Exhibit_AG_FMS-OP1_Part_A_CDRLs.docx

Data Requirements List (DD 1423’s) for

Airframe Depot Maintenance of United States Navy P-8A Poseidon Aircraft

Foreign Military Sales Exhibit AG

Contract Data Requirements List (DD 1423’s) 18 May 2016

EXHIBIT B – IDIQ CDRLs (RAAF)

DIN TITLE SUBTITLE

CONTRACT DATA REQUIREMENTS LIST

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

TDP

TM

OTHER

X XXXX

17. PRICE GROUP

AG01

18. ESTIMATED TOTAL PRICE

b. COPIES

8. APP CODE

16. REMARKS

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

AG02

b. COPIES

8. APP CODE

16. REMARKS

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

X

17. PRICE GROUP

AG03

18. ESTIMATED TOTAL PRICE

b. COPIES

8. APP CODE

16. REMARKS

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

X

17. PRICE GROUP

AG04

18. ESTIMATED TOTAL PRICE

b. COPIES

8. APP CODE

16. REMARKS

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

X

17. PRICE GROUP

AG05

18. ESTIMATED TOTAL PRICE

b. COPIES

8. APP CODE

16. REMARKS

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

X

17. PRICE GROUP

AG06

18. ESTIMATED TOTAL PRICE

b. COPIES

8. APP CODE

16. REMARKS

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

X

17. PRICE GROUP

AG07

18. ESTIMATED TOTAL PRICE

b. COPIES

8. APP CODE

16. REMARKS

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

X

17. PRICE GROUP

AG08

18. ESTIMATED TOTAL PRICE

b. COPIES

8. APP CODE

16. REMARKS

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

TM

OTHER

MISC

X

17. PRICE GROUP

18. ESTIMATED TOTAL PRICE

LT

b. COPIES

8. APP CODE

BLOCK 4: Items to be included in the report are as follows (if applicable):

· Technical description of the completed assessment and repair including Aircraft BUNO, component serial number and location during repair, induction date, repair type, repair work, other.

· List of nomenclature/part number(s)/material used in the repair

· Contractor labor codes/titles and associated hours as well as days for repair

· Applicable weight and balance information

· Certificates of compliance or completion

· Other applicable items or remarks of note

· FAA Form 337 / FAA Form 8130-3 (as required)

· Aircraft Inventory Record (AIR) OPNAV 4790/111 (MRO)

· Acceptance Test results (as required)

BLOCK 8: Government comments will be provided to the contractor NLT 30 days after receipt of contractor submittal. Revised contractor submittal shall be provided within 30 days after receipt of Government comments.

BLOCKS 12 & 13: Due NLT 15 days following Government acceptance of aircraft.

BLOCK 14: All deliverables shall be delivered via the AMRDEC website along with 1 CD ROM to the MPRA Library. If the AMRDEC is not available, the Contractor shall ensure the delivery of electronic media via CD ROM to the PMA-290 Data Manager sent via overnight mail..

15. Total

Don Griffin P-8A Airframe Commercial Depot IPT Lead

Donnie LaRocco P-8A Aircraft Systems IPTL

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

TM

OTHER

SESS

X

17. PRICE GROUP

18. ESTIMATED TOTAL PRICE

LT

b. COPIES

A

BLOCK 4: Shall include all items specified in DI-SESS-80776A (if applicable).

BLOCK 8: Government comments will be provided to the contractor NLT 30 days after receipt of contractor submittal. Revised contractor submittal shall be provided within 30 days after receipt of Government comments.

BLOCKS 12 & 13: The contractor shall deliver the Technical Data Package no later than 5 days after completion.

BLOCK 14: All deliverables shall be delivered via the AMRDEC website along with 1 CD ROM to the MPRA Library. If the AMRDEC is not available, the Contractor shall ensure the delivery of electronic media via CD ROM to the PMA-290 Data Manager sent via overnight mail.

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

17. PRICE GROUP

AG0B

18. ESTIMATED TOTAL PRICE

b. COPIES

8. APP CODE

16. REMARKS

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

X

17. PRICE GROUP

AG0C

18. ESTIMATED TOTAL PRICE

b. COPIES

8. APP CODE

16. REMARKS

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

TM

OTHER

MISC

X

17. PRICE GROUP

18. ESTIMATED TOTAL PRICE

LT

b. COPIES

8. APP CODE

BLOCK 4: Contractor format is acceptable. Report shall contain:

1. Complete list of all maintenance performed on the aircraft while at Depot facility or In-field.

2. FAA Form 337 / FAA Form 8130-3 (as required)

3. All warranty documentation, if applicable.

4. Government/Commercial log book, entries.

5. Weight and Balance Documentation, IAW NA 01-1B-50 as required.

6. All over & above completed.

7. Noted but Not Corrected (NBNC)

8. Parts Required Report (PRR)

BLOCKS 12 & 13: Report due at the time of government acceptance of aircraft.

BLOCK 14: All deliverables shall be delivered via the AMRDEC website along with 1 CD ROM to the MPRA Library. If the AMRDEC is not available, the Contractor shall ensure the delivery of electronic media via CD ROM to the PMA-290 Data Manager sent via overnight mail..

15. Total

Don Griffin P-8A Airframe Commercial Depot IPT Lead

Donnie LaRocco

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

X

17. PRICE GROUP

AG0E

18. ESTIMATED TOTAL PRICE

b. COPIES

8. APP CODE

16. REMARKS

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

TM

OTHER

MISC

X

17. PRICE GROUP

18. ESTIMATED TOTAL PRICE

LT

b. COPIES

8. APP CODE

BLOCK 4: Deliver in a Microsoft Office format (2010 or later); such as, Excel or Access.

Report shall include:

· Date of submittal

· Aircraft Assessment Date

· Component Serial Number

· Aircraft BUNO

· Shipping Activity (FRC/MALS)

· Primary failure item nomenclature

· Primary failure item part number

· Primary failure item failure mode

· Major Structural Repairs

· All temporary structural repairs

· Need for proposed work

· Description of findings/comments (including major discrepancies/work to be performed and resulting benefits)

· Estimated cost/BOE for engineering, materials and equipment and/or services with FAR required proposal supporting documentation and information

· GFE required

· Estimated turn-around time (TAT) and completion date

· Signature/Title

BLOCKS 12 & 13: Due within 4 working days after assessment personnel arrival at the aircraft site, unless significant damage requires further negotiation.

BLOCK 14: All deliverables shall be delivered via the AMRDEC website along with 1 CD ROM to the MPRA Library. If the AMRDEC is not available, the Contractor shall ensure the delivery of electronic media via CD ROM to the PMA-290 Data Manager sent via overnight mail.

15. Total

Don Griffin P-8A Airframe Commercial Depot IPT Lead

Donnie LaRocco

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

X

17. PRICE GROUP

AG0G

18. ESTIMATED TOTAL PRICE

b. COPIES

8. APP CODE

16. REMARKS

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

TDP

TM

OTHER

X

17. PRICE GROUP

AG0H

18. ESTIMATED TOTAL PRICE

b. COPIES

8. APP CODE

16. REMARKS

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

TM

OTHER

MISC

X

17. PRICE GROUP

18. ESTIMATED TOTAL PRICE

LT

b. COPIES

8. APP CODE

BLOCK 4: The Contractor shall deliver an initial Delay Notification Report detailing estimated TAT following completion of the initial inspection/assessment.

The Contractor shall utilize the established Delay Notification Process. This process uses the DNF to document delays during modification or maintenance activity. The DNF details changes in the delivery schedule (TAT) associated with excusable delays as outlined in FAR 52.249-14, including contractor caused delays, duration-based delays, and hours-based delays as calculated per Attachment 7.

The Delay Notification shall include: the relevant contractor Notification Form (DNF) and a technical narrative describing the causes of the impact with relevant backup documentation as follows:

-Funding Related Delays: Contract Letter submitted in accordance with FAR 52.249-14 to request additional funding and any subsequent letters related to work delays or stoppages.

-Parts and GFM Related Delays: Based upon scheduled start date from associated work ticket.

-Warranty Claims - Contract Letter submitted to document warranty claims on GFE/GFM

Continued next page

15. Total

Don Griffin P-8A Airframe Commercial Depot IPT Lead

Donnie LaRocco

A. CONTRACT LINE ITEM NO.

TM

OTHER

MISC

X

16. REMARKS (Continued)

(AG0J)

Late Contract Changes - Contract Letters and Contract Modifications to document changes or late award of additional scope.

-Contractor Caused Delays -Contractor will provide relevant documentation to explain the reason for delay. No TAT relief will be granted for these delays.

BLOCK 12: First submission will be within 10 days of discovering delays to the original established TAT as determined by the Initial Impacted Assessment , based upon Estimate at Complete (EAC), of the aircraft. Extensions may be requested pending completion of the AEPD Inspections.

BLOCK 13: Subsequent submissions will be as required, but not to exceed monthly, with a Final Impact Assessment submitted within 30 Days of DD250 of the aircraft. The final impact assessment shall include Over and Above related delays. The contractor will provide all over and above completed documented in CDRL B00Q, Over and Above (O&A) Status Report. TAT extensions shall be granted based upon the total number of O&A Hours negotiated. The final impact assessment will also include a summary of all duration based delays.

BLOCK 14: All deliverables shall be delivered via the AMRDEC website along with 1 CD ROM to the MPRA Library. If the AMRDEC is not available, the Contractor shall ensure the delivery of electronic media via CD ROM to the PMA-290 Data Manager sent via overnight mail.

Don Griffin P-8A Airframe Commercial Depot IPT Lead

Donnie LaRocco

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

X

17. PRICE GROUP

AG0K

18. ESTIMATED TOTAL PRICE

b. COPIES

8. APP CODE

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

TM

OTHER

MISC

X

17. PRICE GROUP

18. ESTIMATED TOTAL PRICE

LT

b. COPIES

8. APP CODE

BLOCK 4: Contractor format acceptable The Contractor shall deliver the following information for each aircraft: contract number, delivery order number, bureau number, contractual induction date, actual induction date, O&A hours expended to date, O&A hours estimated at completion, contractual delivery date, estimated delivery date, schedule impacts (with a narrative to explain reason for impacts), proposed material cost, number of DRs negotiated, number of DRs to be negotiated, total DRs, list of major discrepancies, and list of minor discrepancies.

BLOCK 8: Government comments will be provided to the contractor NLT 30 days after receipt of contractor submittal. Revised contractor submittal shall be provided within 30 days after receipt of Government comments.

BLOCK 12: The Contractor shall deliver the report no later than 10 days after the completion of AEPD look phase.

BLOCK 14: All deliverables shall be delivered via the AMRDEC website along with 1 CD ROM to the MPRA Library. If the AMRDEC is not available, the Contractor shall ensure the delivery of electronic media via CD ROM to the PMA-290 Data Manager sent via overnight mail.

15. Total

Don Griffin P-8A Airframe Commercial Depot IPT Lead

Donnie LaRocco

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

X

17. PRICE GROUP

AG0M

18. ESTIMATED TOTAL PRICE

b. COPIES

8. APP CODE

16. REMARKS

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

17. PRICE GROUP

AG0N

18. ESTIMATED TOTAL PRICE

b. COPIES

8. APP CODE

16. REMARKS

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

TM

OTHER

X

D. SYSTEM|ITEM

17. PRICE GROUP

AG0P

18. ESTIMATED TOTAL PRICE

b. COPIES

8. APP CODE

16. REMARKS

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract|PR No. listed in Block E.

TM

OTHER

X

D. SYSTEM|ITEM

17. PRICE GROUP

AG0Q

18. ESTIMATED TOTAL PRICE

b. COPIES

8. APP CODE

16. REMARKS

RESERVED

15. Total

Form Approved

(1 Data Item)

OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget. Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract PR No. listed in Block E.

TM

OTHER

FNCL

X

17. PRICE GROUP

18. ESTIMATED TOTAL PRICE

LT

b. COPIES

N/A

Blocks 10 - 13: Prepare the Sustainment Functional Cost Hour Report (SFCHR) in accordance with DI-FNCL-81992 (or the most recently approved version) and the OSD Deputy Director, Cost Assessment (DDCA)-approved contract CSDR Plan.

The DID, DI-FNCL-81992, is available from the Defense Cost and Resource Center (DCARC) website at http://cade.osd.mil/csdr/FormsReporting.aspx#DIDs. The CSDR Plan is included as a contract attachment 18.

Contractors shall be required to submit the Contractor Cost Data Reports (CCDRs) at frequencies specified in the OSD DDCA-approved CSDR plan and in the contract.