Attch_05_01_32_16_00_20_PROJ_SCHED_ _PROG_DOCS.pdf

SECTION 01 32 16.00 20

PROJECT SCHEDULE AND PROGRESS DOCUMENTATION

11/09

PART 1 GENERAL

Pursuant to Contract Clause "FAR 52.236-15, Schedules for Construction Contracts," a Project Schedule as described below shall be prepared.

Scheduling of construction shall be the responsibility of the Contractor.

Contractor management personnel actively participate in the development of the project schedule. Contractor management personnel shall coordinate closely with Contracting Officer/Galley Management/CEMNP in the maintenance of the schedule. Subcontractors and suppliers working on the project shall also contribute in developing and maintaining an accurate schedule. The approved schedule shall be used to measure the progress of work, to aid in evaluating time extensions, and to provide the basis of all progress payments.

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Qualifications; G

Baseline Project schedule; G, 628 CES/CENMP

Initial Contract Progress Report (AF IMT 3065); G, 628 CES/CENM

Initial Contract Progress Schedule (AF IMT 3064); G, 628 CES/CENM

SD-07 Certificates

Monthly Project Schedule Update; G, 628 CES/CENMP

Monthly Contract Progress Report (AF IMT 3065); G

Monthly Contract Progress Schedule (AF IMT 3064); G

1.2 QUALIFICATIONS

The Contractor shall designate an authorized representative responsible for preparing and maintaining the project schedule for this contract. This individual shall have prepared and maintained at least 3 previous schedules of similar size, scope and complexity to this contract. A resume outlining the individual's qualifications shall be submitted for acceptance by the Contracting Officer.

1.3 PROJECT SCHEDULE

1179187112C Typewritten Text FA4418-15-R-0017 Attachment #5

1.3.1 Basis for payment

The Project Schedule shall be the basis for measuring Contractor progress.

Lack of an approved updated project schedule may result in an inability of the Contracting Officer to evaluate the Contractor's progress for the purposes of payment. The Baseline Project Schedule shall be submitted for approval within 30 calendar days after the Notice to Proceed (NTP) has been acknowledged. Acceptance of an error free current Project Schedule is a condition precedent to processing any Contractor's pay request except bond payments. In the cases where Project Schedule revisions have been directed by the Contracting Officer and those revisions have not been included in the Project Schedule, the Contracting Officer may hold retainage up to the maximum amount allowed by the contract, each payment period, until the revisions have been made.

Review comments made by the Government on the Contractor’s schedule(s) will not relieve the Contractor from compliance with the requirements of the Contract Documents. The Contractor is responsible for scheduling, sequencing and prosecuting work to comply with the requirements of the Contract Documents. Government acceptance extends only to the activities of the Contractor’s schedule that the Government has been assigned responsibility and agrees it is responsible. Comments offered on other parts of the schedule, to which the Contractor is assigned responsibility, are offered as a courtesy and are not conditions of Government acceptance;

but are for the general conformance with established industry scheduling concepts.

1.3.2 Schedule Format

1.3.2.1 Use of the Critical Path Method

The Contractor shall use the critical path method (CPM) and the Precedence Diagram Method (PDM) to schedule and control project activities.

1.3.2.2 Scheduling Software

Project schedules shall be prepared and maintained using a commercially available scheduling software program capable of providing all requirements of this specification. Manual methods used to produce any required information shall require prior approval by the Contracting Officer.

1.3.2.3 Level of Detail Required

The Project Schedule shall include an appropriate level of detail to appropriately reflect the complexity of work and to clearly show all construction activities planned for the project as well as all other activities which could impact project completion if delayed, including but not limited to; submittals, government review periods, environmental permitting, material/equipment delivery, utility outages, anticipated weather delays, inspection, testing, and closeout activities. Government and Contractor on-site work activities shall be driven by calendars that reflect Saturdays, Sundays and all Federal Holidays as non-work days. Activities on the critical path shall be clearly indicated. Separate activities shall be created for each Phase, Area, Floor Level and Location the activity is occurring. On-site construction activities with anticipated durations in excess of 20 working days shall be broken into multiple activities. Tasks related to procurement of long lead materials or equipment (procurement cycles of over 90 days) shall be included as separate activities.

At a minimum, each activity shall include the following information:

a. Activity ID

b. Activity Description

c. Original Duration in Work Days

d. Early Start Date

e. Early Finish Date

f. Late Start Date

g. Late Finish Date

h. Total Float

i. Bid Item

j. Percent Complete

All activities shall be identified in the Project Schedule by the Bid Item to which the activity belongs. An activity shall not contain work in more than one bid item.

k. Feature of Work

All activities shall be identified in the Project Schedule according to the Contractor designated Definable Feature of Work to which the activity belongs. An activity shall not contain work in more than one feature of work.

l. Responsibility

All activities shall be identified in the Project Schedule according to the party responsible for accomplishing the work encompassed by the activity. Responsibility includes, but is not limited to, the subcontracting firm, contractor work force, or government agency performing a given task. Activities shall not be assigned to more than one responsible party in the Project Schedule.

Project Start Date Milestone: The Contractor shall include as the first activity on the schedule a start milestone titled "Contract Award", which shall have a Mandatory Start constraint equal to the Contract Award Date.

Projected Completion Milestone: The Contractor shall include an unconstrained finish milestone on the schedule titled "Projected Completion", indicating the point in time at which the project is complete and ready for its intended use. This milestone shall have the Contract Completion Date (CCD) as its only successor.

Contract Completion Date (CCD) Milestone: The Contractor shall include as the last activity on the schedule a finish milestone titled "Contract Completion (CCD)", which shall have a Mandatory Finish constraint equal to the Contract Completion Date. The only predecessor to the Contract Completion Date Milestone shall be the Projected Completion milestone.

With the exception of the Contract Award and Contract Completion Date (CCD) milestone activities, no activity shall be open-ended; each activity shall have predecessor and successor ties. Once an activity exists on the approved schedule, it shall not be deleted or renamed to change the scope of the activity, nor shall it be removed from the schedule logic without approval from the Contracting Officer.

Date/time constraint(s) and/or lags, other than those required by the contract, shall not be allowed unless accepted by the Contracting Officer.

1.3.2.4 Submittals and Procedures

Submit project schedule and updates in hard copy and on electronic media acceptable to the Contracting Officer. Submittals shall be understood to be the Contractor's certification that the submitted schedule meets all requirements of the Contract documents, represents the Contractor's plan on how the work shall be accomplished, and accurately reflects the work that has been accomplished and how it was sequenced (as-built logic).

Actual start and Finish dates shall not be automatically updated by default mechanisms that may be included in the CPM scheduling software system.

Actual Start and Finish dates shall match those dates from the Contractor Quality Control Reports. Updating of the percent complete and the remaining duration of any activity shall be independent functions. Program features which calculate one of these parameters from the other shall be disabled.

1.3.3 PROJECT SCHEDULE UPDATES

The Project Schedule shall be kept current, reflecting actual activity progress and plan for completing the remaining work. Contractor and Government representatives shall meet at monthly intervals to review and agree on the information presented in the updated project schedule. Updated Project Schedules shall also be submitted for Government approval in conjunction with any Contractor requests for additional time. Submit copies of purchase orders and confirmation of delivery dates as directed by the Contracting Officer.

1.3.3.1 Narrative Report

Each updated project schedule shall be accompanied by a narrative report identifying and justifying;

a. progress made in each area of the project

b. the current Critical Path

c. date/time constraint(s), other than those required by the contract

d. changes in the following;

i. added or deleted activities

ii. original and remaining durations for activities which have not started

iii. logic

iv. milestones

v. planned sequence of operations

vi. critical path

e. pending items and status thereof, including permits, changes orders, and time extensions;

f. status of Contract Completion Date and interim milestones;

g. current and anticipated delays (describe cause of delay and corrective actions)

h. description of current and future schedule problem areas.

Each entry in the narrative report will cite the respective Activity ID and Activity description, the date and reason for the change, and description of the change.

1.4 PROGRESS DOCUMENTATION

1.4.1 Contract Progress Reports

Prior to commencement of work, submit the Initial Contract Progress Report (AF IMT 3065). The number of line items on the Contract Progress Schedule shall appropriately reflect the complexity of the work, phasing requirements and other project constraints. At a minimum, the Contract Progress Report shall include a line item for each Definable Feature of Work identified in the approved Quality Control Plan. Once the Initial Contract Progress Report has been approved by the Contracting Officer, submit updated Monthly Contract Progress Reports (AF IMT 3065) for Government approval for the duration of the contract.

1.4.2 Contract Progress Schedules

Prior to commencement of work, submit the Initial Contract Progress Schedule (AF IMT 3064). Work elements shall be identical to the elements listed on the Contract Progress Report (AF IMT 3065) and the overall progress schedule shall reflect the more detailed Project Schedule. Once the Initial Contract Progress Schedule has been approved by the Contracting Officer, submit updated Monthly Contract Progress Schedules (AF IMT 3064) for Government approval for the duration of the contract.

1.4.3 3-WEEK LOOK AHEAD SCHEDULE

The Contractor shall prepare and issue a 3-Week Look Ahead schedule to provide a more detailed day-to-day plan of upcoming work identified on the Project Schedule. The work plans shall cover the planned work for the current and following two-week period and shall include upcoming outages, closures, preparatory meetings, and initial meetings. Identify critical path activities on the Three-Week Look Ahead Schedule. Three hard copies and one electronic file of the 3-Week Look Ahead Schedule shall be delivered to the Contracting Officer no later than 9 a.m. each Monday and reviewed during the CQC Coordination Meetings.

1.5 CORRESPONDENCE AND TEST REPORTS:

All correspondence (e.g., letters, Requests for Information (RFIs), e-mails, meeting minute items, Production and QC Daily Reports, material delivery tickets, photographs, etc.) shall reference Schedule activities that are being addressed. All test reports (e.g., concrete, soil compaction, weld, pressure, etc.) shall reference schedule activities that are being addressed.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

3.1 OWNERSHIP OF FLOAT

Float available in the schedule, at any time, shall not be considered for the exclusive use of either the Government or the Contractor.

3.2 CONTRACT MODIFICATION

Submit a Time Impact Analysis (TIA) with each cost and time proposal for a proposed change clearly illustrating the influence of each change or delay on the Contract Completion Date (CCD) or milestones. TIAs shall be in both narrative and schedule form demonstrating the delay impact. The TIA shall identify the predecessors to new activities and demonstrate impacts to successor activities. The TIA shall show all activity progress as of the date of the proposal. If the impact to the schedule occurs prior to the proposal submission, the TIA schedule shall be updated to show all activity progress as of the time of the impact. If the proposed change does not impact the CCD, a TIA shall not be required.

-- End of Section --

CONTRACT PROGRESS SCHEDULE Form Approved OMB NO. 0704-0188(See Contractor's Instructions on Reverse)

Public reporting burden for this collection of information is estimated to average 15 minutes per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden to Department of Defense, Washington Headquarters Services, Directorate for Information, Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington VA 22202-4302, and to the Office of Management and Budget Paperwork Reduction Project 0704-0188, Washington DC 20503. Please DO NOT RETURN your form/questionnaire to either of these addresses. Send your completed form/questionnaire to : SAF/AQCP, 1060 Air Force Pentagon, Washington DC 20330-1060

DATE SIGNED

DATE SIGNED CONTRACTING OFFICER'S SIGNATURE

CONTRACTOR'S NAME (Last, First, Middle Initial)

1. CONTRACT NO. 8. PROJECT TITLE

3. COMPLETION DATE

4. PURCHASE REQUEST NO.

LINE

NO

A

WORK ELEMENTS� %

C

WEEKS

D E F G H I J K L M N O P Q

10. APPROVAL RECOMMENDED BY:

DATE SIGNED

2. STARTING DATE

INSTALLATIONS ENGINEER'S SIGNATURE

5. PROJECT NO.

6. ACTUAL STARTING DATE

7. ACTUAL COMPLETION DATE

9. SUBMITTED BY:

ADDRESS (Street, City, State, Zip Code)

CONTRACTOR'S SIGNATURE 11. APPROVED BY:

AF IMT 3064, 20030901, V1 PREVIOUS EDITIONS ARE OBSOLETE

Click to sign

Click to sign

INSTRUCTIONS TO CONTRACTORS

1. Prepare three copies of AF Form 3064, in accordance with these instructions, and submit to the contracting officer at the time stated in the contract or as established by the contracting officer.

2. Blocks 1, 2, and 3. Enter the contract number, starting date, and completion date as shown on the contract.

3. Block 8. Enter the title of the project as shown on the contract.

4. Block 9. Enter name and address of your firm. The three copies submitted to the contracting officer must be dated and signed by the contractor or an authorized representative of the firm.

5. Lines 1 through 12. Major elements of work (whether unit price or lump sum contract) such as excavation, concrete work, carpentry, engineering, installation of communication electronic facilities, etc., will be shown in Column B in logical sequence and in sufficient detail to identify the element. If the contract calls for more than 11 work elements, additional copies of the AF Form 3064 may be used as a continuation for the work elements.

6. The percentage of each listed work element to the complete job will be shown opposite each element in Column C. As an example, if 3 work elements are shown: excavation, concrete work, and backfill, and it is estimated that excavation is 50% of the total job, concrete 30%, and backfill 20%, these percentages will be shown opposite each element. The total must equal 100%.

7. Columns D through Q will be used to show planned periodic progress, as required by the contracting officer, during the period of the contract. Only the top half of the space under these columns will be used by contractors. Using the example cited above and assuming that the contract period for performance is 8 weeks, and it is planned to accomplish 10% of the excavation work the 1st week and 20% each week until excavation is complete, 10 would be shown in the upper half of Line 1 under Column D, 20 under Column E, and 20 under Column F for a total of 50%. If it is planned to accomplish the concrete work during the 4th, 5th, and 6th weeks in equal amounts, 10 would be entered under Columns G, H, and I on Line 2. Assuming the backfill will be accomplished during the 7th and 8th weeks, 10 would be entered under Columns J and K on Line 3. If the contract extends beyond 14 weeks, additional copies of AF Form 3064 may be used as a continuation of performance record.

8. Total amount of work planned at intervals as shown in Columns D through Q will be totaled and entered in the top half of the space under the appropriate column of Line 12. Again, using the example cited above, the totals under Columns D through K would read 10, 20, 20, 10, 10, 10, 10, 10 for a total of 100%. These totals will be used to plot an overlay graph using Lines 4 through 11, beginning with Column D and extending to the right the number of columns (weeks) authorized by the contract for performance time.

9. In the event the contract is modified by the contracting officer under terms of the contract, changing the progress of work as originally scheduled, adding or deleting work or changing the original completion date, a revised progress schedule will be prepared and submitted to the contracting officer for approval. In preparing the revised schedule, the amount of work completed will be considered, together with the changed new completion date set forth in the contract modification. Considering these factors, the work under the contract will be rescheduled over the new total performance time in the same manner that the original schedule was prepared. The new completion date will be entered in Block 3. "First Revised Schedule," "Second Revised Schedule," etc., will be entered to the left of the form title. Time of submission of the revised schedule will be determined by the contracting officer.

10. At such intervals as may be established by the contracting officer, the contractor will submit to the contracting officer AF Form 3065, "Contract Progress Report," indicating the percentage of work accomplished for each work element during the established reporting period. Accurate reports are of the utmost importance to the contractor and to the Government, since the percentage of completion, or progress, thus reported is used in administration of the contract and may be used in connection with approval of partial payments under the contract. Care should be taken to plan the work in such manner that it can be accomplished as stated in this schedule. If, for any reason, it becomes known that any part of the progress under this contract will be delayed, this fact should be reported to the contracting officer immediately.

AF IMT 3064, 20030901, V1 PREVIOUS EDITIONS ARE OBSOLETE

OMB NO. 0704-0188CONTRACT PROGRESS REPORT

Public reporting burden for this collection of information is estimated to average 15 minutes per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden to the Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (OMB No. 9000-0058), 1215 Jefferson Davis Highway, Suite 1204, Arlington VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number.

PLEASE DO NOT RETURN YOUR FORM TO THE ABOVE ADDRESS. RETURN COMPLETED FORM TO : SAF/AQCO, 1060 Air Force Pentagon, Washington DC 20330-1060.

CONTRACTOR ADDRESS

REPORT NO. PERIOD COVERED

FROM:

PROJECT NO. CONTRACT NO. COMPLETION DATE

TO:

LINE

NO.

% OF

TOTAL JOB

% COMPLETED

THIS PERIOD

% COMPLETED

CUMULATIVE

WORK ELEMENT

TOTAL

REMARKS

At the Contracting Officer's discretion and according to the payments clause of the contract, the information provided on this form may be used for computing progress payments.

PROGRESS OR COMPLETION CERTIFICATE

I hereby certify that the contractor has satisfactorily completed the indicated percentage of the contract per contract specifications.

SUBMITTED BY OR FOR

CONTRACTOR BASE CIVIL ENGINEER

TYPE OR PRINT NAME AND TITLE SIGNATURE DATE

REVIEWED BY OR FOR CONTRACTING OFFICER

TYPE OR PRINT NAME AND TITLE SIGNATURE DATE

AF IMT 3065, 19960401, V1 PREVIOUS EDITION IS OBSOLETE.