Conformed_Solicitation__-_FA282319RA0040006.pdf

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

9. FOR INFORMATION

CALL:

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See ).

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and copies to perform the work required are due at the place specified in Item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

b. An offer guarantee is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

12b. CALENDAR DAYS

YES NO

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

AMOUNTS

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

FA282319RA0040006

Section A - Solicitation/Contract Form

Section B - Supplies or Services and Prices/Cost

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price Amount

0001 Construction, Restoration & Modernization Repair of Bldg 380 FFP The contractor shall provide all plant, labor, materials, tools, equipment, personnel, management, supervision, and transportation to Modify Control Rooms in Bldg. 380 in accordance with the specifications, drawings, and Statement of Work (SOW) for all work included for item "A". The Period of Performance for item "A" is 180 calendar days. Item "a" is to run concurrently with item "c", with item "a" being complete in 180 days.

Firm Fixed Price

1.0 Job

0002 Construction, Restoration & Modernization Repair of Bldg 380 FFP The contractor shall provide all plant, labor, materials, tools, equipment, personnel, management, supervision, and transportation to Modify Control Rooms in Bldg. 380 in accordance with the specifications, drawings, and Statement of Work (SOW) for all work included for item "C". The Period of Performance for item "C" is 365 calendar days. Item "a" is to run concurrently with item "c", with item "c" being complete in 365 days.

Firm Fixed Price

1.0 Job

Section C - Description/Specifications/Statement of Work

******Due to the location of this project, all contractors working in the locations must be US Citizens*******

This project will cover reconfiguration of the floor plan in Rooms 109, 280, and 290 in Bldg 380. In these rooms there will be removal of some interior walls along with construction of new, advanced security-rated walls and partitions. Some of the secure room doors will have to be relocated. Room 290 will be upgraded to accommodate and High-Performance Computing Environment. All rooms will be modified to relocated power feeds and distribution systems. Room 280 will be modified to add power and cooling.

Requirements Modify Control Rooms Bldg 380

Section D - Packaging and Marking

Section E - Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.246-12 Inspection of Construction. 1996-08 0001 Inspection and Acceptance Location

Both Destination Instructions: All Inspection and Acceptance will be conducted by the Government.

DoDAAC: FA2823 Cage:

DunsNumber:

Duns4Number:

CountryCode:

OfficeCode:

Government Telephone: 850-882-3144 Email:

0002 Inspection and Acceptance Location

Both Destination Instructions: All Inspection and Acceptance will be conducted by the Government.

DoDAAC: FA2823 Cage:

DunsNumber:

Duns4Number:

CountryCode:

OfficeCode:

Government Telephone: 850-882-3144 Email:

Section F - Deliveries or Performance

0001 FoB Details

Contractor Destination

0002 FoB Details

Contractor Destination

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.247-34 F.o.b. Destination. 1991-11

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.247-7023 Transportation of Supplies by Sea. 2014-04

FAR Clauses Incorporated by Full Text

52.211-10 Commencement, Prosecution, and Completion of Work. 1984-04 As prescribed in 11.404(b), insert the following clause in solicitations and contracts when a fixed-price construction contract is contemplated. The clause may be changed to accommodate the issuance of orders under indefinite-delivery contracts for construction. Commencement, Prosecution, and Completion of Work (Apr 1984) The Contractor shall be required to

(a) commence work under this contract within __10__ [Contracting Officer insert number] calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than __365 days__.* The time stated for completion shall include final cleanup of the premises.

Section G - Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.201-7000 Contracting Officer's Representative 1991-12 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. 2012-06 252.236-7000 Modification Proposals--Price Breakdown 1991-12

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. 2013-05 As prescribed in 232.7004(b), use the following clause: WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause- Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization. Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF). Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system. (b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports. (c) WAWF access. To access WAWF, the Contractor shall- (1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and (2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site. (d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the Web Based Training link on the WAWF home page at https://wawf.eb.mil/

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol. (f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order: (1) Document type. The Contractor shall use the following document type(s). __CONSTRUCTION__ (Contracting Officer: Insert applicable document type(s). Note:

If a Combo document type is identified but not supportable by the Contractors business systems, an Invoice (stand-alone) and Receiving Report (stand-alone) document type may be used instead.) (2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer. ____ (Contracting Officer: Insert inspection and acceptance locations or Not applicable.) (3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system. Routing Data Table* | Field Name in WAWF || Data to be entered in WAWF || Pay Official DoDAAC || __F03000__ || Issue By DoDAAC || __FA2823__ || Admin DoDAAC || __FA2823__ || Inspect By DoDAAC || ____ || Ship To Code || ____ || Ship From Code || ____ || Mark For Code || ____ || Service Approver (DoDAAC) || ____ || Service Acceptor (DoDAAC) || ____ || Accept at Other DoDAAC || ____ || LPO DoDAAC || ____ || DCAA Auditor DoDAAC || ____ || Other DoDAAC(s) || ____ | (*Contracting Officer: Insert applicable DoDAAC information or See schedule if multiple ship to/acceptance locations apply, or Not applicable.) (4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request. (5) WAWF email notifications. The Contractor shall enter the e-mail address identified below in the Send Additional Email Notifications field of WAWF once a document is submitted in the system. __Contracting Officer; ronald.wilson.22@us.af.mil__ __Contracting Specialist;

elizabeth.baranishyn@us.af.mil__ (Contracting Officer: Insert applicable email addresses or Not applicable.) (g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activitys WAWF point of contact. __Eglin WAWF Focal Point; pamela.green.3.ctr@us.af.mil__ (Contracting Officer: Insert applicable information or Not applicable.) (2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988. (End of clause)

Section H - Special Contract Requirements

H-2 PERFORMANCE AND PAYMENT BONDS (CONSTRUCTION)

Pursuant to FAR clause 52.228-15, Performance and Payment Bonds, the contractor shall submit its performance and payment bonds no later than 10-days after award of the contract. The Contractor shall furnish two bonds each with surety or sureties acceptable to the Government in the form of a Performance Bond (Standard Form 25) and a Payment Bond (Standard Form 25A). The penal sums of such bonds shall be as follows:

(a) Performance Bond. The penal sum of the Performance Bond shall equal one hundred percent (100%) of the value of the contract. Any bonds will be furnished by the Contractor to the Government prior to commencement of contract performance.

(b) Payment Bonds. The penal sum of the Payment Bond shall equal one hundred percent (100%) of the value of the contract. Any bonds will be furnished by the Contractor to the Government prior to commencement of contract performance.

H-3 CONFORMANCE WITH ENVIRONMENTAL MANAGEMENT SYSTEMS (POLLUTION PREVENTION AND RIGHT-TO-

KNOW INFORMATION)

(a) In addition to the requirements in FAR 52.223-5, contractors shall provide a list of toxic and hazardous chemicals to the Facility Hazardous Materials Cell, 96 CEG/CEIEC, 850-882-5929 before bringing any material onto the facility. This list shall consist of the material name, manufacturer name and address, quantity and size of the materials. This list may be in Microsoft Word or Excel. Updates of this list shall be submitted quarterly to the above office.

(b) The Contractor shall perform work under this contract consistent with the relevant policy and objectives identified in the agency, organizational, or facility environmental management system (EMS) applicable for your contract. The Contractor shall perform work in a manner that conforms to all appropriate Environmental Management Programs and Operational Controls identified by the agency, organizational, or facility EMS, and provide monitoring and measurement information as necessary for the organization to address environmental performance relative to the environmental, energy, and transportation management goals. In the event an environmental nonconformance or noncompliance associated with the contracted services is identified, the contractor shall take corrective and/or preventative actions. In the case of a noncompliance, the Contractor shall respond and take corrective action immediately. In the case of a nonconformance, the Contractor shall respond and take corrective action based on the time schedule established by the EMS Site Coordinator, 96 CEG/CEIEC, 850-882-5929. In addition, the Contractor shall ensure that their employees are aware of the roles and responsibilities identified by the environmental management system and how these requirements affect their work performed under this contract.

(c) All on-site contractor personnel shall complete facility sponsored environmental training specific to the facility. The facility training will take approximately thirty minutes to accomplish. The training must be completed within 90 days of the contractor employee being work on the installation. The method of training can be video or my seminar presentations. Documentation of the training will be provided to EMS Coordinator, 96 CEG/CEIEC, 850-882-5929. Upon contract award, the Contracting Officer's Representative will notify the facility-level Environmental Management Systems Coordinator, 96 CEG/CEIEC, 850-882-5929 to arrange EMS training for appropriate staff.

H-4 CONSTRUCTION PERMITS

In accordance with (IAW) FAR 52.236-7, the Contractor shall obtain a construction permit for any construction work on Eglin Air Force Base. An AF Form 103 "Base Civil Engineering Work Clearance Request" must be submitted with all required signatures, to the Contract Inspector prior to beginning of performance on the job site. No work shall begin until approval of the AF Form 103 has been granted.

H-5 DAILY REPORT TO INSPECTOR

(a) The Contractor shall submit a Daily Report to 96 CEG/CEOM inspectors on 96 TW Form 3. The report shall include weather conditions, work accomplished, test accomplished, test reports, delays and discrepancies. Reports should also include photographs of the site as necessary to document progress and any differing site conditions as necessary.

Documentation of any differing site condition in a daily report does not relieve the Contractor of its responsibility to report any differing site condition to the Contracting Officer pursuant to FAR clause 52.236-2, Differing Site Conditions.

(b) The report to the inspector shall be the original signed by the contractor or his superintendent and turned into 96 CEG/ CEOM inspectors by 12:00 noon the following work day.

H-6 ENVIRONMENTAL INSURANCE REQUIREMENTS

The Contractor shall, at its own expense, provide and maintain insurance during the entire performance period of this contract which specifically provides coverage for environmental damages with a minimum amount of $1,000,000.00 per occurrence.

H-7 HAZARDOUS WASTE REMOVAL

The Contractor shall dispose of all hazardous waste in accordance with all applicable local, federal and state environmental laws and regulations, including but not limited to 40 CFR 260-268, Hazardous Waste Management, and Rule 17-30 Florida Administrative Code. The Contractor shall assume the responsibility of determining what constitutes "hazardous waste" and complying with all environmental laws and regulations governing its removal.

H-8 HURRICANE SEASON

Hurricane season for the state of Florida is normally the period from 01 June through 30 November. During an actual hurricane, tropical storm or tropical depression condition, you may be contacted by the contracting office and requested to secure equipment, clean up your work area and properly protect stored materials. In accordance with the contract clause FAR 52.236-9, "Protection of Existing Vegetation, Structures, Equipment, Utilities and Improvements" and FAR 52.236-12 "Cleaning Up," you should keep this in mind and maintain your work area free from debris and in a safe and secure condition at the completion of each work day. A duty is imposed on the Contractor to monitor local weather conditions, weather bulletins and base closure information in the local media. The Contractor must contact the Contract Administrator with a report of conditions adversely affecting the construction site.

H-9 IMPLEMENTATION OF WARRANTY OF CONSTRUCTION

(a) Any manufacturer's guarantees which extend beyond or in addition to the normal one year guaranty required by contract clause FAR 52.246-21 shall be furnished to the Government in their entirety, including names of vendors responsible for servicing said warranties.

(b) The following paragraph is applicable if this contract requires any painting whatsoever:

If painted surfaces blister, peel, scale, become loose, effloresce, chalk, mildew, or otherwise show defective paint surfaces, the Government shall notify the Contractor in writing within a reasonable time after discovery. The Contractor shall prepare, prime, and repaint those surfaces in accordance with applicable paragraphs of the contract. Repainting shall be carried to natural stopping points such as corners, offsets, points of change of masonry to wood trim, and upward to eaves or ceilings, and downward to ground or floor level, in order that the entire wall will have an even texture. Where the surface to be repainted is a wood surface, the repainting shall be applied to the entire wood surface up to the edge of trim or to eaves, as applicable, in order that the repainted surface shall have an even texture. The contractor shall save harmless the Government against any and all liability and compensate private individuals for damage to their personal property caused directly or indirectly by negligent conduct including over spraying but not limited thereto. Furthermore, the Contractor shall post warning signs within the area where paint is being applied which gives notice that no party should park within the danger area. The location, size and lettering of the signs shall be as approved by the Contracting Officer.

(c) The above stated painting requirement and its effective period will be subject to the provisions of the Warranty of Construction as set forth in FAR 52.246-21.

(d) Prior to final acceptance of the work covered by this contract, the Contractor shall furnish in writing to the Contracting Officer a list of all items of equipment furnished. This list will include:

(1) Nomenclature of each item, type or serial number, and the name and address of the manufacturer;

(2) Cost;

(3) Period of guarantee; (IV) name, telephone number and address of the subcontractor or supplier; and (v) name, telephone number and address of the service agency that will be responsible for service in event of failure or malfunction. This list will be accompanied by applicable guarantee documents.

(e) To prevent delays and inconveniences to the Government and to insure that equipment will be promptly serviced, the contractor shall make service arrangements with agencies located in the vicinity of the contract work.

(f) The Contracting Officer will furnish the prime Contractor the name of the office that will represent the Government regarding guarantee conditions hereunder.

(g) The Contractor, at its expense, shall furnish and affix a decal or tag, as may be directed, to each piece of equipment covered by guarantee. The decal or tag will indicate the serial number of the equipment, guarantee period, contract number and name of Contractor. Such decal or tag shall be affixed where directed by the Contracting Officer.

H-10 INSPECTION AND SURVEILLANCE

The Director, Civil Engineering, Eglin Air Force Base, Florida, is designated as the representative of the Contracting Officer for the purpose of surveillance and inspection of performance of work under this contract. This designation does not include authority to direct or authorize the Contractor to make changes in the scope or terms of the contract without the written authority of the Contracting Officer. The contractor shall notify the Construction Management Branch, 96 CEG/CEOM (telephone 882-2864) at least 24 hours in advance of the date work will commence under this contract; contractor shall also notify that office at earliest possible time of anticipated absence(s) from the job site.

H-11 INSURANCE CLAUSE IMPLEMENTATION

The Contractor shall obtain and maintain the minimum kinds and amounts of insurance during performance of this contract as specified in FAR Sub Part 28.3.

*** In addition to the minimum insurance requirements specified above this contract requires additional property liability coverage in the amount of $2,000,000.00 to cover any damage to electronic equipment or furnishings caused by the Contractor. The policy shall be submitted to the Contracting Officer before the start of any work. ***

H-12 MEDICAL INFORMATION

The name of the Contractor's physician(s) and preferred hospital (for use in the event of industrial injury of employees) shall be posted by the Contractor at the site of the work in a prominent place where it can easily be seen by the workers. This information shall also be furnished to the Director of Base Medical Services, 96 MDG/SG, and Eglin AFB FL 32542-5300.

H-13 ON-BASE PERFORMANCE

(a) Work on this project shall be accomplished during normal hours, which are 7:00 AM to 3:30 PM, Monday through Friday, except legal holidays. Any work desired to be accomplished during other than the normal hours will require prior approval of the Contracting Officer. The Contractor must submit a written request to the Contracting Officer.

(b) The Contractor's performance may be interrupted from time to time because of high priority mission schedules. For each calendar day and/or portion of a calendar day that the contractor is removed from the job site, the contract schedule will be adjusted by one (1) calendar day.

(c) If a building remains occupied throughout construction, special provisions apply as follows:

H-14 SALVAGE MATERIALS

(a) All items of Government property indicated on the drawings or in the specifications to be removed and disposed of by the contractor shall become the property of the contractor and shall be removed promptly from the Eglin AFB Reservation and legally disposed of EXCEPTIONS will be given by each Task Order.

(b) Contractors are encouraged to recycle salvage materials when possible. Contact the Eglin Recycling Center, 850-882-7744, for assistance.

H-15 SUPERINTENDENT

Upon notification of award, the Prime Contractor shall identify a superintendent and alternate for this contract and job site.

The full name, home address, SSN#, date of birth, state driver's license #, days/hours of access required, and consent to a background check for security purposes of each such employee shall be required. The Prime Contractor's superintendent and/or alternate shall be accountable for all individuals allowed onto the installation. The likelihood of a potential employee meeting all security requirements and being granted authorization to access the base should be considered in all hiring and subcontracting decisions. The U.S. Air Force will not be responsible or liable for any costs or delays that a contractor incurs due to a contractor's employee being denied access to Eglin AFB. The Superintendent and/or alternate shall be responsible for collecting badges/PVC cards from all employees upon completion of the project/contract or termination of service. Prior to final payment approval, the Superintendent shall provide a company letter stating that all Eglin AFB access badges issued in the performance of this contract have been properly turned into the 96 Security Forces Squadron (SFS). This letter must have some type of validation from the 96 SFS badging office employee either by stamp or signature.

H-17 UTILITY OUTAGES

Contractor shall notify the Contracting Officer's Representative (COR) in writing two weeks prior to any utility outage anticipated during the performance of this contract.

H-20 WEATHER DELAYS

The Anticipated Normal Weather Delay Schedule shown below is developed by month for this geographic location using National Oceanic and Atmospheric Administration (NOAA) and similar Weather Averaging System data for the project's general location. The Government has included additional time in the allowed performance period using this data. (The basic performance period allows seven calendar days for every five-day working days assuming based on working Monday through Friday. The contractor's progress schedule must take these anticipated adverse weather delays into account in all weather-dependent activities to ensure timely completion of the job.

MONTHLY ANITCIPATED ADVERSE WEATHER DELAY WORK DAYS BASED ON A 5-DAY WORKWEEK

JAN__FEB__MAR__APR__MAY__JUN__JUL__AUG__SEP__OCT__NOV__DEC

5_____5______5____3_____3_____5____8_____6_____5_____3_____4_____5

Upon acknowledgement of Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on his Daily Report (96 TW Form 3), the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for fifty percent or more of the Contractor's scheduled workday and must cause a delay in the work activities critical to contract completion. In order to obtain relief from contract schedule requirements, the Contractor will have to demonstrate not only that the anticipated amount of weather delay was exceeded by actual weather interruption, but also that reasonable efforts were made to compensate for such excess interruptions through changes in work hours, changes in the planned sequence of work, increased concurrent activities, or other available measures. Contemporaneous documentation of such efforts and prompt coordination thereof with government inspectors is encouraged (see below).

In the event that all reasonable effort to complete the required performance on schedule fail and it is determined that excessive inclement weather was the cause of that failure, the Contractor may request extension of the project performance period for any weather delays suffered because of adverse weather beyond the number day indicated on the chart. The number of workdays of delay added to the schedule shall be converted to calendar days by adding the appropriate number of weekend days associated with that number of workdays.

(a) Adverse weather days will not be granted for other than normal workdays that the Contractor requested to work solely for the Contractor's convenience to meet the contract performance period.

(b) Any extensions to the contract because of change orders will have the normal adverse weather days figured into the extension period.

(c) If the contract dictates an alternate performance period other than a normal Monday through Friday five-day workweek, an extension will be considered based on the contract requirement for a workday.

Upon the request of the Contractor made within one workweek after the relevant events, the government inspector will review the Contractor's documentation of weather delays and circumstances relevant to the availability of work around and promptly confirm or dispute the Contractor's conclusions in writing to the Contractor and the Contracting Officer. If the Contractor requests an adjustment to the contract schedule based on the government inspector's review, the contractor shall notify the Contracting Officer in writing and provide relevant information and recommendations regarding the request. The Contracting Officer shall determine whether the request should be promptly granted, deferred pending determination of cumulative weather effects during the contract performance period, denied, or some combination thereof. The reason for any deferral or denial will be simultaneously communicated to the Contractor in writing.

The findings of the Contracting Officer shall be final and conclusive subject to appeal under the Disputes clause. Upon any extension, the Contractor shall immediately submit to the Contracting Officer a revised progress schedule to meet the revised performance period.

H-21 ACCESS TO EGLIN AIR FORCE BASE

(a) The contractor shall obtain base identification and vehicle passes, if required, for all contractor personnel who make frequent visits to or perform work on the Air Force installation(s) cited in the contract. Contractor personnel are required to wear or prominently display installation identification badges or contractor-furnished, contractor identification badges while visiting or performing work on the installation.

(b) The contractor must submit in writing to the designated Contract Specialist or Contracting Officer a request for all personnel needing access to Eglin AFB and associated sites. The Government will provide a memorandum template to the Contractor for the submission of all badges/passes. The memorandum is required regardless of the length of visit. The Contractor shall input the following information into the template:

FROM: Input Company Name, Address, and Point of Contact

Paragraph 1: The following individuals require access to (Eglin AFB) to perform official duties at: Indicate what area you will need access (A) Eglin main base; (B) Duke Field; (C) Ranger Camp; (D) Range Road and (E) 7th SFG. Their duties will include (Input Project Title). All work will begin on (Input work start date) and will be accomplished by (Input work end date).

The contract number (Input contract number).

Paragraph 4: Complete the table providing the names/Days/Hrs of Access/Full SSN/Date of Birth /Driver's License #/State of employees and subcontractor employees needing access to the base.

***NOTE: DO NOT USE NICKNAMES WHEN LISTING PERSONNEL. FOR EXAMPLE, DO NOT USE "BILL" IF THE

INDIVIDUAL'S LEGAL NAME IS "WILLIAM".***

The Contracting Officer or Contracting Specialist will endorse request and then send it to Security Forces via email for processing into the Security Forces database.

Anticipate a three-five business day lead time for Security Forces to process the documents and conduct the required background check. Contractors should submit its requests for badge/passes in a timely manner so as not to delay or impede project progress. Once the background check is complete, a copy will be returned to the POC listed on the envelope. The prime contractor can provide paperwork for their subcontractor(s) and submit as many documents per envelope as necessary.

(c) When reporting to the registration office, the authorized contractor individual(s) should provide a valid driver's license, current vehicle registration, valid vehicle insurance certificate and social security card to obtain a vehicle pass. All deliveries to contractor work sites on Eglin AFB main base must go through the North Gate, located off SR-85 South. Trucks trying to enter the East, West or the Northwest (old ACC) gate will be turned around and told to use the North Gate. Contractors' work trucks carrying equipment and tools are also required to use the North Gate.

(d) During performance of the contract, the contractor shall be responsible for obtaining required identification for newly assigned personnel and for prompt return of credentials and vehicle passes for any employee who no longer requires access to the work site. A new access badge will not be issued when the old/expired badge is not returned to Security Forces. Any lost badges have to be explained in writing using a company letter head, and signed by an authorized company representative. The lost badge letter must be sent to the Contract Specialist and then signed by the Contract Specialist or Contracting Officer, and then the letter will be sent to Security Forces for their review. After Security Forces has the letter a new badge may be issued.

(e) When work under this contract requires unescorted entry to controlled or restricted areas, the contractor shall comply with AFI 31-101, Volume 1, The Air Force Installation Security Program, and AFI 31-501, Personnel Security Program Management citing the appropriate paragraphs as applicable.

(f) Upon completion or termination of the contract or expiration of the identification passes, the prime contractor shall ensure that all base identification passes issued to employees and subcontractor employees are returned to the issuing office.

(g) Failure to comply with these requirements may result in withholding of final payment.

H-22 COMMUNICATIONS CYBER INFRASTRUCTURE REPAIR PROCEDURES

NOTE:

***All temporary and/or permanent repairs made shall be accomplished by the repairing agency at no further cost to the government. Repairs shall be IAW all applicable industry and local standards, whichever is more stringent. ***

1.1 Temporary Repair Actions - Temporary repairs shall be initiated within 12 hours of reported/identified damage. All circuits (pairs, strands, etc...) must be restored to full mission capability within 24 hours. Temporary repairs shall not be considered a permanent repair fix action.

a. The repairing agency shall provide 24 hour/7 day a week on-call maintenance service for temporary repairs until all permanent repairs have been completed and accepted by the 96 CS/SCOW Branch Chief or 96 CS designated representative.

1.2 Permanent Repair Actions - All fiber optic and copper communications cyber infrastructure shall be restored to its original state prior to damage for all permanent repairs. At a minimum, all damaged communications cyber infrastructure shall be replaced regardless of distance and/or cost incurred, to the closest pre-existing, splice/terminal locations. New or additional splices shall not be allowed for permanent repairs without written approval from the 96 CS/SCOW Branch Chief or 96 CS designated representative.

a. The repairing agency shall provide a Statement of Work (SOW), Test Plan and Product Submittals for all proposed permanent repair solutions within 5-business days from date of reported damage to 96 CS/SCOW for written approval prior to beginning any permanent repairs.

NOTES:

***Maximum known distances between existing fiber optic cable splice points is up to 17K feet*** ***Maximum known distances between existing copper cable splice points is up to 5K feet*** ***Polymer type maintenance holes and/or handholes shall not be used for supporting communication cyber infrastructure on

EAFB***

H-23 SECURITY REQUIREMENTS - PERSONNEL

1. Work under this contract is restricted to U.S. citizens.

2. The request for personnel passes shall be accompanied with the following certification:

"I hereby certify that all personnel on this list are either born U.S. citizens, naturalized U.S. citizens with the naturalization number shown."

Signature/Firm Name

3. Documents Acceptable for Proof of Citizenship:

a. Birth registration card

b. Certificate of live birth, birth certificate

c. Certificate of Naturalization

d. Certificate of registration

e. DD-214 (Must Cite Birthplace)

f. DD Form 4 (Contract for Enlistment and Must Cite Birthplace)

g. DD 1966 (Application for Enlistment)

h. Military discharge papers (must cite birthplace)

i. Delayed birth certificate

j. Hawaii certificate of foreign birth

k. Hospital birth certificate

l. Marriage license certificate

m. Merchant marine certificate

n. Military officer ID card

o. Notification of birth registration

p. State of Hawaii ID card

q. USA passport

r. Verbal inquiry with State of Hawaii Vital Statistics Office

Section I - Contract Clauses

52.211-13 - Time Extensions 52.204-22 - Alternative Line Item Proposal.

52.215-2 -- Audit and Records - Negotiation.

52.215-8 -- Order of Precedence -- Uniform Contract Format.

52.223-21 -- Foams.

52.232-18 -- Availability of Funds.

52.236-26 -- Preconstruction Conference.

252.227-7000 Non-Estoppel.

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports.

252.204-7007 Alternate A, Annual Representations and Certifications.

52.219-6 -- Notice of Total Small Business Set-Aside.

52.236-17 -- Layout of Work.

52.252-3 -- Alterations in Solicitation.

52.252-4 -- Alterations in Contract.

52.203-10 -- Price or Fee Adjustment for Illegal or Improper Activity.

52.203-18 - Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-- Representation.

52.219-13 -- Notice of Set-Aside of Orders.

52.232-27 -- Prompt Payment for Construction Contracts.

52.236-21 -- Specifications and Drawings for Construction.

52.252-5 -- Authorized Deviations in Provisions.

52.252-6 -- Authorized Deviations in Clauses.

52.215-12 -- Subcontractor Certified Cost or Pricing Data. (Class Deviation 2018-O0015) 52.215-10 -- Price Reduction for Defective Certified Cost or Pricing Data.

52.215-15 -- Pension Adjustments and Asset Reversions.

52.215-18 -- Reversion or Adjustment of Plans for Postretirement Benefits (PRB) Other Than Pensions.

52.215-19 -- Notification of Ownership Changes.

252.227-7033 Rights in Shop Drawings.

252.225-7016 Restriction on Acquisition of Ball and Roller Bearings.

252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements 252.215-7002 Cost Estimating System Requirements.

252.237-7010 Prohibition on Interrogation of Detainees by Contractor Personnel.

252.215-7009 Proposal Adequacy Checklist.

52.211-12 -- Liquidated Damages -- Construction Liquidated Damages -- Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of ______$332.90_______ for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of Clause)

52.216-1 -- Type of Contract.

Type of Contract (Apr 1984) The Government contemplates award of a firm-fixed price contract resulting from this solicitation.

(End of Clause)

52.228-1 -- Bid Guarantee.

Bid Guarantee (Sep 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds --

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be 20% percent of the bid price or $3,000,000.00, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of Provision)

52.215-20 -- Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data.

(a) Exceptions from certified cost or pricing data.

(1) In lieu of submitting certified cost or pricing data, offerors may submit a written request for exception by submitting the information described in the following subparagraphs. The Contracting Officer may require additional supporting information, but only to the extent necessary to determine whether an exception should be granted, and whether the price is fair and reasonable.

(i) Identification of the law or regulation establishing the price offered. If the price is controlled under law by periodic rulings, reviews, or similar actions of a governmental body, attach a copy of the controlling document, unless it was previously submitted to the contracting office.

(ii) Commercial item exception. For a commercial item exception, the offeror shall submit, at a minimum, information on prices at which the same item or similar items have previously been sold in the commercial market that is adequate for evaluating the reasonableness of the price for this acquisition. Such information may include --

(A) For catalog items, a copy of or identification of the catalog and its date, or the appropriate pages for the offered items, or a statement that the catalog is on file in the buying office to which the proposal is being submitted. Provide a copy or describe current discount policies and price lists (published or unpublished), e.g., wholesale, original equipment manufacturer, or reseller. Also explain the basis of each offered price and its relationship to the established catalog price, including how the proposed price relates to the price of recent sales in quantities similar to the proposed quantities;

(B) For market-priced items, the source and date or period of the market quotation or other basis for market price, the base amount, and applicable discounts. In addition, describe the nature of the market;

(C) For items included on an active Federal Supply Service Multiple Award Schedule contract, proof that an exception has been granted for the schedule item.

(2) The offeror grants the Contracting Officer or an authorized representative the right to examine, at any time before award, books, records, documents, or other directly pertinent records to verify any request for an exception under this provision, and the reasonableness of price. For items priced using catalog or market prices, or law or regulation, access does not extend to cost or profit information or other data relevant solely to the offeror's determination of the prices to be offered in the catalog or marketplace.

(b) Requirements for certified cost or pricing data. If the offeror is not granted an exception from the requirement to submit certified cost or pricing data, the following applies:

(1) The offeror shall submit certified cost or pricing data, data other than certified cost or pricing data, and supporting attachments in the following format: Information will be given in accordance with Table 15-2 from FAR 15-408.

(2) As soon as practicable after agreement on price, but before contract award (except for unpriced actions such as letter contracts), the offeror shall submit a Certificate of Current Cost or Pricing Data, as prescribed by FAR 15.406-2.

(End of Provision) 52.215-1 -- Instructions to Offerors -- Competitive Acquisition.

(a) Definitions. As used in this provision -- "Discussions" are negotiations that occur after establishment of the competitive range that may, at the Contracting Officer's discretion, result in the offeror being allowed to revise its proposal."

"In writing," "writing," or "written" means any worded or numbered expression which can be read, reproduced, and later communicated, and includes electronically transmitted and stored information.

"Proposal modification" is a change made to a proposal before the solicitation's closing date and time, or made in response to an amendment, or made to correct a mistake at any time before award.

"Proposal revision" is a change to a proposal made after the solicitation closing date, at the request of or as allowed by a Contracting Officer as the result of negotiations.

"Time," if stated as a number of days, is calculated using calendar days, unless otherwise specified, and will include Saturdays, Sundays, and legal holidays. However, if the last day falls on a Saturday, Sunday, or legal holiday, then the period shall include the next working day.

(b) Amendments to solicitations. If this solicitation is amended, all terms and conditions that are not amended remain unchanged. Offerors shall acknowledge receipt of any amendment to this solicitation by the date and time specified in the amendment(s).

(c) Submission, modification, revision, and withdrawal of proposals.

(1) Unless other methods (e.g., electronic commerce or facsimile) are permitted in the solicitation, proposals and modifications to proposals shall be submitted in paper media in sealed envelopes or packages

(i) addressed to the office specified in the solicitation, and

(ii) showing the time and date specified for receipt, the solicitation number, and the name and address of the offeror. Offerors using commercial carriers should ensure that the proposal is marked on the outermost wrapper with the information in paragraphs (c)(1)(i) and (c)(1)(ii) of this provision.

(2) The first page of the proposal must show --

(i) The solicitation number;

(ii) The name, address, and telephone and facsimile numbers of the offeror (and electronic address if available);

(iii) A statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation and agreement to furnish any or all items upon which prices are offered at the price set opposite each item;

(iv) Names, titles, and telephone and facsimile numbers (and electronic addresses if available) of persons authorized to negotiate on the offeror's behalf with the Government in connection with this solicitation; and

(v) Name, title, and signature of person authorized to sign the proposal. Proposals signed by an agent shall be accompanied by evidence of that agent's authority, unless that evidence has been previously furnished to the issuing office.

(3) Submission, modification, revision, and withdrawal of proposals.

(i) Offerors are responsible for submitting proposals, and any modification, or revisions, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that proposal or revision is due.

(ii)

(A) Any proposal, modification, or revision received at the Government office designated in the solicitation after the exact time specified for receipt of offers is "late" and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and --

(1) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of proposals; or

(2) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or

(3) It is the only proposal received.

(B) However,…