Attachment 1 Specifications.pdf

SPECIFICATIONS

(FOR CONSTRUCTION OF)

Solicitation No. W91238-21-R-0005

ACCESS CONTROL POINT (GATE 1)

PN 74877 (FY17)

MILITARY OCEAN TERMINAL CONCORD,

CALIFORNIA

Technical Specifications: Divisions 01 - 34

October 2020

Prepared For:

US Army Corps of Engineers - Sacramento District

Prepared By:

OMAHA DISTRICT

This page was intentionally left blank for duplex printing.

00 01 00 - 1 PROJECT TABLE OF CONTENTS

TECHNICAL SPECIFICATIONS FOR CONSTRUCTION OF

ACCESS CONTROL POINT (GATE 1)

PN 074877

MILITARY OCEAN TERMINAL CONCORD, CALIFORNIA

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS*

00 01 00 PROJECT TABLE OF CONTENTS

* - DIVISON 00 SECTIONS ARE UNDER SEPARATE COVER

TECHNICAL SPECIFICATIONS

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 14 00 WORK RESTRICTIONS

01 30 00 ADMINISTRATIVE REQUIREMENTS

01 32 01 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

REGISTER SUBMITTAL REGISTER

01 33 29 SUSTAINABILITY REPORTING

01 33 29AT MOTCO GATE #1 GUIDING PRINCIPLES ASSESSMENT CHECKLIST

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00 QUALITY CONTROL

SPKFORMS SAMPLE FORMS

SPK415-1-2 CONTRUCTION CONTROL MANUAL

01 45 00.15 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 45 35 SPECIAL INSPECTIONS

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 57 20 ENVIRONMENTAL PROTECTION

01 57 23 TEMPORARY STORM WATER POLLUTION CONTROL

01 74 19 CONSTRUCTION WASTE MANAGEMENT AND DISPOSAL

01 78 00 CLOSEOUT SUBMITTALS

01 78 23 OPERATION AND MAINTENANCE DATA

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION

02 82 00 ASBESTOS REMEDIATION

02 83 00 LEAD REMEDIATION

BLDG1A-2 ASBESTORS AND LEAD PANT SURVERY REPORT-BLDG-1A-2

DIVISION 03 - CONCRETE

03 30 53 MISCELLANEOUS CAST-IN-PLACE CONCRETE

03 42 13.00 10 PLANT-PRECAST CONCRETE PRODUCTS FOR BELOW GRADE CONSTRUCTION

00 01 00 - 2 PROJECT TABLE OF CONTENTS

DIVISION 04 - MASONRY

04 20 00 UNIT MASONRY

DIVISION 05 - METALS

05 05 23.16 STRUCTURAL WELDING

05 12 00 STRUCTURAL STEEL

05 30 00 STEEL DECKS

05 40 00 COLD-FORMED METAL FRAMING

05 50 13 MISCELLANEOUS METAL FABRICATIONS

05 50 14 STRUCTURAL METAL FABRICATIONS

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 10 00 ROUGH CARPENTRY

06 41 16.00 10 PLASTIC-LAMINATE-CLAD ARCHITECTURAL CABINETS

06 61 16 SOLID SURFACING FABRICATIONS

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 11 13 BITUMINOUS DAMPPROOFING

07 21 13 BOARD AND BLOCK INSULATION

07 21 16 MINERAL FIBER BLANKET INSULATION

07 22 00 ROOF AND DECK INSULATION

07 24 00 EXTERIOR INSULATION AND FINISH SYSTEMS

07 27 10.00 10 BUILDING AIR BARRIER SYSTEM

07 27 19.01 SELF-ADHERING AIR BARRIERS

07 27 26 SPRAY FOAM INSULATION

07 60 00 FLASHING AND SHEET METAL

07 61 14.00 20 STEEL STANDING SEAM ROOFING

07 92 00 JOINT SEALANTS

DIVISION 08 - OPENINGS

08 11 13 STEEL DOORS AND FRAMES

08 11 16 ALUMINUM DOORS AND FRAMES

08 33 13 COILING COUNTER DOORS

08 33 23 OVERHEAD COILING DOORS

08 34 01 FORCED ENTRY RESISTANT COMPONENTS

08 34 02 BULLET-RESISTANT COMPONENTS

08 41 13 ALUMINUM-FRAMED ENTRANCES AND STOREFRONTS

08 51 13 ALUMINUM WINDOWS

08 71 00 DOOR HARDWARE

08 81 00 GLAZING

08 91 00 METAL WALL LOUVERS

DIVISION 09 - FINISHES

09 06 90 COLOR SCHEDULE

09 22 00 SUPPORTS FOR PLASTER AND GYPSUM BOARD

09 29 00 GYPSUM BOARD

00 01 00 - 3 PROJECT TABLE OF CONTENTS

09 30 10 CERAMIC, QUARRY, AND GLASS TILING

09 51 00 ACOUSTICAL CEILINGS

09 65 00 RESILIENT FLOORING

09 67 23.13 STANDARD RESINOUS FLOORING

09 90 00 PAINTS AND COATINGS

09 96 59 HIGH-BUILD GLAZE COATINGS

DIVISION 10 - SPECIALTIES

10 14 00.10 EXTERIOR SIGNAGE

10 14 00.20 INTERIOR SIGNAGE

10 14 53 TRAFFIC SIGNAGE

10 26 00 WALL AND DOOR PROTECTION

10 28 13 TOILET ACCESSORIES

10 44 16 FIRE EXTINGUISHERS

DIVISION 12 - FURNISHINGS

12 21 00 WINDOW BLINDS

12 48 13 ENTRANCE FLOOR MATS AND FRAMES

DIVISION 13 - SPECIAL CONSTRUCTION

13 12 50 PRE-ENGINEERED METAL CANOPY

13 34 19.02 METAL MAIL FACILITY BUILDING SYSTEMS

13 34 19.03 METAL COMMUNICATIONS HUT SYSTEMS

13 34 23 PREENGINEERED GUARD BOOTH AND OVERWATCH STRUCTURES

13 48 00 SEISMIC PROTECTION FOR MISCELLANEOUS EQUIPMENT

DIVISION 22 - PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 00 00 AIR SUPPLY, DISTRIBUTION, VENTILATION, AND EXHAUST SYSTEMS

23 05 48.19 SEISMIC BRACING FOR HVAC

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 81 00.00 20 UNITARY AIR CONDITIONING EQUIPMENT

DIVISION 25 - INTEGRATED AUTOMATION

25 05 11 CYBERSECURITY FOR FACILITY-RELATED CONTROL SYSTEMS

DIVISION 26 - ELECTRICAL

26 05 48.00 10 SEISMIC PROTECTION FOR ELECTRICAL EQUIPMENT

26 08 00 APPARATUS INSPECTION AND TESTING

26 12 19.10 THREE-PHASE PAD-MOUNTED TRANSFORMERS

26 13 01 PAD-MOUNTED DEAD-FRONT AIR INSULATED SWITCHGEAR

26 20 00 INTERIOR DISTRIBUTION SYSTEM

00 01 00 - 4 PROJECT TABLE OF CONTENTS

26 28 01.00 10 COORDINATED POWER SYSTEM PROTECTION WITH ARC FLASH

26 32 14.00 10 DIESEL-GENERATOR SET, STATIONARY 15-300 KW, STANDBY APPLICATIONS

26 32 33.00 10 STATIC UNINTERRUPTIBLE POWER SUPPLY (UPS)

26 36 00.00 10 AUTOMATIC TRANSFER SWITCHES

26 42 14.00 10 CATHODIC PROTECTION SYSTEM (SACRIFICIAL ANODE)

26 51 00 INTERIOR LIGHTING

26 56 00 EXTERIOR LIGHTING

DIVISION 27 - COMMUNICATIONS

27 10 00 BUILDING TELECOMMUNICATIONS CABLING SYSTEM

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 10 05 ELECTRONIC SECURITY SYSTEMS (ESS)

28 31 76 INTERIOR FIRE ALARM AND MASS NOTIFICATION SYSTEM

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

31 05 19 GEOTEXTILE

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 01 16.17 COLD MILLING ASPHALT PAVING

32 01 19 FIELD MOLDED SEALANTS FOR SEALING JOINTS IN RIGID PAVEMENTS

32 05 33 LANDSCAPE ESTABLISHMENT

32 11 20 SUBBASES FOR FLEXIBLE PAVING

32 11 23 AGGREGATE BASE COURSES

32 12 13 BITUMINOUS TACK COATS

32 12 16 HOT-MIX ASPHALT (HMA) FOR ROADS

32 13 13.06 PORTLAND CEMENT CONCRETE PAVEMENT FOR ROADS AND SITE FACILITIES

32 16 19 CONCRETE CURBS, GUTTERS AND SIDEWALKS

32 17 23 PAVEMENT MARKINGS

32 31 13 CHAIN LINK FENCES AND GATES

32 92 19 SEEDING

DIVISION 33 - UTILITIES

33 11 00 WATER UTILITY DISTRIBUTION PIPING

33 30 00 SANITARY SEWERS

33 40 00 STORM DRAINAGE UTILITIES

33 71 01 OVERHEAD TRANSMISSION AND DISTRIBUTION

33 71 02 UNDERGROUND ELECTRICAL DISTRIBUTION

33 82 00 TELECOMMUNICATIONS OUTSIDE PLANT (OSP)

DIVISION 34 - TRANSPORTATION

34 11 00 RAILROAD TRACK AND ACCESSORIES

34 71 13.19 CRASH RATED ACTIVE VEHICLE BARRIERS AND CONTROLS

34 72 00.00 CABLE-BASED PASSIVE VEHICLE BARRIERS

-- End of Project Table of Contents --

Gate 1 ACP, PN 074877, MOTCO, Concord, CA CA44

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 00 00

GENERAL REQUIREMENTS

05/17

PART 1 GENERAL

1.1 REFERENCES

1.2 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS

CONTRACTS

1.3 SUBMITTALS

1.4 SCRAP MATERIAL

1.5 WRITTEN GUARANTEES AND GUARANTOR'S LOCAL REPRESENTATIVE

1.6 TEMPORARY ELECTRIC WIRING

1.6.1 Temporary Power and Lighting

1.6.2 Construction Equipment

1.6.3 Circuit Protection

1.7 UTILITIES

1.8 PLANNED UTILITY OUTAGES AND STREET CLOSURES

1.9 EXCAVATION PERMITS

1.10 COLOR SCHEME FOR CONTRACTOR FACILITIES

1.11 DAMAGE TO ROADS

1.11.1 Documentation Regarding Potential Damage to Access Routes

1.11.1.1 Preconstruction Access Road Survey

1.11.1.2 Post-Construction Access Road Survey

PART 2 PRODUCTS

2.1 GOVERNMENT FURNISHED MATERIALS

PART 3 EXECUTION

3.1 AFTER AWARD DOCUMENTS

-- End of Section Table of Contents --

SECTION 01 00 00 Page 1

SECTION 01 00 00

GENERAL REQUIREMENTS

05/17

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this section to the extent referenced. The publications are referred to within the text by the basic designation only.

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 70 (2017; ERTA 1-2 2017; TIA 17-1; TIA 17-2;

TIA 17-3; TIA 17-4; TIA 17-5; TIA 17-6;

TIA 17-7; TIA 17-8; TIA 17-9; TIA 17-10;

TIA 17-11; TIA 17-12; TIA 17-13; TIA

17-14; TIA 17-15; TIA 17-16; TIA 17-17 )

National Electrical Code

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety and Health Requirements Manual

1.2 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS CONTRACTS

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS

222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

- U.S. Department of Labor Veterans’ Employment and Training Service (VETS): https://www.dol.gov/vets/

- Federal Veteran Employment Information: https://www.fedshirevets.gov/

- Veterans Opportunity to Work (VOW) Program:

https://www.benefits.va.gov/vow/

- U.S. Army Warrior Transition Command Employment Index:

https://wct.army.mil/modules/employers/index.html

- Hiring Our Heroes:

https://www.uschamberfoundation.org/hiring-our-heroes

1.3 SUBMITTALS

Government approval is required for all submittals with a "G" designation;

submittals not having a designation are for information only. The following must be submitted in accordance with Section 01 33 00 SUBMITTAL

PROCEDURES:

SECTION 01 00 00 Page 2

SD-01 Preconstruction Submittals

Preconstruction Quantity Survey Plan; G

Preconstruction Access Road Survey

Post-construction Access Road Survey

1.4 SCRAP MATERIAL

Materials specified to be removed and become the property of the Contractor are designated as scrap, and the Contractor, by signing this contract, hereby acknowledges that he has made due allowance for value, if any, of such scrap in the contract price.

1.5 WRITTEN GUARANTEES AND GUARANTOR'S LOCAL REPRESENTATIVE

Prior to completion of the contract, obtain and furnish to the Contracting Officer's representative written guarantees for all the equipment and/or appliances furnished under the contract. Furnish with each guarantee: The name, address, and telephone number of the guarantor's representative nearest to the location where the equipment and/or appliances are installed, who, upon request of the Using Service's representative, will honor the guarantee during the guaranty period and will provide the services prescribed by the terms of the guarantee.

1.6 TEMPORARY ELECTRIC WIRING

1.6.1 Temporary Power and Lighting

Provide construction power facilities in accordance with the safety requirements of the NFPA 70 and EM 385-1-1. Enforce all the safety requirements of electrical extensions for the work of all subcontractors.

All work must be accomplished by skilled electrical tradesmen in a workmanlike manner, as approved by the Contracting Officer.

1.6.2 Construction Equipment

In addition to the requirements of EM 385-1-1, all temporary wiring conductors installed for operation of construction tools and equipment must be either Type TW or THW contained in metal raceways, or may be multiconductor cord. Temporary wiring must be secured above the ground or floor in a workmanlike manner and must not present an obstacle to persons or equipment. Open wiring may only be used outside of buildings, and then only in strict accordance with the provisions of the National Electrical Code.

1.6.3 Circuit Protection

In addition to the present requirements in EM 385-1-1 and NFPA 70, all 15 and 20-ampere receptacle outlets used for obtaining power during construction must have ground fault circuit interrupters (GFCI) for personnel protection. Block and brick saws must also be equipped with GFCI. The Contracting Officer may allow an exception to this requirement for circuits for concrete vibrators or circuits operating at other than 60 Hertz normal (in both cases an assured grounding program as described in the NFPA 70, except utilizing the daily inspection frequency of the grounding means of such equipment, may be permitted). The assured grounding program will not be permitted as a substitute for usage of GFCI'S

SECTION 01 00 00 Page 3 except as described above. All generator-powered 15- and 20-ampere, 60 Hertz receptacle outlets must have GFCI'S, and must be properly grounded.

Provide a testing means which will impose a measured fault of 5 milliamperes, plus or minus 1 milliamperes, and result in tripping the GFCI unit.

1.7 UTILITIES

Immediately notify the Contracting Officer in writing if utilities not shown on the plans and not visible as to the date of this contract are encountered within the construction limits of the entire project, and such utilities will interfere with construction operations, to enable a determination by the Contracting Officer as to the necessity for removal or relocation. If such utilities are removed or relocated as directed by the Contracting Officer, an equitable adjustment in the contract price must be made pursuant to the Contract Clause CHANGES to cover the cost of any additional pertinent work or delay.

1.8 PLANNED UTILITY OUTAGES AND STREET CLOSURES

All utility outages and street closures must be of as short a duration as possible and must be scheduled as far in advance as possible with the Contracting Officer, in no case less than 14 days before the outage or closure. Obtain from the Contracting Officer in writing a statement or schedule giving the permissible times of outages or closures for particular installations and the maximum time allowed for each. Strictly observe such schedules and the contractor will be held responsible for any violations.

1.9 EXCAVATION PERMITS

All excavation permits will be issued to the Contractor from the Directorate of Pulic Works (DPW), through the Contracting Officer. The appropriate form, for this request, may be obtained from the Contracting Officer. Processing time required is 14 calendar days. Questions concerning the excavation permit should be directed to the Contracting Officer.

1.10 COLOR SCHEME FOR CONTRACTOR FACILITIES

a. All Contractor storage and operational facilities including temporary structures, signs and fencing, that remain at the site must be compatible with the color scheme used on the project signs as directed by the Contracting Officer.

1.11 DAMAGE TO ROADS

Preserve and protect all existing private or project access or right-of-way roads. At the completion of work and prior to the Contractor leaving the project, he must restore to pre-project conditions all such roads. Repairs must include replacement of base rock and/or surface treatment as required. Refer also to paragraph PROTECTION OF TRAFFIC in section 01 50 00

TEMPORARY CONSTRUCTION FACILITIES.

1.11.1 Documentation Regarding Potential Damage to Access Routes

Preconstruction Quantity Survey Plan stating the names of personnel and license number who will be performing the Preconstruction Access Road Survey and the Post-Construction Access Road Survey. Include the procedures to follow in conducting the surveys.

SECTION 01 00 00 Page 4

1.11.1.1 Preconstruction Access Road Survey

Complete and submit a Preconstruction Access Road Survey including digital video and digital photographs of all public, private, and project access or right-of-way roads before construction begins. Submit two copies of the survey, the digital video, and the digital photographs before the start of construction operations. Video must be digital format. Photographs must be 3 X 5 inch prints.

1.11.1.2 Post-Construction Access Road Survey

After completion of construction of the project, submit a Post-Construction Access Road Survey including digital video and digital photographs of the same area where preconstruction digital video and digital photographs were taken. Submit two copies of the survey, the digital video, and digital photographs.

PART 2 PRODUCTS

2.1 GOVERNMENT FURNISHED MATERIALS

The Government will provide an optical disc at the preconstruction conference that contains the materials specifed in SECTION 01 78 00

CLOSEOUT SUBMITTALS

PART 3 EXECUTION

3.1 AFTER AWARD DOCUMENTS

Provide ten hard copy sets from the CAD contract drawings and specifications. Provide these documents within 5 work days of the NTP.

The hard copy drawings must be ANSI D (22" x 34"), and the specifications must be standard 8-1/2" x 11", 3-hole punched with posts.

-- End of Section --

SECTION 01 00 00 Page 5

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00

SUMMARY OF WORK

08/15

PART 1 GENERAL

1.1 SUBMITTALS

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

1.2.2 Location

1.3 EXISTING WORK

1.4 LOCATION OF UNDERGROUND UTILITIES

1.4.1 Notification Prior to Excavation

1.5 GOVERNMENT-FURNISHED MATERIAL AND EQUIPMENT

1.6 GOVERNMENT-INSTALLED WORK

1.7 SALVAGE MATERIAL AND EQUIPMENT

1.8 CONTRACTOR MANPOWER REPORTING

1.9 PERIOD OF PERFORMANCE

1.10 WAGE DETERMINATION

1.11 PRECONSTRUCTION CONFERENCE

1.12 AUTHORITIES

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 11 00 Page 1

SECTION 01 11 00

SUMMARY OF WORK

08/15

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submittals with an "S" are for inclusion in the Sustainability eNotebook, in conformance with Section 01 33 29 SUSTAINABILITY REPORTING. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Salvage Plan; G, RO

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

The work includes upgraded accesscontrol point (ACP) with 2 - processor Visitor Control Center (VCC), mailfreight facility, new communications hut, new entry and exit lanepavements, ID check islands and lanes, Gatehouse, Guard booths, SearchShelter, ID check canopy, POV/Truck Search Canopy, turnaround(s), Over watch booth, connections to existing perimeter fences, passive and active vehiclebarrier systems, traffic signage and signals, back-up generator, andsupporting facilities including water, sanitary sewer, electrical, storm drainage and information systems.

1.2.2 Location

The work is located at existing Gate #1, Military Ocean Terminal, Concord, California as indicated on the contract drawings.

1.3 EXISTING WORK

In addition to FAR 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements:

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work must be in a condition equal to or better than that which existed before new work started.

1.4 LOCATION OF UNDERGROUND UTILITIES

Obtain digging permits prior to start of excavation, and comply with Installation requirements for locating and marking underground utilities.

SECTION 01 11 00 Page 2

Contact local utility locating service a minimum of 48 hours prior to excavating, to mark utilities, and within sufficient time required if work occurs on a Monday or after a Holiday. Verify existing utility locations indicated on contract drawings, within area of work.

Identify and mark all other utilities not managed and located by the local utility companies. Verify the elevations of existing piping, utilities,and any type of underground or encased obstruction not indicated, or specified to be removed Verify elevations before installing new work closer than nearest manhole or other structure at which an adjustment in grade can be made.

1.4.1 Notification Prior to Excavation

Notify the Contracting Officer at least 48 hours prior to starting excavation work.

1.5 GOVERNMENT-FURNISHED MATERIAL AND EQUIPMENT

There is no Government furnished materials or equipment for installation by the Contractor.

1.6 GOVERNMENT-INSTALLED WORK

There is no Government-Installed work.

1.7 SALVAGE MATERIAL AND EQUIPMENT

Items designated by the Contracting Officer to be salvaged remain the property of the Government. Segregate, itemize, deliver and off-load the salvaged property at the Government designated storage area located on the installation.

Provide a salvage plan, listing material and equipment to be salvaged, and their storage location. Maintain property control records for material or equipment designated as salvage. Use a system of property control that is approved by the Contracting Officer. Store and protect salvaged materials and equipment until disposition by the Contracting Officer.

1.8 CONTRACTOR MANPOWER REPORTING

The Office of the Assistant Secretary of the Army (Manpower & Reserve Affairs) operates and maintains a secure Army data collection site where the contractor will report ALL contractor manpower (including subcontractor manpower) required for performance of this contract. The Contractor shall verify information input by the Government and completely fill in all other required fields in the reporting system using the following web address:

https://cmra.army.mil/.

The required information includes but is not limited to: (1) Contracting Organization, Contracting Officer, Contracting Officer's Technical Representative (COR/COTR); (2) Contract number, including task and delivery order number; (3) Fiscal year covered by reporting period; (4) Contractor name, address, phone number, e-mail address, identity of contractor employee entering data; (5) Direct labor hours (including Subcontractors);

(6) Direct labor dollars paid this reporting period (including Subcontractors); (7) Total invoiced amount (including Subcontractors); (8) Predominant Federal Service Code (FSC) reflecting services provided by Contractor (and separate predominant FSC for each Subcontractor if

SECTION 01 11 00 Page 3 different); (9) Organizational title associated with the Unit Identification Code (UIC) for the Army Requiring Activity (the Army Requiring Activity is responsible for providing the contractor with its UIC for the purposes of reporting this information; and (10) Locations where Contractor and Subcontractors perform the work (specified by zip code in the United States and nearest city, country, when in an overseas location, using standardized nomenclature provided on website). As part of its submission, the Contractor will also provide the estimated total cost (if any) incurred to comply with this reporting requirement.

Reporting period will be the period of performance not to exceed 12 months ending September 30 of each Government fiscal year and must be reported by 31 October of each calendar year. Contractors may use a direct XML data transfer to the database server or fill in the fields on the website. The XML direct transfer is a format for transferring files from a Contractor's systems to the secure website without the need for separate data entries for each required data element at the website. The specific formats for the XML direct transfer may be downloaded from the website. Information from the secure website is considered to be proprietary in nature when the contract number and Contractor identity are associated with the direct labor hours and direct labor dollars. At no time will any data be released to the public with the Contractor name and contract number associated with the data. For internal Army analysis, the reports and queries from the database shall not contain proprietary data.

1.9 PERIOD OF PERFORMANCE

The time duration of performance period is 450 calendar days after Notice to Proceed date

1.10 WAGE DETERMINATION

General Decision Number CA190018, dated 05/03/2019, Contra Costa County, in the State of California, or its most current modification at the time of award are hereby applicable to work performed under this contract. The most current decision or its modification can be found by clicking on hyperlink http://www.wdol.gov/dba.aspx for such information.

https://www.wdol.gov/wdol/scafiles/davisbacon/CA18.dvb?v=3

1.11 PRECONSTRUCTION CONFERENCE

Prior to the initiation of work, a meeting will be held with the Contractor and USACE to discuss matters of mutual interest concerning the contract.

General conditions, work schedule, phasing and coordination, security, safety, permits, and other matters pertinent to work accomplishments will be discussed in this meeting.

1.12 AUTHORITIES

Only a warranted Contracting Officer (either PCO or ACO) acting within his or her delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer.

SECTION 01 11 00 Page 4

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

SECTION 01 11 00 Page 5

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 14 00

WORK RESTRICTIONS

PART 1 GENERAL

1.1 SPECIAL SCHEDULING REQUIREMENTS

1.2 SUBMITTALS

1.3 CONTRACTOR ACCESS AND USE OF PREMISES

1.3.1 Activity Regulations

1.3.1.1 Subcontractors and Personnel Contacts

1.3.1.2 Identification Badges and Installation Access

1.3.1.3 Employee List

1.3.1.4 No Smoking Policy

1.3.2 Working Hours

1.3.3 Work Outside Regular Hours

1.4 SECURITY REQUIREMENTS

1.4.1 Employment Restrictions

1.4.1.1 Personnel List

1.5 OTHER REQUIREMENTS

1.5.1 Vehicle Searches

1.5.2 Photographs

1.5.3 Personnel Restrictions

1.6 WORK SUSPENSION

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 14 00 Page 1

SECTION 01 14 00

WORK RESTRICTIONS

PART 1 GENERAL

1.1 SPECIAL SCHEDULING REQUIREMENTS

a. Pier 3 will be in operation during the entire construction period. The Contractor shall conduct his operations so as to cause the least possible interference with other normal operations of the activity.

Contractor cannot perform work on the pier while a ship is at port conducting a mission. Refer to Paragraph 1.5 of this section.

b. Permission to interrupt any Activity roads, railroads, and/or utility service shall be requested in writing a minimum of 15 calendar days prior to the desired date of interruption.

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

Government acceptance is required for submittals with a "G" designation.

SD-01 Preconstruction Submittals

Personnel List; G list of contact personnel; G

1.3 CONTRACTOR ACCESS AND USE OF PREMISES

1.3.1 Activity Regulations

Ensure that Contractor personnel employed on the Activity become familiar with and obey Activity regulations including safety, fire, traffic and security regulations. Keep within the limits of the work and avenues of ingress and egress. Wear hard hats in designated areas. Do not enter any restricted areas unless required to do so and until cleared for such entry. The Contractor's equipment shall be conspicuously marked for identification.

1.3.1.1 Subcontractors and Personnel Contacts

Furnish a list of contact personnel of the Contractor and subcontractors including addresses and telephone numbers for use in the event of an emergency. As changes occur and additional information becomes available, correct and change the information contained in previous lists.

1.3.1.2 Identification Badges and Installation Access

Application for and use of badges will be as directed.

SECTION 01 14 00 Page 2

1.3.1.3 Employee List

The Contractor shall provide to the Contracting officer, in writing, the names of employees and subcontractor's employees prior to commencement of work who will work and will require identification badges and installation access under this contract.

1.3.1.4 No Smoking Policy

Except in designated smoking areas. This applies to existing buildings, buildings under construction and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. MOTCO DPW will identify designated smoking areas.

1.3.2 Working Hours

Regular working hours shall consist of an 8 1/2 hour period established by the Contracting Officer Monday through Friday.

1.3.3 Work Outside Regular Hours

a. Work outside regular working hours requires Contracting Officer approval. Make application 15 calendar days prior to such work to allow arrangements to be made by the Government for inspecting the work in progress, giving the specific dates, hours, location, type of work to be performed.

b. Contractor may be allowed to work longer hours and more than five days per week subject to Contracting Officer's approval.

1.4 SECURITY REQUIREMENTS

1.4.1 Employment Restrictions

MOTCO is designated as a restricted area in accordance with Army Regulation 190-13, "The Army Physical Security Program" (AR 190-13). As required by paragraph 6-2 of AR 190-13, as well as Homeland Security Presidential Directive (HSPD)-12, Directive-Type Memorandum 09-012, and Army Execution Order (EXORD) 033-15, the MOTCO Installation Commander has restricted MOTCO access to U.S. citizens conducting official business at MOTCO.

Consequently any employee or invitee of the Contractor and any employee or invitee of each subcontractor who is not a United States citizen shall be denied access to the MOTCO installation.

1.4.1.1 Personnel List

Submit for approval, at least 15 days prior to the desired date of entry, an original alphabetical list of personnel who require entry into Government property to perform work on the project. Furnish for each person:

a. Name

b. Date and place of birth

c. Citizenship

d. Home address

SECTION 01 14 00 Page 3

e. Social security number

f. Naturalization number

g. Passport number, place of issue, and expiration date

The request for personnel passes shall be accompanied with the following certification:

"I hereby certify that all personnel on this list are either 1) born U.S.

citizens or 2) naturalized U.S. citizens with the naturalization number shown."

Signature/Firm Name

1.5 OTHER REQUIREMENTS

The Contract Clause entitled "Identification of Employees" and the following apply:

1.5.1 Vehicle Searches

All contractor's vehicles including privately-owned employee's vehicles and construction vehicles will be subject to search by the Facility Security.

1.5.2 Photographs

Photographs are prohibited in and around the Facility unless a written request containing specific justification and details is approved by the security officer via the Contracting Officer. Seven (7) days' advance notice is required to obtain a photo permit.

1.5.3 Personnel Restrictions

Due to sensitivity of Facility operations, the following apply:

a. Restrict personnel to the designated work site.

b. Contractor's movements within the MOTCO will be restricted.

Contractor personnel will be escorted to and from designated work areas. Contractor personnel shall not be permitted outside of designated work areas without being escorted by authorized personnel.

1.6 WORK SUSPENSION

The work and contractor's activity on site may be suspended upon notice by the Contracting Officer given to the Contractor. Normally such suspensions are the result of scheduled mission requirements and are known well in advance.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 14 00 Page 4

SECTION 01 14 00 Page 5

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 30 00

ADMINISTRATIVE REQUIREMENTS

08/15

PART 1 GENERAL

1.1 REFERENCES

1.2 SUBMITTALS

1.3 VIEW LOCATION MAP

1.4 MINIMUM INSURANCE REQUIREMENTS

1.5 FIRST TIER CONTRACTOR REQUIREMENTS FOR ASBESTOS CONTAINING MATERIALS

1.6 SUPERVISION

1.6.1 Minimum Communication Requirements

1.6.2 Superintendent Qualifications

1.6.2.1 Duties

1.6.3 Non-Compliance Actions

1.7 PRECONSTRUCTION CONFERENCE

1.8 PARTNERING

1.8.1 Informal Partnering

1.9 ELECTRONIC MAIL (E-MAIL) ADDRESS

1.10 SCRAP MATERIAL

1.11 WRITTEN GUARANTEES AND GUARANTOR'S LOCAL REPRESENTATIVE

1.12 TEMPORARY ELECTRIC WIRING

1.12.1 Temporary Power and Lighting

1.12.2 Construction Equipment

1.12.3 Circuit Protection

1.13 UTILITIES

1.14 PLANNED UTILITY OUTAGES AND STREET CLOSURES

1.15 EXCAVATION PERMITS

1.16 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.17 COLOR SCHEME FOR CONTRACTOR FACILITIES

1.18 DAMAGE TO ROADS

1.18.1 Documentation Regarding Potential Damage to Access Routes

1.18.1.1 Preconstruction Access Road Survey

1.18.1.2 Post-Construction Access Road Survey

PART 2 PRODUCTS

2.1 GOVERNMENT FURNISHED MATERIALS

PART 3 EXECUTION

3.1 AFTER AWARD DOCUMENTS

SECTION 01 30 00 Page 1

SECTION 01 30 00

ADMINISTRATIVE REQUIREMENTS

08/15

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 70 (2017; ERTA 1-2 2017; TIA 17-1; TIA 17-2;

TIA 17-3; TIA 17-4; TIA 17-5; TIA 17-6;

TIA 17-7; TIA 17-8; TIA 17-9; TIA 17-10;

TIA 17-11; TIA 17-12; TIA 17-13; TIA

17-14; TIA 17-15; TIA 17-16; TIA 17-17 )

National Electrical Code

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety and Health Requirements Manual

ER 415-1-15 (1989) Construction Time Extensions for Weather

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

View Location Map; G, RO

Preconstruction Quantity Survey Plan; G-RO

Preconstruction Access Road Survey

Post-construction Access Road Survey

1.3 VIEW LOCATION MAP

Submit, prior to or with the first digital photograph submittals, a sketch or drawing indicating the required photographic locations. Update as required if the locations are moved.

1.4 MINIMUM INSURANCE REQUIREMENTS

Provide the minimum insurance coverage required by FAR 28.307-2 Liability, SECTION 01 30 00 Page 2 during the entire period of performance under this contract. Provide other insurance coverage as required by Californialaw.

1.5 FIRST TIER CONTRACTOR REQUIREMENTS FOR ASBESTOS CONTAINING MATERIALS

Accomplish all contract requirements of Section 02 82 00 ASBESTOS REMEDIATION, assigned to the Designated Competent Person, directly with a first tier subcontractor.

1.6 SUPERVISION

1.6.1 Minimum Communication Requirements

Have at least one qualified superintendent, or competent alternate, capable of reading, writing, and conversing fluently in the English language, on the job-site at all times during the performance of contract work. In addition, if a Quality Control (QC) representative is required on the contract, then that individual must also have fluent English communication skills.

1.6.2 Superintendent Qualifications

The project superintendent must have a minimum of 10 years experience in construction with at least 5 of those years as a superintendent on projects similar in size and complexity. The individual must be familiar with the requirements of EM 385-1-1 and have experience in the areas of hazard identification and safety compliance. The individual must be capable of interpreting a critical path schedule and construction drawings. The qualification requirements for the alternate superintendent are the same as for the project superintendent. The Contracting Officer may request proof of the superintendent's qualifications at any point in the project if the performance of the superintendent is in question.

1.6.2.1 Duties

The project superintendent is primarily responsible for managing and coordinating day-to-day production and schedule adherence on the project.

The superintendent is required to attend partnering meetings, and quality control meetings. The superintendent or qualified alternative must be on-site at all times during the performance of this contract until the work is completed and accepted.

1.6.3 Non-Compliance Actions

The Project Superintendent is subject to removal by the Contracting Officer for non-compliance with requirements specified in the contract and for failure to manage the project to insure timely completion. Furthermore, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. No part of the time lost due to such stop orders is acceptable as the subject of claim for extension of time for excess costs or damages by the Contractor.

1.7 PRECONSTRUCTION CONFERENCE

After award of the contract but prior to commencement of any work at the site, meet with the Contracting Officer to discuss and develop a mutual understanding relative to the administration of the value engineering and safety program, preparation of the schedule of prices or earned value report, shop drawings, and other submittals, scheduling programming, SECTION 01 30 00 Page 3 prosecution of the work, and clear expectations of the "Interim DD Form 1354" Submittal. Major subcontractors who will engage in the work must also attend.

1.8 PARTNERING

To most effectively accomplish this contract, the Government requires the formation of a cohesive partnership within the Project Team whose members are from the Government, the Contractor and their Subcontractors. Key personnel from the Supported Command, the End User (who will occupy the facility), the Government Design and Construction team and Subject Matter Experts, the Installation, the Contractor and Subcontractors, and the Designer of Record will be invited to participate in the Partnering process. The Partnership will draw on the strength of each organization in an effort to achieve a project that is without any safety mishaps, conforms to the Contract, and stays within budget and on schedule.

The Contracting Officer will provide Information on the Partnering Process and a list of key and optional personnel who should attend the Partnering meeting.

1.8.1 Informal Partnering

The Contracting Officer will organize the Partnering Sessions with key personnel of the project team, including Contractor personnel and Government personnel.

The Initial Partnering session should be a part of the Pre-Construction Meeting. Partnering sessions will be held at a location agreed to by the Contracting Officer and the Contractor (typically a conference room provided by the Resident Engineer office or the Contractor). The Initial Informal Partnering Session will be conducted and facilitated using electronic media (a video and accompanying forms) provided by the Contracting Officer. The Partners will determine the frequency of the follow-on sessions, at no more than 3 to six month intervals.

1.9 ELECTRONIC MAIL (E-MAIL) ADDRESS

Establish and maintain electronic mail (e-mail) capability along with the capability to open various electronic attachments as text files, pdf files, and other similar formats. Within 10 days after contract award, provide the Contracting Officer a single (only one) e-mail address for electronic communications from the Contracting Officer related to this contract including, but not limited to contract documents, invoice information, request for proposals, and other correspondence. The Contracting Officer may also use email to notify the Contractor of base access conditions when emergency conditions warrant, such as hurricanes or terrorist threats.

Multiple email addresses are not allowed.

It is the Contractor's responsibility to make timely distribution of all Contracting Officer initiated e-mail with its own organization including field office(s). Promptly notify the Contracting Officer, in writing, of any changes to this email address.

1.10 SCRAP MATERIAL

Materials specified to be removed and become the property of the Contractor are designated as scrap, and the Contractor, by signing this contract, SECTION 01 30 00 Page 4 hereby acknowledges that he has made due allowance for value, if any, of such scrap in the contract price.

1.11 WRITTEN GUARANTEES AND GUARANTOR'S LOCAL REPRESENTATIVE

Prior to completion of the contract, obtain and furnish to the Contracting Officer's representative written guarantees for all the equipment and/or appliances furnished under the contract. Furnish with each guarantee: The name, address, and telephone number of the guarantor's representative nearest to the location where the equipment and/or appliances are installed, who, upon request of the Using Service's representative, will honor the guarantee during the guaranty period and will provide the services prescribed by the terms of the guarantee.

1.12 TEMPORARY ELECTRIC WIRING

1.12.1 Temporary Power and Lighting

Provide construction power facilities in accordance with the safety requirements of the NFPA 70 and EM 385-1-1. Enforce all the safety requirements of electrical extensions for the work of all subcontractors.

All work must be accomplished by skilled electrical tradesmen in a workmanlike manner, as approved by the Contracting Officer.

1.12.2 Construction Equipment

In addition to the requirements of EM 385-1-1, all temporary wiring conductors installed for operation of construction tools and equipment must be either Type TW or THW contained in metal raceways, or may be multiconductor cord. Temporary wiring must be secured above the ground or floor in a workmanlike manner and must not present an obstacle to persons or equipment. Open wiring may only be used outside of buildings, and then only in strict accordance with the provisions of the National Electrical Code.

1.12.3 Circuit Protection

In addition to the present requirements in EM 385-1-1 and NFPA 70, all 15 and 20-ampere receptacle outlets used for obtaining power during construction must have ground fault circuit interrupters (GFCI) for personnel protection. Block and brick saws must also be equipped with GFCI. The Contracting Officer may allow an exception to this requirement for circuits for concrete vibrators or circuits operating at other than 60 Hertz normal (in both cases an assured grounding program as described in the NFPA 70, except utilizing the daily inspection frequency of the grounding means of such equipment, may be permitted). The assured grounding program will not be permitted as a substitute for usage of GFCI'S except as described above. All generator-powered 15- and 20-ampere, 60 Hertz receptacle outlets must have GFCI'S, and must be properly grounded.

Provide a testing means which will impose a measured fault of 5 milliamperes, plus or minus 1 milliamperes, and result in tripping the GFCI unit.

1.13 UTILITIES

Immediately notify the Contracting Officer in writing if utilities not shown on the plans and not visible as to the date of this contract are encountered within the construction limits of the entire project, and such utilities will interfere with construction operations, to enable a

SECTION 01 30 00 Page 5 determination by the Contracting Officer as to the necessity for removal or relocation. If such utilities are removed or relocated as directed by the Contracting Officer, an equitable adjustment in the contract price must be made pursuant to the Contract Clause CHANGES to cover the cost of any additional pertinent work or delay.

1.14 PLANNED UTILITY OUTAGES AND STREET CLOSURES

All utility outages and street closures must be of as short a duration as possible and must be scheduled as far in advance as possible with the Contracting Officer, in no case less than 30 days before the outage or closure. Obtain from the Contracting Officer in writing a statement or schedule giving the permissible times of outages or closures for particular installations and the maximum time allowed for each. Strictly observe such schedules and the contractor will be held responsible for any violations.

1.15 EXCAVATION PERMITS

All excavation permits will be issued to the Contractor from the Directorate of Pulic Works (DPW), through the Contracting Officer. The appropriate form, for this request, may be obtained from the Contracting Officer. Processing time required is 30 calendar days. Questions concerning the excavation permit should be directed to the Contracting Officer.

1.16 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Default: (Fixed-Price Construction)." In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(06) (05) (05) (04) (01) (00) (00) (00) (01) (02) (05) (06)

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the RMS daily CQC report, any occurrence of adverse weather and resultant impact to normally scheduled work, within 24 hours of the event. Actual adverse weather delay

SECTION 01 30 00 Page 6 days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day. Describe in the RMS daily CQC reports the critical path item that is being affected and provide the critical path activity number(s) from the current schedule. The COR must acknowledge and accept the agreed upon occurrence of each adverse weather delay in RMS for the delays to be considered as adverse weather delays.

At the end of each month, identify the number of actual adverse weather delay days that includes days impacted by actual adverse weather (even if adverse weather occurred in previous month), calculated chronologically from the first to the last day of each month, and recorded as full days.

If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph b. above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Default (Fixed Price Construction)". (ER 415-1-15)

1.17 COLOR SCHEME FOR CONTRACTOR FACILITIES

a. All Contractor storage and operational facilities including temporary structures, signs and fencing, that remain at the site must be compatible with the color scheme used on the project signs as directed by the Contracting Officer.

1.18 DAMAGE TO ROADS

Preserve and protect all existing private or project access or right-of-way roads. At the completion of work and prior to the Contractor leaving the project, he must restore to pre-project conditions all such roads. Repairs must include replacement of base rock and/or surface treatment as required. Refer also to paragraph PROTECTION OF TRAFFIC in section 01 50 00

TEMPORARY CONSTRUCTION FACILITIES.

1.18.1 Documentation Regarding Potential Damage to Access Routes

Preconstruction Quantity Survey Plan stating the names of personnel and license number who will be performing the Preconstruction Access Road Survey and the Post-Construction Access Road Survey. Include the procedures to follow in conducting the surveys.

1.18.1.1 Preconstruction Access Road Survey

Complete and submit a Preconstruction Access Road Survey including digital video and digital photographs of all public, private, and project access or right-of-way roads before construction begins. Submit two copies of the survey, the digital video, and the digital photographs before the start of construction operations. Video must be digital format. Photographs must be 3 X 5 inch prints.

1.18.1.2 Post-Construction Access Road Survey

After completion of construction of the project, submit a Post-Construction Access Road Survey including digital video and digital photographs of the same area where preconstruction digital video and digital photographs were taken. Submit two copies of the survey, the digital video, and digital photographs.

SECTION 01 30 00 Page 7

PART 2 PRODUCTS

2.1 GOVERNMENT FURNISHED MATERIALS

The Government will provide an optical disc at the preconstruction conference that contains the materials specifed in SECTION 01 78 00

CLOSEOUT SUBMITTALS

PART 3 EXECUTION

3.1 AFTER AWARD DOCUMENTS

Provide two hard copy sets from the CAD contract drawings and specifications. Provide these documents within 5 work days of the NTP.

The hard copy drawings must be 1 full size ANSI D (22" x 34") and one half size (11" X 17"), and the specifications must be standard 8-1/2" x 11", 3-hole punched with posts.

SECTION 01 30 00 Page 8

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 32 01

PROJECT SCHEDULE

02/15

PART 1 GENERAL

1.1 REFERENCES

1.2 SUBMITTALS

1.3 PROJECT SCHEDULER QUALIFICATIONS

PART 2 PRODUCTS

2.1 SOFTWARE

2.1.1 Government Default Software

2.1.2 Contractor Software

2.1.2.1 Primavera

2.1.2.2 Other Than Primavera

PART 3 EXECUTION

3.1 GENERAL REQUIREMENTS

3.1.1 Schedule Status Reports

3.1.2 Default Terms

3.2 BASIS FOR PAYMENT AND COST LOADING

3.2.1 Activity Cost Loading

3.2.2 Withholdings / Payment Rejection

3.3 PROJECT SCHEDULE DETAILED REQUIREMENTS

3.3.1 Level of Detail Required

3.3.2 Activity Durations

3.3.3 Procurement Activities

3.3.4 Mandatory Tasks

3.3.5 Government Activities

3.3.6 Standard Activity Coding Dictionary

3.3.6.1 Workers Per Day (WRKP)

3.3.6.2 Responsible Party Coding (RESP)

3.3.6.3 Area…