Exhibit_P_RAAF-OY6_Part_A_CDRLs.pdf

Data Requirements List (DD 1423’s) for

Airframe Depot Maintenance of United States Navy

P-8A Poseidon Aircraft

Exhibit P

Contract Data Requirements List (DD 1423’s)

18 May 2016

EXHIBIT P – OY6 CDRLs (RAAF)

DIN TITLE SUBTITLE

P001 RESERVED

P002 RESERVED

P003 RESERVED

P004 RESERVED

P005 RESERVED

P006 RESERVED

P007 RESERVED

P008 RESERVED

P009 Scientific and Technical Reports RAAF Structural Alteration Report

P00A RESERVED

P00B Scientific and Technical Reports RAAF Aircraft Mishap Damage Report

P00C RESERVED

P00D Scientific and Technical Reports RAAF Depot/In-field Completion Report

P00E RESERVED

P00F Engineering Services Memorandum (ESM) RAAF Aircraft Field Assessment Report

P00G RESERVED

P00H Quality Deficiency Report RAAF Deficiency Reporting

P00J Scientific and Technical Reports RAAF Delay Notification Report

P00K RESERVED

P00L Scientific and Technical Reports RAAF Initial Assessment Report

P00M RESERVED

P00N RESERVED

P00P Internal Contractor Technical Data RAAF Utilization Approval of Used, Rebuilt, Report RAAF Overhauled Parts

P00Q Over and Above Status Report RAAF Status Report

P00R Sustainment Functional Cost-Hour Report RAAF Contractor Cost Data Reporting (CC

P00S Cost Data Summary Report (DD1921) RAAF Contractor Cost Data Reporting (CCDR)

P00T Contractor Work Breakdown Structure RAAF CWBS Dictionary

CONTRACT DATA REQUIREMENTS LIST Form Approved (1 Data Item) OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:

TDP TM OTHER

D. SYSTEM|ITEM E. CONTRACT/PR NO. F. CONTRACTOR

1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE 17. PRICE

GROUP

P001

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18. ESTIMATED

TOTAL PRICE

7. DD 250 REQ 9. DIST STATEMENT

REQUIRED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

Reg Repr

16. REMARKS

RESERVED

15. Total 1

G. PREPARED BY H. DATE I. APPROVED BY J. DATE

DD FORM 1423-1, JUN 90 (EG) Previous editions are obsolete Page 1 of 1 Pages

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:

1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE

P002

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

Reg Repr

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

P003

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

TOTAL

PRICE

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

Reg Repr

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

P004

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

Reg Repr

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

P005

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

Reg Repr

Don Griffin P-8A Airframe Commercial Depot IPT Lead

Derick Diaz P-8A Aircraft Systems IPTL

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

P006

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

Reg Repr

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

P007

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

Reg Repr

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

P008

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

Reg Repr

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:

6037 P

MISC

P-8A Poseidon Depot Maintenance- Airframe

TBD TBD

1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE 17. PRICE

GROUP

P009 Scientific and Technical Report RAAF Structural Alteration Report

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

TOTAL

PRICE

DI-MISC-80711A (See Block 16) SOW 3.6, 3.8, 4.1.4 6, 4.2.2, 5.3.4.4

6.4. PMA-290

7. DD 250 REQ 9. DIST STATEMENT

REQUIRED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

LT ASREQ See Block 16 b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

A D N/A See Block 16 Reg Repr

16. REMARKS See Block 16 1

BLOCK 4: Items to be included in the report are as follows (if applicable):

• Technical description of the completed assessment and repair including

Aircraft BUNO, component serial number and location during repair, induction date, repair type, repair work, other.

• List of nomenclature/part number(s)/material used in the repair

• Contractor labor codes/titles and associated hours as well as days for repair

• Applicable weight and balance information

• Certificates of compliance or completion

• Other applicable items or remarks of note

• FAA Form 337 / FAA Form 8130-3 (as required)

• Aircraft Inventory Record (AIR) OPNAV 4790/111 (MRO)

• Acceptance Test results (as required)

BLOCK 8: Government comments will be provided to the contractor NLT 30 days after receipt of contractor submittal. Revised contractor submittal shall be provided within 30 days after receipt of Government comments.

BLOCKS 12 & 13: Due NLT 15 days following Government acceptance of aircraft.

BLOCK 14: All deliverables shall be delivered via the AMRDEC website along with 1 CD ROM to the MPRA Library. If the AMRDEC is not available, the Contractor shall ensure the delivery of electronic media via CD ROM to the PMA-290 Data Manager sent via overnight mail..

Don Griffin P-8A Airframe Commercial Depot IPT Lead

Donnie LaRocco

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:

P00A

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

Reg Repr

15. Total

DD FORM 1423-1, JUN 90 (EG) Previous editions are obsolete 1 of of 1 Pages

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:

6037 P

Airframe

TBD TBD

1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE 17. PRICE

GROUP

P00B Scientific and Technical Reports RAAF Aircraft Mishap Damage Report

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

TOTAL

PRICE

DI-MISC-80711A (See Block 16) SOW 8.15 PMA-290

7. DD 250 REQ 9. DIST STATEMENT

REQUIRED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

LT ASREQ See Block 16 b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

N/A D N/A ASREQ Reg Repr

16. REMARKS See Block 16 1

BLOCK 4: Report shall include the following:

• Identify and report nature of mishap

• Provide information necessary to complete mishap data report specified in OPNAV Instruction 3750.6 series (worksheet)

• Estimated material cost to repair damage

• Estimated labor hours and other direct costs to repair the aircraft

• Estimated date to make aircraft serviceable

BLOCK 12: Due 6 hours after aircraft mishap and the Contractor shall report by phone any accident or incident to COR/TPOC.

BLOCK 14: All deliverables shall be delivered via the AMRDEC website along with 1 CD ROM to the MPRA Library. If the AMRDEC is not available, the Contractor

Manager sent via overnight mail.

Don Griffin P-8A Airframe Commercial Depot IPT Lead

Donnie LaRocco

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

P00C

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

Reg Repr

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:

6037 P

Airframe

TBD TBD

1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE 17. PRICE

GROUP

P00D Scientific and Technical Reports RAAF Depot/In-Field Completion Report

TOTAL

PRICE

DI-MISC-80711A (See Block 16) SOW 3.6, 4.1.5.1, 4.1.5.3,4.2.2 ,4.3, 4.4, 5.3.4.1, 6.4, 8.20 PMA-290

7. DD 250 REQ 9. DIST STATEMENT

REQUIRED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

LT ASREQ See Block 16 b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

N/A D N/A See Block 16 Reg Repr

BLOCK 4: Contractor format is acceptable. Report shall contain:

1. Complete list of all maintenance performed on the aircraft while at Depot facility or In-field.

2. FAA Form 337 / FAA Form 8130-3 (as required)

3. All warranty documentation, if applicable.

4. Government/Commercial log book, entries.

5. Weight and Balance Documentation, IAW NA 01-1B-50 as required.

6. All over & above completed.

7. Noted but Not Corrected (NBNC)

8. Parts Required Report (PRR)

BLOCKS 12 & 13: Report due at the time of government acceptance of aircraft.

BLOCK 14: All deliverables shall be delivered via the AMRDEC website along with 1 CD ROM to the MPRA Library. If the AMRDEC is not available, the Contractor

Manager sent via overnight mail..

Don Griffin P-8A Airframe Commercial Depot IPT Lead

Donnie LaRocco

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

P00E

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

Reg Repr

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:

6037 P

Airframe

TBD TBD

1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE 17. PRICE

GROUP

P00F Engineering Services Memorandum (ESM) RAAF Aircraft Field Assessment /Repair Report

TOTAL

PRICE

DI-MISC-80748 (See Block 16) SOW 6.1 PMA-290

7. DD 250 REQ 9. DIST STATEMENT

REQUIRED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

LT ASREQ See Block 16 b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

N/A D N/A See Block 16 Reg Repr

16. REMARKS See Block 16 1

BLOCK 4: Deliver in a Microsoft Office format (2010 or later); such as, Excel or Access.

Report shall include:

• Date of submittal

• Aircraft Assessment Date

• Component Serial Number

• Aircraft BUNO

• Shipping Activity (FRC/MALS)

• Primary failure item nomenclature

• Primary failure item part number

• Primary failure item failure mode

• Major Structural Repairs

• All temporary structural repairs

• Need for proposed work

• Description of findings/comments (including major discrepancies/work to be performed and resulting benefits)

• Estimated cost/BOE for engineering, materials and equipment and/or services with FAR required proposal supporting documentation and information

• GFE required

• Estimated turn-around time (TAT) and completion date

• Signature/Title

BLOCKS 12 & 13: Due within 4 working days after assessment personnel arrival at the aircraft site, unless significant damage requires further negotiation.

BLOCK 14: All deliverables shall be delivered via the AMRDEC website along with 1 CD ROM to the MPRA Library. If the AMRDEC is not available, the Contractor

Don Griffin P-8A Airframe Commercial Depot IPT Lead

Donnie LaRocco

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

P00G

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

Reg Repr

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:

6037 P

QCIC

Airframe

TBD TBD

1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE 17. PRICE

GROUP

P00H Quality Deficiency Report RAAF Deficiency Reporting

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

TOTAL

PRICE

DI-QCIC-80736 (See Block 16) SOW 8.14 PMA-290

7. DD 250 REQ 9. DIST STATEMENT

REQUIRED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

LT ASREQ See Block 16 b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

N/A D N/A See Block 16 Reg Repr

16. REMARKS See Block 16 1

BLOCK 4: Deliver in a Microsoft Office format (2010 or later); such as, Word, Excel or Access.

The investigation Report should include, at a minimum, the following data:

• Identify and report deficiency of item

• Identify and report the cause of deficiency for that item

• Recommendations to the Government to alleviate future failures of item

• Manufacture’s recommendations for the correction of deficiency

• Information from the following reports submitted against defective items manufactured, repaired, or overhauled by the Contractor or a Sub- Contractor including vendor parts issued through the On-Site Storeroom:

a. Product Quality Deficiency Report (PQDR)

b. Engineering Investigation (EI)

c. Material Deficiency Report (MDR)

d. Acceptance Inspection Deficiency Report (AIDR)

e. Aircraft Deficiency Report (ADR)

f. Hazardous Material Report (HMR)

g. Technical Publication Deficiency Report (TPDR)

BLOCK 12: Due 30 days after investigation request

BLOCK 13: Due monthly to arrive at PMA-290 NLT the last day of the month, until investigation completion.

BLOCK 14: All deliverables shall be delivered via the AMRDEC website along with 1 CD ROM to the MPRA Library. If the AMRDEC is not available, the Contractor

Don Griffin P-8A Airframe Commercial Depot IPT Lead

Donnie LaRocco

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:

6037 P

Airframe

TBD TBD

1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE 17. PRICE

GROUP

P00J Scientific and Technical Report RAAF Delay Notification Report

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

TOTAL

PRICE

DI-MISC-80711A (See Block 16) SOW 3.5 PMA-290

7. DD 250 REQ 9. DIST STATEMENT

REQUIRED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

LT ASREQ See Block 16 b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

A D N/A See Block 16 Reg Repr

16. REMARKS See Block 16 1

BLOCK 4: The Contractor shall deliver an initial Impact Assessment Report detailing estimated TAT following completion of the initial inspection/assessment.

The Contractor shall utilize the established Delay Notification Process. This process uses the DNF to document delays during modification or maintenance activity. The DNF details changes in the delivery schedule (TAT) associated with excusable delays as outlined in FAR 52.249-14, including contractor caused delays, duration-based delays, and hours-based delays as calculated per Attachment 7.

The Delay Notification shall include: the relevant contractor Notification Form (DNF) and a technical narrative describing the causes of the impact with relevant backup documentation as follows:

-Funding Related Delays: Contract Letter submitted in accordance with FAR 52.249-14 to request additional funding and any subsequent letters related to work delays or stoppages.

-Parts and GFM Related Delays: Based upon scheduled start date from associated work ticket.

-Warranty Claims - Contract Letter submitted to document warranty claims on

GFE/GFM

Continued next page

Don Griffin P-8A Airframe Commercial Depot IPT Lead

Donnie LaRocco P-8A Aircraft Systems IPTL

DD FORM 1423-1, JUN 90 (EG) Previous editions are obsolete Page 1 of 1 Pag es

6037 P

Airframe

TBD TBD

16. REMARKS (Continued) (P00J)

Late Contract Changes - Contract Letters and Contract Modifications to document changes or late award of additional scope.

-Contractor Caused Delays -Contractor will provide relevant documentation to explain the reason for delay. No TAT relief will be granted for these delays.

BLOCK 12: First submission will be at within 10 days of discovering delays to the original established TAT as determined by the Initial Impact Assessment, of the aircraft. Extensions may be requested pending completion of the AEPD Inspections.

BLOCK 13: Subsequent submissions will be as required, but not to exceed monthly, with a Final Impact Assessment submitted within 30 Days of DD250 of the aircraft. The final impact assessment shall include Over and Above related delays.

The contractor will provide all over and above completed documented in CDRL A00Q, the Over and Above Status report. TAT extensions shall be granted based upon the total number of O&A s negotiated. The final impact assessment will also include a summary of all duration based delays.

BLOCK 14: All deliverables shall be delivered via the AMRDEC website along with 1 CD ROM to the MPRA Library. If the AMRDEC is not available, the Contractor shall ensure the delivery of electronic media via CD ROM to the PMA-290 Data

Don Griffin P-8A Airframe Commercial Depot IPT Lead

Donnie LaRocco

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

P00K

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

Reg Repr

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:

6037 P

Airframe

TBD TBD

1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE 17. PRICE

GROUP

P00L Scientific and Technical Report RAAF Initial Assessment Report

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

TOTAL

PRICE

DI-MISC-80711A (See Block 16) SOW 3.3, 4.1.2. PMA-290

7. DD 250 REQ 9. DIST STATEMENT

REQUIRED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

LT ASREQ See Block 16 b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

A D N/A ASREQ Reg Repr

16. REMARKS See Block 16 1

BLOCK 4: Contractor format acceptable The Contractor shall deliver the following information for each aircraft: contract number, delivery order number, bureau number, contractual induction date, actual induction date, O&A hours expended to date, O&A hours estimated at completion, contractual delivery date, estimated delivery date, schedule impacts (with a narrative to explain reason for impacts), proposed material cost, number of DRs negotiated, number of DRs to be negotiated, total DRs, list of major discrepancies, and list of minor discrepancies.

BLOCK 8: Government comments will be provided to the contractor NLT 30 days after receipt of contractor submittal. Revised contractor submittal shall be provided within 30 days after receipt of Government comments.

BLOCK 12: The Contractor shall deliver the report no later than 10 days after the completion of the AEPD look phase.

BLOCK 14: All deliverables shall be delivered via the AMRDEC website along with 1 CD ROM to the MPRA Library. If the AMRDEC is not available, the Contractor

Don Griffin P-8A Airframe Commercial Depot IPT Lead

Donnie LaRocco

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

P00M

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

Reg Repr

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

P00N

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

Reg Repr

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:

6037 P

SESS

D. SYSTEM|ITEM

E. CONTRACT/PR NO. F. CONTRACTOR

P-8A Poseidon Depot Maintenance-Airframe

TBD TBD

P00P Internal Contractor Technical Data Report RAAF Utilization Approval of Used, Rebuilt, Overhauled Parts

TOTAL

PRICE

DI-SESS-81309A (See Block 16) SOW 8.11.1 PMA-290

7. DD 250 REQ 9. DIST

STATEMENT

REQUIRED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

LT ASREQ See Block 16 b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

A D N/A See Block 16 Reg Repr

16. REMARKS See Block 16 1 1

BLOCK 4: Items to be included in the report are as follows (if applicable):

• Approved FAA Form 8130-3

• Complete set of all maintenance, inspection, and service usage records including accumulated cycles / hours and operators

• Service life remaining for any life-limited part

BLOCK 8: Government comments will be provided to the contractor NLT 30 days after receipt of contractor submittal. Revised contractor submittal shall be provided within 30 days after receipt of Government comments.

BLOCKS 12 & 13: Due NLT 15 days following Government acceptance of each engine.

BLOCK 14: All deliverables shall be delivered via the AMRDEC website along with 1 CD ROM to the MPRA Library. If the AMRDEC is not available, the Contractor shall ensure the delivery of electronic media via CD ROM to the PMA-290 Data Manager sent via overnight mail.

15. Total 1 1

Don Griffin P-8A Airframe Commercial Depot IPT Lead

Donnie LaRocco

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:

6037 P

MGMT

Airframe

TBD TBD

1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE 17. PRICE

GROUP

P00Q Over and Above Status Report RAAF Status Report

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18.

ESTIMATED

TOTAL

PRICE

DI-MGMT-80368A (See Block 16) SOW 7.13.1 PMA-290

7. DD 250 REQ 9. DIST STATEMENT

REQUIRED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

LT 30 DAC See Block 16 b. COPIES

8. APP CODE 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

N/A D N/A MONTHLY Reg Repr

16. REMARKS See Block 16 1

BLOCK 4: Deliver in a Microsoft Office format (2010 or later); such as, Excel or Access.

The Contractor shall provide Contractor Monthly Status Report submittals per DID DI-MGMT-80368A with the following exceptions; paragraphs 3.2.1, 3.2.2 and 3.2.3 are not applicable.

Report shall include:

• Tasks completed since last report.

• New tasks started since last report.

• Total projected man hours for each uncompleted task on report

• Total man hours performed on completed tasks

• Estimated completion dates for work in progress

BLOCK 8: Government comments will be provided to the contractor NLT 10 days after receipt of contractor submittal. Revised contractor submittal shall be provided within 10 days after receipt of Government comments or in the next scheduled submission.

BLOCK 12: First submission required 30 calendar days from receipt of first Task Order

BLOCK 14: All deliverables shall be delivered via the AMRDEC website along with 1 CD ROM to the MPRA Library. If the AMRDEC is not available, the Contractor

Don Griffin P-8A Airframe Commercial Depot IPT Lead

Donnie LaRocco

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract PR No. listed in Block E.

A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:

6037 P

FNCL

Airframe

TBD

1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE 17. PRICE

GROUP

P00R Sustainment Functional Cost-Hour Report

(DD1921-5)

RAAF Contractor Cost Data Reporting (CCDR)

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18. ESTIMATED

DI-FNCL-81992 (See Block 16) SOW 7.13.2 NAVAIR 4.2

7. DD 250 REQ 9. DIST STATEMENT

REQUIRED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

LT See Block 16 See Block 16 b. COPIES

8. APP CODE See Block 16 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

N/A See Block 16 See Block 16 Reg Repr

Blocks 10 - 13: Prepare the Sustainment Functional Cost Hour Report (SFCHR) in accordance with DI-FNCL-81992 (or the most recently approved version) and the OSD Deputy Director, Cost Assessment (DDCA)-approved contract CSDR Plan.

The DID, DI-FNCL-81992, is available from the Defense Cost and Resource Center (DCARC) website at http://cade.osd.mil/csdr/FormsReporting.aspx#DIDs. The CSDR Plan is included as a contract attachment 18.

Contractors shall be required to submit the Contractor Cost Data Reports (CCDRs) at frequencies specified in the OSD DDCA-approved CSDR plan and in the contract. The contract CSDR plan uses the event field as the driver for the submission of the reports, not the "as of date." If the event slips, the contractor must notify the Government Program Office that a date change is needed. It is the responsibility of the Government Program Office to submit a request for change in the event-driven date for reporting through the CSDR Submit- Review system for DCARC approval before the date reflected in the OSD DDCA-approved CSDR Plan.

All CCDRs shall be submitted electronically using the CSDR Submit-Review System. The required form and file type for each CCDR is specified in its Data Item Description (DID). Data submitters must register through the DCARC website and possess a DoD-approved ECA digital certificate or DoD-issued CAC to obtain a DCARC Portal account and be authorized to upload CSDR content. Users can obtain access by submitting user information about themselves and their organizations to the DCARC Portal and requesting a CSDR submitter user role. After the registration information has been verified, the DCARC shall authorize the user account and requested roles. All DCARC Portal accounts need to be renewed at least annually.

Subcontractor Reporting: Prime contractors are responsible for flowing down CSDR requirements contained in their prime contracts to all subcontractors who meet the reporting thresholds specified in the DoDI 5000.02, or as required by the CWIPT. This includes requiring subcontractors to electronically report directly to the DCARC using the CSDR Submit-Review System. The prime contractor shall be required to work with the CWIPT and all appropriate subcontractors to prepare separate subcontract CSDR plans for submission to the DCARC for DDCA approval.

DCARC

R L Gage P-8A IPS/O&S Cost Team Lead

Donnie LaRocco http://cade.osd.mil/csdr/FormsReporting.aspx#DIDs

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract PR No. listed in Block E.

A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:

6037 P

Airframe

TBD

1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE 17. PRICE

GROUP

P00S Cost Data Summary Reporting (DD1921) Contractor Cost Data Reporting

(CCDR)

4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18. ESTIMATED

DI-FNCL-81565C (See Block 16) SOW 7.13.2 NAVAIR 4.2

7. DD 250 REQ 9. DIST STATEMENT

REQUIRED

10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION

LT See Block 16 See Block 16 b. COPIES

8. APP CODE See Block 16 11. AS OF DATE 13. DATE OF SUBSEQUENT

SUBMISSION

a. ADDRESSEE DRAFT FINAL

N/A See Block 16 See Block 16 Reg Repr

16. REMARKS See Block 16 1

Blocks 10 - 13: Prepare the Cost Data Summary Report (CDSR) in accordance with DI-FNCL-81565C (or the most recently approved version) and the OSD Deputy Director, Cost Assessment (DDCA)-approved contract CSDR Plan. The DID, DI-FNCL-81565C, is available from the Defense Cost and Resource Center (DCARC) website at http://cade.osd.mil/csdr/FormsReporting.aspx#DIDs . The CSDR Plan is included as a contract attachment 18.

Contractors shall be required to submit the Contractor Cost Data Reports (CCDRs) at frequencies specified in the OSD…