Sol_140L3423Q0001.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

0040601311

BLM MT/DAK EASTERN DIST OFC(MTC000)

111 GARRYOWEN RD

MILES CITY MT 59301

LMM

rundlin@blm.gov

Rebecca Undlin 4062332829

101/18/2023

140L3423Q0001

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

BASIN VIEW LIVESTOCK PIPELINE:

Schedule of Items

Specifications

Maps and Drawings

Attachment A

WBI Energy Checklist and Crossing Encroachment Doc

Wage Determination

Past Performance Questionnaire

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 108 calendar days and complete it within ________________ ________________ calendar days after receiving

02/23/2023

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

BLM MT/DAK EASTERN DIST OFC(MTC000)

111 GARRYOWEN RD

MILES CITY MT 59301

LMM

Rebecca Undlin

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 25

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140L3423Q0001

The Bureau of Land Management (BLM) office in

Miles City, Montana has a requirement to furnish labor, equipment, supplies, and materials to construct a livestock pipeline. The pipeline shall be trenched or ripped (pulled to a minimum depth of 5 feet and all appurtenances shall be installed to 6-foot frost free depth). Please see all attachments for requirements/details.

Work under this contract is located in Dawson

County Montana.

Work is anticipated to start after July 17, 2023, due to the Migratory Bird Act. Contractor shall have 108 days from the Notice to Proceed issued by the contracting officer to complete the project.

The North American Industry Classification System

(NAICS) Code for this procurement is 238990.

This is a total set aside for Small Business

Concerns. The small business size stand is $16.5 million. Estimated price range is between

$25,000 and $150,000.

A 100% payment protection will be required for contracts greater than $35,000. A performance bond shall be required for a contract over

$150,000. Payment protection shall be due within

10 days upon notification of our intent to make award.

Prospective contractors shall be registered in

System for Award Management (SAM) prior to award.

Lack of registration in the SAM database or failure to submit all required quote information as identified in the upcoming solicitation may make a quoter ineligible for award. Information on SAM can be found online at www.sam.gov.

All questions regarding this requirement must be submitted in writing to rundlin@blm.gov at least seven business days prior to the closing date of this RFQ. No other individuals are designated to take questions. An organized Site Tour is scheduled. Please see site tour info listed in the solicitation for details.

Continued ...

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

4 25

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140L3423Q0001

Delivery: 108 Days After Notice to Proceed

Delivery Location Code: 0004276398

BLM-MT MILES CITY FIELD OFFICE*

111 GARRYOWEN ROAD

MILES CITY MT 59301 US

Period of Performance: 03/06/2023 to 11/20/2023

00010 BASIN VIEW LIVESTOCK PIPELINE

Please see all attachments for requirements/details

IMPORTANT: Field work on the project cannot start until after July 15, 2023, due to the

Migratory Bird Act. A Notice to Proceed (NTP) shall be issued by the contracting officer sometime around July 17, 2023, and work shall be completed within 108 days of the NTP.

Product/Service Code: Y1PZ

Product/Service Description: CONSTRUCTION OF

OTHER NON-BUILDING FACILITIES

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

REQUEST FOR QUOTATIONS

SOLICITATION NO: 140L3423Q0001

TITLE: Basin View Livestock Pipeline

U.S. Department of the Interior Bureau of Land Management Eastern MT/DAK District

PROJECT DESCRIPTION: Basin View Livestock Pipeline SOLICITATION NO.: 140L3423Q0001

PROCUREMENT OVERVIEW

Type of Contract: Construction, Firm Fixed Priced (FFP), Single Award Purchase Order

Place of Construction: Dawson County Montana

Type of Construction: Heavy

Estimated Price Range: $25K to $150K

NAICS Code: 238990, All Other Specialty Trade Contractors Size Standard: $16.5 Million

Set-Aside: 100% Small Business

Questions Due Date: Seven Days prior to closing date of solicitation - 1700 Local Mountain Time

Due Date: As listed on Solicitation and in accordance with this Solicitation, Representations, and Quote Submittal Instructions

RESTRICTIONS ON CONTACTS: Beginning upon release of the request for quotation (RFQ) through purchase order award, contacting Government employees who may be associated or have knowledge of this work is inappropriate. Offerors for this RFQ, including subcontractors and teammates, shall not attempt such contacts during this period. ALL correspondence/questions shall be submitted to the Contracting Officer Only. All questions shall be EMAILED directly to the Contracting Officer at rundlin@blm.gov. Only written RFI’s will be considered and responded to by the Government. BLM responses to RFIs will be posted as an amendment to the solicitation.

SITE TOUR: Site Tour Information can be found below under “GENERAL” – Clause 52.236-27 Site Visit (Construction)- Alternate I

Award Selection Process: See Basis for Contract Award Below

INTERNET PAYMENT PLATFORM (IPP): Payment request for the anticipated contract shall be submitted electronically through the U.S. Department of the Treasury’s Invoice Processing Platform (IPP) - See IPP details/requirements under the Clause Section of this Document.

PROJECT DESCRIPTION: Basin View Livestock Pipeline SOLICITATION NO.: 140L3423Q0001

GENERAL

(a) The Bureau of Land Management (BLM) is seeking quotations for construction services as attached in the accompanying statement of work. The BLM intends to conduct this acquisition by use of simplified acquisition procedures in accordance with FAR Part 13. A single contract award will be made to the Offeror that submits a quotation that has been determined to be the best value to the Government.

(b) The Government will not award any contract if the resulting contract would not represent a "best value" to the Government.

(c) To assure timely and equitable evaluation of quotations, respondents are cautioned to strictly comply with all instructions within this solicitation to ensure submission of a complete quotation. Offerors are required to meet all solicitation requirements, including terms and conditions, representations and certifications, and technical requirements. Failure to adhere to quotation requirements, at the time of submission, may result in the quotation being unacceptable to the Government and eliminated from consideration for award. It is the responsibility of offerors to ensure their quote is received by the Contracting Officer no later than the due date and time.

(d) Offerors are cautioned to submit adequate information to enable the Government to fully ascertain each offeror’s capability to perform the requirements in accordance with the requirements of the request for quotation (RFQ).

(e) If a respondent believes that requirements in these instructions contain an error, omission, or are otherwise flawed, the respondent shall immediately notify the Contracting Officer via email with supporting rationale by the question deadline specified on the cover page of this document.

(f) This RFQ does not commit the Government to any costs incurred in the preparation and submission of a quote or for any other costs incurred by any firm submitting a quote in response to this solicitation. Note specifically that the Offeror will not be participating in a sealed bid procurement process under this acquisition method. Issuance of this RFQ does not constitute an award commitment on the part of the Government.

(g) Quotation must be valid for a minimum of 60 days.

(h) Respondents must complete the System for Award Management (SAM) at https://www.sam.gov. The Government will obtain respondent representations and certifications through this system. Please verify that your registration is active, up-to-date and includes the appropriate NAICS code identified in this solicitation. If assistance is needed in registering, please go to http://www.aptac-us-.org to find a Procurement Technical Assistance Center (PTAC) near you. SAM Registration and PTAC Assistance are free of charge.

(i) Award is subject to and based on the availability of funds. This project is currently funded based upon an independent cost estimate.

(j) Including all other factors, to qualify for award, a respondent must be determined responsible in accordance with Federal Acquisition Regulation Part 9.

(k) Respondents shall NOT contact any government personnel related to this requirement other than the Contracting Officer.

(l) All questions shall be emailed directly to the Contracting Officer at rundlin@blm.gov. Only written RFI’s will be considered and responded to by the Government. BLM responses to RFIs will be posted as an amendment to the solicitation.

(m) The successful Offeror shall submit appropriate Alternative Payment Protection in accordance with clause 52.228-13 within 10 days of contract award. Note: If over $150K, Payment Bond will also be required.

52.236-27 Site Visit (Construction)- Alternate I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

An organized site visit has been scheduled for:

February 1, 2023 at 10:00 a.m. mountain time.

Interested Parties will meet at the east end Cenex, 1803 N. Merrill Ave, Glendive, MT 59330 https://www.sam.gov/ http://www.aptac-us-.org/

PROJECT DESCRIPTION: Basin View Livestock Pipeline SOLICITATION NO.: 140L3423Q0001

All prospective quoters shall provide their own transportation on the site tour.

The site tour is not mandatory but highly recommended. Interested parties are responsible for their own transportation to each site. In no event shall failure to inspect the site constitute grounds for a claim after contract award.

QUOTATION SUBMITTAL

Quotes must be in accordance with and in the order detailed in this section. Failure to submit quotes according to the instructions provided within the solicitation may result in an offeror’s quote being deemed unacceptable.

Quotes are due by the date and time specified on the SF1442 Form. You are encouraged to return to the posted solicitation prior to the closing date to ensure all amendments are acknowledged, signed, and included with quote package.

Quotes shall be submitted via email to rundlin@blm.gov. It is highly recommended that follow up contact is made with the Contracting Officer (CO) to ensure quote package was received. CO shall not be responsible for missing, lost, or undelivered packages.

REQUIRED QUOTE PACKAGE DOCUMENTATION

Respondent shall submit the following information in response to this RFQ:

(1) Short Cover Letter:

(i) Offeror’s (company) name, address, and phone number

(ii) SAM UEI number

(iii) Point of contact for individuals within the company

(iv) A response to the following questions:

o Judgments, Claims, and Lawsuits: Are there any judgments, claims, and/or lawsuits pending or outstanding against or involving entity or partners comprising your entity?

o No ___, Yes ___. If “Yes,” submit details of all judgments or claims against either parent office or division/branch that will be responsible for the accomplishment of this project on a separate sheet.

o Is your entity or partners comprising your entity under suspension or debarment by any Federal, state or local agency, or been terminated on any past projects (Federal or others)?

o No ___, Yes ___. If “Yes,” submit details on a separate sheet.

o IAW FAR 52.209-7(b), the offeror [ ] has [ ] does not have current active federal contracts and grants with a total value greater than $10,000,000.

o o IAW FAR 52.204-24(d), the offeror represents that it [ ] will [ ] will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation

(2) Complete and Sign Standard Form (SF)1442, Request for Quotation. Please insert total price quote in block 11 and complete blocks 13 and 14. An official having the authority to contractually bind the Offeror's company must sign the SF1442 in accordance with the procedures prescribed in the Federal Acquisition Regulation Subpart 4.102.

(3) Acknowledgement of Amendments: Acknowledge all request for quote amendments by signing and returning with your SF1442 any SF30s issued (if applicable).

(4) Complete and Submit the Schedule of Items

(5) Complete and Submit the Past Performance Questionnaire accurately and in its entirety mailto:rundlin@blm.gov

PROJECT DESCRIPTION: Basin View Livestock Pipeline SOLICITATION NO.: 140L3423Q0001

BASIS FOR CONTRACT AWARD

(a) This acquisition is a Small Business set-aside under the North American Industry Classification System (NAICS) Code 238990 with a small business size standard of $16.5 million. An offeror determined to be other than a Small Business will be deemed ineligible for award.

(b) Award will be made to the responsible firm whose quote is most advantageous to the Government, price, past performance and experience being considered. Past performance and experience information may be based on the Government’s knowledge of, and previous experience with, the quoter, or another reasonable basis.

(c) For the purpose of initial evaluation of quotations, the following procedures will be utilized in resolving arithmetic discrepancies found on the face of the schedule as submitted by quoters:

(i) In case of discrepancy between unit price and extended price, the unit price will govern;

(ii) Obviously misplaced decimal points will be corrected;

(iii) Apparent errors in extension of unit prices will be corrected; and

(iv) Apparent errors in addition of lump-sum and extended prices will be corrected.

(d) The Government reserves the right to award without discussions as well as the right to hold discussions. If discussions are held, they will be held with all quoters if the Government makes a major change in specifications or terms and conditions. Discussions may be conducted with the firm submitting the lowest priced quotation if price only is discussed.

CONTRACT PROVISIONS

PROVISIONS INCORPORATED BY REFERENCE

52.252-1 Solicitations Provisions Incorporated by Reference (Feb 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this address: http://acquisition.gov/far/index.html.

Provision Title Date

52.204-7 System for Award Management October 2018

52.204-16 Commercial and Government Entity Code Reporting August 2020

52.204-22 Alternative Line-Item Proposal January 2017

PROVISIONS INCORPORATED BY FULL TEXT

52.204-8 Annual Representations and Certifications (Dec 2022)

(a) (1) The North American Industry Classification System (NAICS) code for this acquisition is 238990

(2) The small business size standard is $16.5 million

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees if the acquisition—

(i)Is set aside for small business and has a value above the simplified acquisition threshold;

(ii)Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or http://acquisition.gov/far/index.html

PROJECT DESCRIPTION: Basin View Livestock Pipeline SOLICITATION NO.: 140L3423Q0001

(iii)Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b) (1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

(i) □ Paragraph (d) applies.

(ii) □ Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless–

(A) The acquisition is to be made under the simplified acquisition procedures in part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204- 7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that-

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services-Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations-Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

https://www.acquisition.gov/far/part-52#FAR_52_204_7 https://www.acquisition.gov/far/part-52#FAR_52_204_7 https://www.acquisition.gov/far/part-52#FAR_52_203_2 https://www.acquisition.gov/far/part-13#FAR_Part_13 https://www.acquisition.gov/far/part-52#FAR_52_203_11 https://www.acquisition.gov/far/part-52#FAR_52_203_18 https://www.acquisition.gov/far/part-52#FAR_52_204_3 https://www.acquisition.gov/far/part-52#FAR_52_204_7 https://www.acquisition.gov/far/part-52#FAR_52_204_7 https://www.acquisition.gov/far/part-52#FAR_52_204_5 https://www.acquisition.gov/far/part-52#FAR_52_204_26 https://www.acquisition.gov/far/part-52#FAR_52_209_2 https://www.acquisition.gov/far/part-52#FAR_52_209_5 https://www.acquisition.gov/far/part-52#FAR_52_209_11

PROJECT DESCRIPTION: Basin View Livestock Pipeline SOLICITATION NO.: 140L3423Q0001

(x) 52.214-14, Place of Performance-Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans’ Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial products or commercial services.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA–designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA–designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals-Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American-Free Trade Agreements-Israeli Trade Act Certificate. (Basic, Alternates II and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $50,000, the basic provision applies.

(B) If the acquisition value is $50,000 or more but is less than $92,319, the provision with its Alternate II applies.

(C) If the acquisition value is $92,319 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan-Certification. This provision applies to all solicitations.

https://www.acquisition.gov/far/part-52#FAR_52_214_14 https://www.acquisition.gov/far/part-52#FAR_52_215_6 https://www.acquisition.gov/far/part-52#FAR_52_219_1 https://www.acquisition.gov/far/part-19#FAR_Part_19 https://www.acquisition.gov/far/part-19#FAR_19_000 https://www.acquisition.gov/far/part-52#FAR_52_219_2 https://www.acquisition.gov/far/part-19#FAR_Part_19 https://www.acquisition.gov/far/part-19#FAR_19_000 https://www.acquisition.gov/far/part-52#FAR_52_222_22 https://www.acquisition.gov/far/part-52#FAR_52_222_26 https://www.acquisition.gov/far/part-52#FAR_52_222_25 https://www.acquisition.gov/far/part-52#FAR_52_222_26 https://www.acquisition.gov/far/part-52#FAR_52_222_38 https://www.acquisition.gov/far/part-52#FAR_52_223_1 https://www.acquisition.gov/far/part-52#FAR_52_223_2 https://www.acquisition.gov/far/part-52#FAR_52_223_4 https://www.acquisition.gov/far/part-52#FAR_52_223_22 https://www.acquisition.gov/far/part-52#FAR_52_204_7 https://www.acquisition.gov/far/part-52#FAR_52_225_2 https://www.acquisition.gov/far/part-52#FAR_52_225_1 https://www.acquisition.gov/far/part-52#FAR_52_225_4 https://www.acquisition.gov/far/part-52#FAR_52_225_3 https://www.acquisition.gov/far/part-52#FAR_52_225_6 https://www.acquisition.gov/far/part-52#FAR_52_225_5 https://www.acquisition.gov/far/part-52#FAR_52_225_20

PROJECT DESCRIPTION: Basin View Livestock Pipeline SOLICITATION NO.: 140L3423Q0001

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran- Representation and Certifications. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

__ (i) 52.204-17, Ownership or Control of Offeror.

__ (ii) 52.204-20, Predecessor of Offeror.

__ (iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

__ (iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment- Certification.

__ (v) 52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Certification.

__ (vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA– Designated Products (Alternate I only).

__ (vii) 52.227-6, Royalty Information.

__ (A) Basic.

__ (B) Alternate I.

__ (viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically in SAM website accessed through https://www.sam.gov. After reviewing the SAM information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision) https://www.acquisition.gov/far/part-52#FAR_52_225_25 https://www.acquisition.gov/far/part-52#FAR_52_226_2 https://www.acquisition.gov/far/part-52#FAR_52_204_17 https://www.acquisition.gov/far/part-52#FAR_52_204_20 https://www.acquisition.gov/far/part-52#FAR_52_222_18 https://www.acquisition.gov/far/part-52#FAR_52_222_48 https://www.acquisition.gov/far/part-52#FAR_52_222_52 https://www.acquisition.gov/far/part-52#FAR_52_223_9 https://www.acquisition.gov/far/part-52#FAR_52_227_6 https://www.acquisition.gov/far/part-52#FAR_52_227_15 https://www.acquisition.gov/far/part-4#FAR_4_1201

PROJECT DESCRIPTION: Basin View Livestock Pipeline SOLICITATION NO.: 140L3423Q0001

52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment (Nov 2021)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in paragraph (c)(1) in the provision at 52.204-26, Covered Telecommunications Equipment or Services—Representation, or in paragraph (v)(2)(i) of the provision at 52.212-3, Offeror Representations and Certifications-Commercial Products or Commercial Services. The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it "does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services" in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3.

(a) Definitions. As used in this provision—

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services".

(d) Representation. The Offeror represents that—

(1) It □ will, □ will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that— https://www.acquisition.gov/far/52.204-26#FAR_52_204_26 https://www.acquisition.gov/far/52.212-3#FAR_52_212_3 https://www.acquisition.gov/far/52.204-26#FAR_52_204_26 https://www.acquisition.gov/far/52.212-3#FAR_52_212_3 https://www.acquisition.gov/far/52.204-25#FAR_52_204_25

PROJECT DESCRIPTION: Basin View Livestock Pipeline SOLICITATION NO.: 140L3423Q0001

It □ does, □ does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)(2) of this section.

(e) Disclosures.

(1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(End of provision)

PROJECT DESCRIPTION: Basin View Livestock Pipeline SOLICITATION NO.: 140L3423Q0001

52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction (Feb 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for Minority Participation for Each Trade Goals for Female Participation for Each Trade

3.3%

6.9%

These goals are applicable to all of the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S.

Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the -

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Dawson County MT

52.225-10 Notice of Buy American Requirement – Construction Materials (May 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American— Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers.

(1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

http://acquisition.gov/far/current/html/52_223_226.html#wp1169273 http://acquisition.gov/far/current/html/52_223_226.html#wp1169273

PROJECT DESCRIPTION: Basin View Livestock Pipeline SOLICITATION NO.: 140L3423Q0001

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested—

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations. (End of provision)

SPECIAL CONTRACT REQUIREMENTS

WORK HOURS – FEDERAL HOLIDAYS

The performance period established for this contract is based upon all work being conducted during regular working hours between 6:00am and 6:00pm, Monday through Friday, excluding government holidays. If the Contractor desires to carry on work outside regular hours, including Saturdays, Sundays, and government holidays, a request must be submitted to the Contracting Officer in sufficient time to allow satisfactory arrangements to be made by the Government for access to the work site and inspection.

Federal law (5 U.S.C. 6103) establishes the public holidays for Federal employees. Please note that most Federal employees work on a Monday through Friday schedule. For these employees, when a holiday falls on a non-workday – Saturday or Sunday – the holiday usually is observed on Monday (if the holiday falls on Sunday) or Friday (if the holiday falls on Saturday). To see holidays for specific year, please visit https://www.opm.gov.

FIRE DANGER SEASON

If the Contracting Officer Representative (COR) allows the Contractor to continue work during periods of declared fire danger or season, the Contractor shall comply with all applicable state laws relating to fire prevention and with all special conditions of work as directed by the COR.

DRAWINGS

(a) Typical Drawings. Any drawings titled typical are general only and dimensions of each structure will be fixed by the Contracting Officer to adapt the design to existing conditions at the structure location.

(b) Reduced Size Drawings. Any drawings identified as "REDUCED SIZE DRAWINGS" appearing in the solicitation are photographically reduced in size. Accordingly, measurements and dimensions should not be taken or be based on any numerical scales shown. Prospective bidders desiring to review a copy of the full-size drawings may contact the Contracting Officer identified in the solicitation.

PRESERVATION OF HISTORICAL AND ARCHEOLOGICAL DATA

(a) The Historic and Archeological Data Preservation Act of 1974 provides for the preservation of historical and archeological data that might otherwise be lost as the result of alterations to the terrain caused by a federal or federally licensed activity or program.

(b) If, in connection with operations under this contract, the Contractor, subcontractors, or the employees of any of them, discovers, encounters or becomes aware of any possible historical or archeological data, objects or sites of cultural value on the project area, such as historical ruins, graves or grave markers, fossils, or artifacts, the Contractor shall immediately suspend all operations in the vicinity of the cultural value and shall notify the Contracting Officer in writing, giving the location and nature of the findings. No objects of cultural resource value may be removed.

(c) Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance and/or changes in the work. If such delays and/or changes are ordered, the time of performance and contract price shall be adjusted in accordance with the Changes clause.

(d) The Contractor will be responsible for protecting the cultural resources within the affected area from damage. In addition, the http://acquisition.gov/far/current/html/52_223_226.html#wp1169273…