FA667021R0002 - Giant Voice Solicitation.pdf

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

9. FOR INFORMATION

CALL:

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See ).

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and copies to perform the work required are due at the place specified in Item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

b. An offer guarantee is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

12b. CALENDAR DAYS

YES NO

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

FA667021R0002

1 of 524/4/2021

F3YCFA1012AW01 RVKQ 20-0000

FA6670

FA6670 914 AW LGC

800 KIRKBRIDGE DR

ADMINISTRATIVE ONLY NO REQUISITIONS

NIAGARA FALLS, NY 14304-5000

United States Jason Topick, Email: jason.topick.1@us.af.mil Telephone:

7162362214

CONTRACTING

AF BPN NO MILSBILLS PROCESSES

2720 KIRKBRIDGE DRIVE BLDG. 800

NIAGARA FALLS, NY 14304-5001

United States

Jason Topick, Jason P. Topick, Contracting Officer 7162362214

Project Title: ENGINEER, FURNISH, INSTALL, AND TEST (EFI&T) A GIANT VOICE (GV)

Statement of Objectives (SOO): Giant Voice Systems Upgrade, dated 24 February 2020, 17 pgs.

Location: 914th Air Refueling Wing, Niagara Falls ARS, NY 14304

Site Visit: Please see FAR Clause 52.236-27 of solicitation

Magnitude of Construction: Between $100,000 and $250,000 Request Proposal acceptance through 30 Sept 2021.

Note: This acquisition is restricted to 100% Women-Owned Small Business (WOSB) concerns IAW FAR Subpart 19.15

Notice to Offerors: Funds are not presently available for this project. No award will be made until funds are available to make payment under a contract. The Government reserves the right to cancel this solicitation, either before or after Bid closing, with no obligation to the Offeror by the Government.

All Offerors must be registered in the System for Award Management (SAM) prior to award of any contract resulting from this solicitation. The use of electronic payment requests through the Wide Area Work Flow Receipt & Acceptance (WAWF-RA) electronic invoicing system is mandatory.

10 270

FAR 52.211-10

2 2:00 PM

5/7/2021

AMOUNTS

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal to or greater than theminimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to thiscontract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

Mary E. Pyle Platts Email: mary.pyleplatts@us.af.mil Telephone: 716-236-2215

FA667021R0002

Section A - Solicitation/Contract Form

Section B - Supplies or Services and Prices/Cost

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price Amount

Contractor to furnish all plant, labor, parts, materials, equipment, tools, transportation and supervision required to complete the following construction project, Giant Voice System Upgrade, in strict accordance with the attached Statement of Objectives, Giant Voice System Upgrade, dated 28 Jan 2021, and contract clauses at the 914th Air Refueling Wing, Niagara Falls, NY 14304.

Firm Fixed Price

CIN: 00000000000006190581

1 Each

000101 Funding for CLIN 0001

Section C - Description/Specifications/Statement of Work

Requirements Design, Furnish, Install, and Test (EDFIT) a Giant Voice (GV) System upgrade required at Niagara Falls ARS, New York.

Section D - Packaging and Marking

Section E - Inspection and Acceptance FAR Clauses Incorporated by Reference

Number Title Effective Date 52.246-12 Inspection of Construction. 1996-08

0001 Inspection and Acceptance Location Both Destination Instructions: None

DoDAAC: F5J3DS Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

CIVIL ENGINEERING

AF BPN NO MILSBILLS

PROCESSES

2405 FRANKLIN DR BLDG 403

NIAGARA FALLS, NY 14304 5063

UNITED STATES

OfficeCode:

Chris Rizzo Telephone: 236-3115 Email:

Section F - Deliveries or Performance

Delivery Schedule Ship To Address

Delivery Requested By

11 FEB 2021

1 Each

Ship To DoDAAC: FA6670 Cage:

DunsNumber:

Duns4Number:

CountryCode:

CO:FA6670 914 AW LGC

FA6670 914 AW LGC ADMINISTRATIVE ONLY

NO REQUISITIONS 800 KIRKBRIDGE DR

NIAGARA FALLS NY 14304-5000

000101

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.247-34 F.o.b. Destination. 1991-11

Section G - Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.204-7006 Billing Instructions. 2005-10 252.231-7000 Supplemental Cost Principles 1991-12 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. 2018-12 252.236-7000 Modification Proposals--Price Breakdown 1991-12

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. 2018-12

As prescribed in 232.7004(b), use the following clause:

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) Definitions. As used in this clause-

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall-

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

Construction Payment Invoice

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

N/A

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

(f) Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC F87700 Issue By DoDAAC FA6670 Admin DoDAAC FA6670 Inspect By DoDAAC F5J3DS Service Acceptor (DoDAAC) F5J3LC

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

914 MSG/PK. Jason P. Topick, 716.236.2214,

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

Section H - Special Contract Requirements

CONTRACT HOLIDAYS

a. Working hours for the Contractor will be between the hours of 7:15 am through 4:30 pm excluding Saturdays, Sundays, and Federal holidays. The following federal holidays are observed at Niagara Falls ARS:

New Year's Day Birthday of Martin Luther King, Jr.

Washington's Birthday Memorial Day Independence Day Labor Day Columbus Day Veterans Day Thanksgiving Day Christmas Day

NOTE: Any of the above holidays falling on a Saturday will be observed on the proceeding Friday. Holidays falling on a Sunday will be observed on the following Monday.

b. If the Contractor desires to work during periods other than the above, additional Government inspection forces may be required. The Contractor must request permission to work outside the normal work schedule no later than three days in advance of Contractor's intention to work during other periods to allow assignment of additional inspection forces when the Contracting Officer determines that they are reasonably available. If such force is reasonably available, the Contracting Officer may authorize the Contractor to perform work during periods other than normal duty hours/days; however, if inspectors are required to perform in excess of their normal duty days solely for the benefit of the Contractor, the actual cost of inspection at overtime rates may be charged to the Contractor. These adjustments to the contract price may be made periodically as directed by the Contracting Officer.

INSURANCE CLAUSE

In accordance with FAR 52.228-5, Insurance - Work on a Government Installation, the coverage specified in FAR 28.307-2, Liability, is the minimum insurance required and those requirements are hereby incorporated into the contract.

The minimum amounts of insurance are as follows:

Employers Liability: $100,000

General Liability: Bodily injury liability coverage written on the comprehensive form of the policy: $500,000 per occurrence.

Automotive liability: Automobile liability insurance written on the comprehensive form of the policy - The policy shall provide for bodily injury and property damage liability covering the operation of all automobiles used in connection with performing the contract. Policies of at least $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage. The amount of liability coverage on other policies shall be commensurate with any legal requirements of the locality and sufficient to meet normal and customary claims.

Section I - Contract Clauses

52.236-27 Site Visit (Construction).

As prescribed in 36.523 , insert a provision substantially the same as the following:

Site Visit (Construction) (Feb 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for:

Tuesday, 13 April 2021 at 2:00pm (local) EST

(c) Participants will meet at:

2720 Kirkbridge Dr., Bldg 800, Room 1030 Niagara Falls, NY 14304

(d) Special arrangements are required to gain access to Niagara Falls ARS. In order to attend the site visit, interested parties MUST submit an Entry Access Request (Attachment #4), including the company name and address as well as the full name, date of birth, driver's license number and driver's license state for each of the requested attendees; a state ID number and state will suffice if no driver's license is available.

The Entry Access Request MUST be received by the Contracting Office at least 3 business days prior to the site visit; failure to submit request appropriately before hand may result in denial of base access for the site visit.

Requests for attendance should be forwarded to Jason P. Topick at jason.topick.1@us.af.mil and Mary Pyle Platts at mary.pyleplatts@us.af.mil.

Offerors are cautioned that Niagara Falls ARS has visitor control procedures requiring individuals to obtain a visitor pass prior to entrance. DELAYS SHOULD BE ANTICIPATED. Offerors should allow sufficient time to obtain a visitor pass (requiring valid driver's license, vehicle registration, and current proof of insurance if driving, valid state or government issued ID if passenger).

All questions regarding this solicitation and any questions generated from the site visit must be submitted in writing to Jason P. Topick at jason.topick.1@us.af.mil NLT Monday 19 April 2021 at 3 pm EST. Answers will be posted out under the solicitation on www. beta.sam.gov approx 1 week later. The Contracting Officer will provide clarification through amendment to the solicitation following receipt of any questions. Submission of questions prior to the site visit is also encouraged.

Remarks and explanations provided at the site visit shall NOT qualify the terms of the solicitation and Statement of Objectives. Unless the solicitation is amended in writing, it will remain unchanged. If an amendment is issued, normal procedures relating to the acknowledgment and receipt of solicitation amendments shall apply.

ALL Prime contractors and subcontractors are encouraged to attend the site visit. There will NOT be additional site visits.

(End of provision)

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.203-12 Limitation on Payments to Influence Certain Federal Transactions. 2020-06 52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements. 2017-01

52.204-9 Personal Identity Verification of Contractor Personnel. 2011-01 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. 2020-06 52.204-13 System for Award Management Maintenance. 2018-10 52.204-18 Commercial and Government Entity Code Maintenance. 2020-08

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities. 2018-07

52.209-6 Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. 2020-06

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. 2015-11 52.211-13 Time Extensions. 2000-09 52.215-8 Order of Precedence-Uniform Contract Format. 1997-10 52.219-6 Notice of Total Small Business Set-Aside. 2020-11 52.219-13 Notice of Set-Aside of Orders. 2020-03 52.219-33 Nonmanufacturer Rule. 2020-03 52.222-6 Construction Wage Rate Requirements. 2018-08 52.222-7 Withholding of Funds. 2014-05 52.222-8 Payrolls and Basic Records. 2018-08 52.222-9 Apprentices and Trainees. 2005-07 52.222-10 Compliance with Copeland Act Requirements. 1988-02 52.222-11 Subcontracts (Labor Standards). 2014-05 52.222-12 Contract Termination-Debarment. 2014-05 52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations. 2014-05 52.222-14 Disputes Concerning Labor Standards. 1988-02 52.222-15 Certification of Eligibility. 2014-05 52.222-21 Prohibition of Segregated Facilities. 2015-04 52.222-27 Affirmative Action Compliance Requirements for Construction. 2015-04 52.222-34 Project Labor Agreement. 2010-05 52.222-50 Combating Trafficking in Persons. 2020-10 52.222-55 Minimum Wages Under Executive Order 13658. 2020-11 52.222-62 Paid Sick Leave Under Executive Order 13706. 2017-01 52.223-5 Pollution Prevention and Right-to-Know Information. 2011-05 52.223-6 Drug-Free Workplace. 2001-05 52.223-13 Acquisition of EPEAT#-Registered Imaging Equipment. 2014-06

52.223-17 Affirmative Procurement of EPA-designated Items in Service and Construction Contracts. 2018-08

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. 2020-06 52.223-19 Compliance with Environmental Management Systems. 2011-05 52.223-21 Foams. 2016-06 52.228-2 Additional Bond Security. 1997-10 52.228-11 Pledges of Assets. 2021-02 52.228-12 Prospective Subcontractor Requests for Bonds. 2014-05 52.232-23 Assignment of Claims. 2014-05 52.232-25 Prompt Payment. 2017-01 52.232-27 Prompt Payment for Construction Contracts. 2017-01 52.232-33 Payment by Electronic Funds Transfer-System for Award Management. 2018-10 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. 2013-12 52.233-1 Disputes. 2014-05 52.233-3 Protest after Award. 1996-08 52.233-3 Alternate I Protest after Award. - (Alternate I) 1996-08 52.233-4 Applicable Law for Breach of Contract Claim. 2004-10 52.236-2 Differing Site Conditions. 1984-04 52.236-3 Site Investigation and Conditions Affecting the Work. 1984-04 52.236-5 Material and Workmanship. 1984-04 52.236-6 Superintendence by the Contractor. 1984-04 52.236-7 Permits and Responsibilities. 1991-11 52.236-8 Other Contracts. 1984-04

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements. 1984-04

52.236-10 Operations and Storage Areas. 1984-04 52.236-11 Use and Possession Prior to Completion. 1984-04 52.236-12 Cleaning Up. 1984-04 52.236-13 Accident Prevention. 1991-11 52.236-14 Availability and Use of Utility Services. 1984-04 52.236-17 Layout of Work. 1984-04 52.236-26 Preconstruction Conference. 1995-02 52.242-14 Suspension of Work. 1984-04 52.243-1 Alternate I Changes-Fixed-Price. - (Alternate I) 1987-08 52.243-5 Changes and Changed Conditions. 1984-04 52.246-21 Warranty of Construction. 1994-03 52.249-1 Termination for Convenience of the Government (Fixed-Price) (Short Form). 1984-04 52.253-1 Computer Generated Forms. 1991-01

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.203-7000 Requirements Relating to Compensation of Former DoD Officials 2011-09 252.203-7002 Requirement to Inform Employees of Whistleblower Rights. 2013-09 252.204-7003 Control of Government Personnel Work Product. 1992-04 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting. 2019-12 252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support. 2016-05

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services. 2021-01

252.209-7004 Subcontracting with Firms that are Owned or Controlled by the Government of a Country that is a State Sponsor of Terrorism. 2019-05

252.223-7006 Prohibition on Storage, Treatment, and Disposal of Toxic or Hazardous Materials. 2014-09 252.223-7008 Prohibition of Hexavalent Chromium. 2013-06 252.225-7001 Buy American and Balance of Payments Program. 2017-12 252.225-7002 Qualifying Country Sources as Subcontractors. 2017-12 252.225-7016 Restriction on Acquisition of Ball and Roller Bearings. 2011-06 252.225-7048 Export-Controlled Items. 2013-06 252.232-7010 Levies on Contract Payments. 2006-12

252.232-7017 Accelerating Payments to Small Business Subcontractors-Prohibition on Fees and Consideration. 2020-04

252.237-7010 Prohibition on Interrogation of Detainees by Contractor Personnel. 2013-06 252.243-7001 Pricing of Contract Modifications. 1991-12 252.244-7000 Subcontracts for Commercial Items. 2020-10 252.246-7004 Safety of Facilities, Infrastructure, and Equipment for Military Operations. 2010-10

FAR Clauses Incorporated by Full Text

52.204-1 Approval of Contract. 1989-12

As prescribed in 4.103 , insert the following clause:

Approval of Contract (Dec 1989)

This contract is subject to the written approval of CONTRACTING OFFICER and shall not be binding until so approved.

(End of clause)

52.204-19 Incorporation by Reference of Representations and Certifications. 2014-12

As prescribed in , insert the following clause.4.1202(b)

INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC 2014)

The Contractor's representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

(End of clause)

52.211-10 Commencement, Prosecution, and Completion of Work. 1984-04

As prescribed in 11.404(b), insert the following clause in solicitations and contracts when a fixed-price construction contract is contemplated. The clause may be changed to accommodate the issuance of orders under indefinite-delivery contracts for construction.

Commencement, Prosecution, and Completion of Work (Apr 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 180 days. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 Liquidated Damages-Construction. 2000-09

As prescribed in 11.503(b), insert the following clause in solicitations and contracts:

Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $203.64 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.213-4 Terms and Conditions-Simplified Acquisitions (Other Than Commercial Items). 2021-02

As prescribed in 13.302-5(d), insert the following clause:

Terms and Conditions-Simplified Acquisitions (Other Than Commercial Items) (Jan 2021)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(iii) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Aug 2020) (Section 889 (a)(1)(A) of Pub. L. 115-232).

(iv) 52.222-3, Convict Labor (Jun 2003) (E.O.11755).

(v) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(vi) 52.222-26, Equal Opportunity (Sept 2016) (E.O.11246).

(vii) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(viii) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C.3553).

(ix) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Pub.L.108-77, 108-78 (19 U.S.C. 3805 note)).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (Apr 1984).

(ii) 52.232-8, Discounts for Prompt Payment (Feb 2002).

(iii) 52.232-11, Extras (Apr 1984).

(iv) 52.232-25, Prompt Payment (Jan 2017).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (Jun 2013).

(vi) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Dec 2013).

(vii) 52.233-1, Disputes (May 2014).

(viii) 52.244-6, Subcontracts for Commercial Items (Nov 2020).

(ix) 52.253-1, Computer Generated Forms (Jan 1991).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Jun 2020)(Pub. L. 109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at or above the threshold specified in FAR 4.1403(a) on the date of award of this contract).

(ii) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Jan 2020) (E.O. 13126) (Applies to contracts for supplies exceeding the micro-purchase threshold, as defined in FAR 2.101 on the date of award of this contract).

(iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment., Contracts for Materials, Supplies, Articles, and Equipment (Jun 2020) (41 U.S.C.chapter 65) (Applies to supply contracts over the threshold specified in FAR 22.602 on the date of award of this contract, in the United States, Puerto Rico, or the U.S. Virgin Islands).

(iv) 52.222-35, Equal Opportunity for Veterans (Jun 2020) (38 U.S.C. 4212) (Applies to contracts valued at or above the threshold specified in FAR 22.1303(a) on the date of award of this contract).

(v) 52.222-36, Equal Employment for Workers with Disabilities (Jun 2020) (29 U.S.C. 793) (Applies to contracts over the threshold specified in FAR 22.1408(a) on the date of award of this contract, unless the work is to be performed outside the United States by employees recruited outside the United States). (For purposes of this clause, "United States" includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

(vi) 52.222-37, Employment Reports on Veterans (Jun 2020) (38 U.S.C. 4212) (Applies to contracts valued at or above the threshold specified in FAR 22.1303(a) on the date of award of this contract).

(vii) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf).

(viii)

(A) 52.222-50, Combating Trafficking in Persons (Oct 2020)(22 U.S.C. chapter 78 and E.O. 13627) (Applies to all solicitations and contracts).

(B) Alternate I (Mar 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices:

Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (Nov 2020) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(x) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2017) (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.))

(xi) 52.223-5, Pollution Prevention and Right-to-Know Information (May 2011) (E.O. 13423) (Applies to services performed on Federal facilities).

(xii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693)(applies to contracts for products as prescribed at FAR 23.804(a)(1)).

(xiii) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners).

(xiv) 52.223-15, Energy Efficiency in Energy-Consuming Products (May 2020) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR® Program or Federal Energy Management Program (FEMP)) will be-

(A) Delivered;

(B) Acquired by the Contractor for use in performing services at a Federally-controlled facility;

(C) Furnished by the Contractor for use by the Government; or

(D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance).

(xv) 52.223-20, Aerosols (Jun 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices).

(xvi) 52.223-21, Foams (Jun 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent; or contracts for construction of buildings or facilities.

(xvii) 52.225-1, Buy American-Supplies (Jan 2021) (41 U.S.C. chapter 67) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold, as defined in FAR 2.101 on the date of award of this contract, and the acquisition-

(A) Is set aside for small business concerns; or

(B) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $25,000).

(xviii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations., Promoting Excess Food Donation to Nonprofit Organizations (Jun 2020) (42 U.S.C. 1792) (Applies to contracts greater than the threshold specified in FAR 26.404 on the date of award of this contract, that provide for the provision, the service, or the sale of food in the United States).

(xix) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Oct 2013)(Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the System for Award Management (SAM) as its source of EFT information).

(xx) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) (Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information).

(xxi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. App. 1241) (Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d)).

(2) Listed below are additional clauses that may apply:

(i) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (Jun 2016) (Applies to contracts when the contractor or a subcontractor at any tier may have Federal contract information residing in or transiting through its information system.

(ii) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Jun 2020) (Applies to contracts over the threshold specified in FAR 9.405-2(b) on the date of award of this contract).

(iii) 52.211-17, Delivery of Excess Quantities (Sept 1989) (Applies to fixed-price supplies).

(iv) 52.247-29, F.o.b. Origin (Feb 2006) (Applies to supplies if delivery is f.o.b. origin).

(v) 52.247-34, F.o.b. Destination (Nov 1991) (Applies to supplies if delivery is f.o.b. destination).

(c) FAR 52.252-2, Clauses Incorporated by Reference (Feb 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): www.acquisition.gov

(d) Inspection/Acceptance. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its postacceptance rights-

(1) Within a reasonable period of time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(f) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges that the Contractor can demonstrate to the satisfaction of the Government, using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred that reasonably could have been avoided.

(g) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(h) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(End of clause)

52.219-14 Limitations on Subcontracting. 2020-11

As prescribed in , insert the following clause:19.507(e)

LIMITATIONS ON SUBCONTRACTING (MAR 2020)

This clause does not apply to the unrestricted portion of a partial set-aside.(a)

. This clause applies only to-(b) Applicability

Contracts that have been set aside for small business concerns or 8(a) participants;(1)

Part or parts of a multiple-award contract that have been set aside for small business concerns or 8(a) participants; (2)

Orders set aside for small business concerns or 8(a) participants under multiple-award contracts as described in 8.405-5 and 16.505(b)(2)(3) (i)(F); and

Orders issued directly to small business concerns or 8(a) participants under multiple-award contracts as described in 19.504(c)(1)(ii).(4)

By submission of an offer and execution of a contract, the Contractor agrees that in performance of the (c) Limitations on subcontracting.

contract in the case of a contract for-

. At least 50 percent of the cost of contract performance incurred for personnel shall be expended for (1) Services (except construction) employees of the concern.

. The concern shall perform work for at least 50 percent of (2) Supplies (other than procurement from a nonmanufacturer of such supplies) the cost of manufacturing the supplies, not including the cost of materials.

. The concern will perform at least 15 percent of the cost of the contract, not including the cost of materials, with its (3) General construction own employees.

. The concern will perform at least 25 percent of the cost of the contract, not including the cost (4) Construction by special trade contractors of materials, with its own employees.

The Contractor shall comply with the limitations on subcontracting as follows:(d)

For contracts, in accordance with paragraph (b)(1) and (2) of this clause-(1)

[ ]Contracting Officer check as appropriate.

_ By the end of the base term of the contract and then by the end of each subsequent option period; or

_ By the end of the performance period for each order issued under the contract.

For orders, in accordance with paragraphs (b)(3) and (4) of this clause, by the end of the performance period for the order.(2)

(End of clause)

52.219-28 Post-Award Small Business Program Rerepresentation. 2020-11

As prescribed in 19.309(c)(1), insert the following clause:

Post-Award Small Business Program Rerepresentation (Nov 2020)

(a) Definitions. As used in this clause-

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern-

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (d) of this clause.

Such a concern is "not dominant in its field of operation" when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13 CFR 121.103.

(b) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts-

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, when the Contracting Officer explicitly requires it for an order issued under a multiple-award contract.

(d) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document/support--table-size-standards.

(e) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(f) Except as provided in paragraph (h) of this clause, the Contractor shall make the representation(s) required by paragraph (b) and (c) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause, or with its offer for an order (see paragraph (c) of this clause), that the data have been validated or updated, and provide the date of the validation or update.

(g) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (f) or (h) of this clause.

(h) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

(1) The Contractor represents that it [ ] is, [ ] is not a small business concern under NAICS Code ____ assigned to contract number ____.

(2) [ Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) [ Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause. ] The Contractor represents that it [ ] is, [ ] is not a women-owned small business concern.

(4) Women-owned small business (WOSB) concern eligible under the WOSB Program. [Complete only if the Contractor represented itself as a women-owned small business concern in paragraph (h)(3) of this clause.] The Contractor represents that-

(i) It [ ] is, [ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (h)(4)(i) of this clause is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The Contractor shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture:____.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(5) Economically disadvantaged women-owned small business (EDWOSB) concern.[Complete only if the Contractor represented itself as a women-owned small business concern eligible under the WOSB Program in (h)(4) of this clause. ] The Contractor represents that-

(i) It [ ] is, [ ] is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (h)(5)(i) of this clause is accurate for each EDWOSB concern participating in the joint venture. [The Contractor shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: ____.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(6) [ Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause. ] The Contractor represents that it [ ] is, [ ] is not a veteran-owned small business concern.

(7) [ Complete only if the Contractor represented itself as a veteran-owned small business concern in paragraph (h)(6) of this clause.] The Contractor represents that it [ ] is, [ ] is not a service-disabled veteran-owned small business concern.

(8) [ Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause. ] The Contractor represents that-

(i) It [ ] is, [ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small…