FA4484-14-R-0006_Solicitation.pdf

A. Project Title: Construct New and Repair of Asphalt and Concrete, Indefinite Delivery Indefinite Quantity (IDIQ) Multiple Aw ard Task Order

Contract (MATOC). The NAICS Code is 237310 and Small Business Size Standard is $33.5 Million.

B. This acquisition is set-aside 100% for Small Business. The Government anticipates aw ard of approximately three (3) Small Business contracts.

C. Contract performance period is scheduled for a Base Year plus four (4) one-year Option Periods.

D. The Guaranteed minimum amount over the life of the contract is $500.00. The Guaranteed minimum w ill be satisfied w hen a contractor is aw arded a Task Order at the time of initial contract aw ard.

E. The total aggregate maximum amount expendable under all MATOC contracts aw arded shall not exceed $82,884,468.75 and each contract shall not exceed $27,628,156.25 for base and all option years.

F. The "sample project" magnitude is betw een $250,000.00 and $500,000.00

G. Please pay particular attention to Section L, "Instructions, Conditions, and Notices to Offerors" for proper proposal preparation and refer to

Section J, "List of Attachments" and Section M, "Evaluation Factors for Aw ard".

H. Do not price section B CLINs, provide pricing for the sample and seed projects on the Schedule in Section J.

KARL A. KNOTT 609-754-3956

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

30-May-2014

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

X

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________365 calendar days after receiving aw ard, notice to proceed. This performance period is mandatory, X negotiable. (See _________________________FAR 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________30 Jun 2014 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

87 CONS/LGC

2402 VANDENBERG AVE

JB MCGUIRE-DIX-LAKEHURST NJ 08641

FA4484

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

10:00 AM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

609-754-3735FAX:TEL: 609-754-2413 TEL: FAX:

FA4484-14-R-0006 47

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued)

(Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

FA4484-14-R-0006

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES MAX

QUANTITY

UNIT UNIT PRICE MAX AMOUNT

0001 10,000 Each Concrete and Paving Base Year

FFP

The contractor shall furnish all labor, materials, equipment, transportation, fuel, supervision, permits and all other necessary items required to perform individual task orders for concrete and paving projects at Joint Base McGuire-Dix-

Lakehurst, NJ. All orders shall be performed in accordance with the Statement of

Work. Period of Performance: 9 Sep 14 to 8 Sep 15.

FOB: Destination

SIGNAL CODE: A

MAX

NET AMT

UNIT UNIT PRICE MAX AMOUNT

1001 10,000 Each OPTION Concrete and Paving 1st Option Year

FFP

The contractor shall furnish all labor, materials, equipment, transportation, fuel, supervision, permits and all other necessary items required to perform individual task orders for concrete and paving projects at Joint Base McGuire-Dix-

Lakehurst, NJ. All orders shall be performed in accordance with the Statement of

Work. Period of Performance: 9 Sep 15 to 8 Sep 16.

UNIT UNIT PRICE MAX AMOUNT

2001 10,000 Each OPTION Concrete and Paving 2nd Option Year

FFP

The contractor shall furnish all labor, materials, equipment, transportation, fuel, supervision, permits and all other necessary items required to perform individual task orders for concrete and paving projects at Joint Base McGuire-Dix-

Lakehurst, NJ. All orders shall be performed in accordance with the Statement of

Work. Period of Performance: 9 Sep 16 to 8 Sep 17.

UNIT UNIT PRICE MAX AMOUNT

3001 10,000 Each OPTION Concrete and Paving 3rd Option Year

FFP

The contractor shall furnish all labor, materials, equipment, transportation, fuel, supervision, permits and all other necessary items required to perform individual task orders for concrete and paving projects at Joint Base McGuire-Dix-

Lakehurst, NJ. All orders shall be performed in accordance with the Statement of

Work. Period of Performance: 9 Sep 17 to 8 Sep 18.

UNIT UNIT PRICE MAX AMOUNT

4001 10,000 Each OPTION Concrete and Paving 4th Option Year

FFP

The contractor shall furnish all labor, materials, equipment, transportation, fuel, supervision, permits and all other necessary items required to perform individual task orders for concrete and paving projects at Joint Base McGuire-Dix-

Lakehurst, NJ. All orders shall be performed in accordance with the Statement of

Work. Period of Performance: 9 Sep 18 to 8 Sep 19.

CLIN DELIVERY/TASK ORDER MINIMUM/MAXIMUM QUANTITY AND CLIN ORDER

VALUE

The minimum quantity and order value for the given Delivery/Task Order issued for this CLIN shall not be less than the minimum quantity and order value stated in the following table. The maximum quantity and order value for the given Delivery/Task Order issued for this CLIN shall not exceed the maximum quantity and order value stated in the following table.

CLIN

MINIMUM

QUANTITY

MINIMUM

AMOUNT

MAXIMUM

QUANTITY

MAXIMUM

AMOUNT

0001 1.00

$2,000.00

1.00

$5,000,000.00

1001 1.00

2001 1.00

3001 1.00

4001 1.00

Section C - Descriptions and Specifications

LIST OF ATTACHMENTS

C-1 …………………………………....... Statement of Work (MAR 2013), 77 Pages

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

1001 Destination Government Destination Government

2001 Destination Government Destination Government

3001 Destination Government Destination Government

4001 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.246-12 Inspection of Construction AUG 1996

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS UIC

0001 POP 09-SEP-2014 TO

08-SEP-2015

N/A 87 CES/CEC-F3A3Q9

CYNTHIA LEEK

2401 VANDENBERG AVE

MCGUIRE AFB NJ 08641-5502

609-562-3899

F3A3Q9

1001 POP 09-SEP-2015 TO

08-SEP-2016

N/A (SAME AS PREVIOUS LOCATION)

2001 POP 09-SEP-2016 TO

08-SEP-2017

N/A (SAME AS PREVIOUS LOCATION)

3001 POP 09-SEP-2017 TO

08-SEP-2018

N/A (SAME AS PREVIOUS LOCATION)

4001 POP 09-SEP-2018 TO

08-SEP-2019

N/A (SAME AS PREVIOUS LOCATION)

CLAUSES INCORPORATED BY FULL TEXT

52.242-14 SUSPENSION OF WORK (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting

Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly.

However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

(End of clause)

Section G - Contract Administration Data

ADMINISTRATIVE MATTERS

1.1 ADMINISTRATIVE MATTERS

Mailing address and telephone number for the 87 th

Contracting Construction Flight:

th

Contracting Squadron/LGCB

2402 Vandenberg Ave

Joint Base McGuire-Dix-Lakehurst, NJ 08641

(609) 754-2717

1.2 CONTRACTOR’S CONTRACT ADMINISTRATION

To Be Completed By The Contractor:

Name and Title:______________________________________________________________________

Address:____________________________________________________________________________

Telephone Number:___________________________________________________________________

Email:_____________________________________________________________________________

Cage Code:_________________________________________________________________________

DUNS Number:______________________________________________________________________

Tax Identification Number:_____________________________________________________________

1.3 INDIVIDUAL(S) AUTHORIZED TO NEGOTIATE OR DISCUSS PROPOSAL

Name of Primary:__________________________ Name of Alternate:___________________________

Address:__________________________________ Address:__________________________________

Telephone:________________________________ Telephone:________________________________

Email:___________________________________ Email:____________________________________

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow

(WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training

Course and use the Practice Training Site before submitting payment requests through

WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data

Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

COMBO

(Contracting Officer: Insert applicable document type(s). Note: If a “Combo” document type is identified but not supportable by the Contractor's business systems, an “Invoice” (stand-alone) and

“Receiving Report” (stand-alone) document type may be used instead.)

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in

WAWF, as specified by the contracting officer.

Per Individual Task Order

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC ____

Issue By DoDAAC ____

Admin DoDAAC ____

Inspect By DoDAAC ____

Ship To Code ____

Ship From Code ____

Mark For Code ____

Service Approver (DoDAAC) ____

Service Acceptor (DoDAAC) ____

Accept at Other DoDAAC ____

LPO DoDAAC ____

DCAA Auditor DoDAAC ____

Other DoDAAC(s) ____

(*Contracting Officer: Insert applicable DoDAAC information or “See schedule” if multiple ship to/acceptance locations apply, or “Not applicable.”)

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional

Email Notifications” field of WAWF once a document is submitted in the system.

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

Section H - Special Contract Requirements

SPECIAL CONTRACT REQUIREMENTS

H.1 REQUIRED INSURANCE

Reference FAR 52.228-5 clause entitled, Insurance – Work On A Government Installation, the Contractor shall, at its own expense, procure and thereafter maintain the following kinds of insurance with respect to performance under the contract.

a. Workmen’s Compensation and Employers Liability Insurance as required by law except that if this contract is to be performed in a State which does not require or permit private insurance, then compliance with the statutory or administrative requirements in any such State will be satisfactory. The requirement Workmen’s Compensation insurance shall extend to cover employers with a minimum liability limit of $100,000.

b. General Liability Insurance. Bodily injury liability insurance, in the minimum limits of $500,000 per occurrence shall be required on the comprehensive form of policy.

c. Automobile Liability Insurance. This insurance shall be required on the comprehensive form of policy and shall provide bodily injury liability and property damage liability covering the operation of all automobiles used in connection with the performance of the contract. At least the minimum limits of $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage shall be required.

d. The Certificate of Insurance shall provide for thirty (30) days written notice to the contracting officer by the insurance company prior to cancellation or material change in policy coverage. Other requirements and information are contained in the aforementioned “Insurance” clause.

H.2 FEDERAL HOLIDAYS

The following Federal Legal holidays are observed by this base:

New Year’s Day 1 January

Martin Luther King’s Birthday Third Monday in January

President’s Day Third Monday in February

Memorial Day Last Monday in May

Independence Day 4 July

Labor Day First Monday in September

Columbus Day Second Monday in October

Veteran’s Day 11 November

Thanksgiving Day Fourth Thursday in November

Christmas Day 25 December

H.3 PROPOSAL PREPARATION

All costs for preparation of task order proposals, whether funded or unfunded, shall be the contractor’s responsibility. At no time shall the government provide reimbursement for the preparation of proposals.

H.4 PERFORMANCE AND PAYMENT BOND REQUIREMENTS

a. Performance and Payments Bonds. In accordance with the Miller Act (40 U.S.C. 2701-270f), the bidder to whom award is made shall, within ten (10) calendar days after the date of award, furnish a performance bond (Standard

Form 25) and a Payment Bond (Standard Form 265a), each with good and sufficient surety or sureties acceptable to the Government. A list of authorized sureties can be obtained at http://fms.treas.gov/c570/c570_a-z.html#i. The penal sum of the performance and payment bonds shall equal one hundred percent (100%) of the contract price. If http://fms.treas.gov/c570/c570_a-z.html#i the contract price increases by modification to the contract, an amount equal to one hundred percent (100%) of the increase will be required.

H.5 PREPARATION OF PROGRESS SCHEDULE AND REPORTS

The reports contemplated by the clause herein entitled “Schedules for Construction Contracts” shall be accomplished on and in accordance with instructions pertaining to AF Form 3064, Contract Progress Schedule, and AF Form 3065, Contract Progress Report.

H.6 PREPARATION OF MATERIAL APPROVAL SUBMITTALS

The submittals contemplated by the clause herein entitled “Material and Workmanship” shall be accomplished on and in accordance with instructions pertaining to AF Form 3000, Material Approval Submittal.

H.7 INSTALLATION RULES AND REGULATIONS

The rules and regulations of the installation where services are performed shall apply to the contractor and his employees while on the premises of such installation. These regulations included but are not limited to: presenting valid identification for base entrances, state registration and covered insurance for contractor-owned and/or privately owned vehicles, obeying all posted directives, and providing strict adherence to security police direction in instances where security police have been dispatched to a particular location.

H.8 PERIODS OF NATIONAL EMERGENCY

During periods of national emergency, contractors may be requested to depart the base immediately. Contractors may be denied entry to the base until the Government determines normal operations can resume. In the event this occurs, the contract will be extended, upon written request of the Contractor submitted to the Contracting Officer, for the length of time the contractor was denied entry to the base. No other relief or compensation shall be granted.

H.9 ANTITERRORISM

Reference:

Department of Defense Instruction (DoDI) 2000.16, DoD Antiterrorism (AT) Standards, 02 OCT

2006, paragraph E3.18, DoD Standard 18

Defense Federal Acquisition Regulation Supplement (DFARS) (Reference (r)) reflects current DoD

AT security requirements for defense contractors

Joint Publication 3-07.2 Antiterrorism

Terrorism is defined as:

The calculated use of unlawful violence or threat of unlawful violence to inculcate fear; intended to coerce or to intimidate governments or societies in the pursuit of goals that are generally political, religious, or ideological. See also antiterrorism; combating terrorism; counterterrorism; force protection condition; terrorist; terrorist groups.

Antiterrorism - As a prelude and during performance of any contract, it is critical that the Contractor be supportive of all Department of Defense (DoD) requirements to protect personnel and their families, installations, facilities, information, and other resources from terrorist acts. All Contractors and Sub-Contractors are responsible for providing their personnel information on the JB MDL Antiterrorism Program. During performance of work, personnel security and protection of resources is critical for the installation to maintain a safe work environment.

Contractors and contracted personnel will be alert for any suspicious activities while on the installation. If any situation appears to be suspicious, immediate actions must be taken to properly notify the 87th Security Forces

Squadron (SFS) Law Enforcement Desk at 609-562-6001 (McGuire-Dix) or 732- 323-4000 (Lakehurst).

Contractors must ensure that contracted personnel and vehicles are strictly controlled during performance of duty.

For instance, Contractors shall use reasonable efforts to prevent any personnel or equipment from being placed in harm’s way or in a position that could aid or abet terrorists. It is strongly recommended that all contracted personnel take the computer-based training (CBT) for the DoD-approved Antiterrorism Level I Training at https://atlevel1.dtic.mil/at/. Contractors are encouraged to contact the JB MDL Antiterrorism Office at 609-754-

1397 for information regarding the installation Antiterrorism Program.

REMEMBER IF YOU SEE SOMETHING – SAY SOMETHING

H.10 ON AND OFF RAMPS

The Government intends to utilize an “on and off ramp” concept to manage the recertification process and maintain a sufficient pool of contract awardees. In order to ensure an adequate number of contractors are available at all times to achieve effective competition on all task orders, the Government intends to maintain a pool of small business contractors with proven track records for competing and delivering quality construction projects.

1. Off Ramps: Contract holders are expected, in good faith, to participate in the task order competitions, and if successful, to deliver quality projects on time and on cost, to include management and supervision of subcontractors. If for any reason, a contractor cannot participate in a competition, the contractor shall provide written notice to the Government of the reason(s) for non-participation prior to the proposal due date. Before the exercise of any option period(s), the Government will evaluate all contractors' participation rates and reason(s) for non-participation, and performance evaluations for task orders completed or in effect. Failure to participate in good faith and/or an overall annual performance assessment rating of

Marginal or Unsatisfactory may result in the contractor being off ramped from the multiple award program.

An off ramp decision results in contract expiration on the anniversary date of the current contract year and no remaining option period(s) being exercised.

2. On Ramps: In the event contractor(s) are off ramped, the Government reserves the right to on ramp contractor(s) in order to maintain a pool of small business contractors. On ramp contractors will be selected based on initial evaluation results from the basic multiple award solicitation in order of ranking. Selected on ramp contractors will be subject to a performance validation review before being awarded a contract.

Contractor(s) must be active in SAM and otherwise in compliance with the original multiple award solicitation. If found in compliance, on ramp contractors may be offered a bi-lateral ID/IQ contract with the guaranteed minimum from the original solicitation and allowed to compete on future task order projects.

The Government will not use on ramp procedures beyond the 30 month mark from initial award. The original performance period for contract holders is one base year plus four (4) option years; no contract will extend beyond the original IDIQ’s period of performance plus a six month extension per FAR 52.217-8 regardless of when a basic contract is awarded.

https://atlevel1.dtic.mil/at/

Section I - Contract Clauses

52.202-1 Definitions JAN 2012

52.203-3 Gratuities APR 1984

52.203-5 Covenant Against Contingent Fees APR 1984

52.203-7 Anti-Kickback Procedures OCT 2010

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

JAN 1997

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity JAN 1997

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-13 Contractor Code of Business Ethics and Conduct APR 2010

52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

SEP 2013

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-10 Reporting Executive Compensation and First-Tier Subcontract

Awards

AUG 2012

52.204-13 System for Award Management Maintenance JUL 2013

52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for

Debarment

DEC 2010

52.209-9 Updates of Publicly Available Information Regarding

Responsibility Matters

FEB 2012

52.210-1 Market Research APR 2011

52.215-2 Audit and Records--Negotiation OCT 2010

52.215-8 Order of Precedence--Uniform Contract Format OCT 1997

52.219-6 Notice Of Total Small Business Set-Aside NOV 2011

52.219-8 Utilization of Small Business Concerns JAN 2011

52.219-14 Limitations On Subcontracting NOV 2011

52.222-1 Notice To The Government Of Labor Disputes FEB 1997

52.222-3 Convict Labor JUN 2003

52.222-4 Contract Work Hours and Safety Standards Act - Overtime

Compensation

JUL 2005

52.222-6 Davis Bacon Act JUL 2005

52.222-7 Withholding of Funds FEB 1988

52.222-8 Payrolls and Basic Records JUN 2010

52.222-9 Apprentices and Trainees JUL 2005

52.222-10 Compliance with Copeland Act Requirements FEB 1988

52.222-11 Subcontracts (Labor Standards) JUL 2005

52.222-12 Contract Termination-Debarment FEB 1988

52.222-13 Compliance with Davis-Bacon and Related Act Regulations. FEB 1988

52.222-14 Disputes Concerning Labor Standards FEB 1988

52.222-15 Certification of Eligibility FEB 1988

52.222-21 Prohibition Of Segregated Facilities FEB 1999

52.222-26 Equal Opportunity MAR 2007

52.222-27 Affirmative Action Compliance Requirements for

Construction

FEB 1999

52.222-30 Davis-Bacon Act--Price Adjustment (None or Separately

Specified Method)

DEC 2001

52.222-35 Equal Opportunity for Veterans SEP 2010

52.222-36 Affirmative Action For Workers With Disabilities OCT 2010

52.222-37 Employment Reports on Veterans SEP 2010

52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons FEB 2009

52.222-54 Employment Eligibility Verification JUL 2012

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011

52.223-6 Drug-Free Workplace MAY 2001

52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008

52.227-1 Authorization and Consent DEC 2007

52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007

52.228-1 Bid Guarantee SEP 1996

52.228-2 Additional Bond Security OCT 1997

52.228-5 Insurance - Work On A Government Installation JAN 1997

52.228-11 Pledges Of Assets JAN 2012

52.228-12 Prospective Subcontractor Requests for Bonds OCT 1995

52.228-14 Irrevocable Letter of Credit DEC 1999

52.228-15 Performance and Payment Bonds--Construction OCT 2010

52.229-3 Federal, State And Local Taxes APR 2003

52.232-5 Payments under Fixed-Price Construction Contracts SEP 2002

52.232-17 Interest OCT 2010

52.232-23 Assignment Of Claims JAN 1986

52.232-27 Prompt Payment for Construction Contracts OCT 2008

52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-37 Multiple Payment Arrangements MAY 1999

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013

52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes JUL 2002

52.233-3 Protest After Award AUG 1996

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.236-2 Differing Site Conditions APR 1984

52.236-3 Site Investigation and Conditions Affecting the Work APR 1984

52.236-5 Material and Workmanship APR 1984

52.236-6 Superintendence by the Contractor APR 1984

52.236-7 Permits and Responsibilities NOV 1991

52.236-8 Other Contracts APR 1984

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984

52.236-11 Use and Possession Prior to Completion APR 1984

52.236-12 Cleaning Up APR 1984

52.236-13 Accident Prevention NOV 1991

52.236-14 Availability and Use of Utility Services APR 1984

52.236-15 Schedules for Construction Contracts APR 1984

52.236-17 Layout of Work APR 1984

52.236-26 Preconstruction Conference FEB 1995

52.242-13 Bankruptcy JUL 1995

52.243-4 Changes JUN 2007

52.246-21 Warranty of Construction MAR 1994

52.248-3 Value Engineering-Construction OCT 2010

52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984

52.253-1 Computer Generated Forms JAN 1991

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense-

Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights JAN 2009

252.203-7003 Agency Office of the Inspector General DEC 2012

252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.204-7004 Alt A System for Award Management Alternate A MAR 2014

252.204-7006 Billing Instructions OCT 2005

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Terrorist Country

DEC 2006

252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements DEC 2010

252.223-7004 Drug Free Work Force SEP 1988

252.223-7006 Prohibition On Storage And Disposal Of Toxic And

Hazardous Materials

APR 2012

252.223-7008 Prohibition of Hexavalent Chromium MAY 2011

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006

252.236-7000 Modification Proposals-Price Breakdown DEC 1991

252.236-7001 Contract Drawings, and Specifications AUG 2000

252.236-7005 Airfield Safety Precautions DEC 1991

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.243-7002 Requests for Equitable Adjustment MAR 1998

252.246-7000 Material Inspection And Receiving Report MAR 2008

252.247-7023 Transportation of Supplies by Sea MAY 2002

5352.223-9001 Health and Safety On Government Installations JUN 2012

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian

Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than

$10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

(End of provision)

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the

Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready https://www.acquisition.gov/ for use not later than the period of performance specified in each individual task order.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $492.40 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.216-19 ORDER LIMITATIONS. (OCT 1995)

(a) Minimum order. When the Government requires supplies or services covered by this contract in an amount of less than $2,000, the Government is not obligated to purchase, nor is the Contractor obligated to furnish, those supplies or services under the contract. The initial orders are only to meet the minimum guarantee of the contract and may be less than the stated minimum order amount.

(b) Maximum order. The Contractor is not obligated to honor:

(1) Any order for a single item in excess of $5,000,000;

(2) Any order for a combination of items in excess of $5,000,000; or

(3) A series of orders from the same ordering office within 30 days that together call for quantities exceeding the limitation in subparagraph (1) or (2) above.

(c) If this is a requirements contract (i.e., includes the Requirements clause at subsection 52.216-21 of the Federal

Acquisition Regulation (FAR)), the Government is not required to order a part of any one requirement from the

Contractor if that requirement exceeds the maximum-order limitations in paragraph (b) above.

(d) Notwithstanding paragraphs (b) and (c) above, the Contractor shall honor any order exceeding the maximum order limitations in paragraph (b), unless that order (or orders) is returned to the ordering office within 5 days after issuance, with written notice stating the Contractor's intent not to ship the item (or items) called for and the reasons.

Upon receiving this notice, the Government may acquire the supplies or services from another source.

52.216-22 INDEFINITE QUANTITY. (OCT 1995)

(a) This is an indefinite-quantity contract for the supplies or services specified, and effective for the period stated, in the Schedule. The quantities of supplies and services specified in the Schedule are estimates only and are not purchased by this contract.

(b) Delivery or performance shall be made only as authorized by orders issued in accordance with the Ordering clause. The Contractor shall furnish to the Government, when and if ordered, the supplies or services specified in the Schedule up to and including the quantity designated in the Schedule as the "maximum". The Government shall order at least the quantity of supplies or services designated in the Schedule as the "minimum".

(c) Except for any limitations on quantities in the Order Limitations clause or in the Schedule, there is no limit on the number of orders that may be issued. The Government may issue orders requiring delivery to multiple destinations or performance at multiple locations.

(d) Any order issued during the effective period of this contract and not completed within that period shall be completed by the Contractor within the time specified in the order. The contract shall govern the Contractor's and

Government's rights and obligations with respect to that order to the same extent as if the order were completed during the contract's effective period; provided, that the Contractor shall not be required to make any deliveries under this contract after 8 September 2019.

52.217-8 OPTION TO EXTEND SERVICES (NOV 1999)

The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor within 30 days prior to contract expiration.

52.217-9 OPTION TO EXTEND THE TERM OF THE CONTRACT (MAR 2000)

(a) The Government may extend the term of this contract by written notice to the Contractor within 30 days prior to contract expiration; provided that the Government gives the Contractor a preliminary written notice of its intent to extend at least 60 days prior to contract expiration. The preliminary notice does not commit the Government to an extension.

(b) If the Government exercises this option, the extended contract shall be considered to include this option clause.

(c) The total duration of this contract, including the exercise of any options under this clause, shall not exceed 5 years and 6 months.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (APR 2012)

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the rerepresentation required by paragraph (b) of this clause by validating or updating all its representations in the Online Representations and

Certifications Application and its data in the Central Contractor Registration, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the

Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in ORCA, or does not have a representation in

ORCA for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code 237310- assigned to contract number-----.

(Contractor to sign and date and insert authorized signer's name and title).

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013)

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The

Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the

Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(…