ExeVision+-NDDOT+TIPS+Contract.pdf

TECHNOLOGY CONTRACT: TRANSPORTATION INFRASTRUCTURE

PRECONSTRUCTION SYSTEM

1. PARTIES

The parties to this contract (Contract) are the state of North Dakota, acting through its Department of Transportation (STATE), and ExeVision, Inc., a Utah corporation, having its principal place of business at 895 W Baxter Dr, South Jordan, UT 84095 (CONTRACTOR).

2. DEFINITIONS

a) Control Environment - is the set of standards, processes, and structures that provide the basis for carrying out internal control across the organization.

b) Data - means any information provided to, or collected, generated, stored, or processed by the system. Data includes user identification information and metadata which may contain Data or from which the STATE’s Data may be ascertainable.

c) Data Breach - means any access, destruction, loss, theft, use, modification or disclosure of Data by an unauthorized party or that is in violation of Contract terms and/or applicable state or federal law.

d) Data Classification - means the process of defining data into relevant categories so the information has the appropriate controls in place to protect confidentiality, integrity, and availability based on the type of information.

e) Personally Identifiable Information (PII) - information about an individual maintained by an agency, including that 1) can be used to distinguish or trace an individual’s identity, such as name, social security number, date and place of birth, mother’s maiden name, or biometric records; or (2) is linked or linkable to an individual, such as medical, educational, financial, and employment information.

f) Recovery Point Objective (RPO) - means the point in time to which Data can be recovered and/or systems restored when service is restored after an interruption. The Recovery Point Objective is expressed as a length of time between the interruption and the most proximate backup of Data immediately preceding the interruption. The RPO is detailed in the SLA.

g) Recovery Time Objective (RTO) - means the period within which information technology services, systems, applications and functions must be recovered following an unplanned interruption. The RTO is detailed in the SLA.

h) Software. The ExeVision iPDWeb™ computer application and any updates or maintenance releases thereto.

i) Software as a Service (SaaS). Any software or infrastructure hosted and support services outside the State of North Dakota’s environment for both Cloud Hosting services and Software Application services.

j) Users – means contractors, subcontractors, outsourcing vendors, consultants and others who have a need to use the software for the benefit of STATE and have been supplied user identifications and passwords by STATE.

3. SCOPE OF WORK

CONTRACTOR, in exchange for the compensation paid by STATE under this Contract, shall provide the Transportation Infrastructure Preconstruction System (TIPS) system through IPDWeb as described in the Statement of Work (Exhibit A) and in the documents listed in the Merger and Modification, Conflict in Documents Section. The annual subscription fee shall also allow for unlimited named external users including, but not limited to consultants and contractors, Metropolitan Planning Organizations (MPO) and Local Public Agencies (LPA), Federal Highway Administration (FHWA).

4. COMPENSATION-PAYMENTS

a. Contractual Amount

STATE shall pay for the accepted services provided by CONTRACTOR under this Contract an amount not to exceed $2,754,320.00 (Contractual Amount). The Contractual Amount shall be paid according to the Compensation Details document attached as Exhibit B.

The Contractual Amount is firm for the duration of this Contract and constitutes the entire compensation due CONTRACTOR for performance of its obligations under this Contract regardless of the difficulty, materials or equipment required, including fees, licenses, overhead, profit and all other direct and indirect costs or expenses incurred by CONTRACTOR except as provided by an amendment to this Contract.

b. Retainage All deliverable payments shall be subject to 15% retainage. Retained amounts due to CONTRACTOR shall be paid upon Final Acceptance.

c. Invoicing The final cost set forth on each invoice shall be equivalent to the cost for each deliverable or service as specified in the Scope of Work. CONTRACTOR shall not submit an invoice for any deliverable or service specified in the Scope of Work that STATE has not fully accepted.

d. Payment Payment made in accordance with this Compensation section shall constitute payment in full for the services and work performed and the deliverables provided under this Contract and CONTRACTOR shall not receive any additional compensation hereunder.

STATE shall make payment under this Contract within forty-five (45) calendar days after receipt of an approved invoice.

The Parties will take reasonable steps in good faith to resolve such dispute in a timely manner, including arranging for a meeting of the Parties’ project managers within seven (7) calendar days of receipt of the notice of dispute. Either Party’s project manager will be entitled to escalate the dispute to STATE’s Department Head and Contractor’s senior account executive for resolution.

Payment of an invoice by STATE will not prejudice STATE’s right to object to or question that or any other invoice or matter in relation thereto. CONTRACTOR's invoice will be subject to reduction for amounts included in any invoice or payment made which are determined by STATE not to constitute allowable costs, on the basis of audits conducted in accordance with the terms of this Contract. At STATE’s sole discretion, all payments shall be subject to reduction for amounts equal to prior overpayments to CONTRACTOR.

For any amounts that are or will become due and payable to STATE by CONTRACTOR, STATE reserves the right to deduct the amount owed from payments that are or will become due and payable to CONTRACTOR under this Contract.

e. Travel CONTRACTOR acknowledges travel expenses are covered by the Contractual Amount and shall not invoice STATE for travel expenses.

f. Prepayment STATE will not make any advance payments before performance or delivery by CONTRACTOR under this Contract.

g. Payment of Taxes by State STATE is not responsible for and will not pay local, state, or federal taxes. STATE sales tax exemption number is E-2001. STATE will furnish certificates of exemption upon request by

CONTRACTOR.

h. Taxpayer ID CONTRACTOR’s federal employer ID number is: 87-0520718.

i. Purchasing Card STATE may make payment using a government credit card. CONTRACTOR will accept a government credit card without passing the processing fees for the government credit card back to STATE.

5. EQUIPMENT, MATERIALS, AND WORKSPACE – RESOURCES PROVIDED BY PARTIES

For periods during which the Parties mutually agree that CONTRACTOR’s assigned staff is on site:

a. On site means any location in North Dakota.

b. STATE agrees to provide an adequate working space, when required.

c. Equipment and software for on-site CONTRACTOR personnel is to be provided by

CONTRACTOR.

d. When STATE and CONTRACTOR agree that remote access to systems is required, STATE shall provide the necessary supervised remote access security to enable CONTRACTOR access to the appropriate STATE systems.

6. TERM OF CONTRACT

This Contract term (Term or Initial Term) begins on its Effective Date and ends on November 30, 2030.

a. No Automatic Renewal

This Contract will not automatically renew.

b. Renewal Option

STATE may renew this Contract upon satisfactory completion of the Initial Term. STATE reserves the right to execute up to two (2) options to renew this Contract under the same terms and conditions for a period of twelve (12) months each (Renewal Term).

c. Extension Option STATE reserves the right to extend this Contract for an additional period, not to exceed twelve months, beyond the current termination date of this Contract.

d. Renegotiation Option Because it is unknown how long the solution and services will be used by STATE and ongoing maintenance and support are required for as long as the system is operational STATE and CONTRACTOR may renegotiate this Contract. After completion of the Initial Term, renewals, and extensions, STATE and CONTRACTOR may renegotiate the pricing and Term of this Contract. New pricing and Term shall be mutually agreed upon by the Parties and executed in writing.

If, during the Initial Term, any renewal, or extension STATE determines a realignment of the Term is needed (e.g., to align with STATE’s fiscal biennium, SaaS period), the Parties may mutually agree, in writing, to a new Term with a termination date not to exceed the total available length of Contract including its Initial Term, renewals, and extensions.

7. TERMINATION

a. Termination by Mutual Agreement

This Contract may be terminated by mutual consent of both Parties executed in writing.

b. Early Termination in the Public Interest

STATE is entering this Contract for the purpose of carrying out the public policy of the State of North Dakota, as determined by its Governor, Legislative Assembly, Agencies, and Courts. If this Contract ceases to further the public policy of the State of North Dakota, STATE, in its sole discretion, by written notice to CONTRACTOR, may terminate this Contract in whole or in part.

c. Termination for Lack of Funding or Authority STATE, by written notice to CONTRACTOR, may terminate the whole or any part of this Contract under any of the following conditions:

1) If funding from federal, state, or other sources is not obtained or continued at levels sufficient to allow for purchase of the services or goods in the indicated quantities or term.

2) If federal or state laws or rules are modified or interpreted in a way that the services or good are no longer allowable or appropriate for purchase under this Contract or are no longer eligible for the funding proposed for payments authorized by this Contract.

3) If any license, permit, or certificate required by law or rule, or by the terms of this Contract, is for any reason denied, revoked, suspended, or not renewed.

Termination of this Contract under this subsection is without prejudice to any obligations or liabilities of either Party already accrued prior to termination.

d. Termination for Cause.

STATE may terminate this Contract effective fifteen (15) days after delivery of written notice to CONTRACTOR, or any later date stated in the notice if the basis for termination is not cured by CONTRACTOR during such fifteen (15) day period:

1) If CONTRACTOR fails to provide services or goods required by this Contract within the time specified or any extension agreed to in writing by STATE; or

2) If CONTRACTOR fails to perform any of the other provisions of this Contract, or so fails to pursue the work as to endanger performance of this Contract in accordance with its terms.

The rights and remedies of STATE provided in this subsection are not exclusive and are in addition to any other rights and remedies provided by law or under this Contract.

8. SUSPENSION FOR CONVENIENCE

STATE shall have the right at any time to order the services of CONTRACTOR fully or partially stopped for STATE’s own convenience. STATE shall provide CONTRACTOR written notice of the reason for and duration of the suspension. The schedule and the time for CONTRACTOR’S performance shall be delayed on a day-for-day basis to the extent STATE has issued a stop work order to CONTRACTOR and such stop work order is causing delays in completing services in accordance with the schedule. CONTRACTOR shall have the right to submit claims in accordance with the terms of this Contract as a result of stop work orders issued under this section.

9. FORCE MAJEURE

Neither Party shall be held responsible for delay or default caused by fire, riot, terrorism, pandemic (excluding COVID-19), acts of God, or war if the event was not foreseeable through the exercise of reasonable diligence by the affected Party (“Force Majeure Event”), Force Majeure Event is beyond the Party’s reasonable control, and the affected Party gives notice to the other Party promptly upon occurrence of the Force Majeure Event causing the delay or default or that is reasonably expected to cause a delay or default. If CONTRACTOR is the affected Party and does not resume performance within fifteen (15) days after termination of the Force Majeure Event, or another period agreed between the Parties, then STATE may seek all available remedies, up to and including termination of this Contract pursuant to its Termination Section, and STATE shall be entitled to a pro-rata refund of any amounts paid for which the full value has not been realized, including amounts paid toward software subscriptions, maintenance, or licenses.

10. LIQUIDATED DAMAGES

The Parties agree that STATE may suffer damages due to a failure by CONTRACTOR to provide deliverables or services under this Contract. Because it is difficult to fix the actual damages sustained in the event of such delays, STATE and CONTRACTOR agree that the amount of damages shall be determined as per this section. In the event of any non-performance CONTRACTOR shall pay that amount as liquidated damages and not as a penalty. Amounts due to STATE as liquidated damages may be deducted by STATE from any amounts payable to CONTRACTOR, and any amount outstanding over and above the amounts deducted from the invoice shall be promptly tendered by check from CONTRACTOR to STATE.

Delays due to causes of Force Majeure or due to the responsibility of STATE shall extend the time for performance on a day-for-day basis. STATE shall not assess liquidated damages against CONTRACTOR when the delay in delivery or performance is beyond the control and without the fault or negligence of CONTRACTOR.

Failure to Complete Project on Schedule:

If CONTRACTOR fails to complete the project per the approved project schedule by the specified deadline (or revised deadline as agreed upon between the Parties through the Integrated Change Control Process), STATE shall deduct liquidated damages from amounts payable to CONTRACTOR in the amount of $800.00 per calendar day for each day the project is delayed.

11. LIMITATION OF LIABILITY

TO THE FULLEST EXTENT AVAILABLE UNDER NORTH DAKOTA CENTURY CODE (N.D.C.C.)

§ 32-12.2-15, CONTRACTOR’S ENTIRE AND CUMULATIVE LIABILITY TO STATE FOR ANY

LOSS OR DAMAGES RESULTING FROM ANY CLAIMS, DEMANDS, OR ACTIONS ARISING

OUT OF OR RELATING TO THE PRODUCT, OR PERFORMANCE OF ANY SERVICES,

INCLUDING ANY TORT, SUCH AS NEGLIGENCE, SHALL NOT EXCEED AN AMOUNT EQUAL

TO TWICE THE FEES PAID TO CONTRACTOR UNDER THIS CONTRACT DURING THE

TWELVE (12) MONTH PERIOD IMMEDIATELY PRECEDING THE DATE ON WHICH THE CLAIM

ACCRUED. WITHOUT WAIVER OF THE LIMITATIONS SET FORTH IN THIS SECTION OF THIS

AGREEMENT, IN NO EVENT SHALL CONTRACTOR BE LIABLE FOR ANY INDIRECT,

INCIDENTAL, CONSEQUENTIAL, SPECIAL, OR EXEMPLARY DAMAGES OR LOST PROFITS,

EVEN IF CONTRACTOR HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.

THE FOREGOING LIMITATIONS DO NOT APPLY TO LOSS TO STATE THAT CANNOT BE

LIMITED UNDER N.D.C.C. § 32-12.2-15(4). CONTRACTOR AND STATE AGREE THAT THE

LIMITATIONS OF LIABILITY SET FORTH IN THIS CONTRACT REPRESENT BARGAINED FOR

ALLOCATIONS OF RISK, AND THAT THE FEES, CHARGES, AND COSTS OWING UNDER THIS

AGREEMENT, REPRESENT THE ALLOCATIONS OF SUCH RISK.

12. INJUNCTIVE RELIEF

CONTRACTOR shall immediately report to STATE any and all unauthorized disclosures or uses of STATE’s confidential information or proprietary information of which CONTRACTOR or its staff is aware or has knowledge. CONTRACTOR acknowledges that any unauthorized publication or disclosure of STATE’s confidential information or proprietary information to others may cause immediate and irreparable harm to STATE. If CONTRACTOR should publish or disclose such confidential information or proprietary information without authorization, STATE shall immediately be entitled to injunctive relief or any other remedies to which it is entitled under law or equity without requiring a cure period. CONTRACTOR shall indemnify, defend, and hold harmless STATE from all damages, costs, liabilities, and expenses (including without limitation reasonable attorneys’ fees) caused by or arising from CONTRACTOR’s unauthorized use or disclosure of STATE’s confidential information or proprietary information. As a condition to these indemnity obligations, STATE will provide CONTRACTOR with prompt notice of any claim of which STATE is aware and for which indemnification shall be sought under this Contract and shall cooperate in all reasonable respects with CONTRACTOR in connection with any such claim.

13. RIGHT OF SETOFF DAMAGES

Amounts due STATE by CONTRACTOR, including liquidated or other damages, or claims for damages, may be deducted or set-off by STATE from any money payable to CONTRACTOR pursuant to this Contract.

14. RIGHT TO WITHHOLD AMOUNTS OTHERWISE DUE IF THE CONTRACTOR IS IN BREACH

If CONTRACTOR fails to deliver Deliverables or to provide Services which satisfy CONTRACTOR’s obligations under this Contract, STATE shall have the right to withhold any and all payments due under this Contract. STATE may withhold any and all such payments due under this Contract to CONTRACTOR without penalty or work stoppage by CONTRACTOR, until such failure to perform is cured.

15. RIGHT TO REMEDIES AND CUMULATION OF RIGHTS

Except as otherwise expressly provided in this Contract, no remedy conferred by any of the specific provisions of this Contract is intended to be exclusive of any other remedy, and each and every remedy shall be cumulative and shall be in addition to every other remedy given under this Contract, now or in the future existing at law or in equity or by statute or otherwise.

16. NON-WAIVER

Either party’s failure to exercise any of its rights under this Contract, its delay in enforcing any right, or its waiver of its rights on any occasion, shall not constitute a waiver of such rights on any other occasion. No course of dealing by either party in exercising any of its rights shall constitute a waiver thereof. No waiver of any provision of this Contract shall be effective unless it is in writing and signed by the party against whom the waiver is sought to be enforced.

17. INDEMNIFICATION

CONTRACTOR agrees to defend, indemnify, and hold harmless the state of North Dakota, its agencies, officers and employees (State), from and against claims of third parties based on the vicarious liability of the State or its agents, and which are based on the negligence or willful misconduct of CONTRACTOR, but not against claims based on the State’s contributory negligence, comparative and/or contributory negligence or fault, sole negligence, or intentional misconduct. This obligation to defend, indemnify, and hold harmless does not extend to professional liability claims arising from professional errors and omissions. The legal defense provided by CONTRACTOR to the State under this provision must be free of any conflicts of interest, even if retention of separate legal counsel for the State is necessary. Any attorney appointed to represent the State must first qualify as and be appointed by the North Dakota Attorney General as a Special Assistant Attorney General as required under N.D.C.C. § 54-12-08. CONTRACTOR also agrees to reimburse the State for all costs, expenses and attorneys' fees incurred if the State prevails in an action against CONTRACTOR in establishing and litigating the indemnification coverage provided herein. This obligation shall continue after the termination of this Contract.

18. INTELLECTUAL PROPERTY INFRINGEMENT INDEMNIFICATION

a. CONTRACTOR, at its own expense, shall defend and indemnify STATE against claims that products furnished under this Contract knowingly infringe a United States patent or copyright or misappropriate trade secrets protected under United States law.

CONTRACTOR’S obligation shall not extend to a claim based on any alleged infringement arising from any: (a) additions, changes, or modifications to the services by or on behalf of STATE; (b) incorporation of the services or any component thereof into any other product or process; or (c) use of the services other than as permitted by this Contract.

b. As to any product which is subject to a claim of infringement or misappropriation, CONTRACTOR may (a) obtain the right of continued use of the product for STATE or (b) replace or modify the product to avoid the claim. If neither alternative is available on commercially reasonable terms then, at the request of CONTRACTOR, any applicable Software license and its charges will end, STATE will stop using the product, and will return the product to CONTRACTOR. Upon return of the product, CONTRACTOR will give STATE a credit for the price paid to CONTRACTOR, less a reasonable offset for use and obsolescence.

19. REPRESENTATIONS AND WARRANTIES

CONTRACTOR represents and warrants to STATE that neither CONTRACTOR, in connection with performing the services in performance of this Contract, nor the completed product delivered by CONTRACTOR, will knowingly infringe any patent, copyright, trademark, trade secret or other proprietary right of any person. CONTRACTOR further represents and warrants to STATE that it will not use any trade secrets or confidential or proprietary information owned by any third party in performing the services related to this Contract or in delivery of the completed product unless CONTRACTOR has the authority to license, use or provide those trade secrets or confidential or proprietary information to STATE. CONTRACTOR further represents and warrants to STATE that neither CONTRACTOR nor any other company or individual performing services pursuant to this Contract is under any obligation to assign or give any work done under this Contract to any third party.

20. INSURANCE

a. CONTRACTOR shall secure and keep in force during the term of this Contract and

CONTRACTOR shall require all subcontractors, prior to commencement of an agreement between CONTRACTOR and the subcontractor, to secure and keep in force during the term of this CONTRACT, from insurance companies, government self-insurance pools or government self-retention funds, authorized to do business in North Dakota, the following insurance coverages:

1) Commercial general liability, including premises or operations, contractual, and products or completed operations coverages (if applicable), with minimum liability limits of $2,000,000 per occurrence.

2) Automobile liability, including Owned (if any), Hired, and Non-Owned automobiles, with minimum liability limits of $500,000 per person and $2,000,000 per occurrence.

3) Workers compensation coverage meeting all statutory requirements. The policy shall provide coverage for all states of operation that apply to the performance of this Contract.

4) Employer’s liability or “stop gap” insurance of not less than $2,000,000 as an endorsement on the workers compensation or commercial general liability insurance.

b. The insurance coverages listed above must meet the following additional requirements:

1) Any deductible or self-insured retention amount or other similar obligation under the policies shall be the sole responsibility of the CONTRACTOR.

2) This insurance may be in policy or policies of insurance, primary and excess, including the so-called umbrella or catastrophe form and must be placed with insurers rated “A-” or better by A.M. Best Company, Inc., provided any excess policy follows form for coverage. Less than an “A-” rating must be approved by the State. The policies shall be in form and terms approved by the State.

3) The duty to defend, indemnify, and hold harmless the State under this agreement shall not be limited by the insurance required in this agreement.

4) The state of North Dakota and its agencies, officers, and employees (State) shall be endorsed on the commercial general liability policy, including any excess policies (to the extent applicable), as additional insured. The State shall have all the benefits, rights and coverages of an additional insured under these policies that shall not be limited to the minimum limits of insurance required by this agreement or by the contractual indemnity obligations of the CONTRACTOR.

5) A Waiver of Subrogation” waiving any right to recovery the insurance company may have against the State.

6) CONTRACTOR shall furnish a certificate of insurance to the undersigned STATE representative prior to commencement of this agreement. All endorsements shall be provided as soon as practicable.

7) Failure to provide insurance as required in this agreement is a material breach of contract entitling STATE to terminate this agreement immediately.

8) CONTRACTOR shall provide at least 30-day notice of any cancellation or material change to the policies or endorsements. CONTRACTOR shall provide on an ongoing basis, current certificates of insurance during the term of the Contract. A renewal certificate will be provided 10 days prior to coverage expiration. An updated, current certificate of insurance shall be provided in the event of any change to a policy.

21. OWNERSHIP OF WORKS FOR HIRE

STATE acknowledges that the SaaS product and all other work(s) under this Contract, including any right to derivative work(s), are and shall remain the exclusive property of CONTRACTOR. All software and related materials developed by CONTRACTOR in performance of this Contract for STATE shall be the sole property of CONTRACTOR, and CONTRACTOR does not assign or transfer any of its right, title, and interest therein to STATE. STATE acknowledges that CONTRACTOR is licensing certain works to STATE under this Contract, but CONTRACTOR is not otherwise transferring or assigning any of its rights to such works.

22. WORK PRODUCT

All work product, equipment or materials created for STATE or purchased by STATE under this Contract belong to STATE and must be immediately delivered to STATE at STATE's request upon termination of this Contract.

23. TECHNOLOGY STANDARDS

CONTRACTOR shall comply with applicable STATE enterprise architecture technology standards.

These standards can be found on STATE’s website at https://www.ndit.nd.gov/standards. If CONTRACTOR is unable to comply with any applicable standard, a Request for Exemption from Information Technology Standards or Statutory Policies (SFN 51687) must be submitted in coordination with STATE and CONTRACTOR for the North Dakota Information Technology Department’s review and approval or disapproval.

24. PERSONNEL

a. STATE will designate a Project Manager to serve as the primary project manager for this

Contract. If, during the course of this Contract, it becomes necessary for STATE to change the person assigned as STATE’s Project Manager, STATE will notify CONTRACTOR in writing, pursuant to Notice section of this Contract.

b. Unless STATE otherwise notifies CONTRACTOR, STATE’s Project Manager shall carry out STATE’s administrative and management functions under this Contract, shall be responsible for acceptance of the Contract deliverables, and shall provide support and overall direction to

CONTRACTOR.

c. CONTRACTOR will designate a Project Manager and provide individuals to meet the requirements and accomplish the work as stated in this Contract including any mutually agreed upon Scope of Work.

d. CONTRACTOR agrees and understands that STATE’s execution of this Contract is predicated, in part and among other considerations, on the utilization of the specific individuals and personnel qualifications as identified; primary being Michael Walker (Project Manager), Floyd Millet (Project Sponsor), Tim Daily (Solution Architect), Don Kartchner (Technical Lead).

Therefore, CONTRACTOR agrees that:

1) Prior to reassignment of personnel, CONTRACTOR shall obtain written approval from

STATE for all personnel to be assigned to this project.

2) The personnel assigned must have the knowledge necessary to complete requirements as defined in this Contract.

3) CONTRACTOR shall warrant that all personnel assigned to perform tasks in response to this Contract will remain assigned for the agreed-upon length of time.

4) No replacement, reassignment or substitution of any assigned individuals and personnel qualifications shall be made without the prior written approval of STATE and that such replacement, reassignment or substitution shall be made at no additional cost to STATE.

5) Any substitution made pursuant to this paragraph must be of equal or higher skills, knowledge, and abilities than those personnel originally proposed, and that STATE’s approval of a substitution is not construed as an acceptance of the substitution’s performance potential. STATE agrees that an approval of a substitution will not be unreasonably withheld.

e. Upon request by STATE, CONTRACTOR shall replace any CONTRACTOR personnel that STATE determines, in its sole discretion, to be unable to perform the responsibilities of this https://www.ndit.nd.gov/standards

Contract acceptably, e.g., inappropriate or unprofessional personal conduct, professional inabilities, etc.

f. STATE's working hours are Monday through Friday from 8:00 AM until 5:00 PM (CST or CDT) with one hour for lunch. STATE Project Manager may approve alternate work schedules.

g. According to STATE policy, STATE personnel are only obligated to work a forty-hour workweek, Monday through Friday, and are allowed reasonable vacation, sick and educational absences.

h. CONTRACTOR’s personnel are not expected to work on State holidays or other mandatory leave days.

i. CONTRACTOR agrees that STATE may require any personnel CONTRACTOR assigns to perform work under this Contract, including employees, contracted staff, subcontractors, or other individuals, to submit to a criminal history record check in accordance with N.D.C.C. §12- 60-24, through the authority granted to the chief information officer of the STATE pursuant to N.D.C.C. § 54-59-20. STATE shall have the right to reject any individual CONTRACTOR assigns to perform work under this Contract if, in STATE’s sole discretion, it determines that the results of the criminal history record check make the individual unacceptable. CONTRACTOR agrees to be responsible for all costs associated with criminal history record checks carried out pursuant to this paragraph.

25. PROJECT MANAGEMENT

a. Reporting

1) CONTRACTOR’s Project Manager shall deliver to STATE’s Project Manager, weekly report of CONTRACTOR’s progress on the project and meeting the objective/deliverables as stated in the Scope of Work. Each report must contain a description of the current status of the project, the tasks on which time was spent, the estimated progress to be made in the next reporting period, and the problems encountered the proposed solutions to them and their effect, if any, on the project budget/schedule.

2) Project Variance Reporting – CONTRACTOR must provide data to allow STATE’s project manager to calculate cost and schedule variance in accordance with N.D.C.C. § 54-59-23 as determined by STATE. If STATE’s analysis shows a negative cost or schedule variance exceeding 20%, a subsequent report must also provide proposed corrective measures to address the issues.

b. Integrated Change Control Process CONTRACTOR and STATE will utilize an integrated change control process to manage changes during the life of a project.

1) A change request must be in writing to document the potential change. The write-up for the proposed change must be submitted to CONTRACTOR and STATE’s project managers who will in turn provide it to relevant Parties for assessment.

2) All change requests will be logged and tracked. STATE’s project manager will record the request in the project repository and will update the repository throughout the process.

3) The change will be reviewed and, if acceptable to STATE, CONTRACTOR will submit to STATE an estimate of the impact to cost, schedule, scope, and quality.

4) CONTRACTOR will continue performing the services in accordance with the original Contract unless otherwise agreed upon by STATE’s project manager. Work shall not commence on any new activities related to the change request until all Parties agree in writing.

5) CONTRACTOR’s project manager and STATE’s project manager will adapt the Project Management Plan to incorporate approved changes.

http://www.legis.nd.gov/cencode/t54c59.pdf http://www.legis.nd.gov/cencode/t12c60.pdf http://www.legis.nd.gov/cencode/t12c60.pdf http://www.legis.nd.gov/cencode/t54c59.pdf

6) Each change request duly authorized in writing by the Parties shall be incorporated into and considered part of this Contract.

7) During the course of this Contract, if CONTRACTOR determines or could reasonably determine any STATE actions or directions constitute a requirement to perform additional work, CONTRACTOR shall notify STATE within thirty (30) calendar days that STATE has requested CONTRACTOR to perform additional work in the form of a change request utilizing the process above. CONTRACTOR understands that it waives the right to request additional time and reimbursable costs if CONTRACTOR fails to notify STATE within thirty

(30) calendar days of determining or reasonably being able to determine that any STATE actions or directions constitute a requirement to perform additional work under this Contract.

c. Deliverable Acceptance

1) Upon completion of a deliverable, CONTRACTOR will furnish STATE with the deliverable and associated documentation, the expected performance, and agreed upon Acceptance Criteria.

2) After receipt of items in Paragraph 26(c)(1), STATE will have five (5) working days or a different period of time as is agreed to by the Parties, in which to accept or reject each item in writing. STATE will accept by signature. If STATE rejects it, STATE will specify in writing its grounds for rejection and CONTRACTOR shall use its best efforts to revise any issues for the deliverables to be acceptable to STATE within the following five (5) working days. If STATE rejects it a second time, STATE will have the option of repeating the procedure as described in this acceptance statement above, escalating the issue to the Executive Steering Committee, or terminating this Contract upon written notice to CONTRACTOR.

d. Final Acceptance

1) The successful completion of all deliverables as stated in the Scope of Work in accordance with the deliverable acceptance process AND

2) The final delivered product fully implemented in STATE’s live production environment AND

3) STATE has sixty (60) calendar days thereafter in which to accept or reject it in writing. If

STATE rejects it, STATE shall specify in writing its grounds for rejection and CONTRACTOR shall use its best efforts to make the product conform to the requirements of this Contract as soon as possible and at no additional cost to STATE. CONTRACTOR shall continue to use its best efforts to make the product conform to the requirements of this Contract until STATE accepts the product or terminates this Contract upon written notice to CONTRACTOR.

26. PRODUCT CONFORMITY

CONTRACTOR warrants that the SaaS product delivered to STATE will perform in accordance with information provided to STATE regarding the performance of the SaaS product. As STATE’S exclusive remedy for breach of the foregoing warranty, and upon recognition of an error, deficiency, or defect, by STATE, CONTRACTOR shall be notified by STATE citing any specific deficiency (deficiency being defined as CONTRACTOR having performed incorrectly with the information provided by STATE, not CONTRACTOR having to modify a previous action due to additional and/or corrected information from STATE). CONTRACTOR, at no additional charge to STATE, shall provide a correction or provide a mutually acceptable plan for correction within thirty (30) calendar days following the receipt of STATE’s notice to CONTRACTOR. If CONTRACTOR’s correction is inadequate to correct the deficiency, or defect, or the error recurs, STATE may, at its option, act to correct the problem. CONTRACTOR shall be required to reimburse STATE for any such costs incurred or STATE may consider this to be cause for breach of contract. EXCEPT AS EXPRESSLY

PROVIDED IN SECTION 19 AND 27 OF THIS CONTRACT, CONTRACTOR EXPRESSLY

DISCLAIMS ANY AND ALL OTHER WARRANTIES, INCLUDING ANY IMPLIED WARRANTIES OF

MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, OR NONINFRINGEMENT.

27. WARRANTY

CONTRACTOR shall provide a 90-day warranty on all delivered functionality, encompassing all contractual requirements. This warranty assures that the requirements function as intended during the implementation process and that any bugs that arise will be promptly rectified. CONTRACTOR shall continue to address all application bugs occurring throughout the subscription period, extending for the duration of said subscription. Software maintenance and warranty are comprehensively covered within the Annual Licensing fees. Furthermore, CONTRACTOR guarantees the availability and functionality of the application for use, in accordance with the terms outlined in the Service Level Agreement (SLA), as specified in the solicitation document, and CONTRACTOR’s response.

28. SOFTWARE LICENSE

CONTRACTOR grants to STATE a non-exclusive, revocable, and non-transferable license and right to access and use the SaaS product that is the subject of this Contract solely in accordance with the terms of this Contract. The license does not include a license to any source or object code but is a license to access and use the product on the platform on which it is provided to STATE. All ownership rights to CONTRACTOR’s software provided to STATE under this Contract (intellectual property owned by CONTRACTOR prior to performance of this Contract) shall remain with CONTRACTOR. Any customizations or enhancements developed by CONTRACTOR for STATE will be included in the license and subscription to the product.

29. SOFTWARE AS A SERVICE (SAAS) AND SERVICE LEVEL AGREEMENT (SLA)

The terms and service level obligations are set forth in Exhibit C Software as a Service (SaaS) Service Level Agreement (SLA) are made a part of this Contract through its reference here.

CONTRACTOR shall provide Subscription Services, including software/hardware updates and technical support services for the Subscription Services pursuant to this Contract. CONTRACTOR and STATE shall negotiate the terms and price of such services. CONTRACTOR agrees to continue to offer Subscription Services for the product(s) for a minimum of five (5) years from the date of final acceptance of any software/product update.

a. Subscription Services:

1) The service is based on access of the application by unlimited STATE and external users including contractors, subcontractors, outsourcing vendors, consultants, and others who have a need to use the software for the benefit of STATE. The iPDWeb licensing includes STATE’s ability to create user accounts for city, county, tribal and township contacts to contribute to and manage all State and federally funded projects, including locally funded projects tied to a Federal Aid project.

2) Service shall be extended to any Users who have a need to use the SaaS for the benefit of

STATE.

3) There shall be no limit on the number of machines, number of locations, or size of processors on which STATE can operate the service.

4) If CONTRACTOR reduces or replaces the functionality contained in the software and provides this functionality as a separate or renamed product, then STATE shall be entitled to usage of such software product at no additional fees.

b. Subscription Period The ongoing annual subscription period begins after installation in the Production Environment and thereafter continues on an annual basis.

c. Purchase of Additional Users STATE may purchase additional Users during the term of this Contract at the same price offered by CONTRACTOR under the terms of this Contract.

d. Subscription Fee Cap CONTRACTOR agrees that any change to the annual Services fee may increase by not more than the lower of 3% or Consumer Price Index (CPI). The rates shall be adjusted in accordance with the index titled “All Urban Consumers (CPI-U). for the U.S. City Average. All Items 1982- 84=100”, prepared by the U.S. Bureau of Labor Statistics.

e. Right to Change Support Plan Level STATE may choose to change its subscription to CONTRACTOR’s Subscription Services plan to a higher or lower level plan that is offered by CONTRACTOR at the Contract’s next renewal date upon thirty (30) calendar days’ notice to CONTRACTOR.

f. Right to Modify or Cancel Services STATE may choose to cancel Subscription Services at this Contract’s next renewal date upon thirty (30) calendar days’ notice to CONTRACTOR.

30. SAAS AND DATA SECURITY

Remote access to Data from outside the continental United States, including remote access to Data by authorized support staff in identified support centers, is prohibited. If CONTRACTOR is unable to comply, a Request for Exemption from Information Technology Standards or Statutory Policies (SFN 51687) must be submitted in coordination with STATE and CONTRACTOR for the North Dakota Information Technology Department’s review and approval or disapproval.

31. DATA PROCESSING AND LOCATION:

a) CONTRACTOR shall transmit, process, and store STATE Data within the continental United

States.

b) CONTRACTOR shall notify STATE at least 90 days prior to any relocation of STATE’s Data to a different hosting facility. STATE reserves the right to terminate the Contract without penalty if STATE does not approve of the new hosting facility.

32. SOFTWARE AUDIT

CONTRACTOR may, upon sixty (60) calendar days’ notice to STATE, but not more frequently than once per year, either request a signed certification by an officer of STATE verifying that the software is being used in accordance with the terms of this Contract or audit STATE’s use of the software to ensure compliance with the terms and conditions of this Contract. Any such audit shall be conducted at CONTRACTOR’s expense during regular business hours at STATE’s offices and shall not unreasonably interfere with STATE’s business activities. CONTRACTOR shall provide documentation to STATE defining the scope of the audit not less than thirty (30) calendar days prior to the audit. STATE shall have sixty (60) calendar days to review CONTRACTOR’s audit findings. If an audit reveals that STATE’s use of the Software exceeds the use permitted hereunder, then CONTRACTOR may invoice STATE for the applicable additional amounts based on the price agreement between the Parties as of the date of completion of the audit.

33. NOTICE

All notices or other communications required under this Contract must be given by email, registered or certified mail and are complete on the date postmarked when addressed to the Parties at the following addresses:

STATE CONTRACTOR

Chad Orn Brent D. McKinley Deputy Director for Planning Director, Business Development 608 East Boulevard Ave. 895 W Baxter Dr.

Bismarck, ND 58505 South Jordan, UT, 84095 corn@nd.gov Bmckinley@exevision.com

Notice provided under this provision does not meet the notice requirements for monetary claims against STATE found at N.D.C.C § 32-12.2-04.

34. CONFIDENTIALITY

CONTRACTOR shall not use or disclose any information it receives from STATE under this Contract that STATE has previously identified as confidential or exempt from mandatory public disclosure except as necessary to carry out the purposes of this Contract or as authorized in advance by STATE. STATE shall not disclose any information it receives from CONTRACTOR that CONTRACTOR has previously identified as confidential and that STATE determines in its sole discretion is protected from mandatory public disclosure under a specific exception to the North Dakota public records law, N.D.C.C. ch. 44-04. The duty of STATE and CONTRACTOR to maintain confidentiality of information under this section continues beyond the Term of this Contract.

STATE acknowledges and agrees that CONTRACTOR may disclose confidential information in accordance with applicable law, and if required by a subpoena, court order, or other legal process.

35. COMPLIANCE WITH PUBLIC RECORDS LAWS

Under the North Dakota public records law and subject to the Confidentiality clause of this Contract, certain records may be open to the public upon request.

Public records may include: (a) records STATE receives from CONTRACTOR under this Contract,

(b) records obtained by either Party under this Contract, and (c) records generated by either Party under this Contract.

CONTRACTOR agrees to contact STATE immediately upon receiving a request for information under the public records law and to comply with STATE’s instructions on how to respond to such request.

36. INDEPENDENT ENTITY

CONTRACTOR is an independent entity under this Contract and is not a STATE employee for any purpose, including the application of the Social Security Act, the Fair Labor Standards Act, the Federal Insurance Contribution Act, the North Dakota Unemployment Compensation Law and the North Dakota Workforce Safety and Insurance Act. CONTRACTOR retains sole and absolute discretion in the manner and means of carrying out CONTRACTOR’s activities and responsibilities under this Contract, except to the extent specified in this Contract.

37. ASSIGNMENT AND SUBCONTRACTS

CONTRACTOR may not assign or otherwise transfer or delegate any right or duty without STATE’s express written consent, provided, however, that CONTRACTOR may assign its rights and obligations under this Contract in the event of a change of control or sale of all or substantially all of its assets related to this Contract, whether by merger, reorganization, operation of law, or otherwise.

Should Assignee be a business or entity with whom STATE is prohibited from conducting business, http://www.legis.nd.gov/cencode/t32c12-2.pdf http://www.legis.nd.gov/cencode/t44c04.pdf

STATE shall have the right to terminate in accordance with the Termination for Cause section of this Contract.

CONTRACTOR may enter subcontracts provided that any subcontract acknowledges the binding nature of this Contract and incorporates this Contract, including any attachments. CONTRACTOR is solely responsible for the performance of any subcontractor with whom CONTRACTOR contracts.

CONTRACTOR does not have authority to contract for or incur obligations on behalf of STATE.

38. SPOLIATION – NOTICE OF POTENTIAL CLAIMS

CONTRACTOR shall promptly notify STATE of all potential claims that arise or result from this Contract. CONTRACTOR shall also take all reasonable steps to preserve all physical evidence and information that may be relevant to the circumstances surrounding a potential claim, while maintaining public safety, and grants to STATE the opportunity to review and inspect such evidence, including the scene of an accident.

39. MERGER AND MODIFICATION, CONFLICT IN DOCUMENTS

This Contract, including the following documents, constitutes the entire agreement between the Parties. There are no understandings, agreements, or representations, oral or written, not specified within this Contract. This Contract may not be modified, supplemented, or amended, in any manner, except by written agreement signed by both Parties.

Notwithstanding anything herein to the contrary, in the event of any inconsistency or conflict among the documents making up this Contract, the documents must control in this order of precedence:

a. The terms of this Contract as may be amended;

b. STATE’s Best and Final Offer request to Request for Proposal (“RFP”) number 110.7-24-004 dated May 16, 2024;

c. STATE’s Solicitation Amendment #2 to Request for Proposal (“RFP”) number 110.7-24-004 dated March 19, 2024;

d. STATE’s Solicitation Amendment #1 to Request for Proposal (“RFP”) number 110.7-24-004 dated March 14, 2024;

e. STATE’s Request for Proposal (“RFP”) number 110.7-24-004, dated February 26, 2024;

f. CONTRACTOR’s Best and Final Offer response dated May 23, 2024, in response to RFP number 110.7-24-004

g. CONTRACTOR’s proposal dated April 8, 2024 in response to RFP number 110.7-24-004.

All automated end-user agreements (e.g., click-through, shrink-wrap, or browse-wrap) are specifically excluded and null and void. Clicking shall not represent acknowledgement or agreement to any terms and conditions contained in those agreements.

40. UNANTICIPATED AMENDMENTS

If additional work is required within the scope of this Contract due to a legitimate unforeseen circumstance, STATE shall provide CONTRACTOR a written description of the additional work and request CONTRACTOR to submit a proposal for accomplishing the scope of work. CONTRACTOR will not commence additional work until all Parties agree in writing.

41. SEVERABILITY

If any term of this Contract is declared to be illegal or unenforceable by a court having competent jurisdiction, the validity of the remaining terms is unaffected and, if possible, the rights and obligations of the Parties are to be construed and enforced as if this Contract did not contain that term.

42. APPLICABLE LAW AND VENUE

This Contract is governed by and construed in accordance with the laws of the State of North Dakota. Any action to enforce this Contract must be adjudicated exclusively in the state District Court of Burleigh County, North Dakota. Each Party consents to the exclusive jurisdiction of such court and waives any claim of lack of jurisdiction or forum non conveniens.

43. ALTERNATIVE DISPUTE RESOLUTION – JURY TRIAL

By entering this Contract, STATE does not agree to binding arbitration, mediation, or any other form of mandatory Alternative Dispute Resolution. The Parties may enforce the rights and remedies in judicial proceedings. STATE does not waive any right to a jury trial.

44. NONDISCRIMINATION - COMPLIANCE WITH LAWS

CONTRACTOR agrees to comply with all applicable federal and state laws, rules, and policies, including those relating to nondiscrimination, accessibility and civil rights. (See N.D.C.C. Title 34 – Labor and Employment, specifically N.D.C.C. ch. 34-06.1 Equal Pay for Men and Women.)

CONTRACTOR agrees to timely file all required reports, make…