FA448617R0010.pdf

F2N33Q7145A001

1) Project Title: Replace Roof and Siding Port. Whrs T-1214

2) Location: Lajes Field, Azores, Portugal

3) This acquisition is 100% Full and Open Competition.

4) Aw ard of this solicitation w ill result in a Firm-Fixed Price (FFP) contract.

5) Magnitude: FAR Part 36.204 (d) Betw een $250,000 and $500,000 NOTE 1: The US Government intends to evaluate proposals and aw ard a contract w ithout discussions w ith offerors (except clarif ications as described in FAR 15.306(a)). Therefore, the offeror's initial proposal should contain the offeror's best terms from a price and technical standpoint.

NOTE 2: Site Visit attendance is highly recommended how ever, not mandatory. Please see section L, FAR 52.236-27 for more information.

Only one site visit w ill be conducted.

PEDRO N MENDES 011-351-295-57-6492

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

12-Jun-2017

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________210 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

YES X NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________12 Jul 2017 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

65 CONF/LGCA

65TH CONTRACTING FLIGHT

APO AE 09720-7710

FA4486

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

04:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

011-351-295-573758FAX:TEL: 011-351-295-571468 TEL: FAX:

FA448617R0010 28

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

FA448617R0010

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Project Repair Roof & Siding Port. Wrhs, T-1214

FFP

The contractor's scope of work includes supplying all plant, labor, equipment, supervision and specified material to perform all operations required to complete all work as specified in the contract. Work shall be performed as described in the Specification and Project Drawings.

FOB: Destination

PURCHASE REQUEST NUMBER: F2N33Q7145A001

NET AMT

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 210 dys. ANP 1 65 CES/CERF - F2N33Q

BASE CIVIL ENGINEERING

BLDG T-570

APO AE 09720

011-351-295-573495 FOB: Destination

F2N33Q

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.204-13 System for Award Management Maintenance OCT 2016 52.204-17 Ownership or Control of Offeror JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-20 Predecessor of Offeror JUL 2016 52.209-2 Prohibition on Contracting with Inverted Domestic

Corporations--Representation

NOV 2015

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under and Federal Law

FEB 2016

52.211-12 Liquidated Damages--Construction SEP 2000 52.222-50 Combating Trafficking in Persons MAR 2015 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-18 Availability Of Funds APR 1984 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-12 Cleaning Up APR 1984 52.242-14 Suspension of Work APR 1984 52.243-5 Changes and Changed Conditions APR 1984 52.249-2 Termination For Convenience Of The Government (Fixed-

Price)

APR 2012

52.249-10 Default (Fixed-Price Construction) APR 1984 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.229-7000 Invoices Exclusive of Taxes or Duties JUN 1997 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7008 Assignment of Claims (Overseas) JUN 1997 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the

Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 210 days from notice to proceed. The time stated for completion shall include final cleanup of the premises.

*The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

(End of clause)

52.213-4 TERMS AND CONDITIONS--SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL

ITEMS) (JAN 2017).

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are ncorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

(iii) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(iv) 52.222-26, Equal Opportunity (SEPT 2016) (E.O. 11246).

(v) 52.225-13, Restrictions on Certain Foreign Purchases (JUN 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(vi) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(vii) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78 (19 U.S.C. 3805 note).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (APR 1984).

(ii) 52.232-8, Discounts for Prompt Payment (FEB 2002).

(iii) 52.232-11, Extras (APR 1984).

(iv) 52.232-25, Prompt Payment (JAN 2017).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (JUN 2013).

(vi) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (DEC 2013).

(vii) 52.233-1, Disputes (MAY 2014).

(viii) 52.244-6, Subcontracts for Commercial Items (JAN 2017).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (MAR 2016) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at $30,000 or more).

(ii) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126). (Applies to contracts for supplies exceeding the micro-purchase threshold).

(iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment Exceeding $15,000 (MAY 2014) (41 U.S.C. chapter 65) (Applies to supply contracts over $15,000 in the United States, Puerto Rico, or the U.S. Virgin Islands).

(iv) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212) (applies to contracts of $150,000 or more).

(v) 52.222-36, Equal Employment for Workers with Disabilities (JUL 2014) (29 U.S.C. 793) (Applies to contracts over $15,000, unless the work is to be performed outside the United States by employees recruited outside the United States). (For purposes of this clause, ``United States'' includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

(vi) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212) (Applies to contracts of $150,000 or more).

(vii) 52.222-41, Service Contract Labor Standards (MAY 2014) (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S.

Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf).

(viii)(A) 52.222-50, Combating Trafficking in Persons (MAR 2015) (22 U.S.C. chapter 78 and E.O 13627) (Applies to all solicitations and contracts).

(B) Alternate I (MAR 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (DEC 2015) (Executive Order 13658) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(x) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.))

(xi) 52.223-5, Pollution Prevention and Right-to-Know Information (MAY 2011) (E.O. 13423) (Applies to services performed on Federal facilities).

(xii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (June, 2016) (E.O. 13693)(applies to contracts for products as prescribed at FAR 23.804(a)(1)).

(xiii) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (June, 2016) (E.O. 13693) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners).

(xiv) 52.223-15, Energy Efficiency in Energy-Consuming Products (DEC 2007) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR[supreg] Program or Federal Energy Management Program (FEMP) will be--

(A) Delivered;

(B) Acquired by the Contractor for use in performing services at a Federally-controlled facility;

(C) Furnished by the Contractor for use by the Government; or

(D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance).

(xv) 52.223-20, Aerosols (June, 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices).

(xvi) 52.223-21, Foams (June, 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent;

or contracts for construction of buildings or facilities.

(xvii) 52.225-1, Buy American--Supplies (MAY 2014) (41 U.S.C. chapter 67) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold and the acquisition--

(A) Is set aside for small business concerns; or

(B) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $25,000).

(xviii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (MAY 2014) (42 U.S.C. 1792) (Applies to contracts greater than $25,000 that provide for the provision, the service, or the sale of food in the United States).

(xix) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (JUL 2013) (Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the System for Award Management (SAM) database as its source of EFT information.)

(xx) 52.232-34, Payment by Electronic Funds Transfer--Other than System for Award Management (JUL 2013) (Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information.)

(xxi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (FEB 2006) (46 U.S.C. App. 1241) (Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d).)

(2) Listed below are additional clauses that may apply:

(i) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (June, 2016) (Applies to contracts when the contractor or a subcontractor at any tier may have Federal contract information residing in or transiting through its information system.

(ii) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015) (Applies to contracts over $35,000).

(iii) 52.211-17, Delivery of Excess Quantities (SEP 1989) (Applies to fixed-price supplies).

(iv) 52.247-29, F.o.b. Origin (FEB 2006) (Applies to supplies if delivery is f.o.b. origin).

(v) 52.247-34, F.o.b. Destination (NOV 1991) (Applies to supplies if delivery is f.o.b. destination).

(c) FAR 52.252-2, Clauses Incorporated by Reference (FEB 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/

(d) Inspection/Acceptance. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its postacceptance rights--

(1) Within a reasonable period of time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(f) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges that the Contractor can demonstrate to the satisfaction of the Government, using its standard record keeping system, have resulted from the termination.

The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred that reasonably could have been avoided.

(g) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(h) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/ https://www.acquisition.gov/

(End of provision)

252.225-7043 ANTITERRORISM/FORCE PROTECTION POLICY FOR DEFENSE CONTRACTORS

OUTSIDE THE UNITED STATES (JUN 2015)

(a) Definition. United States, as used in this clause, means, the 50 States, the District of Columbia, and outlying areas.

(b) Except as provided in paragraph (c) of this clause, the Contractor and its subcontractors, if performing or traveling outside the United States under this contract, shall--

(1) Affiliate with the Overseas Security Advisory Council, if the Contractor or subcontractor is a U.S. entity;

(2) Ensure that Contractor and subcontractor personnel who are U.S. nationals and are in-country on a non-transitory basis, register with the U.S. Embassy, and that Contractor and subcontractor personnel who are third country nationals comply with any security related requirements of the Embassy of their nationality;

(3) Provide, to Contractor and subcontractor personnel, antiterrorism/force protection awareness information commensurate with that which the Department of Defense (DoD) provides to its military and civilian personnel and their families, to the extent such information can be made available prior to travel outside the United States; and

(4) Obtain and comply with the most current antiterrorism/force protection guidance for Contractor and subcontractor personnel.

(c) The requirements of this clause do not apply to any subcontractor that is--

(1) A foreign government;

(2) A representative of a foreign government; or

(3) A foreign corporation wholly owned by a foreign government.

(d) Information and guidance pertaining to DoD antiterrorism/force protection can be obtained from PGI 225.372-

1.

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

SF1442

(Contracting Officer: Insert applicable document type(s). Note: If a “Combo” document type is identified but not supportable by the Contractor's business systems, an “Invoice” (stand-alone) and “Receiving Report” (stand-alone) document type may be used instead.)

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

F2N33Q

(Contracting Officer: Insert inspection and acceptance locations or “Not applicable”.)

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC F78900 Issue By DoDAAC FA4486 Admin DoDAAC FA4486 Inspect By DoDAAC F2N33Q Service Acceptor (DoDAAC) F2N33Q

(*Contracting Officer: Insert applicable DoDAAC information or “See schedule” if multiple ship to/acceptance locations apply, or “Not applicable.”)

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

pedro.mendes.pt@us.af.mil

(Contracting Officer: Insert applicable email addresses or “Not applicable.”)

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

pedro.mendes.pt@us.af.mil

(Contracting Officer: Insert applicable information or “Not applicable.”)

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

Title File Number of Pages Government Drawings January 2017 7

OMBUDSMAN (APR 2014)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the interested party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employee-employer actions, contests of OMB Circular A-76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, the interested party may contact the ombudsman, Primary:

Mr. Douglas Guldan

AFICA/KU, UNIT 3103, APO, AE 09094-3103

AFICA/KU, Geb 404, Flugplatz Ramstein, 66877 Ramstein-Miesenbach, Germany E-mail: douglas.guldan@us.af.mil Tel: DSN: (314)480-2209 Fax: (49)-6731-47-2025

Alternate:

Ms. Heidi Hoehn

AFICA/KU, UNIT 3103, APO, AE 09094-3103

AFICA/KU, Geb 404, Flugplatz Ramstein, 66877 Ramstein-Miesenbach, Germany E-mail: heidi.hoehn.de@us.af.mil Tel: DSN: (314)480-9330 Fax: (49)-6731-47-2025

Concerns, issues, disagreements, and recommendations that cannot be resolved at the Center/MAJCOM/DRU/HQ AFICA/AFISRA/SMC ombudsman level, may be brought by the interested party for further consideration to the Air Force ombudsman, Associate Deputy Assistant Secretary (ADAS) (Contracting), SAF/AQC, 1060 Air Force Pentagon, Washington DC 20330-1060, phone number (571) 256-2395, facsimile number (571) 256-2431.

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements. Such inquiries shall be directed to the Contracting Officer.

Section J - List of Documents, Exhibits and Other Attachments

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

Attachment 1 Submittal Requirements 3 01-MAY-2017 Attachment 2 Specifications 171 01-MAY-2017 Attachment 3 Government Drawings 7 02-JAN-2017

Section K - Representations, Certifications and Other Statements of Offerors

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2017)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238160.

(2) The small business size standard is $15,000,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding elinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.222-57, Representation Regarding Compliance with Labor Laws (Executive Order 13673). This provision applies to solicitations expected to exceed $50 million which are issued from October 25, 2016 through April 24, 2017, and solicitations expected to exceed $500,000, which are issued after April 24, 2017.

Note to paragraph (c)(1)(xvi): By a court order issued on October 24, 2016, 52.222-57 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,533, the provision with its Alternate II applies.

(D) If the acquisition value is $77,533 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

Section L - Instructions, Conditions and Notices to Bidders

SECTION L & M

SECTION L - Instructions, Conditions and Notices to Bidders

PROPOSAL PREPARATION INSTRUCTIONS

A. This soliciation is Full and Open and is unrestricted.

B. To assure a timely and equitable evaluation of proposals, offerors must follow the instructions contained herein.

Offerors are required to meet all solicitation requirements, including terms and conditions, representations and Certifications, technical requirements, in addition to those identified as evaluation factors or subfactors (Section M).

Failure to meet a requirement may result in an offer being ineligible for award. Offerros must clearly identify any exception to the solicitation terms and conditions and provide complete accompanying rationale. The response shall consist of two (2) separate parts; Part I - Price Proposal and Part II - Technical Proposal.

C. The contracting officer has determined there is a high probability of adequate price competition in this acquisition. Upon examination of the initial offers, the contracting officer will review this determination and if, in the Contracting Officer’s opinion, adequate price competition exists no additional cost information will be requested and certification under FAR 15.406-2 will not be required. However, if at any time during this competition the contracting officer determines that adequate price competition no longer exists; offerors may be required to submit information to the extent necessary for the contracting officer to determine the reasonableness and affordability of the price.

C. Specific instructions:

1. PART I – PRICE PROPOSAL

a. Complete blocks 14 through 20C of the solicitation Section A, SF 1442. In doing so, the offeror accedes to the contract terms and conditions as written in solicitation Sections A through K. These sections constitute the model contract.

b. Insert proposed unit and extended prices in Section B for each Contract Line Item Number (CLIN)

c. Complete the necessary fill-ins and certifications in Sections K. Section K shall be returned in its entirety. For Sections F through J, the offeror shall submit only those pages that require a fill-in.

d. A letter of authorization for the contracting officer to verify offeror’s financial responsibility.

Include name, address and phone numbers for financial institutions to include point of contact.

e. Acknowledgement of all amendments to the solicitation in accordance with the instructions on the

SF 30 (amendment form).

2. PART II – TECHNICAL PROPOSAL - Limited to no more than 10 pages.

a. Subfactor 1 - Alvara Certification: Offerors shall provide one (1) current copy, in Portuguese and one (1) officially translated English copy of the Alvara Certification. Offeror shall furnish Alvara Certification that proves they are certified to conduct business in the country of Portugal using the scope and magnitude of this requirement. If offeror proposes to use a sub-contractor they must provide the Alvara Certification of this company with the sub-contractor’s.

b. Subfactor 2 – Staffing Plan: This sub-factor shows the offeror’s proposed methodology to meet the unique staffing and manning requirements for paving projects as described in the attached specifications (Attachment 1), to include organization structure, and recruitment and coverage of key positions. The offeror’s proposal shall include at a minimum the following positions:

Project Manager Site Superintendent Quality Control Manager

3. Documents submitted in response to this solicitation must be fully responsive to and consistent with the following:

(a) Requirements of the solicitation (Specifications) and government standards and regulations pertaining to the specifications.

(b) Evaluation Factors for Award in Section M of this solicitation.

(c) Any limitation on the number of proposal pages. Pages exceeding the limitations set forth in this Section L will not be read or evaluated, and will be removed from the proposal.

D. General Information:

1. Format for proposal Parts II shall be as follows:

(a) The proposals will be 8 1/2” x 11” paper or standard A4 paper, except for fold-outs used for charts, tables, or diagrams, which may not exceed 11” x 17”.

(b) A page is defined as one face of a sheet of paper containing information.

(c) Typing shall not be less than 10 point.

(d) Elaborate formats, bindings or color presentations are not desired or required.

2. Offeror should allow sufficient time to arrive and submit the proposals to Contracting Office PRIOR to the set closing time. Late proposals will be processed in accordance with the provisions established in FAR 15.208 “Late Submission, Modifications, and Withdrawals of Proposals”. If a gate access is not granted please contact the Contracting Offocer immediately. The contractors are responsible for coordinating and processing gate pass requests in a timely manner. The USAF shall not be held accountable. The USAF shall not be responsible for delays due to in-processing or out-processing the base.

3. All contractor’s questions in response to this solicitation must be emailed to pedro.mendes.pt@us.af.mil and 65CONF.LGC.ALL@us.af.mil no later than 1 July 2017 at 1400 AZOST. The US Government will not be held responsible for answering any questions after this time. All questions/answers resulting from this solicitation will be disseminated via email.

4. This section provides general guidance for preparing proposals. Offerors’ proposals must include all data and information requested by this solicitation and must be submitted and conducted in strict accordance with these instructions. Non-conformance with the specific organization, content, and page limitations may result in proposal not being considered for award or depending on the magnitude of the nonconformance; the proposals may be eliminated from further consideration.

5. The proposal must be completed and returned no later than 10 July 2017 at 1400 AZOST. To :

65 CONF/LGCA

Attn: Pedro Mendes, FA4486-17-R-0010

UNIT 7710

Lajes Air Field, Lajes, Portugal 09720

6. Notice to Offerors: The Government reserves the right to cancel this solicitation, either before or after the closing date. In the event the Government cancels this solicitation, the Government has no obligation to reimburse an offeror for any costs.

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2016 52.204-7 System for Award Management OCT 2016 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.214-34 Submission Of Offers In The English Language APR 1991 52.215-1 Instructions to Offerors--Competitive Acquisition JAN 2017 52.236-27 Alt I Site Visit (Construction) (Feb 1995) - Alternate I FEB 1995 252.204-7006 Billing Instructions OCT 2005 252.225-7042 Authorization to Perform APR 2003

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from Pedro Mendes, 65 CONF, Unit 7710, APO AE 09720.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

252.204-7004 ALTERNATE A, SYSTEM FOR AWARD MANAGEMENT (FEB 2014)

(a) Definitions. As used in this provision—

“System for Award Management (SAM) database” means the primary Government repository for contractor information required for the conduct of business with the Government.

“Commercial and Government Entity (CAGE) code” means—

(1) A code assigned by the Defense Logistics Information Service (DLIS) to identify a commercial or Government entity; or

(2) A code assigned by a member of the North Atlantic Treaty Organization that DLIS records and maintains in the CAGE master file. This type of code is known as an “NCAGE code.”

“Data Universal Numbering System (DUNS) number” means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities.

“Data Universal Numbering System +4 (DUNS+4) number” means the DUNS number assigned by D&B plus a 4-character…