S02 - Att 2 P1600101 100 CD Specifications.pdf

Contract No. 676-16-102 100% Construction Documents – February 9, 2018 Tomah VA Medical Center – Replace HVAC & AC B404

Tomah, Wisconsin

Specifications

For

REPLACE HVAC & AC B404

TOMAH VA MEDICAL CENTER

BUILDING 404

TOMAH, WISCONSIN

100% CONSTRUCTION DOCUMENTS SUBMISSION

February 9, 2018

(LEFT INTENTIONALLY BLANK)

VA MEDICAL CENTER DEPARTMENT OF VETERAN AFFAIRS

TOMAH, WI

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 05-01-17

00 01 10-1

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

DIVISION 00 - SPECIAL SECTIONS DATE

00 01 15 List of Drawing Sheets 07-15

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 11-15

01 32 16.15 Project Schedules (Small Projects – Design/Bid/Build 02-15

01 33 23 Shop Drawings, Product Data, and Samples 05-17

01 35 26 Safety Requirements 02-17

01 42 19 Reference Standards 05-16

01 57 19 Temporary Environmental Controls 01-11

01 74 19 Construction Waste Management 09-13

01 81 13 Sustainable Construction Requirements 10-17

01 91 00 General Commissioning Requirements 10-15

DIVISION 02 – EXISTING CONDITIONS

02 41 00 Demolition 08-17

DIVISION 03 – CONCRETE

03 30 53 (Short-Form) Cast-in-Place Concrete 02-16

DIVISION 04 – MASONRY

04 05 13 Masonry Mortaring 10-17

04 05 16 Masonry Grouting 02-16

04 20 00 Unit Masonry 08-17

DIVISION 05 – METALS

05 50 00 Metal Fabrications 07-14

DIVISION 06 – WOOD,PLASTICS AND COMPOSITES – NOT USED

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 60 00 Flashing and Sheet Metal 07-14

07 84 00 Firestopping 02-16

07 92 00 Joint Sealants 10-17

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 05-01-17

00 01 10-2

DIVISION 08 - OPENINGS

08 11 13 Hollow Metal Doors and Frames 08-16

08 71 00 Door Hardware 01-16

08 90 00 Louvers and Vents 05-15

DIVISION 09 – FINISHES

09 51 00 Acoustical Ceilings 12-16

09 91 00 Painting 01-16

DIVISION 10 – SPECIALTIES – NOT USED

DIVISION 11 – EQUIPMENT – NOT USED

DIVISION 12 – FURNISHINGS – NOT USED

DIVISION 13 - SPECIAL CONSTRUCTION – NOT USED

DIVISION 14– CONVEYING EQUIPEMENT – NOT USED

DIVISION 21- FIRE SUPPRESSION

21 08 00 Commissioning of Fire Suppression System 11-16

21 13 13 Wet-Pipe Sprinkler Systems 06-15

DIVISION 22 – PLUMBING

22 05 11 Common Work Results for Plumbing 07-16

22 05 23 General-Duty Valves for Plumbing Piping 09-15

22 07 11 Plumbing Insulation 09-15

22 11 00 Facility Water Distribution 09-15

22 13 00 Facility Sanitary and Vent Piping 09-15

22 40 00 Plumbing Fixtures 09-15

DIVISION 23 – HEATING, VENTILATING, AND AIR

CONDITIONING (HVAC)

23 05 11 Common Work Results for HVAC 08-17

23 05 12 General Motor Requirements for HVAC and Steam

Generation Equipment

08-17

23 05 41 Noise and Vibration Control for HVAC Piping and

Equipment

02-15

23 05 93 Testing, Adjusting, and Balancing for HVAC 02-15

23 07 11 HVAC and Boiler Plant Insulation 02-15

23 08 00 Commissioning of HVAC Systems 06-13

23 09 23 Direct-Digital Control System for HVAC 09-11

23 21 13 Hydronic Piping 08-17

23 21 23 Hydronic Pumps 08-17

23 22 13 Steam and Condensate Heating Piping 08-17

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 05-01-17

00 01 10-3

23 25 00 HVAC Water Treatment 02-15

23 31 00 HVAC Ducts and Casings 03-13

23 34 00 HVAC Fans 02-15

23 40 00 HVAC Air Cleaning Devices 02-12

23 72 00 Air-to-Air Energy Recovery Equipment 05-11

23 73 00 Indoor Central-Station Air-Handling Units 04-11

23 82 16 Air Coils 04-11

DIVISION 25 – INTEGRATED AUTOMATION

25 13 00 Building Automation System (BAS) Integration 08-13

DIVISION 26 – ELECTRICAL

26 05 11 Requirements for Electrical Installations 01-16

26 05 19 Low-Voltage Electrical Power Conductors and Cables 01-17

26 05 26 Grounding and Bonding for Electrical Systems 01-17

26 05 33 Raceway and Boxes for Electrical Systems 05-14

26 08 00 Commissioning of Electrical Systems 11-16

26 27 26 Wiring Devices 01-16

26 29 11 Motor Controllers 08-14

DIVISION 27 – COMMUNICATIONS– NOT USED

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

28 31 00 Fire Detection and Alarm 10-11

DIVISION 31 – EARTHWORK – NOT USED

DIVISION 32 – EXTERIOR IMPROVEMENTS – NOT USED

DIVISION 33 – UTILITIES – NOT USED

DIVISION 34 – TRANSPORTATION – NOT USED

DIVISION 48 – ELECTRICAL POWER GENERATION – NOT USED

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 07-01-15

00 01 15 - 1

SECTION 00 01 15

LIST OF DRAWING SHEETS

The drawings listed below accompanying this specification form a part of the contract.

Drawing No. Title

GENERAL INFORMATION

GI001 TITLE SHEET

GC101 PHASING DEMOLITION

GC102 PHASING NEW WORK

GC103 INFECTION CONTROL GENERAL NOTES AND DETAILS

GC104 INFECTION CONTROL PLANS

CIVIL

C001 SITE DETAILS

C101 SITE STAGING AND EQUIPMENT LAYOUT PLAN

ARCHITECTURAL

A001 ARCHITECTURAL LEGEND, ABBREVIATIONS, SCHEDULES,

AND DETAILS

AD101 ARCHITECTURAL DEMOLITION

AS101 ARCHITECTURAL NEW WORK

AS201 ARCHITECTURAL REFLECTED CEILING PLAN

A401 ARCHITECTURAL ELEVATIONS

A402 ARCHITECTURAL ELEVATIONS

FIRE PROTECTION

F001 FIRE PROTECTION LEGEND, ABBREVIATIONS,

SCHEDULES, AND DETAILS

FD101 FIRE PROTECTION SUPPRESSION DEMOLITION

FD102 FIRE PROTECTION DETECTION AND ALARM DEMOLITION

FX101 FIRE PROTECTION DUPPRESSION NEW WORK

FA101 FIRE PROTECTION DETECTION AND ALARM NEW WORK

PLUMBING

P001 PLUMBING LEGEND, ABBREVIATIONS, AND DIAGRAMS

PD101 PLUMBING DEMOLITION

PL101 PLUMBING NEW WORK - THIRD FLOOR

PL102 PLUMBING NEW WORK - ATTIC

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 07-01-15

00 01 15 - 2

HEATING, VENTILATING, AIR

CONDITIONING AND REFRIGERATION

M001 MECHANICAL LEGEND, ABBREVIATIONS, AND NOTES

MD101 MECHANICAL BASEMENT DEMOLITION

MD102-A MECHANICAL PARTIAL ATTIC DEMOLITION – DUCTWORK

MD102-B MECHANICAL PARTIAL ATTIC DEMOLITION – DUCTWORK

MD102-C MECHANICAL PARTIAL ATTIC DEMOLITION – DUCTWORK

MD103-A MECHANICAL PARTIAL ATTIC DEMOLITION – PIPING

MD103-B MECHANICAL PARTIAL ATTIC DEMOLITION – PIPING

MD103-C MECHANICAL PARTIAL ATTIC DEMOLITION – PIPING

MH101 MECHANICAL BASEMENT NEW WORK

MH102-A MECHANICAL PARTIAL ATTIC NEW WORK – DUCTWORK

MH102-B MECHANICAL PARTIAL ATTIC NEW WORK – DUCTWORK

MH102-C MECHANICAL PARTIAL ATTIC NEW WORK – DUCTWORK

MP102-A MECHANICAL PARTIAL ATTIC NEW WORK – PIPING

MP102-B MECHANICAL PARTIAL ATTIC NEW WORK – PIPING

MP102-C MECHANICAL PARTIAL ATTIC NEW WORK – PIPING

M301 MECHANICAL SECTIONS

M302 MECHANICAL SECTIONS

M501 MECHANICAL DETAILS AND DIAGRAMS

M502 MECHANICAL DETAILS AND DIAGRAMS

M601 MECHANICAL SCHEDULES

M701 MECHANICAL CONTROL DIAGRAMS

M702 MECHANICAL CONTROL DIAGRAMS

M703 MECHANICAL AIRFLOW DIAGRAMS

M704 MECHANICAL FLOW DIAGRAMS

ELECTRICAL

E001 ELECTRICAL LEGEND, ABBREVIATIONS, AND SCHEDULE

ED101 ELECTRICAL DEMOLITION

ES101 ELECTRICAL NEW WORK

E301 ELECTRICAL MCC ELEVATIONS

E302 ELECTRICAL MCC ELEVATIONS

- - - END - - -

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 11-01-15

i

SECTION 01 00 00

GENERAL REQUIREMENTS

TABLE OF CONTENTS

1.1 SAFETY REQUIREMENTS

1.2 GENERAL INTENTION

1.3 STATEMENT OF BID ITEM(S)

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

1.5 CONSTRUCTION SECURITY REQUIREMENTS

1.6 OPERATIONS AND STORAGE AREAS

1.7 ALTERATIONS

1.8 DISPOSAL AND RETENTION

1.9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT,

UTILITIES, AND IMPROVEMENTS

1.10 RESTORATION

1.11 PHYSICAL DATA

1.12 PROFESSIONAL SURVEYING SERVICES

1.13 LAYOUT OF WORK

1.14 AS-BUILT DRAWINGS

1.15 USE OF ROADWAYS

1.16 COR'S FIELD OFFICE

1.17 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

1.18 TEMPORARY USE OF EXISTING ELEVATORS

1.19 TEMPORARY USE OF NEW ELEVATORS

1.20 TEMPORARY TOILETS

1.21 AVAILABILITY AND USE OF UTILITY SERVICES

1.22 NEW TELEPHONE EQUIPMENT

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 11-01-15

ii

1.23 TESTS

1.24 INSTRUCTIONS

1.25 GOVERNMENT-FURNISHED PROPERTY

1.26 RELOCATED EQUIPMENT ITEMS

1.27 STORAGE SPACE FOR DEPARTMENT OF VETERANS AFFAIRS EQUIPMENT

1.28 CONSTRUCTION SIGN

1.29 SAFETY SIGN

1.30 PHOTOGRAPHIC DOCUMENTATION

1.31 FINAL ELEVATION Digital Images

1.32 HISTORIC PRESERVATION

1.33 SUBMITTAL EXCHANGE

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 1

SECTION 01 00 00

GENERAL REQUIREMENTS

1.1 SAFETY REQUIREMENTS

Refer to section 01 35 26, SAFETY REQUIREMENTS for safety and infection control requirements.

1.2 GENERAL INTENTION

A. Contractor shall completely prepare site for building operations, including demolition and removal of existing structures, and furnish labor and materials and perform work for “REPLACE HVAC EQUIPMENT AT

B404” as required by drawings and specifications.

B. Visits to the site by Bidders may be made only by appointment with the

Medical Center Engineering Officer..

C. Offices of Penn Construction Group, as Architect-Engineers, will render certain technical services during construction. Such services shall be considered as advisory to the Government and shall not be construed as expressing or implying a contractual act of the Government without affirmations by Contracting Officer or his duly authorized representative.

D. All employees of general contractor and subcontractors shall comply with VA security management program and obtain permission of the VA police, be identified by project and employer, and restricted from unauthorized access.

1.3 STATEMENT OF BID ITEM(S)

A. ITEM I, Provide Architectural, Mechanical, Fire Protection, Plumbing, and Electrical design for replacing HVAC equipment in Building 404 attic and basement spaces. The HVAC equipment consists of six (6) air handling units, related exhaust and return fans, two heat exchangers, and the building automation system air compressor. The HVAC equipment was installed in 1987, and has reached the end of its useful life.

B. ALTERNATE NO.1: Deduct all work associated with the removal and replacement of the Controls Air Compressor.

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 2

C. ALTERNATE NO. 2: Deduct all work associated with the removal and replacement of AHU-8 and EF-6.

D. ALTERNATE NO. 3: Deduct all work associated with the removal and replacement of the heat exchangers.

E. ALTERNATE NO. 4: Deduct all work associated with the removal and replacement of AHU-4.

F. ALTERNATE NO. 5: Deduct all work associated with the removal and replacement of AHU-1 and AHU-3 and the replacement of exhaust fans EF-

1, EF-3-1 and EF-3-2.

G. ALTERNATE NO. 6: Deduct all work associated with the removal and replacement of AHU-2 and AHU-5; the replacement of exhaust fans EF-2-3, EF-5-1 and EF-5-2; and the new masonry opening in the west wall for new access doors.

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. Drawings and contract documents may be obtained from the website where the solicitation is posted. Additional copies will be at Contractor's expense.

1.5 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The General Contractor is responsible for assuring that all sub-contractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

1. General Contractor’s employees shall not enter the project site without appropriate badge. They may also be subject to inspection of their personal effects when entering or leaving the project site.

2. Before starting work the General Contractor shall give one week’s notice to the Contracting Officer so that security arrangements can

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 3 be provided for the employees. This notice is separate from any notices required for utility shutdown described later in this section.

3. No photography of VA premises is allowed without written permission of the Contracting Officer.

4. VA reserves the right to close down or shut down the project site and order General Contractor’s employees off the premises in the event of a national emergency. The General Contractor may return to the site only with the written approval of the Contracting Officer.

C. Key Control:

1. The General Contractor shall provide duplicate keys and lock combinations to the Contracting officers representative (COR)for the purpose of security inspections of every area of project including tool boxes and parked machines and take any emergency action.

2. The General Contractor shall turn over all permanent lock cylinders to the VA locksmith for permanent installation. See Section 08 71

00, DOOR HARDWARE and coordinate.

D. Document Control:

1. Before starting any work, the General Contractor/Sub Contractors shall submit an electronic security memorandum describing the approach to following goals and maintaining confidentiality of

“sensitive information”.

2. The General Contractor is responsible for safekeeping of all drawings, project manual and other project information. This information shall be shared only with those with a specific need to accomplish the project.

3. Certain documents, sketches, videos or photographs and drawings may be marked “Law Enforcement Sensitive” or “Sensitive Unclassified”.

Secure such information in separate containers and limit the access to only those who will need it for the project. Return the information to the Contracting Officer upon request.

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 4

4. These security documents shall not be removed or transmitted from the project site without the written approval of Contracting

Officer.

5. All paper waste or electronic media such as CD’s and diskettes shall be shredded and destroyed in a manner acceptable to the VA.

6. Notify Contracting Officer and Site Security Officer immediately when there is a loss or compromise of “sensitive information”.

7. All electronic information shall be stored in specified location following VA standards and procedures using an Engineering Document

Management Software (EDMS).

a. Security, access and maintenance of all project drawings, both scanned and electronic shall be performed and tracked through the

EDMS system.

b. “Sensitive information” including drawings and other documents may be attached to e-mail provided all VA encryption procedures are followed.

E. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitted 24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

2. A limited number of (2 to 5) permits shall be issued for General

Contractor and its employees for parking in designated areas only.

1.6 OPERATIONS AND STORAGE AREAS

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the Contracting Officer. The Contractor shall hold and save the

Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

B. Temporary buildings (e.g., storage sheds, shops, offices) and utilities may be erected by the Contractor only with the approval of the

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 5

Contracting Officer and shall be built with labor and materials furnished by the Contractor without expense to the Government. The temporary buildings and utilities shall remain the property of the

Contractor and shall be removed by the Contractor at its expense upon completion of the work. With the written consent of the Contracting

Officer, the buildings and utilities may be abandoned and need not be removed.

C. The Contractor shall, under regulations prescribed by the Contracting

Officer, use only established roadways, or use temporary roadways constructed by the Contractor when and as authorized by the Contracting

Officer. When materials are transported in prosecuting the work, vehicles shall not be loaded beyond the loading capacity recommended by the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the Contractor shall protect them from damage. The

Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

(FAR 52.236-10)

D. Working space and space available for storing materials shall be as shown on the drawings..

E. Workmen are subject to rules of Medical Center applicable to their conduct.

F. Execute work so as to interfere as little as possible with normal functioning of Medical Center as a whole, including operations of utility services, fire protection systems and any existing equipment, and with work being done by others. Use of equipment and tools that transmit vibrations and noises through the building structure, are not permitted in buildings that are occupied, during construction, jointly by patients or medical personnel, and Contractor's personnel, except as permitted by COR.

1. Do not store materials and equipment in other than assigned areas.

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 6

2. Schedule delivery of materials and equipment to immediate construction working areas within buildings in use by Department of

Veterans Affairs in quantities sufficient for not more than two work days. Provide unobstructed access to Medical Center areas required to remain in operation.

3. Where access by Medical Center personnel to vacated portions of buildings is not required, storage of Contractor's materials and equipment will be permitted subject to fire and safety requirements.

G. Phasing:

The Medical Center must maintain its operation 24 hours a day 7 days a week. Therefore, any interruption in service must be scheduled and coordinated with the COR to ensure that no lapses in operation occur.

It is the CONTRACTOR'S responsibility to develop a work plan and schedule detailing, at a minimum, the procedures to be employed, the equipment and materials to be used, the interim life safety measure to be used during the work, and a schedule defining the duration of the work with milestone subtasks. The work to be outlined shall include, but not be limited to:

To insure such executions, Contractor shall furnish the COR with a schedule of approximate phasing dates on which the Contractor intends to accomplish work in each specific area of site, building or portion thereof. In addition, Contractor shall notify the COR two weeks in advance of the proposed date of starting work in each specific area of site, building or portion thereof. Arrange such phasing dates to insure accomplishment of this work in successive phases mutually agreeable to

Medical Center Director, COR and Contractor, as follows:

See Drawings GC101 and GC102 for phasing plans and narrative.

H. Building No. 404 will be occupied during performance of work; but immediate areas of alterations will be vacated.

I. When a building and/or construction site is turned over to Contractor, Contractor shall accept entire responsibility including upkeep and maintenance therefore:

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 7

1. Contractor shall maintain a minimum temperature of 4 degrees C (40 degrees F) at all times, except as otherwise specified.

2. Contractor shall maintain in operating condition existing fire protection and alarm equipment. In connection with fire alarm equipment, Contractor shall make arrangements for pre-inspection of site with Fire Department or Company (Department of Veterans Affairs or municipal) whichever will be required to respond to an alarm from

Contractor's employee or watchman.

J. Utilities Services: Maintain existing utility services for Medical

Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services.

Where necessary to cut existing water, steam, gases, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR.

1. No utility service such as water, gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior approval of COR. Electrical work shall be accomplished with all affected circuits or equipment de-energized.

When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without a detailed work plan, the Medical Center Director’s prior knowledge and written approval. Refer to specification Section 26 05 11, REQUIREMENTS FOR ELECTRICAL INSTALLATIONS for additional requirements.

2. Contractor shall submit a request to interrupt any such services to

COR, in writing, 7 days n advance of proposed interruption. Request shall state reason, date, exact time of, and approximate duration of such interruption.

3. Contractor will be advised (in writing) of approval of request, or of which other date and/or time such interruption will cause least inconvenience to operations of Medical Center. Interruption time

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 8 approved by Medical Center may occur at other than Contractor's normal working hours.

4. Major interruptions of any system must be requested, in writing, at least 15 calendar days prior to the desired time and shall be performed as directed by the COR.

5. In case of a contract construction emergency, service will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

K. Abandoned Lines: All service lines such as wires, cables, conduits, ducts, pipes and the like, and their hangers or supports, which are to be abandoned but are not required to be entirely removed, shall be sealed, capped or plugged at the main, branch or panel they originate from. The lines shall not be capped in finished areas, but shall be removed and sealed, capped or plugged in ceilings, within furred spaces, in unfinished areas, or within walls or partitions; so that they are completely behind the finished surfaces.

L. To minimize interference of construction activities with flow of

Medical Center traffic, comply with the following:

1. Keep roads, walks and entrances to grounds, to parking and to occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles.

M. Coordinate the work for this contract with other construction operations as directed by COR. This includes the scheduling of traffic and the use of roadways, as specified in Article, USE OF ROADWAYS.

1.7 ALTERATIONS

A. Survey: Before any work is started, the Contractor shall make a thorough survey with the COR and a representative of VA Supply Service, of areas of buildings in which alterations occur and areas which are anticipated routes of access, and furnish a report, signed by all three, to the Contracting Officer. This report shall list by rooms and spaces:

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 9

1. Existing condition and types of resilient flooring, doors, windows, walls and other surfaces not required to be altered throughout affected areas of building.

2. Existence and conditions of items such as plumbing fixtures and accessories, electrical fixtures, equipment, venetian blinds, shades, etc., required by drawings to be either reused or relocated, or both.

3. Shall note any discrepancies between drawings and existing conditions at site.

4. Shall designate areas for working space, materials storage and routes of access to areas within buildings where alterations occur and which have been agreed upon by Contractor and COR.

B. Any items required by drawings to be either reused or relocated or both, found during this survey to be nonexistent, or in opinion of COR and/or Supply Representative, to be in such condition that their use is impossible or impractical, shall be furnished and/or replaced by

Contractor with new items in accordance with specifications which will be furnished by Government. Provided the contract work is changed by reason of this subparagraph B, the contract will be modified accordingly, under provisions of clause entitled "DIFFERING SITE

CONDITIONS" (FAR 52.236-2) and "CHANGES" (FAR 52.243-4 and VAAR

852.243-70).

C. Re-Survey: Thirty days before expected partial or final inspection date, the Contractor and COR together shall make a thorough re-survey of the areas of buildings involved. They shall furnish a report on conditions then existing, of resilient flooring, doors, windows, walls and other surfaces as compared with conditions of same as noted in first condition survey report:

1. Re-survey report shall also list any damage caused by Contractor to such flooring and other surfaces, despite protection measures; and, will form basis for determining extent of repair work required of

Contractor to restore damage caused by Contractor's workmen in executing work of this contract.

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 10

D. Protection: Provide the following protective measures:

1. Wherever existing roof surfaces are disturbed they shall be protected against water infiltration. In case of leaks, they shall be repaired immediately upon discovery.

2. Temporary protection against damage for portions of existing structures and grounds where work is to be done, materials handled and equipment moved and/or relocated.

3. Protection of interior of existing structures at all times, from damage, dust and weather inclemency. Wherever work is performed, floor surfaces that are to remain in place shall be adequately protected prior to starting work, and this protection shall be maintained intact until all work in the area is completed.

1.8 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work removed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

1. Reserved items which are to remain property of the Government are noted on drawings or in specifications as items to be stored. Items that remain property of the Government shall be removed or dislodged from present locations in such a manner as to prevent damage which would be detrimental to re-installation and reuse. Store such items where directed by COR.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from Medical Center.

3. Items of portable equipment and furnishings located in rooms and spaces in which work is to be done under this contract shall remain the property of the Government. When rooms and spaces are vacated by the Department of Veterans Affairs during the alteration period, such items which are NOT required by drawings and specifications to be either relocated or reused will be removed by the Government in advance of work to avoid interfering with Contractor's operation.

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 11

1.9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS

A. The Contractor shall preserve and protect all structures, equipment, and vegetation (such as trees, shrubs, and grass) on or adjacent to the work site, which are not to be removed and which do not unreasonably interfere with the work required under this contract. The Contractor shall only remove trees when specifically authorized to do so, and shall avoid damaging vegetation that will remain in place. If any limbs or branches of trees are broken during contract performance, or by the careless operation of equipment, or by workmen, the Contractor shall trim those limbs or branches with a clean cut and paint the cut with a tree-pruning compound as directed by the Contracting Officer.

B. The Contractor shall protect from damage all existing improvements and utilities at or near the work site and on adjacent property of a third party, the locations of which are made known to or should be known by the Contractor. The Contractor shall repair any damage to those facilities, including those that are the property of a third party, resulting from failure to comply with the requirements of this contract or failure to exercise reasonable care in performing the work. If the

Contractor fails or refuses to repair the damage promptly, the

Contracting Officer may have the necessary work performed and charge the cost to the Contractor.

(FAR 52.236-9)

C. Refer to Section 01 57 19, TEMPORARY ENVIRONMENTAL CONTROLS, for additional requirements on protecting vegetation, soils and the environment. Refer to Articles, "Alterations", "Restoration", and

"Operations and Storage Areas" for additional instructions concerning repair of damage to structures and site improvements.

1.10 RESTORATION

A. Remove, cut, alter, replace, patch and repair existing work as necessary to install new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, and do not disturb any ducts, plumbing, steam, gas, or electric work without approval of the

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 12

COR. Existing work to be altered or extended and that is found to be defective in any way, shall be reported to the COR before it is disturbed. Materials and workmanship used in restoring work, shall conform in type and quality to that of original existing construction, except as otherwise shown or specified.

B. Upon completion of contract, deliver work complete and undamaged.

Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, lawns, paving, roads, walks, etc.) disturbed or removed as a result of performing required new work, shall be patched, repaired, reinstalled, or replaced with new work, and refinished and left in as good condition as existed before commencing work.

C. At Contractor's own expense, Contractor shall immediately restore to service and repair any damage caused by Contractor's workmen to existing piping and conduits, wires, cables, etc., of utility services or of fire protection systems and communications systems (including telephone) which are not scheduled for discontinuance or abandonment.

D. Expense of repairs to such utilities and systems not shown on drawings or locations of which are unknown will be covered by adjustment to contract time and price in accordance with clause entitled "CHANGES"

(FAR 52.243-4 and VAAR 852.243-70) and "DIFFERING SITE CONDITIONS" (FAR

52.236-2).

1.11 PHYSICAL DATA – NOT USED

1.12 PROFESSIONAL SURVEYING SERVICES – NOT USED

1.13 LAYOUT OF WORK – NOT USED

1.14 AS-BUILT DRAWINGS

A. The contractor shall maintain two full size sets of as-built drawings which will be kept current during construction of the project, to include all contract changes, modifications and clarifications.

B. All variations shall be shown in the same general detail as used in the contract drawings. To insure compliance, as-built drawings shall be made available for the COR review, as often as requested.

C. Contractor shall deliver two approved completed sets of as-built drawings in the electronic version (scanned PDF) to the COR within 15

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 13 calendar days after each completed phase and after the acceptance of the project by the COR.

D. Paragraphs A, B, & C shall also apply to all shop drawings.

1.15 USE OF ROADWAYS

A. For hauling, use only established public roads and roads on Medical

Center property and, when authorized by the COR, such temporary roads which are necessary in the performance of contract work. Temporary roads shall be constructed and restoration performed by the Contractor at Contractor's expense. When necessary to cross curbing, sidewalks, or similar construction, they must be protected by well-constructed bridges.

1.16 COR'S FIELD OFFICE – NOT USED

1.17 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

A. Use of new installed mechanical and electrical equipment to provide heat, ventilation, plumbing, light and power will be permitted subject to written approval and compliance with the following provisions:

1. Permission to use each unit or system must be given by COR in writing. If the equipment is not installed and maintained in accordance with the written agreement and following provisions, the

COR will withdraw permission for use of the equipment.

2. Electrical installations used by the equipment shall be completed in accordance with the drawings and specifications to prevent damage to the equipment and the electrical systems, i.e. transformers, relays, circuit breakers, fuses, conductors, motor controllers and their overload elements shall be properly sized, coordinated and adjusted.

Installation of temporary electrical equipment or devices shall be in accordance with NFPA 70, National Electrical Code, (2014

Edition), Article 590, Temporary Installations. Voltage supplied to each item of equipment shall be verified to be correct and it shall be determined that motors are not overloaded. The electrical equipment shall be thoroughly cleaned before using it and again immediately before final inspection including vacuum cleaning and wiping clean interior and exterior surfaces.

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 14

3. Units shall be properly lubricated, balanced, and aligned.

Vibrations must be eliminated.

4. Automatic temperature control systems for preheat coils shall function properly and all safety controls shall function to prevent coil freeze-up damage.

5. The air filtering system utilized shall be that which is designed for the system when complete, and all filter elements shall be replaced at completion of construction and prior to testing and balancing of system.

6. All components of heat production and distribution system, metering equipment, condensate returns, and other auxiliary facilities used in temporary service shall be cleaned prior to use; maintained to prevent corrosion internally and externally during use; and cleaned, maintained and inspected prior to acceptance by the Government.

B. Prior to final inspection, the equipment or parts used which show wear and tear beyond normal, shall be replaced with identical replacements, at no additional cost to the Government.

C. This paragraph shall not reduce the requirements of the mechanical and electrical specifications sections.

D. Any damage to the equipment or excessive wear due to prolonged use will be repaired replaced by the contractor at the contractor’s expense.

1.18 TEMPORARY USE OF EXISTING ELEVATORS

A. Temporary use of the existing elevator is not allowed - no exceptions.

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 15

1.19 TEMPORARY USE OF NEW ELEVATORS – NOT USED

1.20 TEMPORARY TOILETS – NOT USED

1.21 AVAILABILITY AND USE OF UTILITY SERVICES

A. The Government shall make all reasonably required amounts of utilities available to the Contractor from existing outlets and supplies, as specified in the contract. The amount to be paid by the Contractor for chargeable electrical services shall be the prevailing rates charged to the Government. The Contractor shall carefully conserve any utilities furnished without charge.

B. The Contractor, at Contractor's expense and in a workmanlike manner, in compliance with code and as satisfactory to the Contracting Officer, shall install and maintain all necessary temporary connections and distribution lines, and all meters required to measure the amount of electricity used for the purpose of determining charges. Before final acceptance of the work by the Government, the Contractor shall remove all the temporary connections, distribution lines, meters, and associated paraphernalia and repair restore the infrastructure as required.

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 16

1.22 NEW TELEPHONE EQUIPMENT – NOT USED

1.23 TESTS

A. The government will provide and utilize a 3rd party independent commissioning agent. Contractor shall fill out the necessary start-up form and shall participate in commissioning meetings and testing/verification.

B. Pre-test mechanical and electrical equipment and systems and make corrections required for proper operation of such systems before requesting final tests. Final test will not be conducted unless pre-tested.

C. Conduct final tests required in various sections of specifications in presence of an authorized representative of the Contracting Officer.

Contractor shall furnish all labor, materials, equipment, instruments, and forms, to conduct and record such tests.

D. Mechanical and electrical systems shall be balanced, controlled and coordinated. A system is defined as the entire system which must be coordinated to work together during normal operation to produce results for which the system is designed. For example, air conditioning supply air is only one part of entire system which provides comfort conditions for a building. Other related components are return air, exhaust air, steam, chilled water, refrigerant, hot water, controls and electricity, etc. Another example of a system which involves several components of different disciplines is a boiler installation. Efficient and acceptable boiler operation depends upon the coordination and proper operation of fuel, combustion air, controls, steam, feedwater, condensate and other related components.

E. All related components as defined above shall be functioning when any system component is tested. Tests shall be completed within a reasonably period of time during which operating and environmental conditions remain reasonably constant and are typical of the design conditions.

F. Individual test result of any component, where required, will only be accepted when submitted with the test results of related components and of the entire system.

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 17

1.24 INSTRUCTIONS

A. Contractor shall furnish Maintenance and Operating manuals (hard copies and electronic) and verbal instructions when required by the various sections of the specifications and as hereinafter specified.

B. Manuals: Maintenance and operating manuals and one compact disc (four hard copies and one electronic copy each) for each separate piece of equipment shall be delivered to the COR coincidental with the delivery of the equipment to the job site. Manuals shall be complete, detailed guides for the maintenance and operation of equipment. They shall include complete information necessary for starting, adjusting, maintaining in continuous operation for long periods of time and dismantling and reassembling of the complete units and sub-assembly components. Manuals shall include an index covering all component parts clearly cross-referenced to diagrams and illustrations. Illustrations shall include "exploded" views showing and identifying each separate item. Emphasis shall be placed on the use of special tools and instruments. The function of each piece of equipment, component, accessory and control shall be clearly and thoroughly explained. All necessary precautions for the operation of the equipment and the reason for each precaution shall be clearly set forth. Manuals must reference the exact model, style and size of the piece of equipment and system being furnished. Manuals referencing equipment similar to but of a different model, style, and size than that furnished will not be accepted.

C. Instructions: Contractor shall provide qualified, factory-trained manufacturers' representatives to give detailed training to assigned

Department of Veterans Affairs personnel in the operation and complete maintenance for each piece of equipment. All such training will be at the job site. These requirements are more specifically detailed in the various technical sections. Instructions for different items of equipment that are component parts of a complete system, shall be given in an integrated, progressive manner. All instructors for every piece of component equipment in a system shall be available until instructions for all items included in the system have been completed.

This is to assure proper instruction in the operation of inter-related

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 18 systems. All instruction periods shall be at such times as scheduled by the COR and shall be considered concluded only when the COR is satisfied in regard to complete and thorough coverage. The contractor shall submit a course outline with associated material to the COR for review and approval prior to scheduling training to ensure the subject matter covers the expectations of the VA and the contractual requirements. The Department of Veterans Affairs reserves the right to request the removal of, and substitution for, any instructor who, in the opinion of the COR , does not demonstrate sufficient qualifications in accordance with requirements for instructors above.

1.25 GOVERNMENT-FURNISHED PROPERTY – NOT USED

1.26 RELOCATED EQUIPMENT ITEMS - NOT USED

1.27 STORAGE SPACE FOR DEPARTMENT OF VETERANS AFFAIRS EQUIPMENT – NOT USED

1.28 CONSTRUCTION SIGN

A. Provide a Construction Sign attached to the chain link construction fence. Sign shall be 36” x 36” minimum. All wood members shall be of framing lumber. Cover sign frame with 0.7 mm (24 gage) galvanized sheet steel nailed securely around edges and on all bearings.

B. Paint all surfaces of sign with two coats of white gloss paint. Border and letters shall be of black gloss paint, except project title which shall be blue gloss paint. Sign shall include contractor’s name and phone number.

C. Maintain sign and remove it when directed by the COR.

1.29 SAFETY SIGN – NOT USED

1.30 PHOTOGRAPHIC DOCUMENTATION

A. During the construction period through completion, provide photographic documentation of construction progress and at selected milestones including electronic indexing, navigation, storage and remote access to the documentation, as per these specifications.

B. Photographic documentation elements:

1. Each digital image shall be taken with a professional grade camera with minimum size of 6 megapixels (MP) capable of producing

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 19

200x250mm (8 x 10 inch) prints with a minimum of 2272 x 1704 pixels and 400x500mm (16 x 20 inch) prints with a minimum 2592 x 1944 pixels.

2. Indexing and navigation system shall utilize actual AUTOCAD construction drawings, making such drawings interactive on an on-line interface. For all documentation referenced herein, indexing and navigation must be organized by both time (date-stamped) and location throughout the project.

3. Documentation shall combine indexing and navigation system with inspection-grade digital photography designed to capture actual conditions throughout construction and at critical milestones.

Documentation shall be accessible on-line through use of an internet connection. Documentation shall allow for secure multiple-user access, simultaneously, on-line.

4. Construction progress for all trades shall be tracked at pre-determined intervals, but not less than once every thirty (30) calendar days (“Progressions”). Progression documentation shall track both the exterior and interior construction of the building.

Exterior Progressions shall track 360 degrees around the site and each building. Interior Progressions shall track interior improvements beginning when stud work commences and continuing until

Project completion.

5. As-built conditions of mechanical, electrical, plumbing and all other systems shall be documented post-inspection and pre-insulation, sheet rock or dry wall installation. This process shall include all finished systems located in the walls and ceilings of all buildings at the Project. Overlapping photographic techniques shall be used to insure maximum coverage. Indexing and navigation accomplished through interactive architectural drawings.

6. Miscellaneous events that occur during any Contractor site visit, or events captured by the Department of Veterans Affairs independently, shall be dated, labeled and inserted into a Section in the navigation structure entitled “Slideshows,” allowing this information to be stored in the same “place” as the formal scope.

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 10-01-17

01 00 00 - 20

7. Customizable project-specific digital photographic documentation of other details or milestones. Indexing and navigation accomplished through interactive architectural plans.

8. In event a greater or lesser number of images than specified above are required by the COR, adjustment in contract price will be made in accordance with clause entitled "CHANGES" (FAR 52.243-4 and VAAR

852.243-70).

C. Coordination of photo shoots is accomplished through COR. Contractor shall also attend construction team meetings as necessary. Contractor’s operations team shall provide regular updates regarding the status of the documentation, including photo shoots concluded, the availability of new Progressions or Exact-Builts viewable on-line and anticipated future shoot dates.

D. Contractor shall provide all on-line domain/web hosting, security measures, and redundant server back-up of the documentation.

E. Contractor shall provide technical support related to using the system or service.

F. Upon completion of the project, final copies of the documentation (the

“Permanent Record”) with the indexing and navigation system embedded

(and active) shall be provided in an electronic media format, typically a DVD or external hard-drive. Permanent Record shall have Building

Information Modeling (BIM) interface capabilities. On-line access terminates upon delivery of the Permanent Record.

1.31 FINAL ELEVATION DIGITAL IMAGES – NOT USED

1.32 HISTORIC PRESERVATION – NOT USED

1.33 SUBMITTAL EXCHANGE

A. The VA will provide access to an electronic submittal exchange.

- - - E N D - - -

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 02-01-15

01 32 16.15 - 1

SECTION 01 32 16.15

PROJECT SCHEDULES

(SMALL PROJECTS – DESIGN/BID/BUILD)

PART 1- GENERAL

1.1 DESCRIPTION:

A. The Contractor shall develop a Critical Path Method (CPM) plan and schedule demonstrating fulfillment of the contract requirements

(Project Schedule), and shall keep the Project Schedule up-to-date in accordance with the requirements of this section and shall utilize the plan for scheduling, coordinating and monitoring work under this contract (including all activities of subcontractors, equipment vendors and suppliers). Conventional Critical Path Method (CPM) technique shall be utilized to satisfy both time and cost applications.

1.2 CONTRACTOR'S REPRESENTATIVE:

A. The Contractor shall designate an authorized representative responsible for the Project Schedule including preparation, review and progress reporting with and to the Contracting Officer's Representative (COR).

B. The Contractor's representative shall have direct project control and complete authority to act on behalf of the Contractor in fulfilling the requirements of this specification section.

C. The Contractor’s representative shall have the option of developing the project schedule within their organization or to engage the services of an outside consultant. If an outside scheduling consultant is utilized, Section 1.3 of this specification will apply.

1.3 CONTRACTOR'S CONSULTANT:

A. The Contractor shall submit a qualification proposal to the COR, within

10 days of bid acceptance. The qualification proposal shall include:

1. The name and address of the proposed consultant.

2. Information to show that the proposed consultant has the qualifications to meet the requirements specified in the preceding paragraph.

3. A representative sample of prior construction projects, which the proposed consultant has performed complete project scheduling services. These representative samples shall be of similar size and scope.

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 02-01-15

01 32 16.15 - 2

B. The Contracting Officer has the right to approve or disapprove the proposed consultant, and will notify the Contractor of the VA decision within seven calendar days from receipt of the qualification proposal.

In case of disapproval, the Contractor shall resubmit another consultant within 10 calendar days for renewed consideration. The

Contractor shall have their scheduling consultant approved prior to submitting any schedule for approval.

1.4 COMPUTER PRODUCED SCHEDULES

A. The contractor shall provide monthly, to the Department of Veterans

Affairs (VA), all computer-produced time/cost schedules and reports generated from monthly project updates. This monthly computer service will include: three copies of up to five different reports (inclusive of all pages) available within the user defined reports of the scheduling software approved by the Contracting Officer; a hard copy listing of all project schedule changes, and associated data, made at the update and an electronic file of this data; and the resulting monthly updated schedule in PDM format. These must be submitted with and substantively support the contractor’s monthly payment request and the signed look ahead report. The COR shall identify the five different report formats that the contractor shall provide.

B. The contractor shall be responsible for the correctness and timeliness of the computer-produced reports. The Contractor shall also responsible for the accurate and timely submittal of the updated project schedule and all CPM data necessary to produce the computer reports and payment request that is specified.

C. The VA will report errors in computer-produced reports to the

Contractor’s representative within ten calendar days from receipt of reports. The Contractor shall reprocess the computer-produced reports and associated diskette(s), when requested by the Contracting Officer’s representative, to correct errors which affect the payment and schedule for the project.

1.5 THE COMPLETE PROJECT SCHEDULE SUBMITTAL

A. Within 45 calendar days after receipt of Notice to Proceed, the

Contractor shall submit for the Contracting Officer's review; three blue line copies of the interim schedule on sheets of paper 765 x 1070 mm (30 x 42 inches) and an electronic file in the previously approved

CPM schedule program. The submittal shall also include three copies of

REPLACE HVAC EQUIPMENT AT B404

VA PROJECT: 676-16-102 02-01-15

01 32 16.15 - 3 a computer-produced activity/event ID schedule showing project…