Solicitation.doc

Section B - Supplies or Services and Prices

Construct Drop Arm Gate 12A

FFP

RECOVERY. THIS PROJECT IS FUNDED BY THE AMERICAN RECOVERY AND RENVESTMENT ACT (ARRA) Provide and install (2) 15-ft sliding gates with card reader on "T" Road just NW of existing Gate 12A. The security bar shall have a Department of State K8 Certification or better. This shall include all necessary foundation requirements for the installation. The security bar shall have a decorative fence securely mounted to it to match the adjacent 4-ft decorative fence in appearance (supplied under Project No. 09-1886-C). Contractor shall insure proper operation of gate after installation. Contractor shall provide power, fixtures and required wiring as needed for gate installation and supporting devices. Contractor shall provide suitable housings for outdoor use. Contractor shall provide and install Common Access Cards (CAC) readers manufactured by Synergistics, Inc. model number KSR1063SELH. Programming shall be done by the contractor. This effort shall be accomplished IAW the documents specified in Section J of this solicitation.

FOB: Destination

NET AMT

Section C - Descriptions and Specifications

PKJ C001 - ENGLISH LANGUAGE RE

PKJ C001 - ENGLISH LANGUAGE REQUIREMENTS

(a) Deliver all documents in the English language.

(b) Provide an English language speaking person during on-site visits, inspections, reviews, audits, and other similar activities.

(End of clause)

Section E - Inspection and Acceptance

PKJ E001 - INSPECTION AND ACCE

PKJ E001 - INSPECTION AND ACCEPTANCE

(IAW FAR 46.401(b) and 46.503)

Inspection and acceptance of the (Services/Supplies) will be performed at Wright-Patterson AFB OH by 88 ABW/CEC.

(End of Clause)

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLAUSES INCORPORATED BY REFERENCE

Section F - Deliveries or Performance

DELIVERY INFORMATION

NO CONTACT IDENTFIED

1450 LITTRELL RD

WRIGHT-PATTERSON AFB OH 45433-5209

FOB: Destination

F4F2AA

CLAUSES INCORPORATED BY REFERENCE

Section G - Contract Administration Data

PKJ G002 - CONTRACT HOLIDAYS

PKJ G002 - CONTRACT HOLIDAYS

(a) The prices/costs in Section B of the contract include holiday observances; accordingly, the Government will not be billed for such holidays, except when services are required by the Government and are actually performed on a holiday. Holidays in addition to those reflected in this contract, which are designated by the Government, will be billable provided the assigned Contractor employee was available for performance and was precluded from such performance.

(b) The following days are contract holidays: New Year’s Day; Martin Luther King’s Birthday; Presidents’ Day; Memorial Day; Independence Day; Labor Day; Columbus Day; Veteran’s Day; Thanksgiving Day; Christmas Day.

(End of Clause)

CLAUSES INCORPORATED BY FULL TEXT

88 CONS G-001, WIDE AREA WORK FLOW – RECEIPT AND ACCEPTANCE (WAWF-RA) ELECTRONIC INVOICING AND RECEIVING REPORT INSTRUCTIONS

1. Contractors shall submit invoices through WAWF-RA for payment. Submission of invoices via any other method shall delay payment. Hard copies of invoices are no longer acceptable methods of submission and may be returned to the contractor.

2. The contractor shall be paid after submission of a properly prepared invoice and after final inspection and acceptance by the Government. In accordance with DFARS 252.232-7003, use of electronic payment requests is mandatory. Wide Area Workflow – Receipt and Acceptance (WAWF-RA) is the Department of Defense system preferred choice for submission of electronic payment requests and receipt and acceptance documents. The following information will aid in the submission of an invoice through WAWF-RA.

3. Information regarding WAWF-RA is available on the Internet at https://wawf.eb.mil. Note that the Software Users Manual posted to WAWF-RA is an excellent source for information when completing the invoice submission process. WAWF-RA training is also available at http://www.wawftraining.com.

4. Invoices shall be submitted (Selection determined by the Contracting Officer by placing an X in the appropriate block):

a. [. .] After Delivery of Supplies or Services

b. [XX] Monthly (After Performance)

c. [. .] Quarterly (After Performance)

d. [. .] Semi-annually (After Performance)

e. [. .] Yearly (After Performance)

5. The following codes are required to properly route your invoices and/or receiving reports through WAWF-RA. Missing elements in the following areas may cause delays in the payment process.

a. ISSUE DATE: . .

b. CONTRACT NUMBER:FA8601-10-R-0017

c. DELIVERY ORDER NUMBER: . . (Note to contractor : Blank unless provided by the contracting officer )

d. CAGE CODE: . .

e. PAY OFFICE DODAAC: F03000

6. The contractor shall submit invoices using the following format for Payment Type. Be advised that only the selections noted below shall be used in the submittal process. the contractor shall sTRICTly aDhere TO THE selection noted below to avoid delays in the paymenT process. SUBMISSION OF INVOICE OTHER THAN THAT SPECIFIED BELOW MAY DELAY PAYMENT AND/OR CAUSE INVOICE TO BE RETURNED. Invoices must clearly delineate the cost to the respective Contract Line Item Number (CLIN) and sub-CLIN. (See FAR 4, DFARS 204.71 and AFMC FAR Supp 5304.71)

a. [. .] Invoice (Note to contractor: To be used ONLY if authorized by the Contracting Officer)

b. [. .] Invoice 2n1 (Services Only)

c. [XX] Construction Payment Invoice

d. [. .] Commercial Item Financing (Note to contractor: To be used ONLY if authorized by the Contracting Officer)

e. [. .] Performance Based Payment (Note to contractor: To be used ONLY if authorized by the Contracting Officer)

f. [. .] Progress Payments (Note to contractor: To be used ONLY if authorized by the Contracting Officer)

g. [. .] Receiving Report

h. [. .] Invoice and Receiving Report (COMBO)

Note: Inspection = . . (source, destination) Acceptance = . . (source, destination)

i. [. .] Public Voucher (Note to contractor: If no selection is specified above, contractor shall utilize the Invoice 2n1 (Services Only) format. Contact the Contracting Officer for clarification when in doubt on how to submit an invoice through Wide Area Work Flow. Also note that if the contractual document requires attachments to be submitted (e.g., a copy of a paid freight bill), this can be accomplished by following instructions under Software User’s Manual on the WAWF-RA site regarding “attachments”.

7. The following additional codes are required to properly route your invoices and/or receiving reports through WAWF-RA. Note that if errors are received in the creation of your document, stop and call the Contracting Officer for verification of code required. Also note that some fields shown may or may not be included depending upon the type of invoice created. An example of the fields required when submitting an invoice are provided:

a. ISSUE BY DODAAC: FA8601

b. ADMIN DODAAC: FA8601 (Note to contractor: This field may also be referred to as ADMIN BPN)

c. INSPECT BY DODAAC or BPN: F4F2AA EXT: . . (Note to contractor: These fields may be blank if not filled out by the contracting office, EXT may be blank even if the Inspect By DODAAC is shown.)

d. MARK FOR CODE: Leave Blank

e. SHIP TO CODE: F4F2AA EXT: . . (Note to contractor: EXT may be blank even if the first code here is shown. Also note this may also be referred to as Service Acceptor Code or Contracting Officer Code. In the future, this code may be referred to as BPN)

f. SHIP FROM CODE: Leave Blank

g. SHIPMENT NUMBER: (Note to contractor: This field is created and provided by the contractor. If no shipment number is completed in the WAWF process, the invoice number will be the default number.)

h. INVOICE NUMBER: (Note to contractor: This is the invoice number created and provided by the contractor)

i. ADDRESSES TAB (Note to contractor: WAWF-RA will pre-populate the address information, ensure it is correct.)

j. DISCOUNT TAB (Note to contractor: This allows for prompt payment discounts)

k. FOB: D (D, S, V) (D denotes destination shipping, S denotes shipment address same as contractor’s address, V denotes shipment from other than contractor’s address.) (Note to contractor: If other than Destination (D), submission of a paid freight bill may be required as an attachment to substantiate shipping charge.)

8. When creating invoices and/or receiving reports, the contractor shall select the “Additional

E-mail Notifications” link and enter the e-mail addresses below. The Government will advise the contractor of changes to these e-mail notifications by letter or e-mail vs. contract modification. Upon receipt of the change(s), the contractor shall include the new e-mail notifications when creating invoices and/or receiving reports. Contractor shall send an email notification to the addressees listed below upon submittal of an invoice through Wide Area Work Flow (WAWF-RA).

a. INSPECTOR: John.Vanscoy@wpafb.af.mil

b. ACCEPTOR: Kevin.Parks@wpafb.af.mil

c. CONTRACT ADMINISTRATOR: Jonathan.Richardson@wpafb.af.mil

d. CONTRACTING OFFICER: Kevin.Parks@wpafb.af.mil

e. ADDITIONAL CONTACT: John.Vanscoy@wpafb.af.mil

9. Questions concerning payments should be directed to the Defense Finance Accounting Services (DFAS) located in Block Block # of payment address of the contract/order. The contract, purchase order, or invoice number is required when inquiring about payment status. Payment information may also be accessed from the DFAS web site at https://myinvoice.csd.disa.mil/index.html.

10. DEFINITIONS. Following is a list of definitions that may be helpful. Additional information can be found at http://farsite.hill.af.mil/ and http://www.dod.mil/dfas/commpay/contractorpayment/.

BPN: Business Partner Number. An integrated electronic infrastructure the Government uses to manage (i.e., collect, validate, access and maintain) the information it needs to transact business with its contractors. The BPN is located at http://www.bpn.gov.

CAGE CODE: Commercial and Government Entity Code. A CAGE Code is a five (5)-position code that identifies companies doing or wishing to do business with the Federal Government. http://www.ccr.gov/

Commercial Item FINANCING is a form of contract financing resulting from the Federal Acquisition Streamlining Act (FASA) of 1994. Use of this type of invoicing shall be approved by the Contracting officer.

CONTRACTING OFFICER: The person with the authority to enter into, administer, and/or terminate contracts and make related determinations and findings.

CONTRACTOR: Also known as vendor

DODAAC: Department of Defense Activity Address Code. A six-position code that uniquely identifies a unit, activity, or organization that has the authority to requisition and/or receive materiel

Delivery order: An order for supplies placed against an established contract or with Government sources.

F.o.b. destination: Free on board at destination; i.e., the seller or consignor delivers the goods on seller’s or consignor’s conveyance at destination.

F.O.B. ORIGIN: Free on board at origin; i.e., the seller or consignor places the goods on the conveyance. Unless the contract provides otherwise, the buyer or consignee is responsible for the cost of shipping and risk of loss.

Inspection: means examining and testing supplies or services (including, when appropriate, raw materials, components, and intermediate assemblies) to determine whether they conform to contract requirements.

Invoice: means a contractor's bill or written request for payment under the contract for supplies delivered or services performed (see also “proper invoice”).

Must: see SHALL.

Performance Based Payments: A provision for the use of Performance Based Payments (PBPs) as an alternative to progress payments for contract financing. Use of Performance Based Payment method shall be approved by the Contracting Officer

Progress Payments: Progress payments are payments made based on the cost incurred by the contractor as work progresses under the contract. Use of Progress payment method shall be approved by the Contracting Officer.

Proper invoice: An invoice that meets the minimum standards specified in FAR 32.905(b).

Receiving report: Written evidence that indicates Government acceptance of supplies delivered or services performed.

SHALL: The imperative.

SHOULD: An expected course of action or policy that is to be followed unless inappropriate for a particular circumstance.

Taxpayer Identification Number (TIN): The number required by the IRS to be used by the offeror in reporting income tax and other returns.

Section H - Special Contract Requirements

PKJ H-008 - GOVERNMENT DOWN TI

PKJ H-008 - GOVERNMENT DOWN TIME FOR VARIOUS AUTHORITIES INCLUDING THE PRESIDENT, SECRETARY OF DEFENSE, SECRETARY OF THE AIR FORCE, AFMC/CC, ASC/CC, 88 ABW/CC, AND PROGRAM MANAGERS

(a) Base Closures Due to Emergencies. From time to time, the Center or Base Commander or other authority may decide to close all or part of the base in response to an unforeseen emergency or similar occurrence. Sample emergencies include, but are not limited to, adverse weather such as snow or flood, an act of God such as a tornado or earthquake, acts of war or terrorism, computer failures, or a base disaster such as a natural gas leak or fire. Contractor personnel are “non-essential” for purposes of any instructions regarding the emergency.

(1) Contractor shall be officially dismissed upon notification of a base closure in accordance with paragraph b. Contractor shall promptly secure all government furnished property appropriately and evacuate in an expedient but safe manner.

(2) With regard to work under the contract, the Government shall retain the following options:

(i) Government may grant a time extension in each task order delayed by the closure equal to the time of the closure, subject to the availability of funds.

(ii) Government may forego the work. The Contractor will not be paid for work not performed.

(iii) Government may reschedule the work on any day satisfactory to both parties.

(iv) The Government may, in its discretion, permit the Contractor to perform at an off-site location during the period of base closure if meaningful work can be accomplished. Contractor shall certify to the Government by letter within 5 business days of returning to work, the nature and scope of the work completed off-site. Contractor shall be permitted to bill the Government at the labor rates identified in the contract.

(v) In rare instances, Government may request that the Contractor continue on-site performance during the base closure period. Such a request shall be subject to agreement by Contractor.

(b) Base Closure Notification Procedures.

(1) After an official decision to close Wright-Patterson AFB has been made by the Base Commander, the following radio and television stations shall be notified of the closure:

Television:

WHIO 7

WDTN 2

WTJC 26

WKEF 22

Radio:

WHIO AM 1290

WBVE FM 96-5

WONE AM 980

WTUE FM 104.7

WBLY AM 1600

WBZI FM 95.3

WIZE AM 1340

WYSO FM 91.3

WLW AM 700

WYMJ FM 103.9

WDAO AM 1210

WFCJ FM 93.7

WING AM 1410

WHKO FM 99.1

WAZU FM 102.9

WVUD FM 99.9

(2) The Contractor is directed to listen or watch one of the radio or television stations listed in paragraph b.1 for a base closure. Contractor should follow instructions intended for non-essential personnel.

(3) The Contractor will not receive any other form of notification of a base closure from the Government. The Contractor is responsible for notification of his or her employees.

(4) If the decision to close all or part of the base is made during the duty day, and the Base Commander’s decision is transmitted through official notification channels, the Contractor shall follow the instructions as given. Contractor personnel shall notify their task monitor and act in accordance with the task monitor’s instruction.

(c) Base Closure Due to Non-Emergencies. The Center or Base Commander or other authority may elect to close all or part of the base for non-emergency reasons such as time-off award, base open house, etc. In the event of a non-emergency base closure, the Contract Task Monitor and the Contractor shall jointly choose a course of action within the following options:

(1) If there is a need for the service during the base closure and a Government employee will be present, Contractor shall bill the Government at the labor rates identified in the contract.

(2) If there is a need for work during the base closure but either a Government employee will not be present or access will not be available, the Contractor may work off-site provided meaningful work may be accomplished. Contractor shall certify to the Government by letter within 5 business days or returning on-site the nature and scope of the work completed off-site. Contractor shall bill the Government at the labor rates specified in the contract.

(3) If there is no need for the service during the scheduled base closure, contractor shall not work on or off-site. Government may grant a time extension in each task order delayed by the closure equal to the amount of time of the closure, subject to the availability of funds. The Government will not be liable for time not worked.

(End of Clause)

PKJ H-018 - EMS TRAINING

PKJ H-018 - EMS TRAINING

Initial Environmental Management System awareness-level training is required for all personnel working on base at WPAFB.

(a) The installation office responsible for providing the EMS training is 88 ABW/CEVY

(b) The training requires less than thirty minutes

(c) The EMS Awareness-level training shall be accomplished within thirty days of contract (or modification) award. New contract employees shall be trained within thirty days of starting work on the installation.

(d) The EMS Awareness-level training is available via the 88 ABW/CEVY website (https://wrigem.wpafb.af.mil/viewchild.cfm?id=228), which provides materials that meet the training requirement.

(e) Upon completion of the training, the contractor shall provide the AF program manager (PM) a list of the contractor employees' names and the date the training was completed.

(End of Clause)

PKJ H-019 PROGRESS MEETINGS

PKJ H-019

Progress Meetings The contractor shall be responsible for conducting project progress meetings at least every two weeks. The days and times shall be coordinated after contract award.

The meeting shall discuss at a minimum:

· Work elements completed or scheduled to be completed

· Open Requests for Information (RFI)

· Submittals

· Schedule discussion (Percentages scheduled to be complete/Percentages actually completed)

· Project Issues/Action Items

· Change Order Status Progress meeting minutes shall be provided to all individuals attending and all other individuals deemed vital to the project. A sample format of the progress meeting minutes can be provided by 88 CONS/PKJ upon request after contract award.

(End of Clause)

CLAUSES INCORPORATED BY FULL TEXT

88 CONS H-002 - Delivery Procedures Commercial Vehicles (JUL 2005)

All vehicles larger than a large pick-up truck are required to be inspected by the Wright-Patterson Air Force Base Commercial Vehicle Delivery Gate (CVDG) prior to entering the installation. Vehicles to be inspected include, but are not limited to, the following:

1. Step van/panel truck

2. Tractor/trailer, box and flat bed containing cargo

3. Tanker trucks

4. Box trucks

5. Tour buses

6. Garbage/recycled waste trucks

7. Concrete trucks/mixers, dump trucks

8. Cranes, recreational vehicles, petroleum tanker

This inspection will be conducted at Gate 16A located off State Route 444.

The following are exemptions to vehicles utilizing the CVDG:

1. If the vehicle has the product inside (concrete and asphalt trucks) and timely delivery is necessary due to product deterioration it does not need to enter the CVDG. To bypass the CVDG, the contractor shall submit a list containing drivers’ names, social security numbers and the state in which the driver's license is held for those drivers who will be entering the base. This shall be accomplished 24 hours prior to requested entry time. If entry is requested on Monday, this list must be submitted by Friday at 1630 hours. All lists shall be submitted to the 88th ABW/CE Directorate contract inspector. The only gates that may be used under this exemption shall be 15A, 26C, 38C, 1B, 26C and gate 1B. If the driver's name is not on the list, he/she will not be allowed access to the installation through these gates and the base will not assume liability for denied access.

2. If a delivery vehicle must exit, and then re-enter the base to complete its route, the vehicle shall be resealed upon exiting the base. After initially passing through the commercial vehicle delivery gate, trucks shall be resealed at Gates 15A, 38C and 22B. The resealing of the trucks will allow them to continue to any other area of the installation (Areas A, B, C, or Kittyhawk) without reprocessing through the CVDG. To receive resealing assistance, the drivers shall physically stop at one of the three authorized gates and request the installation entry controller to reseal their truck and provide the next location of their delivery. The controller will reseal the truck and give the delivery driver a pre-clearance form. The driver shall present the pre-clearance form to the entry controller at the next point of installation entry. This reentry can be through any base gate.

Vehicles may be subject to an inspection at any of installation entry control points during a directed random antiterrorism measure (RAM.) Any commercial vehicle, regardless of size, can be directed to the CVDG at the discretion of the installation entry controller.

CLAUSES INCORPORATED BY FULL TEXT

88 CONS H003 PROCEDURES FOR RETURNING GOVERNMENT-ISSUED IDENTIFICATION (December 2006) The Contractor shall use the following procedures for returning Government-issued identification. Government-issued identification includes, but is not limited to, the common access card (CAC), vehicle stickers, medical center badges, and badges required for entry into buildings or secured areas of the base.

It is the Contractor’s responsibility to ensure all Government-issued identification is safeguarded from theft or misuse as well as returned to the Government upon expiration or termination of the contract or order. Contractors shall follow these instructions at the end of each option year, if applicable, regardless of the decision to exercise the next option.

Returning Government-Issued Identification

1. The Contractor’s Contract Manager (or Program Manager) shall be responsible for collecting all Government-issued identification.

2. The Contractor shall contact Security Forces at (937) 257-6506 to schedule an appointment for identification return. All identification for this contract or order shall be returned during this appointment with minimal exception.

3. Upon return of all identification Security Forces will provide the Contractor with a letter verifying receipt of identification. This letter will identify any badges that were not returned.

4. Medical center badges shall be returned to the medical center staff. The Contractor shall obtain a letter of receipt from the medical center staff.

5. Final invoices will not be paid until letters of receipt are received by the acceptor identified in this contract or order.

6. The Government may withhold monetary consideration from the final invoice for identification(s) that are not returned.

7. The Government reserves the right to consider the Contractor’s history of returning Government-issued identification when evaluating past performance and responsibility for future awards. Failure to return Government-issued identification may result in ineligibility for future contract awards if the contractor is barred from the base.

(End) Section I - Contract Clauses

PKJ I-001 - PREPARATION OF MAT

PKJ I-001 - PREPARATION OF MATERIAL APPROVAL SUBMITTALS

The materials and workmanship submittals shall be done in accordance with AF Form 3000 “Material Approval Submittal” instructions.

(End of clause)

CLAUSES INCORPORATED BY REFERENCE

CLAUSES INCORPORATED BY FULL TEXT

52.204-11 AMERICAN RECOVERY AND REINVESTMENT ACT-REPORTING REQUIREMENTS (MAR 2009)

(a) Definitions. As used in this clause—

Contract, as defined in FAR 2.101, means a mutually binding legal relationship obligating the seller to furnish the supplies or services (including construction) and the buyer to pay for them. It includes all types of commitments that obligate the Government to an expenditure of appropriated funds and that, except as otherwise authorized, are in writing. In addition to bilateral instruments, contracts include (but are not limited to) awards and notices of awards; job orders or task letters issued under basic ordering agreements; letter contracts; orders, such as purchase orders, under which the contract becomes effective by written acceptance or performance; and bilateral contract modifications. Contracts do not include grants and cooperative agreements covered by 31 U.S.C. 6301, et seq. For discussion of various types of contracts, see FAR Part 16.

First-tier subcontract means a subcontract awarded directly by a Federal Government prime contractor whose contract is funded by the Recovery Act.

Jobs created means an estimate of those new positions created and filled, or previously existing unfilled positions that are filled, as a result of funding by the American Recovery and Reinvestment Act of 2009 (Recovery Act). This definition covers only prime contractor positions established in the United States and outlying areas (see definition in FAR 2.101). The number shall be expressed as “full-time equivalent” (FTE), calculated cumulatively as all hours worked divided by the total number of hours in a full-time schedule, as defined by the contractor. For instance, two full-time employees and one part-time employee working half days would be reported as 2.5 FTE in each calendar quarter.

Jobs retained means an estimate of those previously existing filled positions that are retained as a result of funding by the American Recovery and Reinvestment Act of 2009 (Recovery Act). This definition covers only prime contractor positions established in the United States and outlying areas (see definition in FAR 2.101). The number shall be expressed as “full-time equivalent” (FTE), calculated cumulatively as all hours worked divided by the total number of hours in a full-time schedule, as defined by the contractor. For instance, two full-time employees and one part-time employee working half days would be reported as 2.5 FTE in each calendar quarter.

Total compensation means the cash and noncash dollar value earned by the executive during the contractor’s past fiscal year of the following (for more information see 17 CFR 229.402(c)(2)):

(1) Salary and bonus.

(2) Awards of stock, stock options, and stock appreciation rights. Use the dollar amount recognized for financial statement reporting purposes with respect to the fiscal year in accordance with the Statement of Financial Accounting Standards No. 123 (Revised 2004) ( FAS 123R), Shared Based Payments.

(3) Earnings for services under non-equity incentive plans. Does not include group life, health, hospitalization or medical reimbursement plans that do not discriminate in favor of executives, and are available generally to all salaried employees.

(4) Change in pension value. This is the change in present value of defined benefit and actuarial pension plans.

(5) Above-market earnings on deferred compensation which is not tax-qualified.

(6) Other compensation. For example, severance, termination payments, value of life insurance paid on behalf of the employee, perquisites or property if the value for the executive exceeds $10,000.

(b) This contract requires the contractor to provide products and/or services that are funded under the American Recovery and Reinvestment Act of 2009 (Recovery Act). Section 1512(c) of the Recovery Act requires each contractor to report on its use of Recovery Act funds under this contract. These reports will be made available to the public.

(c) Reports from contractors for all work funded, in whole or in part, by the Recovery Act, and for which an invoice is submitted prior to June 30, 2009, are due no later than July 10, 2009. Thereafter, reports shall be submitted no later than the 10th day after the end of each calendar quarter.

(d) The Contractor shall report the following information, using the online reporting tool available at www.FederalReporting.gov.

(1) The Government contract and order number, as applicable.

(2) The amount of Recovery Act funds invoiced by the contractor for the reporting period. A cumulative amount from all the reports submitted for this action will be maintained by the government's on-line reporting tool.

(3) A list of all significant services performed or supplies delivered, including construction, for which the contractor invoiced in this calendar quarter.

(4) Program or project title, if any.

(5) A description of the overall purpose and expected outcomes or results of the contract, including significant deliverables and, if appropriate, associated units of measure.

(6) An assessment of the contractor’s progress towards the completion of the overall purpose and expected outcomes or results of the contract (i.e., not started, less than 50 percent completed, completed 50 percent or more, or fully completed). This covers the contract (or portion thereof) funded by the Recovery Act.

(7) A narrative description of the employment impact of work funded by the Recovery Act. This narrative should be cumulative for each calendar quarter and only address the impact on the contractor’s workforce. At a minimum, the contractor shall provide—

(i) A brief description of the types of jobs created and jobs retained in the United States and outlying areas (see definition in FAR 2.101). This description may rely on job titles, broader labor categories, or the contractor’s existing practice for describing jobs as long as the terms used are widely understood and describe the general nature of the work; and

(ii) An estimate of the number of jobs created and jobs retained by the prime contractor, in the United States and outlying areas. A job cannot be reported as both created and retained.

(8) Names and total compensation of each of the five most highly compensated officers of the Contractor for the calendar year in which the contract is awarded if—

(i) In the Contractor’s preceding fiscal year, the Contractor received—

(A) 80 percent or more of its annual gross revenues from Federal contracts (and subcontracts), loans, grants (and subgrants) and cooperative agreements; and

(B) $25,000,000 or more in annual gross revenues from Federal contracts (and subcontracts), loans, grants (and subgrants) and cooperative agreements; and

(ii) The public does not have access to information about the compensation of the senior executives through periodic reports filed under section 13(a) or 15(d) of the Securities Exchange Act of 1934 (15 U.S.C. 78m(a), 78o(d)) or section 6104 of the Internal Revenue Code of 1986.

(9) For subcontracts valued at less than $25,000 or any subcontracts awarded to an individual, or subcontracts awarded to a subcontractor that in the previous tax year had gross income under $300,000, the Contractor shall only report the aggregate number of such first tier subcontracts awarded in the quarter and their aggregate total dollar amount.

(10) For any first-tier subcontract funded in whole or in part under the Recovery Act, that is over $25,000 and not subject to reporting under paragraph 9, the contractor shall require the subcontractor to provide the information described in (i), (ix), (x), and (xi) below to the contractor for the purposes of the quarterly report. The contractor shall advise the subcontractor that the information will be made available to the public as required by section 1512 of the Recovery Act. The contractor shall provide detailed information on these first-tier subcontracts as follows:

(i) Unique identifier (DUNS Number) for the subcontractor receiving the award and for the subcontractor’s parent company, if the subcontractor has a parent company.

(ii) Name of the subcontractor.

(iii) Amount of the subcontract award.

(iv) Date of the subcontract award.

(v) The applicable North American Industry Classification System (NAICS) code.

(vi) Funding agency.

(vii) A description of the products or services (including construction) being provided under the subcontract, including the overall purpose and expected outcomes or results of the subcontract.

(viii) Subcontract number (the contract number assigned by the prime contractor).

(ix) Subcontractor’s physical address including street address, city, state, and country. Also include the nine-digit zip code and congressional district if applicable.

(x) Subcontract primary performance location including street address, city, state, and country. Also include the nine-digit zip code and congressional district if applicable.

(xi) Names and total compensation of each of the subcontractor’s five most highly compensated officers, for the calendar year in which the subcontract is awarded if—

(A) In the subcontractor’s preceding fiscal year, the subcontractor received—

(l) 80 percent or more of its annual gross revenues in Federal contracts (and subcontracts), loans, grants (and subgrants), and cooperative agreements; and

(2) $25,000,000 or more in annual gross revenues from Federal contracts (and subcontracts), loans, grants (and subgrants), and cooperative agreements; and

(B) The public does not have access to information about the compensation of the senior executives through periodic reports filed under section 13(a) or 15(d) of the Securities Exchange Act of 1934 (15 U.S.C. 78m(a), 78o(d)) or section 6104 of the Internal Revenue Code of 1986.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 180 days after receivingthe notice to proceed.

* The time stated for completion shall include final cleanup of the premises.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $224.19 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (APR 2009)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/services/contractingopportunities/sizestandardstopics/.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the rerepresentation required by paragraph (b) of this clause by validating or updating all its representations in the Online Representations and Certifications Application and its data in the Central Contractor Registration, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in ORCA, or does not have a representation in ORCA for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code 238290- assigned to contract number TBD.

(Contractor to sign and date and insert authorized signer's name and title).

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.225-21 Required Use of American Iron, Steel, and Other Manufactured Goods—Buy American Act—Construction Materials (MAR 2009)

(a) Definitions. As used in this clause—

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Domestic construction material means—

(1) An unmanufactured construction material mined or produced in the United States; or

(2) A construction material manufactured in the United States.

Foreign construction material means a construction material other than a domestic construction material.

Manufactured construction material means any construction material that is not unmanufactured construction material.

Steel means an alloy that includes at least 50 percent iron, between .02 and 2 percent carbon, and may include other elements.

United States means the 50 States, the District of Columbia, and outlying areas.

Unmanufactured construction material means raw material brought to the construction site for incorporation into the building or work that has not been—

(1) Processed into a specific form and shape; or

(2) Combined with other raw material to create a material that has different properties than the properties of the individual raw materials.

(b) Domestic preference.

(1) This clause implements—

(i) Section 1605 of the American Recovery and Reinvestment Act of 2009 (Recovery Act) (Pub. L. 111-5), by requiring, unless an exception applies, that all iron, steel, and other manufactured goods used as construction material in the project are produced in the United States; and

(ii) The Buy American Act (41 U.S.C. 10a - 10d) by providing a preference for unmanufactured domestic construction material.

(2) The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraph (b)(3) and (b)(4) of this clause.

(3) This requirement does not apply to the construction material or components listed by the Government as follows:

(Contracting Officer to list applicable excepted materials or indicate “none”)

(4) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(3) of this clause if the Government determines that—

(i) The cost of domestic construction material would be unreasonable.

(A) The cost of domestic iron, steel, or other manufactured goods used as construction material is unreasonable when the cumulative cost of such material will increase the cost of the contract by more than 25 percent;

(B) The cost of unmanufactured construction material is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available quantities and of a satisfactory quality; or

(iii) The application of the restriction of section 1605 of the Recovery Act or the Buy American Act to a particular construction material would be inconsistent with the public interest.

(c) Request for determination of inapplicability of Section 1605 of the Recovery Act or the Buy American Act. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(4) of this clause shall include adequate information for Government evaluation of the request, including—

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Cost;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(4) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed cost comparison table in the format in paragraph (d) of this clause.

(iii) The cost of construction material shall include all delivery costs to the construction site and any applicable duty.

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to section 1605…