R17PS00304_Amend_0003.pdf

(x)

R17PS00304

x x copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT

THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

Billings MT 59107

R60

PO Box 36900 Regional Office Great Plains Region Bureau of Reclamation

04/25/2017000003

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

03/31/2017

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not, is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Project: Kirwin Spillway Gates Guide Replacement and Painting

See Page 2 of 2 for changes incorporated by this Amendment

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Gerri Voto-Braun

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

NSN 7540-01-152-8070

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

Amendment No. 0003 Solicitation No. R17PS00304

Description of Changes:

1. The period of performance has changed from 300 calendar days to 180 calendar days.

Therefore, in Section F – Remove Section F in its entirety and insert the attached revised Section F.

Receipt of Proposals: The hour and date for receipt of proposals remains unchanged at May 11, 2017 at 3:00 p.m. Mountain Time.

Questions and Answers: The deadline to submit questions is 3 p.m. on April 26, 2017.

The following contractors were in attendance at the organized site visit, which took place on April 19, 2017:

Leon Pfannenstiel Leon’s Welding 785-625-5736 Brennan Pfannenstiel Leon’s Welding 785-625-5736 Blake Hine Gerace Construction 989-496-2440 Terry Bigger Site Master 918-633-7596 Jim Hopkins Site Master 918-269-5094 Sean Casey Coatings Unlimited 314-914-3445 Gerry Granahan Gracon LLC 970-667-2203 Raymond Harrigton McCormick Painting 501-374-5599 Jerry Barr McCormick Painting 501-374-5599 Dale Horner JR Merit 360-693-7474 Randy Miller Hartman Walsh Painting Company 812-243-5615 Clint Curtiss Inland Potable Services, Inc 303-400-4220 Tommy Morrison PSC 479-264-6867 Rick Mollenhoff Alltech Engineering Corp 651-452-7893

Kirwin Dam Spillway Gates Solicitation R17PS00304 Guide Replacement and Maintenance Painting Specifications No. 60-C0640

F - 1

SECTION F -- DELIVERIES OR PERFORMANCE

F.1 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION

OF WORK

APR 1984

The Contractor shall be required to:

(a) Commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed,

(b) Prosecute the work diligently, and

(c) Complete the entire work ready for use not later than 180 calendar days after the date the Contractor receives the notice to proceed. The time stated for completion shall include final cleanup of the premises.

F.2 52.211-18 VARIATION IN ESTIMATED QUANTITY APR 1984

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

F.3 52.242-14 SUSPENSION OF WORK APR 1984

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer's failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed -

Revised

Kirwin Dam Spillway Gates Solicitation R17PS00304 Guide Replacement and Maintenance Painting Specifications No. 60-C0640

F - 2

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

Revised