Tab_13_Amendment_2_Attachment_4_REVISED_Section_F_R16PS01019_T C's.pdf

Solicitation No. R16PS01019 Cutter Lateral Reach 22B Page 12

SECTION F – DELIVERIES OR PERFORMANCE

F.1 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF

WORK

APR 1984

The Contractor shall be required to

(a) commence work under this contract within 10 calendar days after the date the Contractor receives: the notice to proceed,

1) Notice to Proceed for non-site work under this contract,

2) Notice to Proceed for site work for Station 22249+52.72 to Station 22634+26.55, and Station 22774+58.31 to Station 23093+38.55, is anticipated to be issued no later than December 1, 2016, and

3) Notice to Proceed for site work for Station 22634+26.55 to Station 22774+58.31 is anticipated to be issued no later than March 1, 2017.

(b) prosecute the work diligently, and

(c) complete the entire work ready for use not later than 667 calendar days after the contractor receives the initial non-site work Notice to Proceed notice to proceedissued in accordance with (a)(1) above. The time stated for completion shall include final cleanup of the premises.

F.2 52.211-12 LIQUIDATED DAMAGES – CONSTRUCTION SEPT 2000

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $6,017.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

F.3 52.211-18 VARIATION IN ESTIMATED QUANTITY APR 1984

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

F.4 52.242-14 SUSPENSION OF WORK APR 1984

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

Formatted: Font: Not Bold

Solicitation No. R16PS01019 Cutter Lateral Reach 22B Page 13

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted

(1) by an act of the Contracting Officer in the administration of this contract, or

(2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed --

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.