Solicitation_-_AG-82A7-S-17-0051.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

JOB CORPS AQM

USDA FOREST SERVICE

740 SIMMS STREET

GOLDEN CO 80401

82A7

BRIAN MCCABE 303-275-5305

1x 04/20/2017

AG-82A7-S-17-0051

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

Scope of Work

Terms and Conditions

Attachment 1 - Project Specification - Culinary Arts Buildout

Attachment 2 - Drawings - Culinary Arts Buildout

Attachment 3 - Projects Specifications - Misc. Building Exterior Repairs

Attachment 4 - Drawings - Misc. Building Exterior Repairs

Attachment 5 - Project Specifications and Drawings - Fire Detection System

Attachment 6 - Walk-In Refrigerator and Freezer Specifications

Attachment 7 - DB - Pine Knot - Residential

Attachment 8 - DB - Pine Knot - Building

Attachment 9 - Proposal Submission Package (to be deleted at Award)

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 240 calendar days and complete it within ________________ ________________ calendar days after receiving

05/22/2017

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

JOB CORPS AQM

USDA FOREST SERVICE

740 SIMMS STREET

GOLDEN CO 80401

82A7

BRIAN N. MCCABE

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 70

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

AG-82A7-S-17-0051

Miscellaneous Construction/CRA Project - Pine

Knot Job Corps Center

Delivery: 240 Days After Notice to Proceed

FOB: Destination

001 Culinary Arts Build Out - Utilities

002 Culinary Arts Build Out - Mechanical, Electrical and Plumbing (MEP)

(Option Line Item)

003 Culinary Arts Build Out - Building Finishes

(Option Line Item)

004 Culinary Arts Build Out - Exterior Construction

(Option Line Item)

005 Miscellaneous Building Exterior Repairs - Masonry and Window Work - Culinary

006 Miscellaneous Building Exterior Repairs -

Roofing, Soffit and Fascia Work - Culinary

007 Miscellaneous Building Exterior Repairs - 5 EA

Sheathing (estimated quantity) - Culinary

008 Miscellaneous Building Exterior Repairs - Roofing

Work - Education

009 Miscellaneous Building Exterior Repairs - 5 EA

Sheathing (estimated quantity) - Education

010 Miscellaneous Building Exterior Repairs - Gutter and Downspout Installation - Culinary

(Option Line Item)

011 Miscellaneous Building Exterior Repairs - Roofing

Continued ...

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

4 70

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

AG-82A7-S-17-0051

Work - Female Dormitory

(Option Line Item)

012 Miscellaneous Building Exterior Repairs - 5 EA

Sheathing (estimated quantity) - Female Dormitory

(Option Line Item)

013 Fire Detection Systems Replacement - Building 9

Center Maintenance (Voc Admin) Fire Alarm

014 Fire Detection Systems Replacement - Building 14

Gym Fire Alarm

015 Fire Detection Systems Replacement - Building 57

King Hall Dorm Fire Alarm

016 Fire Detection Systems Replacement - Building 59

Perkins Hall Dorm Fire Alarm

017 Fire Detection Systems Replacement - Building 60

Washington Hall Dorm Fire Alarm

018 Fire Detection Systems Replacement - Building 74

Urban Forestry Fire Alarm

019 Fire Detection Systems Replacement - Building 76

Student Activity Center Fire Alarm

020 Fire Detection Systems Replacement - Building 75

Dispensary (Wellness Center) Fire Alarm

(Option Line Item)

021 Fire Detection Systems Replacement - Building 66

Computer Tech Classroom (First Floor of Vocation

Building) Fire Alarm

(Option Line Item)

Continued ...

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

5 70

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

AG-82A7-S-17-0051

022 Walk-In Refrigerator Replacement

023 Walk-In Freezer Replacement

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED

AG-82A7-S-17-0051

PAGE OF

6 | 70

TABLE OF CONTENTS

SECTION DESCRIPTION PAGE

PART I – The Schedule A Solicitation/Contract Form 1 B Supplies/Services and Prices 10 C Descriptions/Specifications/Statement of Work 13 D Packaging and Marking 27 E Inspection and Acceptance 28

52.246-12 Inspection of Construction 452.246-70 Inspection and Acceptance--Alternate I

F Deliveries or Performance 29 52.242-14 Suspension of Work 52.211-10 Commencement, Prosecution, and Completion of Work

G Contract Administration Data 30 H Special Contract Requirements 36

Special Clause 1: Option for Additional Services—Separately Priced Line Items Special Clause 2: Key Personnel Special Clause 3: Release of Claims Special Clause 4: Reporting Alleged Child Abuse AGAR 452.228-71 – Insurance Coverage

PART II – Contract Clauses I Contract Clauses 38

452.211-72 Statement of Work/Specifications 452.232-70 Reimbursement for Bond Premiums—Fixed-Price Construction Contracts 452.234-72 Use of Premises 452.236-76 Samples and Certificates 452.236-77 Emergency Response 52.202-1 Definitions 52.203-3 Gratuities 52.203-5 Covenant Against Contingent Fees 52.203-6 Restrictions on Subcontractor Sales to the Government 52.203-7 Anti-Kickback Procedures 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity 52.203-10 Price or Fee Adjustment for Illegal or Improper Activity 52.203-12 Limitation on Payments to Influence Certain Federal Transactions 52.203-17 Contractor Employee Whistleblower Rights and Requirement to Inform Employees of Whistleblower Rights 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper 52.204-9 Personal Identity Verification of Contractor Personnel 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards 52.204-13 System for Award Management Maintenance 52.204-18 Commercial and Government Entity Code Maintenance 52.204-19 Incorporation by Reference of Representations and Certifications 52.209-6 Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment 52.209-10 Prohibition on Contracting with Inverted Domestic Corporations

AG-82A7-S-17-0051

7 | 70

52.215-2 Audit and Records—Negotiation 52.215-8 Order of Precedence—Uniform Contract Format 52.215-17 Waiver of Facilities Capital Cost of Money 52.219-6 Notice of Total Small Business Set-Aside 52.219-8 Utilization of Small Business Concerns 52.219-28 Post-Award Small Business Program Rerepresentation 52.222-3 Convict Labor 52.222-4 Contract Work Hours and Safety Standards—Overtime Compensation 52.222-6 Construction Wage Rate Requirements 52.222-7 Withholding of Funds 52.222-8 Payrolls and Basic Records 52.222-9 Apprentices and Trainees 52.222-10 Compliance with Copeland Act Requirements 52.222-11 Subcontracts (Labor Standards) 52.222-12 Contract Termination—Debarment 52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations 52.222-14 Disputes Concerning Labor Standards 52.222-15 Certification of Eligibility 52.222-20 Contracts for Materials, Supplies, Articles, and Equipment Exceeding $15,000 52.222-21 Prohibition of Segregated Facilities 52.222-26 Equal Opportunity 52.222-27 Affirmative Action Compliance Requirements for Construction 52.222-35 Equal Opportunity for Veterans 52.222-36 Equal Opportunity for Workers with Disabilities 52.222-37 Employment Reports on Veterans 52.222-40 Notification of Employee Rights Under the National Labor Relations Act 52.222-50 Combating Trafficking in Persons 52.222-54 Employment Eligibility Verification 52.222-55 Minimum Wages Under Executive Order 13658 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts 52.223-3 Hazardous Material Identification and Material Safety Data—Alternate I 52.223-5 Pollution Prevention and Right-to-Know Information 52.223-6 Drug-Free Workplace 52.223-11 Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons 52.223-12 Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners 52.223-15 Energy Efficiency in Energy-Consuming Products 52.223-17 Affirmative Procurement of EPA-designated Items in Service and Construction Contracts 52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving 52.223-20 Aerosols 52.223-21 Foams 52.225-13 Restrictions on Certain Foreign Purchases 52.227-1 Authorization and Consent 52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement 52.227-4 Patent Indemnity—Construction Contracts 52.228-2 Additional Bond Security 52.228-5 Insurance—Work on a Government Installation 52.228-11 Pledges of Assets 52.228-12 Prospective Subcontractor Requests for Bonds

AG-82A7-S-17-0051

8 | 70

52.228-14 Irrevocable Letter of Credit 52.228-15 Performance and Payment Bonds—Construction 52.229-3 Federal, State, and Local Taxes 52.232-5 Payments under Fixed-Price Construction Contracts 52.232-17 Interest 52.232-23 Assignment of Claims 52.232-27 Prompt Payment for Construction Contracts 52.232-33 Payment by Electronic Funds Transfer—System for Award Management 52.232-39 Unenforceability of Unauthorized Obligations 52.232-40 Providing Accelerated Payments to Small Business Subcontractors 52.233-1 Disputes—Alternate I 52.233-3 Protest after Award 52.233-4 Applicable Law for Breach of Contract Claim 52.236-2 Differing Site Conditions 52.236-3 Site Investigation and Conditions Affecting the Work 52.236-5 Material and Workmanship 52.236-6 Superintendence by the Contractor 52.236-7 Permits and Responsibilities 52.236-8 Other Contracts 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements 52.236-10 Operations and Storage Areas 52.236-11 Use and Possession Prior to Completion 52.236-12 Cleaning Up 52.236-13 Accident Prevention 52.236-14 Availability and Use of Utility Services 52.236-15 Schedules for Construction Contracts 52.236-21 Specifications and Drawings for Construction 52.236-26 Preconstruction Conference 52.242-13 Bankruptcy 52.243-4 Changes 52.244-6 Subcontracts for Commercial Items 52.245-1 Government Property 52.246-21 Warranty of Construction—Alternate I 52.248-3 Value Engineering—Construction 52.249-2 Termination for Convenience of the Government (Fixed-Price)—Alternate I 52.249-10 Default (Fixed-Price Construction) 52.253-1 Computer Generated Forms 452.204-71 Personal Identify Verification of Contractor Personnel 452.236-75 Maximum Workweek—Construction Schedule 52.225-9 Buy American—Construction Materials 52.252-2 Clauses Incorporated by Reference

PART III – List of Documents, Exhibits, and Other Attachments J List of Attachments 45

PART IV – Representations and Instructions K Representations, Certifications, and Other Statements of Offerors 46

452.204-70 – Inquiries 452.211-6 – Brand Name or Equal

AG-82A7-S-17-0051

9 | 70

452.215-73 – Post Award Conference 452.219-70 – Size Standard and NAICS Code Information 52.203-11 – Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions 52.204-7 System for Award Management 52.204-8 Annual Representations and Certifications 52.204-16 – Commercial and Government Entity Code Reporting 52.204-17 – Ownership or Control or Offeror 52.204-20 – Predecessor of Offeror 52.209-2 – Prohibition on Contracting with Inverted Domestic Corporations - Representations 52.209-5 – Certification Regarding Responsibility Matters 52.211-6 – Brand Name or Equal 52.216-1 – Type of Contract 52.219-1 – Small Business Program Representations 52.222-22 – Previous Contracts and Compliance Reports 52.223-1 – Biobased Product Certification 52.225-20 – Prohibition on Conducting Restricted Business in Sudan - Certification 52.225-25 – Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran – Representations and Certifications

L Instructions, Conditions, and Notices to Offerors 58 Instructions for the Submission of Offers and Other Information 52.211-3 - Availability of Specifications Not Listed in the GSA Index of Federal Specifications, Standards and Commercial Item Descriptions.

52.215-1 – Instructions to Offerors - Competitive 52.215-16 – Facilities Capital Cost of Money 52.215-20 – Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data – Alternate IV 52.217-5 – Evaluation of Options 52.222-5 Construction Wage Rate Requirements—Secondary Site of the Work 52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction 52.222-38 – Compliance with Veterans’ Employment Reporting Requirements 52.225-10 Notice of Buy American Requirement—Construction Materials 52.228-1 Bid Guarantee 52.232-13 – Notice of Progress Payments 52.233-2 Service of Protest 52.236-27 Site Visit (Construction) 52.236-28 Preparation of Proposals—Construction 52.252-1 Solicitation Provisions Incorporated by Reference

M Evaluation Factors for Award 69 Evaluation Factors for Award Special Provision 1: Evaluation of Options

AG-82A7-S-17-0051

10 | 70

PART I - THE SCHEDULE

SECTION B – SUPPLIES OR SERVICES AND PRICES/COSTS

SCHEDULE OF ITEMS

Miscellaneous CRA/Construction Projects Pine Knot Job Corps Center Pine Knot, KY 42635-9999

McCreary County, Kentucky

Item Method of No. Description Measurement Total

BASE ITEM – Culinary Arts Build Out

001 Utilities Lump Sum $

BASE ITEM TOTAL $

OPTIONAL/ADDITVE ITEMS – Culinary Arts Buildout – Subject to Availability of Funding

002 Mechanical, Electrical and Plumbing (MEP) Lump Sum $

003 Building Finishes Lump Sum $

004 Exterior Construction Lump Sum $

BASE AND OPTIONAL/ADDITIVE ITEMS TOTAL $

BASE ITEMS – Miscellaneous Building Exterior Repairs

005 Masonry and Window Work - Culinary Lump Sum $

006 Roof, Soffit and Fascia Work - Culinary Lump Sum $

007 Sheathing (estimated quantity*) Qty - 5 EA $

008 Roofing Work – Education Lump Sum $

009 Sheathing (estimated quantity*) Qty – 5 EA $

BASE ITEM TOTAL $

OPTIONAL/ADDITVE ITEMS – Miscellaneous Building Exterior Repairs – Subject to Availability of Funding

010 Gutter and downspout installation - Lump Sum $ Culinary

011 Roofing work – Female Dormitory Lump Sum $

012 Sheathing (estimated quantity*) Qty – 5 EA $

AG-82A7-S-17-0051

11 | 70

BASE AND OPTIONAL/ADDITIVE ITEMS TOTAL $

BASE ITEMS – Fire Detection Systems Replacement

013 Building 9 Center Maintenance (Voc Lump Sum $ Admin) Fire Alarm

014 Building 14 Gym Fire Alarm Lump Sum $

015 Building 57 King Hall Dorm Fire Alarm Lump Sum $

016 Building 59 Perkins Hall Dorm Fire Alarm Lump Sum $

017 Building 60 Washington Hall Dorm Fire Lump Sum $ Alarm

018 Building 74 Urban Forestry Fire Alarm Lump Sum $

019 Building 76 Student Activity Center Fire Lump Sum $ Alarm

BASE ITEM TOTAL $

OPTIONAL/ADDITIVE ITEM – - Fire Alarm Systems Replacement - Subject to the Availability of Funding

020 Building 75 Dispensary (Wellness Center) Lump Sum $ Fire Alarm

021 Building 66 Computer Tech Classroom (First Lump Sum $ Floor of Vocation Building) Fire Alarm

BASE AND OPTIONAL/ADDITIVE ITEMS TOTAL $

BASE ITEMS – Walk-in Refrigerator/Freezer for Dining Hall

022 Walk-in Refrigerator Replacement Lump Sum $

023 Walk-in Freezer Replacement Lump Sum $

BASE ITEM TOTAL $

TOTAL ALL BASE AND OPTIONAL/ADDITIVE ITEMS $

Lump Sum Quantities: These quantities denote one complete unit of work as required by or described in the contract including necessary materials, equipment, and labor to complete the job. They will not be measured.

AG-82A7-S-17-0051

12 | 70

* Estimated Quantity – Since it is difficult to determine the exact quantity of sheathing that requires replacement until actual roof tear off is executed, the Government established a base estimate of five (5) sheets (32 SQFT per sheet) to establish a fixed price cost per sheet. Contractor shall price up to estimated quantity stated in line items, and shall give a total price per sheet to replace damaged sheathing inclusive of all labor and materials. Should additional sheathing above the estimated quantity need to be replaced once work has begun, the contractor shall provide a cost proposal based on the fixed price cost per sheet provided in proposal that will be used to issue a modification to contract.

FAR 36.204 Disclosure of the magnitude of construction projects (Tailored)

The Government’s estimate is:

Between $100,000 and $260,000 for Base Items Between $100,000 and $1,250,000 for Base and all Optional/Additive Items

AG-82A7-S-17-0051

13 | 70

SECTION C - DESCRIPTION/SPECIFICATION/STATEMENT OF WORK

C.1 INTRODUCTION

Job Corps is a national residential training and employment program administered by the Department of Labor to address the multiple barriers to employment faced by disadvantaged youth throughout the United States. The Economic Opportunity Act of 1964 originally established Job Corps; current authorization for the program is Title I, Chapter 6, Subtitle C, of the Workforce Investment Act of 1998.

C.2 BACKGROUND

Job Corps provides educational and occupational skills training and support services to youth between 16 and not yet 25 years of age. The unique combination of services provided in the Job Corps program is intended to better prepare youth to obtain and hold gainful employment, pursue further education or training, or satisfy entrance requirements for careers in the Armed Forces.

The Workforce Investment Act (WIA) mandates that Job Corps graduates be provided with transition, placement, and support services for one year following initial placement. WIA also requires that the placement status and wages of graduates be measured at six- and twelve-month intervals after the graduates are placed, and that Job Corps operator be evaluated in part on the basis of these performance measures.

The U.S. Department of Agriculture Forest Service operates 26 Job Corps Center nationally, through an interagency agreement with the Department of Labor.

C.3 PURPOSE

The Washington Office (WO) AQM- Job Corps Support Branch as a new requirement for a qualified and licensed general contractor who is capable of performing multiple construction related projects at the Pine Knot Job Corps Center. The contractor must be able to provide all labor, materials, equipment, utilities, incidentals, freight and delivery and all necessary valid licenses and permits for the work provided within this Scope of Work (SOW) (see C.5 Tasks for specific descriptions).

Some of the work identified in the SOW are subject to the availability of funding as stated in Schedule of Items and below in Section C.5 – Tasks, and may or may not be included at time of award, or included later as optional/additive items subject to the availability of funds.

C.4 PLACE OF PERFORMANCE AND HOURS OF OPERATION

All work shall be performed at:

Pine Knot Job Corps Center Highway 27 Pine Knot, KY 42635-9999

Normal operational hours are from 07:30 am to 4:00 PM Eastern Time, Monday through Friday. The maximum workweek that will be approved is 40 hours.

No work shall occur when the Government facility is closed due to local or national emergencies, administrative closings, weather related closings, Federal Holidays, or Government directed facility closings.

AG-82A7-S-17-0051

14 | 70

New Year’s Day – January 1st

Martin Luther King Junior’s Birthday – Third Monday in January President’s Day – Third Monday in February Memorial Day – Last Monday in May Independence Day – July 4th

Labor Day – First Monday in September Columbus Day – Second Monday in October Veteran’s Day – November 11th

Thanksgiving Day – Fourth Thursday in November Christmas Day – December 25th

C.5 TASKS

C.5.1 - Culinary Arts Buildout

Base Item o Utilities – all work shall include all materials, equipment, demolition, labor, mobilization, demobilization and incidentals for the installation of building utilities exterior to the building and up to an accessible termination point within the building/crawlspace; including piping, conduit and conductors, trenching and backfill, lift station, grease trap, gas shutoff valve, CT cabinet, 800 amp disconnect, and junction box, associated concrete paving removal, installation and landscape modification to permit utility installation.

Optional/Additive Items – Subject to Availability of Funding o Mechanical, Electrical and Plumbing (MEP) - all work shall include all materials, equipment, demolition, labor, mobilization, demobilization and incidentals for plumbing, mechanical, and electrical systems in the building, including concrete equipment pads, associated roof curb/flashing and building openings.

o Building Finishes - all work shall include all materials, equipment, demolition, labor, mobilization, demobilization and incidentals to complete building construction including remaining framing, insulation, interior building finishes and equipment, structural elements, exterior doors, and minor brick work.

o Exterior Construction - all work shall include all materials, equipment, demolition, labor, mobilization, demobilization and incidentals for exterior construction items including concrete landings, stairs, railing, fencing, and associated landscape modifications.

C.5.2 Miscellaneous Building Exterior Repairs o Masonry and Window Work - Culinary - all work shall include all materials, equipment, demolition, labor, mobilization, demobilization and incidentals to finish masonry wall on exterior, clean existing masonry, and re-install and flash the windows. Government will furnish bricks, sand and mortar for this project.

o Roofing, Soffit, and Fascia Work - Culinary – all work shall include all materials, equipment, demolition, labor, mobilization, demobilization and incidentals to remove an existing 3,700 square feet of asphalt shingle roof and install new roof and associated accessories.

AG-82A7-S-17-0051

15 | 70 o Roofing Work – Education - all work shall include all materials, equipment, demolition, labor, mobilization, demobilization and incidentals to remove an existing 6,300 square feet of asphalt shingle roof and install new roof and associated accessories.

Optional/Additive Items – Subject to Availability of Funding o Gutter and Downspouts Installation – all work shall include all materials, equipment, demolition, labor, mobilization, demobilization and incidentals to install gutters, downspouts, and associated accessories.

o Roofing Work – Female Dormitory - all work shall include all materials, equipment, demolition, labor, mobilization, demobilization and incidentals to remove an existing 9,000 square feet of asphalt shingle roof and install new roof and associated accessories.

C.5.3 Fire Detection System Replacement

Base Items o Building 9 Center Maintenance (Voc Building) Fire Alarm - all work shall include all materials, equipment, labor and incidentals to remove existing and design/install new code-compliant addressable fire alarm system. Re-use existing conduit and wiring to the extent permissible by code. Replace old, not code compliant wiring. All fire alarm wiring to be in electrical metal tubing (EMT) conduit. The new fire alarm system shall be provided with battery backup and integral Transient Voltage Surge Suppression (TVSS) device, and have adequate zones/points. The new design and installation shall meet the requirements of the latest edition of NFPA 72, including complete testing and documentation.

o Building 14 Gym Fire Alarm - all work shall include all materials, equipment, labor and incidentals to remove existing and design/install new code-compliant addressable fire alarm system. Re-use existing conduit and wiring to the extent permissible by code. Replace old, not code compliant wiring. All fire alarm wiring to be in electrical metal tubing (EMT) conduit. The new fire alarm system shall be provided with battery backup and integral Transient Voltage Surge Suppression (TVSS) device, and have adequate zones/points. The new design and installation shall meet the requirements of the latest edition of NFPA 72, including complete testing and documentation.

o Building 57 King Hall Dorm Fire Alarm - all work shall include all materials, equipment, labor and incidentals to remove existing and design/install new code-compliant addressable fire alarm system. Re-use existing conduit and wiring to the extent permissible by code. Replace old, not code compliant wiring.

All fire alarm wiring to be in electrical metal tubing (EMT) conduit. The new fire alarm system shall be provided with battery backup and integral Transient Voltage Surge Suppression (TVSS) device, and have adequate zones/points. The new design and installation shall meet the requirements of the latest edition of NFPA 72, including complete testing and documentation.

o Building 59 Perkins Hall Dorm Fire Alarm - all work shall include all materials, equipment, labor and incidentals to remove existing and design/install new code-compliant addressable fire alarm system. Re-use existing conduit and wiring to the extent permissible by code. Replace old, not code compliant wiring.

All fire alarm wiring to be in electrical metal tubing (EMT) conduit. The new fire alarm system shall be provided with battery backup and integral Transient Voltage Surge Suppression (TVSS) device, and have adequate zones/points. The new design and installation shall meet the requirements of the latest edition of NFPA 72, including complete testing and documentation.

o Building 60 Washington Hall Dorm Fire Alarm - all work shall include all materials, equipment, labor and incidentals to remove existing and design/install new code-compliant addressable fire alarm system.

AG-82A7-S-17-0051

16 | 70

Re-use existing conduit and wiring to the extent permissible by code. Replace old, not code compliant wiring. All fire alarm wiring to be in electrical metal tubing (EMT) conduit. The new fire alarm system shall be provided with battery backup and integral Transient Voltage Surge Suppression (TVSS) device, and have adequate zones/points. The new design and installation shall meet the requirements of the latest edition of NFPA 72, including complete testing and documentation.

o Building 74 Urban Forestry Fire Alarm - all work shall include all materials, equipment, labor and incidentals to remove existing and design/install new code-compliant addressable fire alarm system. Re-use existing conduit and wiring to the extent permissible by code. Replace old, not code compliant wiring.

All fire alarm wiring to be in electrical metal tubing (EMT) conduit. The new fire alarm system shall be provided with battery backup and integral Transient Voltage Surge Suppression (TVSS) device, and have adequate zones/points. The new design and installation shall meet the requirements of the latest edition of NFPA 72, including complete testing and documentation.

o Building 76 Student Activity Center Fire Alarm - all work shall include all materials, equipment, labor and incidentals to remove existing and design/install new code-compliant addressable fire alarm system.

Re-use existing conduit and wiring to the extent permissible by code. Replace old, not code compliant wiring. All fire alarm wiring to be in electrical metal tubing (EMT) conduit. The new fire alarm system shall be provided with battery backup and integral Transient Voltage Surge Suppression (TVSS) device, and have adequate zones/points. The new design and installation shall meet the requirements of the latest edition of NFPA 72, including complete testing and documentation.

Optional/Additive Items – Subject to Availability of Funding o Building 75 – Wellness Center – all work shall include all materials, equipment, labor and incidentals to evaluate existing fire alarm system and provide recommendation for repair and/or replacement. Provide cost with proposal. Price shall include design, if applicable, and installation.

o Building 66 – Computer Tech Classroom (First Floor of Vocation Building) - all work shall include all materials, equipment, labor and incidentals to evaluate existing fire alarm system and provide recommendation for repair and/or replacement. Provide cost with proposal. Price shall include design, if applicable, and installation.

C.5.4 Walk-in Refrigerator and Walk-In Freezer Replacements o Walk-in Refrigerator Replacement - all work shall include all materials, equipment, demolition, labor, delivery and incidentals to remove an existing walk-in refrigerator and deliver and install a new walk-in refrigerator.

o Walk-in Freezer Replacement - all work shall include all materials, equipment, demolition, labor, delivery and incidentals to remove an existing walk-in freezer and deliver and install a new walk-in freezer.

The Contractor shall furnish all the necessary supervision, management, personnel, materials, equipment, labor, all necessary permits and valid licenses, utilities, freight and delivery and incidentals for the work stated in the Statement of Work, Special Project Specifications, and Drawings incorporated herein and/or attached in Section J.

Refer to Section C.6 Special Project Specifications for specific details and technical requirements required in performance of this contract, in addition to what is stated in this Statement of Work (SOW).

C.6 SPECIAL PROJECT SPECIFICATIONS

AG-82A7-S-17-0051

17 | 70

Special Project Specifications applicable to this contract are attached in Section J (separate documents):

Culinary Arts Buildout

Section Specification 010150 General Requirements 033000 Cast-in-place Concrete 055000 Metal Fabrications 055213 Pipe and Tube Railings 061000 Rough Carpentry 061600 Sheathing 062023 Interior Finish Carpentry 064023 Interior Architectural Woodwork 071930 Plastic Vapor Barrier/Retarders 072100 Thermal Insulation 078413 Penetration Fire stopping 079200 Joint Sealants 081113 Hollow Metal Doors and Frames 081416 Flush Wood Doors 083110 Access Doors and Frames 083800 Special Doors 087100 Door Hardware 088000 Glazing 092900 Gypsum Board 096720 Seamless Flooring System 097200 Vinyl Wall Coverings 099100 Painting 101423 Panel Signage 102113 Plastic Toilet Compartments 102800 Toilet, Bath, and Laundry Accessories 104416 Fire Extinguishers 220500 Common Work Results for Plumbing 220529 Hangers and Supports for Plumbing Piping and Equipment 220700 Pipe Insulation 221116 Domestic Water Piping 221119 Domestic Water Piping Specialties 221313 Facility Sanitary Sewers 221316 Sanitary Waste and Vent Piping 221319 Sanitary Interceptors 221329 Life Station 224000 Plumbing Fixtures 230500 Common Work Results for HVAC 230529 Hangers and Supports for HVAC and Equipment 230593 Testing, Adjusting, and Balancing 230700 HVAC Insulation 230900 Instrumentation and Controls for HVAC 231123 Facility Natural-Gas Piping 233113 Metal Ducts 233300 Air Duct Accessories 233450 Fans

AG-82A7-S-17-0051

18 | 70

233713 Diffusers, Grilles, and Relief Hoods 233813 Commercial Kitchen Hoods 237413 Packaged, Outdoor, Central-Station Air-Handling Units 237433 Packaged, Outdoor, Make-up Air Units 238126 Ductless Split Air Conditioning Units 260100 Common Work Results for Electrical 260500 Conductors, Cables, and Raceways 260526 Grounding and Bonding 260553 Identification for Electrical Systems 262210 Electrical Service 262416 Panelboards 262726 Wiring Devices 262813 Fuses 262816 Enclosed Switches and Circuit Breakers 264313 Surge Protection Devices 265100 Lighting 270100 Voice and Data Communication Cabling 283100 Fire Detection and Alarm 312250 Earthwork 312317 Trenching, Bedding and Backfilling for Utilities Structural Engineering Report

Drawing # Title T1.0 Title Sheet T.1.1 Drawing Index U1.1 Utility Site Plan U1.2 Photographs U2.1 Utility Details U2.2 Grease Trap and Lift Station Details A0.1 Code Analysis A0.2 Code Analysis A0.3 Code Analysis – Legend and Abbreviations A1.1 Floor Plan A1.2 Equipment Plan A2.1 North and East Elevations A2.2 South and West Elevations A3.1 Restroom Sections A4.1 Details and Sections A4.2 Miscellaneous Details A4.3 Wash Area Guard Rail Details A4.4 Wash Area Privacy Fence Details A4.5 West Egress Landing and Stairs Details A5.1 Schedules and Sections A6.1 Photographs A6.2 Exterior Photographs S0.1 Details S0.2 Details S1 General Notes S2 General Notes S3 General Notes S4 Foundation Plan

AG-82A7-S-17-0051

19 | 70

S5 Floor Framing Plan S6 Roof Framing Plan S7 Foundation and Floor Details S8 Foundation and Floor Details S9 Details S10 Wood Details S11 Wood Details S12 Wood Details S13 Wood Details P0.1 Plumbing Legend, Schedules, and Notes P1.1 Crawlspace Plumbing Plan P1.2 First Floor Plumbing Plan P2.1 Plumbing Isometrics P2.2 Plumbing Details and Photographs M0.1 HVAC Legend and Schedules M0.2 Schedules M1.1 Crawl Space HVAC Plan M1.2 First Floor HVAC Plan M2.1 HVACC Details and Photographs E0.1 Electrical Legend and Abbreviations E0.2 Schedules, Photographs, Details, and One Line Diagram E0.3 Equipment Connection Schedule E1.0 Crawlspace Power, Fire Detection, and Lighting Plan E1.1 First Floor Power and Communication Plan E1.2 First Floor Lighting and Fire Detection Plan E1.3 Attic Lighting and Fire Detection Plan E2.1 Panelboard Schedules

Miscellaneous Building Exterior Repairs

Section Specification 010150 General Requirements 073113 Asphalt Shingles 076200 Sheet Metal Flashing and Trim

Drawing # Title T1.0 Title Sheet A1.1 North and East Elevations A1.2 South and East Elevations – Culinary Arts Building A2.1 Photographs and Detail – Culinary Arts Building A2.2 Photographs and Floor Plan – Education Building A3.1 Photographs and Floor Plan – Female Dormitory

Fire Detection System Replacement

Section Specification 010150 General Requirements 283111 Fire Alarm System

Drawing # Title Vicinity Map

AG-82A7-S-17-0051

20 | 70

Location Map Existing Site Plan Photographs – Building 9 – Center Maintenance Floor Plan – Building 9 – Center Maintenance Photographs – Building 14 – Gym First Floor - Floor Plan – Building 14 – Gym Second Floor – Floor Plan – Building 14 – Gym Photographs – Building 57 – King Hall Dorm (Male) Lower Level Floor Plan – Building 57 – King Hall Dorm (Male) First Floor – Floor Plan – Building 57 – King Hall Dorm (Male) Photographs – Building 59 – Perkins Dorm (Male) Floor Plan – Building 59 – Perkins Dormitory (Male) Photographs – Building 60 – Washington Dorm (Male) Floor Plan – Building 60 – Washington Dorm (Male) Photographs – Building 74 – Forestry Floor Plan – Building 74 – Forestry Photographs – Building 76 – Student Activity Center Floor Plan – Building 76 – Student Activities Center Photographs – Building 75 – Dispensary Floor Plan – Building 75 – Dispensary Photographs – Building 66 – Vocational Shops Floor Plan – Building 66 – Vocational Shops

Walk-In Refrigerator/Freezer Replacement - Attachment 6

C.7 CONTRACTOR AND PRODUCT MINIMUM REQUIREMENTS

The contractor is responsible for adherence to all Occupational Safety and Health Administration (OSHA) Regulation, specifically 29 CFR 1910 - General Industry and 29 CFR 1926 – Construction.

Contractor shall be responsible for obtaining all required permits and scheduling all applicable inspections.

All inspections must be signed off and completed prior to receipt of final payment. All applicable submittals required, which may include warranty, production information, operation and maintenance documentation, etc. as defined throughout various sections of Special Project Specifications must be provided to COR and CO prior to submission of final invoice. Invoice will be rejected until are required documentation is submitted.

Please refer to each Special Project Specification for required submittals.

All trash and debris removal must be in accordance with local, state and federal regulations.

All materials and equipment are to be installed per manufacturer’s installation guidance.

Contractor must have adequate liability insurance and proper license to perform all work stated herein.

C.8 BIOBASED AND SUSTAINABLE PRODUCTS

The Contractor must comply with the Agricultural Act of 2014; the Food, Conservation and Energy Act of 2008 (FCEA), 7 U.S.C. 8102; the Farm Security and Rural Investment Act of 2002 (FSRIA), 7 U.S.C. 8102; the Federal Acquisition Regulation; Executive Order (EO) 13514, “Federal Leadership in Environmental, Energy and Economic Performance,” dated October 5, 2009; EO 13423, “Strengthening Federal Environmental, Energy, and Transportation Management,” dated January 24, 2007; and Presidential Memorandum, “Driving Innovation and Creating Jobs in Rural America

AG-82A7-S-17-0051

21 | 70 through Biobased and Sustainable Product Procurement,” dated February, 2012 to provide biobased products.

All supplies and materials shall be of a type and quantity that conform to applicable Federal specifications and standards, and to the extent feasible and reasonable; include the exclusive use of biobased and recycled products.

The following is a list of categories for biopreferred products that a r e required for performance of this service contract.

Adhesive and Mastic Removers – 58% Minimum BioBased Content Asphalt and Tar Removers – 80% Minimum BioBased Content Bioremediation Materials – 86% Minimum BioBased Content Composite Panels – Acoustical – 37% Minimum BioBased Content Composite Panels – Countertops – 89% Minimum BioBased Content Composite Panels – Interior Panels – 55% Minimum BioBased Content Composite Panels – Plastic Lumber – 23% Minimum BioBased Content Composite Panels – Structural Interior Panels – 89% Minimum BioBased Content Composite Panels – Structural Wall Panels – 94% Minimum BioBased Content Concrete and Asphalt Release Fluids – 87% Minimum BioBased Content Diesel Fuel Additives – 90% Minimum BioBased Content Dust Suppressants – 85% Minimum BioBased Content Erosion Control Materials – 77% Minimum BioBased Content Fertilizers – 71% Minimum BioBased Content Floor Coverings (Non-Carpet) – 91% Minimum BioBased Content Inks – Sheetfed (Black) – 49% Minimum BioBased Content Inks – Sheetfed (Color) – 67% Minimum BioBased Content Interior Paints and Coatings – Latex and Waterborne Alkyd – 20% Minimum BioBased Content Interior Paints and Coatings – Oil-Based and Solventborne Alkyd – 67% Minimum BioBased Content Metal Cleaners and Corrosion Removers – Corrosion Removers – 71% Minimum BioBased Content Metal Cleaners and Corrosion Removers – Other Metal Cleaners – 56% Minimum BioBased Content Metal Cleaners and Corrosion Removers – Stainless Steel – 75% Minimum BioBased Content Metalworking Fluids – General Purpose Soluble, Semi-Synthetic, and Synthetic Oils – 57% Minimum

BioBased Content Mobile Equipment Hydraulic Fluids – 44% Minimum BioBased Content Mulch and Compost – 95% Minimum BioBased Content Multipurpose Lubricants – 88% Minimum BioBased Content Plastic Insulating Foam for Residential and Commercial Construction – 7% Minimum Biobased Content Pneumatic Equipment Lubricants – 67% Minimum BioBased Content Roof Coatings – 20% Minimum BioBased Content Slide Way Lubricants – 74% Minimum BioBased Content Wood and Concrete Sealers – Membrane Concrete Sealers – 11% Minimum BioBased Content Wood and Concrete Sealers – Penetrating Liquids – 79% Minimum BioBased Content Wood and Concrete Stains – 39% Minimum BioBased Content

For more information regarding the Department of Agriculture Biobased Program go to:

http://www.biopreferred.gov.

http://www.biopreferred.gov./

AG-82A7-S-17-0051

22 | 70

C.9 SAFETY

During the execution of this contract, the Contractor shall conform to the rules and regulations as set forth by OSHA Safety and Health Standards, 29 CFR Part 1926 – Safety and Health Regulations for Construction or the US Army Corps of Engineers “Safety and Health Requirements Manual”, Sept 15 2008 (free online) whichever is more stringent.

Additional safety requirements are contained in Section H of the solicitation. Smoking will not be permitted in any building or structure. Fire precautions to prevent wildfire may be included in each Task Order or initiated when weather and site conditions pose a significant opportunity for ignition of wildfire.

C.10 LANDSCAPE PRESERVATION

The Contractor shall confine operations to within the clearing limits or other areas designated in contract documents, and prevent the depositing debris outside of these limits. Material which falls outside of these limits shall be retrieved, disposed of, or incorporated in the work as directed by the Contracting Officer, and damage to vegetation or structures outside the clearing limits shall be repaired as directed by the Contracting Officer.

C.11 CONFORMITY WITH DRAWINGS AND SPECIFICATIONS

Unless working tolerances are specified, all work performed and materials furnished shall be in reasonably close conformity with lines, grades, cross sections, dimensions, and material requirements shown on the drawings, indicated in the specifications, or designated on the ground. “Reasonably close conformity” is compliance with reasonable and customary manufacturing and construction tolerance.

A. Definition. "Work" includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

B. The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

C. Government inspections and tests are for the sole benefit of the Government and do not--

1. Relieve the Contractor of responsibility for providing adequate quality control measures;

2. Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

3. Constitute or imply acceptance; or

4. Affect the continuing rights of the Government after acceptance of the completed work under paragraph

(I) below.

D. The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer's written authorization.

E. The Contractor shall promptly furnish, without additional charge, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer.

The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary.

The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work.

Special, full size, and performance tests shall be performed as described in the contract.

F. The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract

AG-82A7-S-17-0051

23 | 70 requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

G. If the Contractor does not promptly replace or correct rejected work, the Government may (1) by contract or otherwise, replace or correct the work and charge the cost to the Contractor or (2) terminate for default the Contractor's right to proceed.

H. If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

I. Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government's rights under any warranty or guarantee.

C.12 WARNING SIGNS AND RESTRICTIONS

Contractor shall be totally responsible for safety signing, barricades and other signing to maintain a safe site to the public and Government employees.

C.13 MATERIALS, EQUIPMENT, TRAINING, AND UTILITIES

C.13.1 Legal Relations and Responsibilities

Contractor's Responsibility for Utilities: In the event of interruption to utility services because of accidental breakage the Contractor shall promptly notify the utility authority and shall cooperate with that authority in the restoration of service.

C.13.2 Use of Premises

The Contractor shall comply with the regulations governing the operation of premises which are occupied and shall perform this contract in such a manner as not to interrupt or interfere with the conduct of Government business.

C.13.3 Prosecution of Work

A. The following special controls will affect the Contractor’s prosecution of work: Students will be on site.

B. The Contractor may encounter other contractors performing work on projects in the area.

C. Utilities made available by the Government for use by the Contractor are: Sanitation, Potable water, and 110v.

C.13.4 Disposal of Material

Debris encountered in the construction (metals, etc.) and other waste materials generated in the

AG-82A7-S-17-0051

24 | 70 construction (cartons, scrap, etc.) shall be removed and disposed of in a State or County approved site off of National Forest Service Land.

C.14 PROJECT MANAGER

It shall be the responsibility of the contractor to provide a…