Tab_13_Amendment_2_Attachment_1_REVISED_00_00_01_-_Specifications.pdf

Navajo Gallup Water Supply Project Cutter Lateral - Reach 22B Solicitation No.

Table of Contents

00 01 10 - 1

SECTION C - DESCRIPTION / SPECIFICATIONS

TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 Summary of Work 01 14 10 Use of Site 01 31 19 Project Management and Coordination 01 31 30 Contract Document Management System 01 32 10 Construction Program 01 33 00 Submittals 01 33 26 Electrical Drawings and Data 01 35 10 Safety Data Sheets 01 35 20 Safety and Health 01 35 22 First Aid 01 35 30 Contractor’s Onsite Safety Personnel 01 42 10 Reference Standards 01 46 00 Quality Procedures 01 46 20 Testing Agency Services 01 51 00 Temporary Utilities 01 55 00 Vehicular Access and Parking 01 55 20 Traffic Control 01 56 10 Protection of Existing Installations 01 56 15 Protection of Existing Utilities 01 56 20 Existing Fences 01 56 32 Temporary Safety Fence 01 57 20 Environmental Controls 01 57 30 Water Pollution Control 01 57 50 Tree and Plant Protection 01 57 60 Protected Species 01 57 90 Preservation of Historical and Archeological Data 01 60 00 Product Requirements 01 71 20 Surveying 01 74 00 Cleaning and Waste Management 01 78 30 Project Record Documents

DIVISION 03 - CONCRETE

03 11 10 Concrete Forming 03 20 00 Concrete Reinforcing 03 30 00 Cast-In-Place Concrete 03 48 00 Precast Concrete Structures 03 63 00 Epoxy Grout

00 01 10 - 2

DIVISION 04 - MASONRY

04 22 10 Reinforced Concrete Unit Masonry Assemblies

DIVISION 05 - METALS

05 21 00 Steel Joists 05 30 00 Metal Roof Deck 05 50 00 Metal Fabrications

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 41 13 Preinsulated Metal Roof Panels 07 42 13 Preinsulated Metal Wall Panels 07 72 30 Roof Hatches

DIVISION 08 - OPENINGS

08 34 53 Security Doors and Frames 08 71 00 Door Hardware

DIVISION 09 - FINISHES

09 65 10 Rubber Wall Base 09 96 20 Coatings

DIVISION 10 - SPECIALTIES

10 14 26 Utility Markers

DIVISION 22 - PLUMBING

22 11 35 Pre-manufactured Pump Station 22 13 16 Foundation and Building Drainage Piping

DIVISION 23 - HEATING, VENTILATING, AND AIR-CONDITIONING (HVAC)

23 05 93 Testing, Adjusting, and Balancing for HVAC Equipment 23 33 10 Duct Accessories 23 34 00 HVAC Fans 23 82 39 Unit Heaters

00 01 10 - 3

DIVISION 25 - INTEGRATED AUTOMATION

25 00 01 Control and Monitoring 25 00 02 Programmable Controller 25 08 10 Automation System Testing, Acceptance, and Training

DIVISION 26 - ELECTRICAL

26 05 02 Basic Electrical Materials and Methods 26 05 10 Conductors and Cables 26 05 13 Medium-Voltage Power Cable System 26 05 20 Grounding and Bonding 26 05 33 Raceways and Boxes 26 05 90 Wiring Checkout and Tests 26 13 26 Metal-Clad Switchgear 26 16 13 Primary Unit Substation 26 22 12 Dry-Type Transformers 26 24 41 Distribution Panelboards 26 27 40 Wiring Devices 26 42 10 Buried Galvanic Anode Cathodic Protection and Corrosion Monitoring Systems 26 42 11 Submerged Galvanic Anode Cathodic Protection System for Welded Tanks 26 42 12 Bolted Tank Submerged Galvanic Anode Cathodic Protection System 26 51 00 Interior Lighting 26 52 00 Emergency and Exit Lighting 26 56 00 Exterior Lighting

DIVISION 27 - COMMUNICATIONS

27 15 00 Communications Cabling 27 20 01 Radio Equipment 27 30 01 Telephone Equipment

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 10 01 Security and Surveillance Equipment 28 31 00 Fire Detection and Alarm

DIVISION 31 - EARTHWORK

31 02 10 Water for Dust Abatement 31 02 30 Dust Palliative 31 11 00 Clearing and Grubbing 31 14 10 Stripping 31 23 02 Compacting Earth Materials 31 23 10 Earthwork

00 01 10 - 4

31 23 22 Pipe Trench Earthwork 31 23 39 Disposal of Excavated Materials 31 23 70 Controlled Low Strength Materials (CLSM) 31 31 30 Soil-Applied Herbicide 31 37 00 Riprap

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 15 10 Gravel Surfacing 32 31 10 Chain Link Fence 32 91 60 Erosion Control Blanket 32 92 20 Seeding

DIVISION 33 - UTILITIES

33 05 21 Bored Utility Crossings 33 09 08 Probe Magnetic Flowmeter 33 11 10 Pipeline General Requirements 33 11 12 Steel Line Pipe 33 11 13 Ductile Iron Pipe 33 11 13 Ductile Iron Pipe 33 11 16 PVC Pressure Pipe 33 11 18 HDPE Pressure Pipe 33 11 19 Fiberglass Pipe 33 11 50 Pipe Crossings at Existing Utility Pipelines 33 12 05 NAPI Turnout 33 12 10 Valves and Equipment for Line Pipe Installations 33 16 14 Air Chambers 33 16 50 Steel Tanks 33 21 95 Metal Piping for Line Pipe Installations 33 42 30 Corrugated Metal Pipe Culvert

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

35 21 95 Steel Pipe 35 22 15 Valves and Equipment 35 42 35 Bank Protection

DIVISION 48 - ELECTRICAL POWER GENERATION

48 14 00 Solar And Electrical Equipment

DIVISION 52 - DRAWINGS

52 00 00 Drawings

00 01 10 - 5

DIVISION 53 - GEOLOGIC INVESTIGATIONS AND RECORDS

53 10 00 Geology 53 20 00 Records of Geologic and Subsurface Investigations

END OF CONTENTS

00 01 10 - 6

This page intentionally left blank.

Submittals

01 33 00 - 1

SECTION 01 33 00

SUBMITTALS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in the Price Schedule for other items of work.

1.02 REFERENCE STANDARDS

A. American Society of Mechanical Engineers (ASME)

1. ASME Y14.1-12 Decimal-inch Drawing Sheet Size and Format

B. National Institute of Building Sciences (NIBS)

1. NIBS NCS-14 United States National CAD Standards, Version 6

1.03 DEFINITIONS

A. Days: Calendar days.

B. Required Submittal Number (RSN): Identifies items to be submitted together as a complete submittal.

C. Submittal Types, as listed in Table 01 33 00A - List of Submittals:

1. A - Action:

a. Government will respond as to adequacy of submittal.

b. Action Submittals: Considered “shop drawings” within the terms of the clause at FAR 52.236-21, Specifications and Drawings for Construction.

2. I - Informational:

a. Government will acknowledge receipt of Informational submittals.

b. Government may reject an Informational submittal when the submittal does not satisfy contract requirements. Correct mistakes or deficiencies in rejected Informational submittals and resubmit.

c. Informational Submittals: Considered “shop drawings” within terms of the clause at FAR 52.236-21, Specifications and Drawings for Construction, except that approval by Government is not required.

01 33 00 - 2

1.04 SUBMITTAL REQUIREMENTS

A. In case of conflict between requirements of this section and requirements included elsewhere in these specifications, requirements included elsewhere take precedence.

B. General:

1. Prepare in English.

2. Label with contract number and title, and RSN.

3. Measurement Units: US Customary Units.

4. Electronic Documents:

a. Searchable .pdf.

b. Includes submittals which are not drawings or photographs.

C. Drawings:

1. Minimum Identification in Title Block:

a. Contract number and title.

b. Contractor’s or supplier’s title and drawing number.

c. Date.

2. Reserve 3 by 3 inch space next to title block for review stamps.

3. Size: D size (22 inches by 34 inches) as defined by ASME Y14.1.

4. Draw to scale using computer drafting or drafting equipment, unless otherwise specified.

a. Computer drafted drawings:

1) In accordance with NIBS NCS.

2) Electronic file format: Compatible with AUTOCAD, Version 2015 or later.

3) Compile using “eTransmit” utility in AUTOCAD.

b. Drawing prepared with drafting equipment, when allowed: Lettering shall be neat.

5. Drawings Designated as “Government Format” in Specifications:

a. Computer drafted.

b. Government will provide an electronic AutoCAD format template.

c. Title block and sheet format:

1) As shown on standard drawing 40-D-7102.

2) Government will provide template.

01 33 00 - 3

3) Government will provide specific title block information to be used.

6. Final Drawings:

a. Computer drafted.

b. Government will provide an electronic AutoCAD format template.

c. Show as-built changes, including revision dates, made during installation.

Indicate changes by clouding.

7. Electronic Files:

a. On CD or DVD discs.

D. Product Data:

1. Mark manufacturer's data for commercial products or equipment, such as catalog cut sheets.

a. Identify manufacturer's name, type, model, size, and characteristics.

b. Illustrate that product or equipment meets requirements of specifications.

c. Mark items to be furnished in a manner that will photocopy (no highlighter).

d. Strike through items that do not apply.

E. Certifications:

1. Certifications by a Registered Professional: Signed and sealed by registered professional.

2. Manufacturer’s Certifications: Signed by authorized representative of manufacturer.

F. Manuals:

1. Copies:

a. Printed copies: Bound and indexed.

b. Electronic copies: Searchable Adobe pdf on CD or DVD discs.

1) Bookmark longer files to assist in navigating file.

2) Electronic files may be submitted as separate parts of a manual.

After each separate electronic file is approved, compile each approved electronic file to assemble an entire manual which shall be consistent with a single final manual submittal.

2. Contents:

a. Parts identification lists, lists of special tools, and accessories.

b. Schematics and wiring diagrams.

01 33 00 - 4

c. Detailed instructions for installing, operating, lubricating, and maintaining equipment.

d. As-built drawings, photographs, and test records or reports if required by the specifications.

G. Photographs:

1. Include negatives or digital files on CD or DVD in .jpeg or similar format.

H. Samples and Color Selection Submittals:

1. Label with complete manufacturer's product and color identification.

2. Include type and quantity of materials specified in the referenced section in each “set” of samples.

3. Samples: Representative of product to be installed. Xerographic sheets for color selection are not acceptable.

4. Color Chips: Sample paint chips. Ink color reproductions are not acceptable.

5. Label each sample, sample kit, set of color chips, or color chart with contract number and title.

6. Government will select architectural color and pattern after product approval.

1.05 SUBMITTALS PROCEDURES

A. Submit only checked submittals. Submittals without evidence of Contractor's approval will be returned for resubmission.

B. Submit complete sets of required materials for each RSN as specified in “Submittals Required” column in Table 01 33 00A - List of Submittals. A complete set includes listed items for RSNs with multiple parts.

C. Submit sets specified in “Sets to be sent:” columns in Table 01 33 00A - List of Submittals.

1. Submittals identified with “CDMS” in the “Sets to be sent” column shall be submitted electronically in accordance with Section 01 31 30 - Contract Document Management System.

D. Include the following information in transmittal letters:

1. Contract number and title.

2. RSN for each attached submittal.

3. Responsible code.

4. Number of sets for each RSN.

5. Identify submittal as initial or resubmittal.

01 33 00 - 5

E. Resubmittal of submittals not approved:

1. Mark changes such that they are readily identifiable and show revision date.

2. Describe reasons for significant changes in transmittal letter.

3. Resubmit returned submittals within 28 days after receiving the comments, unless otherwise directed.

4. Requirements for initial submittals apply to resubmittals.

1.06 REVIEW OF SUBMITTALS

A. Time Required:

1. Submittal review will require 21 days for review of each submittal or resubmittal, unless otherwise specified.

2. Time required for review of each submittal or resubmittal begins when complete sets of materials required for a particular RSN are received and extends through return mailing postmark date.

B. Time in Excess of Specified:

1. CO may extend contract completion date to allow additional time for completing work affected by excess review time.

a. Time extension will be to extent that excess review time caused delay to contract completion date.

b. Time extension will not exceed time used in excess of specified number of days for review of submittals or resubmittals.

c. Concurrent days of excess review time resulting from review of 2 or more separate submittals or resubmittals will be counted only once in extending contract completion date.

2. No time extension will be allowed if Contractor fails to make complete action submittals in sequence and within time periods specified.

3. Adjustment for delay will be made only to the extent that:

a. Approval was required under the contract, and.

b. Requests for approval were properly and timely submitted and were approved.

4. Adjustment will be subject to terms of paragraphs (b) and (c) of clause at FAR 52.242-14, Suspension of Work; however, no such delay shall be deemed to be a “suspension order” as term is used in that clause.

C. Return of Submittals:

1. Return of submittals will be by CDMS response or hard copy, as applicable.

2. Action Submittals: 1 set of submittals required for action will be returned either approved, approved with comments or not approved.

01 33 00 - 6

a. Revise and resubmit submittals not approved.

b. Do not change designs without approval of CO after drawings, documentation, and technical data have been approved.

3. Informational Submittals: Government will acknowledge Informational submittals.

a. Informational submittals will not be returned when they satisfy contract requirements.

b. Informational submittals that do not satisfy contract requirements may be returned for resubmittal or additional information may be requested.

1.07 HARD COPY TRANSMITTALS

A. Addresses for codes listed in Table 01 33 00A - List of Submittals:

1. Contracting Officer, Bureau of Reclamation, Attn UC-840, 125 South State St, Room 6107, Salt Lake City, UT 84138-1147.

2. Construction Engineer, Bureau of Reclamation, 1235 La Plata Hwy, Farmington, New Mexico, 87401.

3. Technical Service Center, Bureau of Reclamation, Attn: 86-68510, P.O. Box 25007, Denver CO 80225-0007; Express Mail: Sixth and Kipling, Building 67, Room 152.

B. Send original transmittal letter with appropriate number of sets to office listed in “Responsible Code” column in Table 01 33 00A - List of Submittals.

1. Responsible codes starting with “86-6” are located in Technical Service Center.

Send these submittals to the TSC address shown above.

C. Send copy of transmittal letter with appropriate number of sets to offices that are not responsible code, but show “Sets to be sent” in Table 01 33 00A - List of Submittals.

D. When “Sets to be sent” is 0, send a copy of transmittal letter to that office.

E. Submittals required by specifications, but not listed in Table 01 33 00A - List of Submittals:

1. Submit in accordance with this section.

2. Submit to CE unless otherwise specified.

PART 2 PRODUCTS

Not Used

01 33 00 - 7

PART 3 EXECUTION

Not Used

01 33 00 - 8

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

01 14 10-1 Use of Site Land Use and Landscape Rehabilitation Plan

At least 28 days before use of Government land

A CE CDMS

01 31 19-1 Project Management and Coordination

Written Summary Monthly once on-site construction begins

A CE CDMS

01 31 19-2 Project Management and Coordination

Off Easement Land Use Coordination

At least 4 months prior to use of land

A CE CDMS

01 31 30-1 Contract Document Management System

Approval Data Within 7 days of Award A CE 0 1 0

01 31 30-2 Contract Document Management System

Final Data Within 14 days of completion of work

I CE 0 2 2

01 32 10-1 Construction Program

Representative Information

Within 7 days after receipt of Notice of Award

I CE CDMS

01 32 10-2 Construction Program

Baseline Schedule Within 21 days after receipt of Notice to Proceed

A CE 0 5 3

01 32 10-3 Construction Program

Updated Schedule Reports

With monthly requests for progress payments.

A CE CDMS

01 32 10-4 Construction Program

Time Impact Analysis

Within 28 days after CO directs a contract change, with any proposal for a future modification, with any value engineering proposal, or with any request or claim for an equitable adjustment to the contract

A CE CDMS

01 35 10-1 Safety Data Sheets

Complete LHM and

SDS

At least 14 days before jobsite delivery of hazardous material

I CE CDMS

01 35 10-2 Safety Data Sheets

Updated LHM and

SDS

At least 14 days before jobsite delivery of hazardous material not previously listed

I CE CDMS

01 33 00 - 9

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

01 35 20-1 Safety and Health

Emergency Action Plans Written Program and Training Records

At least 21 days before beginning onsite work

A CE CDMS

01 35 20-2 Safety and Health

Job Hazard Analyses

(JHA)

At least 28 days before beginning onsite work

A CE CDMS

01 35 20-3 Safety and Health

Exposer Assessment Form

At least 28 days before beginning onsite work

A CE CDMS

01 35 20-4 Safety and Health

Monthly Accident Summary Report

First day of each month. See paragraph

3.8 of RSHS.

A CE CDMS

01 35 20-5 Safety and Health

Respirator User Documentation

At least 30 days before beginning onsite work

A CE CDMS

01 35 20-6 Safety and Health

Crane Training Certificates

At least 28 days before beginning onsite work

A CE CDMS

01 35 20-7 Safety and Health

Other Training Certificates, as applicable

At least 28 days before beginning onsite work

A CE CDMS

01 35 22-1 First-Aid Medical Facilities Plan

Submitted and approved before start of operations

A CO CDMS

01 35 30-1 Contractor‘s Onsite Safety Personnel

Resume At least 14 days before beginning on-site construction

I CE CDMS

01 35 30-2 Contractor’s Onsite Safety Personnel

Safety Inspection Reports

Once each week I CE CDMS

01 46 20-1 Testing Agency Services

Testing Agency Services Plan

At least 28 days before testing is required

A CE CDMS

01 55 00-1 Vehicular Access and Parking

Initial Digital Recording

At least 21 days before beginning on-site work

A CE 0 1 0

01 55 00-2 Vehicular Access and Parking

Post Construction Digital Recording

At least 21 days before leaving site.

A CE 0 1 0

01 55 00-3 Vehicular Access and Parking

Post Repair Digital Recording

Within 14 days of making repairs.

A CE 0 1 0

01 55 20-1 Traffic Control

Traffic Control Plan At least 60 days before affecting public traffic.

A CE CDMS

01 33 00 - 10

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

01 55 20-2 Traffic Control

Permit Applications At least 60 days before affecting public traffic

A CE CDMS

01 55 20-3 Traffic Control

Permits At least 14 days before affecting public traffic

I CE CDMS

01 56 10-1 Protection of Existing Installations

Plan for Protecting Existing Installations

At least 28 days before start of onsite construction work

A CE CDMS

01 56 15-1 Protection of Existing Utilities

Utility Owner Acknowledgment

At least 28 days before start of onsite construction work

A CE CDMS

01 56 15-2 Protection of Existing Utilities

Utility Investigation At least 7 days after completing investigation

I CE CDMS

01 57 20-1 Environment al Controls

Copy of Applicable Air Quality Permit

At least 14 days before beginning on-site work

I CE CDMS

01 57 30-1 Water Pollution Control

Updated Stormwater Pollution Prevention Plan (SWPPP)

At least 28 days before commencing construction activities

A CE CDMS

01 57 30-2 Water Pollution Control

Spill Prevention Control and Countermeasure (SPCC) Plan

At least 28 days before delivery or storage of oil

A CE CDMS

01 57 50-1 Tree and Plant Protection

Protection Plan At least 28 days before commencing on site construction work

A CE CDMS

01 57 90-1 Preservation of Historical and Archeologic al Data

Alternate Use Area or Borrow Area

At least 28 days before commencing on site construction work

A CE CDMS

01 71 20-1 Surveying Surveying Plan At least 28 days before beginning survey work

A CE CDMS

01 71 20-2 Surveying Resume At least 28 days before beginning survey work;

At least 28 days before personnel change

I CE CDMS

01 71 20-3 Surveying Accuracy Check Results

At least 28 days before beginning work

I CE CDMS

01 71 20-4 Surveying Completed and Reduced Survey Notes

Within 2 days of completing and reducing notes

I CE CDMS

01 71 20-5 Surveying Original Field Survey Books

Weekly I CE CDMS

01 33 00 - 11

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

01 71 20-6 Surveying Quantity Survey Notes and Computations

Accompanying progress payment requests

I CE CDMS

01 71 20-7 Surveying Workday's Survey Notes

At conclusion of workday if requested by Government

I CE CDMS

01 74 00-1 Cleaning and Waste Management

Waste Production and Disposal Plan

At least 28 days before starting onsite work

I CE CDMS

01 74 00-2 Cleaning and Waste Management

Waste Production and Disposal Records

Within 7 days of waste disposal

I CE CDMS

01 74 00-3 Cleaning and Waste Management

Environmental Consultant Resume

At least 28 days before beginning environmental assessment

I CE CDMS

01 74 00-4 Cleaning and Waste Management

Environmental Site Assessment

Within 14 days of completion of work

I CE CDMS

01 78 30-1 Project Record Documents

Progress As-built Drawings

Within 14 days of completion of structures or every 14 days whichever is fewer.

I CE 0 1 1

CDMS

01 78 30-1 Project Record Documents

Final As-built Drawings

Within 14 days of completion of work

I CE 0 1 1

CDMS

03 20 00-1 Concrete Reinforcing

Reinforcement Diagrams and Lists

At least 42 days before placing concrete

A 86-68530 CDMS

03 30 00-1 Cast-In- Place Concrete

Approval Data At least 42 days before placing concrete

A 86-68530 CDMS

03 30 00-2 Cast-In- Place Concrete

Certifications At least 42 days before placing concrete

A 86-68530 CDMS

03 30 00-3 Cast-In- Place Concrete

Cementitious Materials Certification and Test Reports

At least 42 days before placing concrete

A 86-68530 CDMS

03 30 00-4 Cast-In- Place Concrete

Test Reports At least 42 days before placing concrete

A 86-68530 CDMS

03 48 00-1 Precast Concrete Structures

Product Drawings and Data

At least 42 days before casting first structure

A 86-68120 CDMS

01 33 00 - 12

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

03 48 00-2 Precast Concrete Structures

Mix Design At least 42 days before casting first structure

I 86-68530 CDMS

03 48 00-3 Precast Concrete Structures

Curing, Handling and Storage Requirements

At least 42 days before casting first structure

A 86-68530 CDMS

03 63 00-1 Epoxy Grout Approval Data At least 42 days before placing grout

A 86-68530 CDMS

04 22 10-1 Reinforced Concrete Unit Masonry Assemblies

Approval Data At least 42 days before beginning construction with concrete masonry units

A 86-68120 CDMS

04 22 10-2 Reinforced Concrete Unit Masonry Assemblies

Sample Kit At least 42 days before beginning construction with concrete masonry units

A 86-68120 0 0 1

04 22 10-3 Reinforced Concrete Unit Masonry Assemblies

Certifications At least 42 days before beginning construction with concrete masonry units

A 86-68120 CDMS

04 22 10-4 Reinforced Concrete Unit Masonry Assemblies

Mix Design At least 42 days before beginning construction with concrete masonry units

A 86-68120 CDMS

04 22 10-5 Reinforced Concrete Unit Masonry Assemblies

Instructions At least 42 days before beginning construction with concrete masonry units

A 86-68120 CDMS

05 21 00-1 Steel Joists Approval Drawings, Data, and Certification

At least 42 days before fabricating joists

A 86-68120 CDMS

05 21 00-2 Steel Joists Welder Qualifications

At least 42 days before fabricating joists

A 86-68120 CDMS

05 21 00-3 Steel Joists Inspection Reports Within 30 days of completing inspection

A 86-68120 CDMS

05 30 00-1 Metal Roof Deck

Approval Drawings and Data

At least 42 days before installing roof deck

A 86-68120 CDMS

05 30 00-2 Metal Roof Deck

Welder Qualifications

At least 42 days before installing roof deck

A 86-68120 CDMS

01 33 00 - 13

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

07 41 13-1 Preinsulated Metal Roof Panels

Sample and Color Sample Kit

At least 42 days before installing panels

A 86-68120 0 0 1

07 41 13-2 Preinsulated Metal Roof Panels

Product Data and Shop Drawings

At least 42 days before installing panels

A 86-68120 CDMS

07 41 13-3 Preinsulated Metal Roof Panels

Closeout Maintenance Data

Within 14 days of installing panels

A 86-68120 CDMS

07 42 13-1 Preinsulated Metal Wall Panels

Sample and Color Sample Kit

At least 42 days before installing panels

A 86-68120 0 0 1

07 42 13-2 Preinsulated Metal Wall Panels

Product Data and Shop Drawings

At least 42 days before installing panels

A 86-68120 CDMS

07 42 13-3 Preinsulated Metal Wall Panels

Closeout Maintenance Data

Within 14 days of installing panels

A 86-68120 CDMS

08 34 53-1 Security Doors and Frames

Approval Drawings and Data

At least 42 days before installing doors

A 86-68120 CDMS

08 34 53-2 Security Doors and Frames

Instructions At least 42 days before installing doors

A 86-68120 CDMS

08 71 00-1 Door Hardware

Approval Data At least 42 days before installing hardware

A 86-68120 CDMS

08 71 00-2 Door Hardware

Instructions At least 42 days before installing hardware

A 86-68120 CDMS

09 65 10-1 Rubber Wall Base

Approval Data and Color Sample Kit

At least 42 days before installing wall base

A 86-68120 CDMS

09 65 10-2 Rubber Wall Base

Instructions At least 42 days before installing wall base

A 86-68120 CDMS

09 96 20-1 Coatings Approval Data At least 42 days before beginning coating work

A 86-68540 CDMS

09 96 20-2 Coatings Final Approval Data At least 42 days before beginning coating work

A 86-68540 CDMS

09 96 20-3 Coatings Contractor Testing Data for “Shop or Field Applied” Coatings

At least 42 days before beginning coating work

A 86-68540 CDMS

10 14 26-1 Utility Markers

Utility Marker Plan At least 42 days before start of construction activities

01 33 00 - 14

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

22 11 35-1 Pre- Manufacture d Pump Station

Pre-construction Data and Drawings

At least 42 days before fabrication or procurement

A 86-68410 CDMS

22 11 35-2 Pre- Manufacture d Pump Station

Manufacturer Post Production Testing Results

At least 42 days before fabrication or procurement

A 86-68410 CDMS

22 11 35-3 Pre- Manufacture d Pump Station

Manufacturer On-site Testing Results and Final Documents

At least 42 days before fabrication or procurement

A 86-68420 0 1 1

CDMS

22 13 16-1 Foundation and Building Drainage Piping

Approval Data Within 42 days after Notice to proceed

A 86-68410 CDMS

23 05 93-1 Testing, Adjusting, and Balancing for HVAC Equipment

Approval Data Within 42 days after Notice to proceed

A 86-68410 CDMS

23 05 93-2 Testing, Adjusting, and Balancing for HVAC Equipment

Certified Testing Adjusting and Balance Reports

Within 14 days of final testing

A 86-68410 CDMS

23 33 10-1 Duct Accessories

HVAC Accessories Approval Data

Within 42 days after Notice to proceed

A 86-68410 CDMS

23 33 10-2 Duct Accessories

HVAC Accessories Final Data

Within 14 days of final testing

A 86-68410 CDMS

23 34 00-1 HVAC Fans Approval Data Within 42 days after Notice to proceed

A 86-68410 CDMS

23 34 00-2 HVAC Fans Final Data Within 14 days of final testing

A 86-68410 CDMS

23 82 39-1 Unit Heaters Approval Data Within 42 days after Notice to proceed

A 86-68410 CDMS

23 82 39-2 Unit Heaters Final Data Within 14 days of final testing

A 86-68410 CDMS

01 33 00 - 15

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

25 00 01-1 Control and Monitoring

Approval Data - Monitoring and Control Systems Technical Specialist Work Summary

Within 42 days after Notice to Proceed

A 86-68450 CDMS

25 00 01-2 Control and Monitoring

Approval Drawings and Data

Within 42 days after Notice to Proceed

A 86-68450 CDMS

25 00 01-3 Control and Monitoring

Approval Data - Software Development Documentation

Within 42 days after Notice to Proceed

A 86-68450 CDMS

25 00 01-4 Control and Monitoring

Check Prints At same time as equipment is shipped to the site

A 86-68450 CDMS

25 00 01-5 Control and Monitoring

Approval Data - Final Drawings, Documentation, and Operations and Maintenance Manuals

Within 42 days after Notice to Proceed

A 86-68450 CDMS

25 00 02-1 Programmab le Controller

Approval Drawings Within 42 days after Notice to Proceed

A 86-68450 CDMS

25 00 02-2 Programmab le Controller

Approval Data Within 42 days after Notice to Proceed

A 86-68450 CDMS

25 00 02-3 Programmab le Controller

Final Drawings, Documentation, and Operations and Maintenance Manuals

Within 28 days after installation

I 86-68450 CDMS

25 08 10-1 Automation System Testing, Acceptance, and Training

FAT Procedure and Start Date

At least 42 days before beginning test

A 86-68450 CDMS

25 08 10-2 Automation System Testing, Acceptance, and Training

FAT Test Report Not more than 28 days after test

I 86-68450 CDMS

25 08 10-3 Automation System Testing, Acceptance, and Training

SPAT Procedure and Start Date

At least 42 days before beginning test

A 86-68450 CDMS

01 33 00 - 16

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

25 08 10-4 Automation System Testing, Acceptance, and Training

SPAT Test Report Not more than 28 days after test

I 86-68450 CDMS

25 08 10-5 Automation System Testing, Acceptance, and Training

OAT Procedure and Start Date

At least 42 days before beginning test

A 86-68450 CDMS

25 08 10-6 Automation System Testing, Acceptance, and Training

OAT Report Not more than 28 days after test

I 86-68450 CDMS

25 08 10-7 Automation System Testing, Acceptance, and Training

Training Plan No less than 42 days before first commissioning is scheduled to begin

I 86-68450 CDMS

26 05 10-1 Conductors and Cables

Approval Data Within 42 days after Notice to Proceed

A 86-68430 CDMS

26 05 10-2 Conductors and Cables

Field Test Reports Not more than 30 days after test

I 86-68430 CDMS

26 05 13-1 Medium- Voltage Power Cable System

Approval Drawings and Data

Within 42 days after Notice to Proceed

A 86-68430 CDMS

26 05 13-2 Medium- Voltage Power Cable System

Field Test Reports Within 14 days after tests are completed

I 86-68430 CDMS

26 05 20-1 Grounding and Bonding

Approval Drawings and Data

Within 42 days after Notice to Proceed

A 86-68430 CDMS

26 05 20-2 Grounding and Bonding

Test Reports Within 14 days after tests are completed

I 86-68430 CDMS

26 05 33-1 Raceways and Boxes

Approval Drawings and Data

Within 42 days after Notice to Proceed

A 86-68430 CDMS

26 13 26-1 Medium- Voltage Metal-Clad Switchgear

Approval Drawings and Data

Within 42 days after Notice to Proceed

A 86-68430 CDMS

01 33 00 - 17

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

26 13 26-2 Medium- Voltage Metal-Clad Switchgear

Wiring Diagrams Within 14 days after tests are completed

I 86-68430 CDMS

26 13 26-3 Medium- Voltage Metal-Clad Switchgear

Check Prints At same time as equipment is shipped to the site

A 86-68430 CDMS

26 13 26-4 Medium- Voltage Metal-Clad Switchgear

Factory Test Reports Within 14 days after tests are completed

I 86-68430 CDMS

26 13 26-5 Medium- Voltage Metal-Clad Switchgear

Field Test Reports Within 14 days after tests are completed

I 86-68430 CDMS

26 13 26-6 Medium- Voltage Metal-Clad Switchgear

Final Drawings Within 14 days after installation

A 86-68430 CDMS

26 13 26-7 Medium- Voltage Metal-Clad Switchgear

Operation and Maintenance Instruction Book

Within 14 days after installation

I 86-68430 CDMS

26 16 13-1 Primary Unit Substation

Approval Drawings and Data

Within 42 days after Notice to Proceed

A 86-68430 CDMS

26 16 13-2 Primary Unit Substation

Schematic and Wiring Diagrams

Within 42 days after Notice to Proceed

A 86-68430 CDMS

26 16 13-3 Primary Unit Substation

Factory Test Notification

At least 14 days prior to testing

A 86-68430 CDMS

26 16 13-4 Primary Unit Substation

Check Prints At same time as equipment is shipped to the site

A 86-68430 CDMS

26 16 13-5 Primary Unit Substation

Factory Test Reports Within 14 days after tests are completed

A 86-68430 CDMS

26 16 13-6 Primary Unit Substation

Field Test Reports Within 14 days after tests are completed

A 86-68430 CDMS

26 16 13-7 Primary Unit Substation

Final Drawings Within 28 days after installation

A 86-68430 CDMS

26 16 13-8 Primary Unit Substation

Operation and Maintenance Instruction Book

Within 14 days after Final Drawings acceptance

A 86-68430 CDMS

01 33 00 - 18

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

26 22 12-1 Dry-Type Transformer s

Approval Data Within 42 days after Notice to proceed

A 86-68430 CDMS

26 22 12-2 Dry-Type Transformer s

Operation and Maintenance Instruction Book

Within 14 days after installation

I 86-68430 CDMS

26 24 41-1 Distribution Panelboards

Approval Data Within 42 days after Notice to proceed

A 86-68430 CDMS

26 24 41-2 Distribution Panelboards

Approval Layouts Within 42 days after Notice to proceed

A 86-68430 CDMS

26 24 41-3 Distribution Panelboards

Test Data Within 14 days after tests are completed

I 86-68430 CDMS

26 27 40-1 Wiring Devices

Approval Data Within 42 days after Notice to proceed

A 86-68430 CDMS

26 42 10-1 Buried Galvanic Anode Cathodic Protection and Corrosion Monitoring Systems

Certification and Data

At least 42 days before procuring materials

A 86-68540 CDMS

26 42 10-2 Buried Galvanic Anode Cathodic Protection and Corrosion Monitoring Systems

Final Data Within 7 days of final testing

A 86-68540 CDMS

26 42 11-1 Submerged Galvanic Anode Cathodic Protection System for Welded Tanks

Certification and Data

At least 42 days before procuring materials

A 86-68540 CDMS

01 33 00 - 19

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

26 42 11-2 Submerged Galvanic Anode Cathodic Protection System for Welded Tanks

Final Data Within 7 days of final testing

A 86-68540 CDMS

26 42 12-1 Bolted Tank Submerged Galvanic Anode Cathodic Protection System

Certification, Design, and Manufacturer’s Data

At least 42 days before procuring materials

A 86-68540 CDMS

26 42 12-2 Bolted Tank Submerged Galvanic Anode Cathodic Protection System

Final Data Within 7 days of final testing

A 86-68540 CDMS

26 51 00-1 Interior Lighting

Approval Data Within 42 days after Notice to proceed

A 86-68430 CDMS

26 52 00-1 Emergency and Exit Lighting

Approval Data Within 42 days after Notice to proceed

A 86-68430 CDMS

26 56 00-1 Exterior Lighting

Approval Data Within 42 days after Notice to proceed

A 86-68430 CDMS

27 15 00-1 Communicat ions Cabling

Approval Data Within 42 days after Notice to Proceed

A 86-68450 CDMS

27 15 00-2 Communicat ions Cabling

Approval Data Within 42 days after Notice to Proceed

A 86-68450 CDMS

27 20 01-1 Radio Equipment

Approval Drawings and Data

Within 42 days after Notice to Proceed

A 86-68450 CDMS

27 20 01-2 Radio Equipment

Operations and Maintenance Manual

Within 30 days after installation

I 86-68450 CDMS

27 30 01-1 Telephone Equipment

Approval Drawings and Data

Within 42 days after Notice to Proceed

A 86-68450 CDMS

27 30 01-2 Telephone Equipment

Check Prints Within 14 days after installation

A 86-68450 CDMS

27 30 01-3 Telephone Equipment

Operations and Maintenance Manual

Within 30 days after installation

I 86-68450 CDMS

01 33 00 - 20

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

27 30 01-4 Telephone Equipment

Field Operational Checkout Test Report

At least 42 days before beginning test

I 86-68450 CDMS

28 10 01-1 Security and Surveillance Equipment

Approval Drawings and Data

Within 42 days after Notice to Proceed

A 86-68450 CDMS

28 10 01-2 Security and Surveillance Equipment

Test Procedure and Start Date

At least 42 days before beginning test

I 86-68450 CDMS

28 10 01-3 Security and Surveillance Equipment

Test Report Not more than 28 days after test

I 86-68450 CDMS

28 10 01-4 Security and Surveillance Equipment

Check Prints At same time as equipment is shipped to the site

A 86-68450 CDMS

28 10 01-5 Security and Surveillance Equipment

Final Drawings and Operations and Maintenance Manuals

Within 28 days after installation

I 86-68450 CDMS

28 31 00-1 Fire Detection and Alarm

Approval Data Within 42 days after Notice to Proceed

A 86-68450 CDMS

28 31 00-2 Fire Detection and Alarm

Testing Procedure and Notification

At least 42 days before beginning test

I 86-68450 CDMS

28 31 00-3 Fire Detection and Alarm

Test Reports Not more than 28 days after test

I 86-68450 CDMS

28 31 00-4 Fire Detection and Alarm

Training Materials Within 28 days after installation

I 86-68450 CDMS

28 31 00-5 Fire Detection and Alarm

Operation and Maintenance Instruction Book

Within 28 days after installation

I 86-68450 CDMS

31 02 10-1 Water for Dust Abatement

Meter Calibration At least 42 days before beginning on-site work

A CE CDMS

31 02 30-1 Dust Palliative

Proposed Application Area for Dust Palliative

At least 42 days before beginning on-site work

A CE CDMS

31 23 02-1 Compacting Earth Materials

Test Results Within 7 days after completion of tests

I CE CDMS

01 33 00 - 21

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

31 23 70-1 Controlled Low Strength Material

(CLSM)

Approval Data For CLSM Produced Without Native Soil

At least 42 days before placing

A 86-68530 CDMS

31 23 70-2 Controlled Low Strength Material

(CLSM)

Approval Data For CLSM Produced With Native Soil

At least 42 days before placing

A CE CDMS

31 23 70-3 Controlled Low Strength Material

(CLSM)

Contractor Field Quality Testing Results

Within 7 days of testing A CE CDMS

31 31 30-1 Soil-Applied Herbicide

Use Plan At least 28 days before placing

A CE CDMS

31 31 30-2 Soil-Applied Herbicide

Applier Certification At least 28 days prior to beginning work

A CE CDMS

31 37 00-1 Riprap Approval Data and Test Results

At least 42 days before placing lining

A CE CDMS

32 15 10-1 Gravel Surfacing

Gravel Certification At least 42 days before placing surfacing

A CE CDMS

32 15 10-2 Gravel Surfacing

Geofabric Installation

At least 42 days before placing surfacing

A CE CDMS

32 15 10-3 Gravel Surfacing

Geofabric Certification

At least 42 days before placing surfacing

A CE CDMS

32 31 10-1 Chain Link Fence

Certification At least 42 days before installing fencing

A CE CDMS

32 91 60-1 Erosion Control Blanket

Manufacturer’s Information

At least 28 days before placing blanket

A CE CDMS

32 91 60-2 Erosion Control Blanket

Installation Plan At least 28 days before placing blanket

A CE CDMS

32 92 20-1 Seeding Seeding Plan At least 28 days before seeding

A CE CDMS

32 92 20-2 Seeding Certifications At least 28 days prior to beginning work

A CE CDMS

33 05 21-1 Bored Utility Crossings

Placement Plan At least 28 days prior to beginning work

01 33 00 - 22

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

33 05 21-1 Bored Utility Crossings

Material Certification

At least 28 days prior to beginning work

A CE CDMS

33 09 08-1 Probe Magnetic Flowmeter

Approval Data At least 42 days before procurement

A 86-68410 CDMS

33 09 08-2 Probe Magnetic Flowmeter

Final Data Within 14 days prior to shipment to site

I 86-68410 CDMS

33 09 08-3 Probe Magnetic Flowmeter

Test Reports Within 14 days of completion of tests

I 86-68410 CDMS

33 11 10-1 Pipeline General Requirement s

Qualifications At least 42 days before pipe fabrication or procurement

A CE CDMS

33 11 10-2 Pipeline General Requirement s

Pipelaying Diagrams At least 42 days before pipe fabrication or procurement

A 86-68140 CDMS

33 11 10-3 Pipeline General Requirement s

Filling and Testing Plan

At least 42 days before pipe fabrication or procurement

A 86-68140 CDMS

33 11 10-4 Pipeline General Requirement s

Floatation Prevention Plan

At least 42 days before pipe fabrication or procurement

A 86-68140 CDMS

33 11 12-1 Steel Line Pipe

Shop Drawings At least 42 days before pipe fabrication or procurement

A 86-68140 CDMS

33 11 12-2 Steel Line Pipe

Ventilation Plan At least 42 days before pipe fabrication or procurement

A 86-68140 CDMS

33 11 13-1 Ductile Iron Pipe

Shop Drawings At least 42 days before pipe fabrication or procurement

A 86-68140 CDMS

33 11 16-1 PVC

Pressure Pipe

Shop Drawings At least 42 days before pipe fabrication or procurement

A 86-68140 CDMS

33 11 16-2 PVC

Pressure Pipe

Pipe Manufacture Certification

Within 24 hours of taking measurements

01 33 00 - 23

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

33 11 16-3 PVC

Pressure Pipe

Test Results Within 14 days of completion of tests

I CE CDMS

33 11 18-1 HDPE

Pressure Pipe

Heat Fusion Joint Operator Qualifications

At least 42 days before pipe fabrication or procurement

A CE CDMS

33 11 18-2 HDPE

Pressure Pipe

Shop Drawings At least 42 days before pipe fabrication or procurement

A 86-68140 CDMS

33 11 18-3 HDPE

Pressure Pipe

Certification 14 days before shipping A CE CDMS

33 11 18-4 HDPE

Pressure Pipe

Fusion Procedures At least 42 days before pipe fabrication or procurement

A CE CDMS

33 11 19-1 Fiberglass Pipe

Shop Drawings At least 42 days before pipe fabrication or procurement

A 86-68140 CDMS

33 11 19-2 Fiberglass Pipe

Joint Repair Plan At least 42 days prior to delivery

A 86-68140 CDMS

33 11 50-1 Pipe Crossings at Existing Utility Pipelines

Rubber Gasket Data At least 42 days before pipe fabrication or procurement

A CE CDMS

33 12 10-1 Valves and Equipment for Line Pipe Installations

Commercial Product Data

At least 42 days before fabrication or procurement

A 86-68140 CDMS

33 12 10-2 Valves and Equipment for Line Pipe Installations

Service Manuals Within 14 days after installation

I 86-68140 CDMS

33 16 14-1 Air Chambers

Qualifications At least 42 days before fabrication or procurement

A 86-68420 CDMS

33 16 14-2 Air Chambers

Shop Drawings, Design Calculations, and Design Data

At least 42 days before fabrication or procurement

A 86-68420 CDMS

33 16 14-3 Air Chambers

Surge Analysis At least 42 days before fabrication or procurement

A 86-68420 CDMS

01 33 00 - 24

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

33 16 14-4 Air Chambers

Commercial Products Data

At least 42 days before fabrication or procurement

A 86-68420 CDMS

33 16 14-5 Air Chambers

Service Manuals Within 14 days after installation

I 86-68420 CDMS

33 16 50-1 Steel Tanks Shop Drawings, Design Calculations and Design Data

At least 42 days before fabrication or procurement.

A 86-68420 CDMS

33 16 50-2 Steel Tanks Qualifications At least 42 days before fabrication or procurement.

A 86-68420 CDMS

33 16 50-3 Steel Tanks Nondestructive Weld Test Reports

Within 7 days after installation.

I 86-68420 CDMS

33 16 50-4 Steel Tanks Commercial Products Data

At least 42 days before fabrication or procurement.

A 86-68420 CDMS

33 16 50-5 Steel Tanks Final Drawings and Data

Within 14 days after installation.

I 86-68420 CDMS

33 21 95-1 Metal Piping for Line Pipe Installations

Shop Drawings At least 42 days before fabrication or procurement

A 86-68140 CDMS

33 21 95-2 Metal Piping for Line Pipe Installations

Commercial Products Data

At least 42 days before fabrication or procurement

A 86-68140 CDMS

33 21 95-3 Metal Piping for Line Pipe Installations

Final Drawings Within 14 days after installation

I 86-68140 CDMS

35 21 95-1 Steel Pipe Shop Drawings At least 42 days before fabrication or procurement.

A 86-68420 CDMS

35 21 95-2 Steel Pipe Commercial Products Data

At least 42 days before fabrication or procurement.

A 86-68420 CDMS

35 21 95-3 Steel Pipe Final Drawings Within 14 days after installation

I 86-68420 CDMS

35 22 15-1 Valves and Equipment

Commercial Product Data

At least 42 days before fabrication or procurement.

A 86-68420 CDMS

35 22 15-2 Valves and Equipment

Service Manuals Within 14 days after installation.

I 86-68420 CDMS

35 42 35-1 Bank Protection

Samples Within 14 days after tests are completed

A 86-68240 0 0 1

35 42 35-2 Bank Protection

Certifications Within 14 days after tests are completed

A 86-68240 CDMS

01 33 00 - 25

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Type

Respon-sible code

Sets to be sent: **

CO CE TSC

48 14 00-1 Solar and Electrical Equipment

Approval Data Within 42 days after Notice to Proceed

A 86-68430 CDMS

48 14 00-2 Solar and Electrical Equipment

Approval Drawings Within 42 days after Notice to Proceed

A 86-68430 CDMS

48 14 00-3 Solar and Electrical Equipment

Test Report Within 14 days after tests are completed

I 86-68430 CDMS

END OF SECTION

01 33 00 - 26

Concrete Forming

03 11 10 - 1

SECTION 03 11 10

CONCRETE FORMING

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include transformer foundation forming in the price in the Price Schedule for Complete Electrical System.

B. Cost:

1. Include thrust block forming in the price in Price Schedule for Line Pipe.

C. Cost:

1. Include in the price in Price Schedule for Air Chamber No. 1.

D. Cost:

1. Include in the price in Price Schedule for Air Chamber No. 2.

E. Cost:

1. Include in the price in Price Schedule for Regulating Tank No. 1.

F. Cost:

1. Include in the price in Price Schedule for Regulating Tank No. 2.

1.02 REFERENCE STANDARDS

A. American Concrete Institute

1. ACI 318-11 Building Code Requirements for Structural Concrete and Commentary

B. APA - The Engineered Wood Association (APA)

1. APA PS 1-09 Structural Plywood

C. Bureau of Reclamation (USBR)

1. RSHS Reclamation Safety and Health Standards, including revisions posted at http://www.usbr.gov/ssle/safety/RSHS/rshs.

html

03 11 10 - 2

D. Western Wood Products Association (WWPA)

1. WWPA WLGR-11 Western Lumber Grading Rules

PART 2 PRODUCTS

2.01 THRUST BLOCKS

A. See Section 33 11 10 - Line Pipe.

2.02 AIR CHAMBER NO. 1 AND NO. 2

A. See Section 33 16 14 - Air Chambers.

2.03 REGULATING TANK NO. 1 AND NO. 2

A. See Section 33 16 50 - Steel Tanks.

PART 3 EXECUTION

3.01 FORM MATERIALS

A. Sheathing or Lining: Conform to Table 03 11 10A - Form Sheathing or Lining Materials, or provide other materials which will produce equivalent results.

Table 03 11 10A - Form Sheathing or Lining Materials

Finish Wood sheathing or lining Steel sheathing or lining

F1 Any grade common board or plywood

Steel sheathing permitted Steel lining permitted

F2 No. 2 common or better, shiplap, or plywood

Steel sheathing permitted Steel lining permitted if approved

F3 Plywood Steel sheathing permitted Steel lining not permitted

B. Steel sheathing is steel sheets not…