labor Disputes. 1997-02 52.222-3 Convict Labor. 2003-06 52.222-4 Contract Work Hours and Safety Standards -Overtime Compensation. 2018-03 52.222-6 Construction Wage Rate Requirements. 2018-08 52.222-7 Withholding of Funds. 2014-05 52.222-8 Payrolls and Basic Records. 2018-08 52.222-9 Apprentices and Trainees. 2005-07 52.222-10 Compliance with Copeland Act Requirements. 1988-02 52.222-11 Subcontracts (Labor Standards). 2014-05 52.222-12 Contract Termination-Debarment. 2014-05 52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations. 2014-05 52.222-14 Disputes Concerning Labor Standards. 1988-02 52.222-15 Certification of Eligibility. 2014-05 52.222-21 Prohibition of Segregated Facilities. 2015-04 52.222-27 Affirmative Action Compliance Requirements for Construction. 2015-04 52.222-34 Project Labor Agreement. 2010-05 52.222-37 Employment Reports on Veterans. 2016-02 52.222-50 Combating Trafficking in Persons. 2019-01 52.222-55 Minimum Wages Under Executive Order 13658. 2015-12 52.222-62 Paid Sick Leave Under Executive Order 13706. 2017-01

52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

2013-09

52.223-5 Pollution Prevention and Right-to-Know Information. 2011-05 52.223-6 Drug-Free Workplace. 2001-05

52.223-11 Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons.

2016-06

52.223-12 Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners.

2016-06

52.223-17 Affirmative Procurement of EPA-designated Items in Service and Construction Contracts.

2018-08

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. 2011-08 52.223-21 Foams. 2016-06 52.225-13 Restrictions on Certain Foreign Purchases. 2008-06 52.227-1 Authorization and Consent. 2007-12 52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement. 2007-12 52.228-2 Additional Bond Security. 1997-10 52.228-5 Insurance-Work on a Government Installation. 1997-01 52.228-11 Pledges of Assets. 2018-08 52.228-12 Prospective Subcontractor Requests for Bonds. 2014-05 52.228-14 Irrevocable Letter of Credit. 2014-11 52.228-15 Performance and Payment Bonds-Construction. 2010-10 52.232-8 Discounts for Prompt Payment. 2002-02 52.232-11 Extras. 1984-04 52.232-17 Interest. 2014-05

52.232-18 Availability of Funds. 1984-04 52.232-23 Assignment of Claims. 2014-05 52.232-25 Prompt Payment. 2017-01 52.232-27 Prompt Payment for Construction Contracts. 2017-01 52.232-33 Payment by Electronic Funds Transfer-System for Award Management. 2018-10 52.232-39 Unenforceability of Unauthorized Obligations. 2013-06 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. 2013-12 52.233-1 Disputes. 2014-05 52.233-3 Protest after Award. 1996-08 52.233-4 Applicable Law for Breach of Contract Claim. 2004-10 52.236-2 Differing Site Conditions. 1984-04 52.236-3 Site Investigation and Conditions Affecting the Work. 1984-04 52.236-5 Material and Workmanship. 1984-04 52.236-6 Superintendence by the Contractor. 1984-04 52.236-7 Permits and Responsibilities. 1991-11 52.236-8 Other Contracts. 1984-04

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements.

1984-04

52.236-10 Operations and Storage Areas. 1984-04 52.236-11 Use and Possession Prior to Completion. 1984-04 52.236-12 Cleaning Up. 1984-04 52.236-13 Accident Prevention. 1991-11 52.236-14 Availability and Use of Utility Services. 1984-04 52.236-15 Schedules for Construction Contracts. 1984-04 52.236-17 Layout of Work. 1984-04 52.236-21 Specifications and Drawings for Construction. 1997-02 52.236-26 Preconstruction Conference. 1995-02 52.242-13 Bankruptcy. 1995-07 52.242-14 Suspension of Work. 1984-04 52.243-1 Alternate I Changes-Fixed-Price. - (Alternate I) 1987-08 52.243-5 Changes and Changed Conditions. 1984-04 52.244-6 Subcontracts for Commercial Items. 2019-08 52.246-21 Warranty of Construction. 1994-03 52.249-1 Termination for Convenience of the Government (Fixed-Price) (Short Form). 1984-04 52.249-10 Default (Fixed-Price Construction). 1984-04 52.253-1 Computer Generated Forms. 1991-01

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.203-7000 Requirements Relating to Compensation of Former DoD Officials 2011-09

252.203-7001 Prohibition on Persons Convicted of Fraud or Other Defense-Contract-Related Felonies.

2008-12

252.203-7002 Requirement to Inform Employees of Whistleblower Rights. 2013-09

252.203-7003 Agency Office of the Inspector General. As prescribed in 203.1004(a), use the following clause:

2019-08

252.204-7003 Control of Government Personnel Work Product. 1992-04 252.204-7008 Compliance with Safeguarding Covered Defense Information Controls. 2016-10 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting. 2019-12 252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support. 2016-05

252.209-7004 Subcontracting with Firms that are Owned or Controlled by the Government of a Country that is a State Sponsor of Terrorism.

2019-05

252.223-7006 Prohibition on Storage, Treatment, and Disposal of Toxic or Hazardous Materials. 2014-09 252.223-7008 Prohibition of Hexavalent Chromium. 2013-06 252.225-7001 Buy American and Balance of Payments Program. 2017-12 252.225-7002 Qualifying Country Sources as Subcontractors. 2017-12 252.225-7012 Preference for Certain Domestic Commodities. 2017-12 252.225-7016 Restriction on Acquisition of Ball and Roller Bearings. 2011-06 252.225-7025 Restriction on Acquisition of Forgings. 2009-12 252.225-7030 Restriction on Acquisition of Carbon, Alloy, and Armor Steel Plate. 2006-12 252.225-7048 Export-Controlled Items. 2013-06 252.227-7033 Rights in Shop Drawings. 1966-04 252.232-7010 Levies on Contract Payments. 2006-12 252.236-7005 Airfield Safety Precautions. 1991-12 252.237-7010 Prohibition on Interrogation of Detainees by Contractor Personnel. 2013-06 252.243-7001 Pricing of Contract Modifications. 1991-12 252.243-7002 Requests for Equitable Adjustment. 2012-12 252.244-7000 Subcontracts for Commercial Items 2013-06

252.246-7003 Notification of Potential Safety Issues. 2013-06

AFFARS Clauses Incorporated by Reference

Number Title Effective Date 5352.223-9001 Health and Safety on Government Installations 11/1/2012

FAR Clauses Incorporated by Full Text

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. 2016-02

As prescribed in (d), insert the following provision:9.104-7

REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A FELONY CONVICTION UNDER ANY

FEDERAL LAW (FEB 2016)

As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), (a) and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that-

Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or (1) have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is (2) aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

The Offeror represents that-(b)

It is is not a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative (1) remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

It is is not a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.(2)

(End of provision)

52.211-10 Commencement, Prosecution, and Completion of Work. 1984-04

As prescribed in , insert the following clause in solicitations and contracts when a fixed-price construction contract is contemplated. The 11.404(b) clause may be changed to accommodate the issuance of orders under indefinite-delivery contracts for construction.

COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within calendar days after [ ]10 days Contracting Officer insert number the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than

.* The time stated for completion shall include final cleanup of the premises.45 days

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

(End of clause)

52.211-12 Liquidated Damages-Construction. 2000-09

As prescribed in , insert the following clause in solicitations and contracts:11.503(b)

LIQUIDATED DAMAGES-CONSTRUCTION (SEPT 2000)

If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the (a) Government in the amount of for each calendar day of delay until the work is completed or accepted. [ ]410 Contracting Officer insert amount

If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. (b) These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.219-28 Post-Award Small Business Program Rerepresentation. 2020-03

As prescribed in , insert the following clause:19.309(c)(1)

POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (MAR 2020)

. As used in this clause-(a) Definitions means a contract of more than five years in duration, including options. However, the term does not include contracts that Long-term contract exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of Small business concern operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in of this clause. Such a concern is "not dominant in its field of operation" when it does not exercise a controlling or major influence on paragraph (d) a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the (1) novation agreement was executed prior to inclusion of this clause in the contract.

Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to (2) include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

For long-term contracts-(3)

Within 60 to 120 days prior to the end of the fifth year of the contract; and(i)

Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.(ii)

(c) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, when the Contracting Officer explicitly requires it for an order issued under a multiple-award contract.

The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that (d) corresponds to the North American Industry Classification System (NAICS) assigned to this contract. The small business size standard code(s) corresponding to this NAICS can be found at http://www.sba.gov/content/table-small-business-size-standards.code(s) small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a (e) The construction or service contract, is 500 employees.

(f) Except as provided in paragraph (h) of this clause, the Contractor shall make the representation(s) required by paragraph (b) and (c) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause, or with its offer for an order (see paragraph (c) of this clause), that the data have been validated or updated, and provide the date of the validation or update.

the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not (g) If required to, take the actions required by of this clause.paragraphs (f) or (h)

(h) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

(1) The Contractor represents that it is, is not a small business concern under NAICS Code assigned to contract number .____ ____

.(2) [ Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause

] The Contractor represents that it is, is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) [ Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.

] The Contractor represents that it is, is not a women-owned small business concern.

[(4) Women-owned small business (WOSB) concern eligible under the WOSB Program. Complete only if the Contractor represented itself ] as a women-owned small business concern in paragraph (h)(3) of this clause. The Contractor represents that-

(i) It is, is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It is, is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (h)(4)(i) of this clause is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture.

[The Contractor shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are .]participating in the joint venture:____ Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

[(5) Economically disadvantaged women-owned small business (EDWOSB) concern. Complete only if the Contractor represented itself as a women-owned small business concern eligible under the WOSB Program in (h)(4) of this clause. ] The Contractor represents that-

(i) It is, is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It is, is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (h)(5)(i) of this clause is accurate for each EDWOSB concern participating in the joint venture. [The Contractor shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: .] Each EDWOSB concern participating in the joint venture shall ____ submit a separate signed copy of the EDWOSB representation.

(6) [ Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.

] The Contractor represents that it is, is not a veteran-owned small business concern.

](7) [ Complete only if the Contractor represented itself as a veteran-owned small business concern in paragraph (h)(6) of this clause.

The Contractor represents that it is, is not a service-disabled veteran-owned small business concern.

(8) [ Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause. ] The Contractor represents that-

(i) It is, is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and

(ii) It is, is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126, and the representation in paragraph (h)(8)(i) of this clause is accurate for each HUBZone small business concern participating in the HUBZone joint venture.

[ ]The Contractor shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: .____ Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

[ ]Contractor to sign and date and insert authorized signer's name and title.

(End of clause)

52.222-26 Equal Opportunity. 2016-09

As prescribed in , insert the following clause:22.810(e)

EQUAL OPPORTUNITY (SEPT 2016)

. As used in this clause.(a) Definition means any payments made to, or on behalf of, an employee or offered to an applicant as remuneration for employment, including Compensation but not limited to salary, wages, overtime pay, shift differentials, bonuses, commissions, vacation and holiday pay, allowances, insurance and other benefits, stock options and awards, profit sharing, and retirement.

means the amount and type of compensation provided to employees or offered to applicants, including, but not Compensation information limited to, the desire of the Contractor to attract and retain a particular employee for the value the employee is perceived to add to the Contractor's profit or productivity; the availability of employees with like skills in the marketplace; market research about the worth of similar jobs in the relevant marketplace; job analysis, descriptions, and evaluations; salary and pay structures; salary surveys; labor union agreements; and Contractor decisions, statements and policies related to setting or altering employee compensation.

means the fundamental job duties of the employment position an individual holds. A job function may be considered Essential job functions essential if-

The access to compensation information is necessary in order to perform that function or another routinely assigned business task; or(1)

The function or duties of the position include protecting and maintaining the privacy of employee personnel records, including (2) compensation information.

has the meaning given by the Department of Labor's Office of Federal Contract Compliance Programs, and is found at Gender identity http://www.dol.gov/ofccp/LGBT/LGBT_FAQs.html.

has the meaning given by the Department of Labor's Office of Federal Contract Compliance Programs, and is found at Sexual orientation http://www.dol.gov/ofccp/LGBT/LGBT_FAQs.html.

means the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. United States, Virgin Islands, and Wake Island.

(b) If, during any 12-month period (including the 12 months preceding the award of this contract), the Contractor has been or is awarded (1) nonexempt Federal contracts and/or subcontracts that have an aggregate value in excess of $10,000, the Contractor shall comply with this clause, except for work performed outside the United States by employees who were not recruited within the United States. Upon request, the Contractor shall provide information necessary to determine the applicability of this clause.

If the Contractor is a religious corporation, association, educational institution, or society, the requirements of this clause do not apply (2) with respect to the employment of individuals of a particular religion to perform work connected with the carrying on of the Contractor's activities (41

CFR 60-1.5).

(c) The Contractor shall not discriminate against any employee or applicant for employment because of race, color, religion, sex, sexual (1) orientation, gender identity, or national origin. However, it shall not be a violation of this clause for the Contractor to extend a publicly announced preference in employment to Indians living on or near an Indian reservation, in connection with employment opportunities on or near an Indian reservation, as permitted by 41 CFR 60-1.5.

The Contractor shall take affirmative action to ensure that applicants are employed, and that employees are treated during employment, (2) without regard to their race, color, religion, sex, sexual orientation, gender identity, or national origin. This shall include, but not be limited to-

Employment;(i)

Upgrading;(ii)

Demotion;(iii)

Transfer;(iv)

Recruitment or recruitment advertising;(v)

Layoff or termination;(vi)

Rates of pay or other forms of compensation; and(vii)

Selection for training, including apprenticeship.(viii)

The Contractor shall post in conspicuous places available to employees and applicants for employment the notices to be provided by the (3) Contracting Officer that explain this clause.

The Contractor shall, in all solicitations or advertisements for employees placed by or on behalf of the Contractor, state that all qualified (4) applicants will receive consideration for employment without regard to race, color, religion, sex, sexual orientation, gender identity, or national origin.

(5) The Contractor shall not discharge or in any other manner discriminate against any employee or applicant for employment because (i) such employee or applicant has inquired about, discussed, or disclosed the compensation of the employee or applicant or another employee or applicant. This prohibition against discrimination does not apply to instances in which an employee who has access to the compensation information of other employees or applicants as a part of such employee's essential job functions discloses the compensation of such other employees or applicants to individuals who do not otherwise have access to such information, unless such disclosure is in response to a formal complaint or charge, in furtherance of an investigation, proceeding, hearing, or action, including an investigation conducted by the employer, or is consistent with the

Contractor's legal duty to furnish information.

The Contractor shall disseminate the prohibition on discrimination in paragraph (c)(5)(i) of this clause, using language prescribed by (ii) the Director of the Office of Federal Contract Compliance Programs (OFCCP), to employees and applicants by-

Incorporation into existing employee manuals or handbooks; and(A)

Electronic posting or by posting a copy of the provision in conspicuous places available to employees and applicants for (B) employment.

The Contractor shall send, to each labor union or representative of workers with which it has a collective bargaining agreement or other (6) contract or understanding, the notice to be provided by the Contracting Officer advising the labor union or workers' representative of the Contractor's commitments under this clause, and post copies of the notice in conspicuous places available to employees and applicants for employment.

The Contractor shall comply with Executive Order11246, as amended, and the rules, regulations, and orders of the Secretary of Labor.(7)

The Contractor shall furnish to the contracting agency all information required by Executive Order11246, as amended, and by the rules, (8) regulations, and orders of the Secretary of Labor. The Contractor shall also file Standard Form100 (EEO-1), or any successor form, as prescribed in 41 CFR Part 60-1. Unless the Contractor has filed within the 12 months preceding the date of contract award, the Contractor shall, within 30 days after contract award, apply to either the regional Office of Federal Contract Compliance Programs (OFCCP) or the local office of the Equal Employment Opportunity Commission for the necessary forms.

The Contractor shall permit access to its premises, during normal business hours, by the contracting agency or the OFCCP for the (9) purpose of conducting on-site compliance evaluations and complaint investigations. The Contractor shall permit the Government to inspect and copy any books, accounts, records (including computerized records), and other material that may be relevant to the matter under investigation and pertinent to compliance with Executive Order11246, as amended, and rules and regulations that implement the Executive Order.

If the OFCCP determines that the Contractor is not in compliance with this clause or any rule, regulation, or order of the Secretary of (10) Labor, this contract may be canceled, terminated, or suspended in whole or in part and the Contractor may be declared ineligible for further Government contracts, under the procedures authorized in Executive Order11246, as amended. In addition, sanctions may be imposed and remedies invoked against the Contractor as provided in Executive Order11246, as amended; in the rules, regulations, and orders of the Secretary of Labor; or as otherwise provided by law.

The Contractor shall include the terms and conditions of this clause in every subcontract or purchase order that is not exempted by the (11) rules, regulations, or orders of the Secretary of Labor issued under Executive Order11246, as amended, so that these terms and conditions will be binding upon each subcontractor or vendor.

The Contractor shall take such action with respect to any subcontract or purchase order as the Director of OFCCP may direct as a (12) means of enforcing these terms and conditions, including sanctions for noncompliance, provided, that if the Contractor becomes involved in, or is threatened with, litigation with a subcontractor or vendor as a result of any direction, the Contractor may request the United States to enter into the litigation to protect the interests of the United States.

Notwithstanding any other clause in this contract, disputes relative to this clause will be governed by the procedures in 41 CFR 60-1.(d)

(End of clause)

52.222-35 Equal Opportunity for Veterans. 2015-10

As prescribed in , insert the following clause:22.1310(a)(1)

EQUAL OPPORTUNITY FOR VETERANS (OCT 2015)

. As used in this clause-(a) Definitions

"Active duty wartime or campaign badge veteran," "Armed Forces service medal veteran," "disabled veteran," "protected veteran," "qualified disabled veteran," and "recently separated veteran" have the meanings given at FAR 22.1301.

Equal opportunity clause. The Contractor shall abide by the requirements of the equal opportunity clause at 41 CFR 60-300.5(a), as of (b) March 24, 2014. This clause prohibits discrimination against qualified protected veterans, and requires affirmative action by the Contractor to employ and advance in employment qualified protected veterans.

Subcontracts. The Contractor shall insert the terms of this clause in subcontracts of $150,000 or more unless exempted by rules, regulations, (c) or orders of the Secretary of Labor. The Contractor shall act as specified by the Director, Office of Federal Contract Compliance Programs, to enforce the terms, including action for noncompliance. Such necessary changes in language may be made as shall be appropriate to identify properly the parties and their undertakings.

(End of clause)

52.222-36 Equal Opportunity for Workers with Disabilities. 2014-07

As prescribed in , insert the following clause:22.1408(a)

EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (JUL 2014)

Equal opportunity clause. The Contractor shall abide by the requirements of the equal opportunity clause at 41 CFR 60-741.5(a), as of (a) March 24, 2014. This clause prohibits discrimination against qualified individuals on the basis of disability, and requires affirmative action by the Contractor to employ and advance in employment qualified individuals with disabilities.

Subcontracts. The Contractor shall include the terms of this clause in every subcontract or purchase order in excess of $15,000 unless (b) exempted by rules, regulations, or orders of the Secretary, so that such provisions will be binding upon each subcontractor or vendor. The Contractor shall act as specified by the Director, Office of Federal Contract Compliance Programs of the U.S. Department of Labor, to enforce the terms, including action for noncompliance. Such necessary changes in language may be made as shall be appropriate to identify properly the parties and their undertakings.

(End of clause)

52.223-3 Hazardous Material Identification and Material Safety Data. 1997-01

As prescribed in , insert the following clause:23.303

HAZARDOUS MATERIAL IDENTIFICATION AND MATERIAL SAFETY DATA (JAN 1997)

"Hazardous material," as used in this clause, includes any material defined as hazardous under the latest version of Federal Standard No.313 (a) (including revisions adopted during the term of the contract).

The offeror must list any hazardous material, as defined in paragraph (a) of this clause, to be delivered under this contract. The hazardous (b) material shall be properly identified and include any applicable identification number, such as National Stock Number or Special Item Number. This information shall also be included on the Material Safety Data Sheet submitted under this contract.

Material ( )Ifnone,insert"None" Identification No.

This list must be updated during performance of the contract whenever the Contractor determines that any other material to be delivered (c) under this contract is hazardous.

The apparently successful offeror agrees to submit, for each item as required prior to award, a Material Safety Data Sheet, meeting the (d) requirements of 29 CFR1910.1200(g) and the latest version of Federal Standard No.313, for all hazardous material identified in paragraph (b) of this clause. Data shall be submitted in accordance with Federal Standard No.313, whether or not the apparently successful offeror is the actual manufacturer of these items. Failure to submit the Material Safety Data Sheet prior to award may result in the apparently successful offeror being considered nonresponsible and ineligible for award.

If, after award, there is a change in the composition of the item(s) or a revision to Federal Standard No.313, which renders incomplete or (e) inaccurate the data submitted under paragraph (d) of this clause, the Contractor shall promptly notify the Contracting Officer and resubmit the data.

Neither the requirements of this clause nor any act or failure to act by the Government shall relieve the Contractor of any responsibility or (f) liability for the safety of Government, Contractor, or subcontractor personnel or property.

Nothing contained in this clause shall relieve the Contractor from complying with applicable Federal, State, and local laws, codes, (g) ordinances, and regulations (including the obtaining of licenses and permits) in connection with hazardous material.

The Government's rights in data furnished under this contract with respect to hazardous material are as follows:(h)

To use, duplicate and disclose any data to which this clause is applicable. The purposes of this right are to-(1)

Apprise personnel of the hazards to which they may be exposed in using, handling, packaging, transporting, or disposing of hazardous (i) materials;

Obtain medical treatment for those affected by the material; and(ii)

Have others use, duplicate, and disclose the data for the Government for these purposes.(iii)

To use, duplicate, and disclose data furnished under this clause, in accordance with paragraph (h)(1) of this clause, in precedence over (2) any other clause of this contract providing for rights in data.

The Government is not precluded from using similar or identical data acquired from other sources.(3)

(End of clause)

52.223-9 Estimate of Percentage of Recovered Material Content for EPA-Designated Items. 2008-05

As prescribed in , insert the following clause:23.406(d)

ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA-DESIGNATED ITEMS (MAY 2008)

. As used in this clause-(a) Definitions means a material or finished product that has served its intended use and has been discarded for disposal or recovery, Postconsumer material having completed its life as a consumer item. Postconsumer material is a part of the broader category of "recovered material."

"Recovered material" means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products…