N4033918RF014-Amendment_02.pdf

N4891518RCBA097

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

USS GLADIATOR SRA (MCM-11)

1. The purpose of this amendment is to provide responses to the clarif ications received from the industry for the USS GLADIATOR SRA.

2. Please see attached section (B) price break dow n, the w ork item number of CLIN#0001 is here by corrected to read as Work Item No.

(993-21-001) vice Work Item No. 993-11-001.

3. Please see section (C), the NAVSEA standard item FY19 is here by corrected to read as NAVSEA standard item FY19 Change 1 vice

FY19 Change 2.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 12

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 06-May-2018

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N4033918RF014

X 9B. DATED (SEE ITEM 11)

25-Apr-2018

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

06-May-2018

CODE

NAVSUP FLC BAHRAIN CODE 200

PSC 851 BOX 430

FPO AE 09834-0005

N40339 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N4033918RF014

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been added by full text:

QUESTION AND ANSWERS

Work Item/

Description

QUESTION/CLARIFICATION GOVERNMENT’s RESPONSE/ANSWER

130-11-002: Overhead

Repairs accomplish

- Ref 2.9: Received Rev B drawing. Please provide Rev F drawing. - This is a typographical error, contractors will received the correct revision.

233-11-001: Main Propulsion

Diesel Engine (MPDE) Jacket

Water Coolers; clean and test.

- Ref 2.3: Received Rev 1 Tech

Manual. Please provide Rev 3

Tech Manual.

- Reference will be sent through AMRDEC. The link and password will be sent to you separately.

241-11-001: Main Propulsion

Diesel Engine and Reduction

Gear Resilient Mounts;

Replace.

- Ref 2.7: Received Rev A drawing.

Please provide Rev B drawing.

- This is a typographical error, contractors will received the correct revision.

442-11-001: AN/WQC-2 Sonar

Communication Set

Transducer Replace.

- Ref 2.2: Not received. Please provide. - Waterborne Sonar Transducer Replacement Procedure. See

WQC-2 in the Tech Man.

505-00-002: Silicon Aluminum

Bronze (SAB) Union Fittings;

inspect and replace.

- Ref 2.2: Received Rev B drawing. Please provide Rev G drawing.

- This is a typographical error, contractors will received the correct revision

- Ref 2.4: Received Rev C drawing. Please provide Rev D drawing.

- Ref 2.5: Received Rev B drawing. Please provide Rev C drawing.

512-11-001: Galley and

Laundry Exhaust

Ventilation; clean.

- Ref 2.2: Not received. Please provide.

512-11-003: Ventilation Fan;

repair and test.

- Ref 2.2: Received Rev D drawing. Please provide Rev F drawing.

- Ref 2.5: Received Rev B drawing.

Please provide Rev C drawing.

521-11-002: Fire main Valve;

replace.

- Ref 2.7: Not received. Please provide.

521-21-001: Fire Pump and

Motor; repair and test.

- Ref 2.5: Received Rev 3 drawing.

Please provide Rev 9 drawing.

593-11-002: CHT Piping

System Chemical Cleaning;

accomplish.

- Ref 2.4: Received Rev C drawing. Please provide Rev F drawing.

correct revision.

992-31-001: Cleaning and

Pumping; accomplish.

- Ref 2.3: Please confirm if the required reference is CH-541 or CH-542. We have received CH-542 only.

- S9086-SP-STM-010/CH-542, Ship's Fuel and Fuel

Systems is correct STM.

077-11-001: Hazardous Waste

Produced on Naval Vessels;

control.

- Para 2.1: Not received. Please

992-11-002: Temporary

Service; provide.

- Para 2.2: Not received. Please

993-31-001: Temporary Deck

Covering Install.

- Para 2.1: Not received. Please

SECTION B - SUPPLIES OR SERVICES AND PRICES

The following have been modified:

PRICE BREAKDOWN

CLIN

SOW

Paragraph

DESCRIPTION

MAN

HOU

RS

LABOR

COST

MATERIAL

COST

OTHE

R

COST*

TOTAL

COST

CLIN 0001 - MAINTENANCE AND REPAIR WORKS

042-00-001 Accountability of Man-hour and

Material Reservation; accomplish-

042-00-003 Work Completion Certification;

accomplish

0001 110-11-001 Limber Chain; repair

0001 120-11-001 Tie Rod; inspect and repair

123-14-001 Potable Water Tank; clean, inspect, repair and test

130-11-001 Exterior Wood Repair; accomplish

0001 130-11-002 Overhead Repairs; accomplish

171-11-001 Main Mast; stage, repair and preserve

233-11-001 Main Propulsion Diesel Engine

(MPDE) Jacket Water Coolers;

clean and test

233-11-002 No. 2A Main Propulsion Diesel

Engine (MPDE) Vibracon Mount;

replace

233-11-003 Main Reduction Gear (MRG to

Main Propulsion Diesel Engine

(MPDE) Alignment; accomplish

241-11-001 Main Propulsion Diesel Engine and

Reduction Gear Resilient Mounts;

252-11-001 MCM-11 SCD 89081/86374

Alteration Installation Team (AIT)

Industrial Support Service; provide

256-11-001 Auxiliary Seawater Cooling

Pumping Unit; overhaul

262-11-001 Reduction Gear Lube Oil Cooler;

clean and test

264-30-001 Main Reduction Gear (MRG) and

Controllable Pitch Propeller (CPP)

Lube Oil Polisher Heater; inspect and clean

0001 321-11-001 2SP Shore Power Cable; replace

442-11-001 AN/WQC-2 Sonar Communication

Set Transducer; replace

476-11-001 Vehicle Handling System (VHS);

repair

476-11-002 Minesweeping Winch Interlock

Display Cable; replace

505-00-002 Silicon Aluminum Bronze (SAB)

Union Fittings; inspect and replace

508-11-001 Machinery Spaces and Non

Machinery Interior Spaces Lagging and Insulation; repair

NTE Labor: 80 Man Days

NTE Materials: $20,000.00

512-11-001 Galley and Laundry Exhaust

Ventilation; clean

512-11-002 Ventilation Fan Motor Resilient

Mount; replace

0001 512-11-003 Ventilation Fan; repair and test

514-11-001 Number One & 2 AC Condenser

Retube; accomplish

514-11-002 A/C Plant Chill Water Pump and

Motor; repair

514-11-003 Air Conditioning Plant Compressor;

516-11-001 Refrigeration Plant Condenser

Retube; accomplish

516-11-002 Number 2 Refrigeration Plant Valve;

516-11-003 Refrigeration Plant Compressor;

overhaul and test

0001 521-11-001 Remote Operator Deck Box; replace

0001 521-11-002 Fire main Valve; replace

521-11-003 Fire Main Cascade Orifice Resistive

Device (CORD); rebuild

0001 521-21-001 Fire Pump and Motor; repair and test

0001 524-11-001 Sea Valves; remove and replace

524-11-002 Fire main Piping System; clean and flush

524-11-003 Auxiliary Sea Water Piping; clean and flush

526-11-001 Deck Drain and Deck Penetration;

533-11-001 Potable Water Pump and Motor;

overhaul

551-11-001 Medium Pressure Air Compressor

(MPAC); repair

0001 561-11-001 Hydraulic Power Unit Cooler; clean

561-11-002 Starboard Steering Gear Pump;

581-11-001 Anchor and Chain; clean, inspect and preserve

0001 581-11-002 Anchor Windlass; replace

583-11-001 Boat Davit: repair and weight test;

accomplish

0001 583-11-002 Boat Sling Weight Test; accomplish

583-31-001 Rigid Hull Inflatable Boat (RHIB);

593-11-001 Waste Water Ejection Pump;

overhaul

593-11-002 CHT Piping System Chemical

Cleaning; accomplish

0001 593-11-003 Waste Water Ejection Tank; repair

0001 622-11-001 GRP Deck Plate; replace

622-11-002 PVC Pipe Connector; fabricate and install

0001 624-11-001 Joiner Door; repair

0001 624-11-002 Fume tight Joiner Door; repair

0001 631-11-001 Superstructure; preserve

0001 631-11-002 Bilge; preserve

0001 631-41-001 Freeboard; preserve

0001 634-11-002 Nonskid; replace

0001 634-11-003 Decking; repair

0001 634-11-004 Electrical Grade Matting; replace

0001 641-11-001 Crew Head Counter Top; replace

0001 642-11-001 Watch Chair; repair

0001 651-11-001 Electric Steam Jacketed Kettle; test

0001 665-11-001 Furniture; replace

0001 837-11-001 Antenna Photographs; provide

897-11-001 Availability Program Management

AIT Integrator; provide

980-11-001 Alteration Installation Team (AIT)

Support Services (SA70392K BOW

THRUSTER MODS); provide

0001 980-11-002 Assist Ship's Force; provide

982-31-002

Preliminary Light-Off Assessment

(LOA) Discrepancy Correction for

Government Responsible

Discrepancies; provide

NTE Labor: 15 Man Days

NTE Materials: $5,000.00

992-21-001 Small Boat Storage and Repair

Facility; provide

0001 992-31-001 Cleaning and Pumping; accomplish

0001 993-11-001 Alteration Installation Team (AIT)

Support Services (SA70392K BOW

THRUSTER MODS); provide

0001 993-21-001 Crane, Rigging, Forklift and

Transportation Service; provide

CLIN 0001 Total:

Items with NTE are NOT TO EXCEED work items. As per the individual scope of work (para. 3.1), the contractor will have to provide up to the requested number of Man Days and Material Cost. The contractor is required to give the Contracting Officer a written notice when the total amount reaches 75 percent of the stated ceiling for this CLIN. The contractor WILL NOT BE reimbursed for anything above the stated amount without a prior written notice to the Contracting Officer and a modification to the contract.

CLIN 0002 –TEMPORARY SERVICES

077-11-001 Hazardous Waste Produced on

Naval Vessels; control

857-11-001 Temporary Off-Ship Galley and

Messing Facility; provide

857-11-002 Temporary Duty Section Berthing

Off-Ship; provide

991-12-001 Temporary Staging for Ship's Force

Use; install

992-00-001 Force Protection; provide

0002 992-11-002 Temporary Service; provide

0002 993-31-001 Temporary Deck Covering Install

CLIN 0002 Total:

CLIN 0003 – SEA TRIALS

982-31-003

Dock Trials, Fast Cruise and Sea

Trial; accomplish

CLIN 0004, 0005, 0006 and 0007 –OPTION WORK ITEMS EXTENSIONS

0004 042-00-002 Continuation of Temporary Services;

provide (First Option) (15 Days

Extension)

0005 042-00-002 Continuation of Temporary Services;

provide (Second Option) (15 Days

0006 042-00-002 Continuation of Temporary Services;

provide (First Option) (30 Days

0007 042-00-002 Continuation of Temporary Services;

provide (Second Option) (30 Days

CLIN 0008 – SHIP SERVICE - OPTION

0008 311-22-001 Ship Service Diesel Generator

(SSDG); clean, repair and test

(Option)

GRAND TOTAL:

* The contractor shall specify what other costs are for all above work items.

The Growth Work Labor rate for this SRA project is _______________.

If an offeror intends to propose $0.00 or NSP for any of the work items listed above, then the offeror shall explain the reasons for proposing $0.00 or NSP in their proposal.

SECTION C - DESCRIPTIONS AND SPECIFICATIONS

The following have been modified:

SECTION C

C-1 GENERAL

The Contractor shall prepare and accomplish all work items on the Selected Restricted Availability (SRA) on the

USS GLADIATOR (MCM-11) as specified herein and in accordance with the Specification Package as provided herein, test procedures and other detailed data provided by the Government.

The Contractor shall perform planning, document preparation, engineering, procurement, prefabrication and shipyard production work, and/or any other work necessary to prepare for and accomplish the alterations, repairs, maintenance and routine work specified herein. These requirements include, but are not limited to, the following:

(a) Provide the management, procurement, production, testing, quality assurance, technical capability and resources necessary to prepare for and accomplish the repairs and alterations in accordance with the requirements stated herein, the contract work specifications, and the additional work specifications if necessary within the availability time period specified in Section F.

(b) Accomplish planning and scheduling to ensure timely procurement of Contractor Furnished

Material/Contractor Furnished Property (CFM/CFP) and receipt, storage, and installation of Government

Furnished Material/Government Furnished Property (GFM/GFP) and CFM/CFP.

(c) Apply progress measurement systems to determine the physical progress of completed work for each of the elements in the contractor’s scheduling plan, including material and manpower control, engineering, production, tests and trials in accordance with the Contract Data Requirements and the Contractor's own Technical Proposal, and the work item package. The progressing system shall permit a direct comparison of the physical progress of completed work to the planned performance measurement baseline for each of the elements in the scheduling plan.

(d) Establish management procedure and systems to identify behind schedule conditions and unfavorable schedule variance, using the scheduling plan performance measurement baseline, each of the elements in the baseline, and the progress measurement systems. The applied systems and procedures shall provide timely identification of scheduling problem areas to permit prompt management action to correct unsatisfactory conditions.

(e) Develop a performance milestone schedule/critical path chart to measure scheduled performance. Deviations from the milestone schedule/critical path chart must be submitted to and approved by the Contracting Officer.

The Contractor warrants that all work required by Section C of this contract shall be completed within the performance period stated in Section F of the Contract. A performance milestone schedule and critical path chart shall be developed and submitted in accordance with the Work Item Package.

(f) Apply approved quality control procedures as required by this contract and the work item package to ensure procured material and performed production work conforms to the required quality standards.

(g) Apply procedures to ensure that the ship's equipment and systems remain configured to existing baselines with regard to procured material, production work, and software.

(h) Apply stringent configuration control procedures to ensure that configuration baselines are maintained for procured material and production work.

(i) Provide for staging and storing of Long Lead Time Material (LLTM) for use in the availabilities, as required by the Work Item Package.

C-2 STATEMENT OF WORK (SOW)

There are a total of Eighty seven (87) work items incorporated to this solicitation. This includes seventy-four (74) regular work items, seven (7) temporary services work items, one (1) Sea Trials work item, one (1) Ship Service

Diesel Generator (SSDG) is an optional item and (4) extensions work items. Please see Section J-1 for reference.

C-3 FORCE PROTECTION

(a) The contractor shall be responsible to provide deck, flat or other suitable barges be tied alongside U.S. vessels while tied pier side of the contractor's facility.

(b) Barges should be utilized in the following circumstances:

1. U.S. vessel is tied pier side for at least 48 hours.

2. Barge does not interfere with vessel's maintenance availability.

(c) Barges should provide cover the length of the U.S. vessel. Multiple barges may be utilized but if more than one barge is placed it should be done in such a manner as to establish overhang fore and aft over the length of the U.S.

vessel, limiting areas of vulnerability to only the bow and stern.

(d) Barges should provide a minimum of 12 feet of waterside standoff from the U.S. vessel. Fenders may be used to meet this requirement.

(e) Barges should not restrict fields of view or fire from established Crew served weapons locations or watch positions.

(f) A suitable floating boat barricade may be used in lieu of a barge, should one be available.

(g) Contractor must strictly control access to the shipyard. Only authorized personnel and vehicles are permitted to enter the shipyard with proper identification displayed at all times. All personnel and vehicles gaining access into the U.S. secured work area around the vessel will be subject to search by U.S. armed security personnel.

(h) U.S. armed security personnel will be allowed to maintain a 24 hour a day presence onboard the vessel and within the secured work area around the vessel.

(i) Physical security barriers (anti-vehicle "jersey" type concrete barriers and drop arm) must be placed around work/gathering places where U.S. personnel will congregate. Work/gathering areas for U.S. personnel will be segregated from other areas by fence (U.S. personnel will control access to this fenced compound). Access to the vessel must be controlled and barriers in place to the extent possible around the vessel to provide maximum standoff from a potential explosive-laden vehicle. COMUSNAVCENT can provide concrete barriers. Contractor is required to move and place barriers as directed. This effort will be accomplished at no additional cost to the USCG and will be amortized over the cost of the entire availability. Force Protection is not a separately priced line item.

(j) Adequate lighting must be available around the secured work area, vessel, and dry-dock to provide sufficient illumination at night for U.S. security personnel.

(k) U.S. security personnel (along with bomb sniffing dogs) will be allowed to search for explosive devices around the areas of the vessel, dry-dock, and secured work areas around the vessel.

(l) U.S. armed small boats will be allowed to patrol in the vicinity of the dry-docked vessel to provide waterside standoff from a potential waterborne attack.

(m) U.S. Navy divers be allowed to perform underwater search of dry-dock and any vessels nearby the secured work area.

(n) No watercraft will be allowed near the dry-docked vessel without prior permission from U.S security personnel.

Any watercraft required to be near the dry-docked vessel will be subject to a vessel search for explosive devices, including underwater inspection of the hull.

(o) A site survey will be conducted by COMUSNAVCENT, post award, to assess and discuss specific requirements for the awardee's shipyard. The information above is provided as prudent guidance and cannot be construed as complete.

C-4 MILESTONE AND PRODUCTION DATES

Contractor shall abide by the following milestone and production completion date. Any exceptions to the milestone plan shall be pre-arranged and approved by Contracting Officer and Contracting Officer’s Representative.

USS GLADIATOR (MCM-11) EXECUTION MILESTONES & KEY EVENTS

FY 18 DPMA 20 AUGUST 2018 – 29 NOVEMBER 2018 (100 Days Avail)

EVENT DATE WEEKDAY COMMENTS

Start Availability 20 Aug 18 Monday Key Event

25% Conference 03 Sep 18 Monday Milestone

50% Conference 08 Oct 18 Monday Milestone

PCD 27 Oct 18 Saturday Key Event

Light Off Assessment 17 Nov 18 Saturday Milestone

Dock Trials 22 Nov 18 Thursday Key Event

Fast Cruise 23 Nov 18 Friday Key Event

Sea Trials 26 Nov 18 Monday Milestone

Complete Availability 27 Nov 18 Tuesday Key Event

C-5 CONTRACT DATA REQUIREMENTS LISTS

Awardee shall submit the following:

. Submit the Critical Path Work Items in Work Breakdown Structure (WBS) format with an emphasis on trades and man hours at least ten (10) days prior to the start of the period of performance (POP).

2. Submit the Manning Curves for other Government projects, including Coast Guard, IAW NAVSEA Standard

Item 009-60 paragraph 3.6 at least ten (10) days prior to the start of the period of performance (POP).

3. Provide the Total Project Float and individual work item float IAW NAVSEA Standard Item 009-60 paragraph at least ten (10) days prior to the start of the period of performance (POP).

4. Provide the Quality Management Test and Inspection Plan IAW NAVSEA Standard Item 009-04 for all contracted production work at least ten (10) days prior to the start of the period of performance (POP).

5. Provide the Ship Departure Report IAW NAVSEA Standard Item 009-99 within 60 days of completion of the period of performance (POP).

6. Provide the Comprehensive Test Plan IAW NAVSEA Standard Item 009-67 at least fifteen (15) days prior to the start of the POP.

7. All reports will require legible copy of a report in English, in hard copy and electronic media.

*Instructions for the content of the Critical Path Work Items in Work Breakdown Structure format are as follows:

a. Definitions:

Critical Path: That sequence of industrial activities which form the longest duration, and directly affects the completion of the availability. Factors in determining critical path are: time duration required for the activity, space limitations, manpower available, and the interface between Work Item activities.

Controlling Work Items: Those Work Items which are on the critical path and/or those Work Items which, by virtue of scope, material requirements, complexity, or other considerations, have the potential for impact on the scheduled project key events or completion of the availability

Network: A graphic display showing the planned sequence and interdependent relationship of activities, milestones, or key events within the contract.

b. Instructions:

Prepare a time-oriented work package network in Gantt chart format that displays critical path Work Items and controlling Work Items, key events, milestones, and Work Items that interrelate with controlling Work Items.

Display critical path and controlling Work Items at the activity level.

The network may be partitioned into sub-networks by key events, milestones, ship's system, ship area, or other logical divisions.

The following data elements are required to allow for filtering and sorting for ad hoc extraction of network data.

These data elements shall be entered at the Work Item activity level or the lowest Work Breakdown Structure

(WBS) activity level, as appropriate. These data elements shall include but are not limited to:

Data Element Description

Alteration Number Ship Alteration Number

Component Component Unit (tank, valve, motor, pump, etc.)

Hot Work Yes or No (Yes, if hot work is associated with task)

JCN JCN (filter on work center)

Key Event Key Event or Milestone

Key Trade Key Trade involved in task

Location Work location/compartment number (deck/frame/Port or Stbd)

Executing Activity MSR/Contractor/Subcontractor/AIT/CIS/etc.

SWLIN SWLIN (filter: 123, 221, 253, 533, etc.)

System System(s) affected (FM, HAB, CHT, JP5, etc.)

Title Search for text in Work Item or Task title

Work Item Number 4-E specification Work Item number

Superintendent or Zone Manager Responsible Superintendent or Zone Manager

SBS Responsible Ship Building Specialist

The network or any sub-network thereof may be continued on additional pages. Each page of the network or sub-networks shall be clearly identified and show all off page interdependencies.

Label each Work Item, activity, milestone, and key event of the network with the activity or event identifier (ID) and title.

**Instructions for the content of the Manning Curves for other FLC contracted projects are as follows:

Develop individual key trade manpower curves showing proposed manning by trade throughout the contract period in men per day. The curves shall indicate that portion of the total that is subcontractor provided.

***Instructions for the content of the Quality Management Test and Inspection plan are as follows:

Required tests shall include but are not limited to: hydrostatic, operational, weight and safety device tests by the work item. List scheduled start and finish dates for each test. The list of tests shall be incorporated into the

Quality Management Plan submission. The Quality Management Plan should encompass the quality system utilized by the contractor to prove its work to the government

The Quality Management plan will define requirements of both the Contractor and Government for general and special purpose test equipment, and test weights, to accomplish ship system testing. The Contractor shall identify known and anticipated deficiencies in required type, quantity, calibration, or availability that will support the production schedule.

In addition to the above and after contract award, the awardee shall submit the following documents:

1) Awarded contractor must submit the final production schedule ten (10) days after award or at least five days prior to start of availability whichever date is first.

2) Awarded contractor must submit Process Control Procedures (PCP) document no later than 14 days prior to start of the required process.

3) All NAVSEA Category 1 standard work items shall be invoked in the execution.

4) NAVSEA standard item FY19 Change 1 will be applicable as Standard items are invoked for this SRA availability.

INDEMNIFICATION FOR ACCESS TO VESSEL

Notwithstanding any provision in the “ACCESS TO VESSEL” clause (DFARS 252.217-7011), or any other clause of the contract, the Contractor agrees to allow officers, employees, and associates of the Government, or other prime contractors with the Government and their subcontractors, and officers, employees, and associates of offerors on other contemplated work, admission to the Contractor’s facilities and access to the vessel without any further request for indemnification from any party, which has not been previously included in the contract price.

MANAGEMENT AND DISPOSAL OF HAZARDOUS WASTE

(a) GENERAL

(1) The Contractor shall comply with the Resource Conservation and Recovery Act (RCRA), the

Comprehensive Environmental Response, Compensation, and Liability Act of 1980 (CERCLA), 10 U.S.C. 7311 and all other applicable Federal, State and local laws, codes, ordinances and regulations for the management and disposal of hazardous waste.

(2) Compensation – This contract includes an amount of work performed by the Contractor for duties of the

Contractor regarding hazardous waste specified under this requirement and Item No. 023 of the contract

(3) Nothing contained in this special contract requirement shall relieve the Contractor from complying with applicable Federal, State, and local Laws, codes, ordinances, and regulations, including obtaining licenses and permits, giving notices and submitting reports, in connection with hazardous waste management and disposal in the performance of this contract. Nothing contained herein shall serve to alter either party's liability or responsibility under CERCLA.

(4) Materials contained in ship systems are not waste until after removal from the system.

(b) IDENTIFICATION OF HAZARDOUS WASTES

Specification item 023 of this contract identifies the types and amounts of hazardous wastes that are required to be removed by the Contractor, or that are expected to be generated, during the performance of work under this contract.

(c) GENERATOR IDENTIFICATION NUMBERS

(1) Documentation related to hazardous waste generated solely by the physical actions of ship's force or Navy employees on board the vessel shall only bear a generator identification number issued to the Navy pursuant to applicable law.

(2) Documentation related to hazardous waste generated solely by the physical actions of Contractor personnel shall only bear a generator identification number issued to the Contractor pursuant to applicable law. Regardless of the presence of other materials in or on the shipboard systems or structures which may have qualified a waste stream as hazardous, where the Contractor performs work on a system or structure using materials (whether or not the use of such materials was specified by the Navy) which by themselves would cause the waste from such work to be a hazardous waste, documentation related to such waste shall only bear a generator identification number issued to the

Contractor.

(3) Documentation related to hazardous waste generated by the combined physical actions of Navy and

Contractor personnel shall bear a generator identification number issued to the Contractor pursuant to applicable law and shall also cite in the remarks block a generator identification number issued to the Navy pursuant to applicable law.

(4) Notwithstanding paragraphs (c)(1) - (c)(3) above, hazardous wastes are considered to be co-generated in cases where: (a) the Contractor merely drains a system and such drainage creates hazardous waste or (b) the

Contractor performs work on a system or structure using materials which by themselves would not cause the waste from such work to be hazardous waste but such work nonetheless creates a hazardous waste. Documentation related to such co-generated waste shall bear a generator identification number in accordance with the provisions of paragraph (c)(3) above.

(5) In the event of a failure by the parties to agree to the assignment of a generator identification number to any hazardous waste as set forth in paragraphs (c)(1) through (c)(4) above, the Government may direct which party or parties shall provide generator identification numbers for the waste and such number(s) shall be used on all required documentation. Any disagreement with this direction shall be a dispute within the meaning of clause of this contract entitled "DISPUTES" (FAR 52.233-1). However, the Contractor shall not stop any work but shall continue with performance of all work under this contract as specified in the "DISPUTES" clause.

(6) Hazardous Waste Manifests For wastes described in (c)(2), (c)(3), and (c)(4) above (and (c)(5) as applicable), the Contractor shall sign the generator certification on the Uniform Hazardous Waste Manifest whenever use of the Manifest is required for disposal. The Contractor shall obtain concurrence with the categorization of wastes under paragraphs (c)(3) and (c)(4) above before completion of the manifest. Manifests prepared pursuant to paragraph (c)(1) above shall be presented to the Contracting Officer for completion after the hazardous waste has been identified.

(7) For purposes of paragraphs (c)(2) and (3) herein, if the Contractor, while performing work at a Government facility, cannot obtain a separate generator identification number from the State in which the availability will be performed, the Contractor shall notify the Contracting Officer 3 business days of receipt of written notification by the State. After obtaining Contracting Officer approval, the Contractor shall use the Navy site generator identification number and insert in the remarks block the contractor generator identification number issued for the site where his main facilities are located. For purposes of paragraph (c)(1) herein, if the work is being performed at a contractor facility and the Government cannot obtain a separate generator identification number for the State, the

Government shall use the Contractor site generator identification number and shall cite in the remarks block a Navy generator identification number. In both instances described above, the Contractor shall prepare the Uniform

Hazardous Waste Manifest described in paragraph (c)(6) above and present it to RMC for completion.

(End of Summary of Changes)