Amendment1.PDF

A CONTRACT ID CODE PAGE 1 OF 3 PAGES

2 AMENDMENT/MODIFICATION NO.

3. EFFECTIVE DATE

03/11/2015

4. REQUISITION/PUCHASE REQ. NO. 5. PROJECT NO.(IF APPLICABLE)

6. ISSUE BY CODE 7.ADMINISTERED BY (if other than item 6) CODE

Wallowa -Whitman National Forest 3160 NE 3 rd Street Prineville, OR 97754

8.NAME AND ADDRESS OF CONTRACTOR(No., street, county, State and ZIP Code) 9A.Amend Solicitation. AG -04M3 -S-15-0015

* 9B.Dated 2/24/2015

* 10A.Mod Contract/Order #

* 10B.Dated (see Item 13) code facility code

11. THIS ITEM APPLIES ONLY TO AMENDMENT OF SOLICITATION

[x] The above numbered solicitation is amended as set forth in the item 14. The hour and date specified for receipt of Offers [ ] is extended [x ] is not extended. Offerors must acknowledge receipt of this amendment prior to the hour and date specified in the solicitatio n or as amended, by one of the following methods: (a) By completing items 8 and 15 and returning (b) By acknowledging receipt of this amendment on each copy of the offer submitted, or (c) By separate letter or telegram which includes a reference to the s olicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT THE PLACE DES IGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegam or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12 . Accounting and Appropriation Data (if required)

13. THIS ITEM APPLIES ONLY TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. This change order is issued pursuant to; (specifiy authority) The changes set forth in item 14 are made in the Contract/Order # in item 10A.

B. The above numbered Contract/Order is modified to reflect the administrative changes (such as changes in paying office, appropriation date, etc.) set forth in item 14, pursuant to the authority of FAR 43.103(b)..

C. This supplemental agreement is entered into pursuant to authority of:

D Other: (Specify type of modification and authority):

E. IMPORTANT: Contractor [ ] is not [ ] is required to sign this document and return _ Original to the issuing office.:

14. DESCRIPTION OF AMENDMENT/MODIFICATION

Project Name and Location :

This amendment addresses the following (see attached addendum)

1. Revisions to Specifications, Drawings, and Bid Schedule

2. Pre -Bid Inquiries (PBI’s) for Contract Bidding

3. Requests for Information (RFI’s) for Plans and Specifications

By signature in Block 15B Contractor releases the Government from all claims relating to this modification. This settlement is complete accord and satisfaction. Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heret ofore changed , remains unchanged and in full force and effect.

15A.NAME AND TITLE OF SIGNER (Type or print) 16A.NAME AND TITLE OF CONTRACTING OFFICER

Contracting Officer

15B .CONTRACTOR/OFFEROR

By ______________________________ (Signature of person authorized to sign)

15C.DATE SIGNED 16B .UNITED STATES OF AMERICA

By______________________________ (Signature of Contracting Officer)

16C.DATE SIGNED

Standard Form 30 Prescribed by GSA FAR (48CFR) 53.243

MENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1 copies of the amendment;

BAKER COMPOUND WORK CENTER BUILDING

Addendum to Amendment 1

REVISIONS, PRE -BID INQUIRIES, REQUEST FOR INFORMATION BAKER COMPOUND WORK CENTER BUILDING

REVISIONS

Pre-Bid Inquiries (PBI’s) for Contract Bidding

December 01, 2015 is the end of the performance period.

Requests for Information (RFI’s) for Plans and Specifications

Yes, the contractor is required to obtain and pay for all costs, training, and archived copies of files per specification.

None

PBI-001

Section F, (SF 1442), Commencement, Prosecution and Completion of Work. It appears that the Performance Period of the project is May 3, 2015 through December 01, 2016, Is this correct, PLEASE VERIFY.

RFI-001

Spec Section 01 3100 -5, (3.01), Electronic Document Submittal Service. Please verify, The contractor is required to obtain and pay for the services of a Document Submittal Service. PLEASE VERIFY.

Replaces page 8 of the solicitation

SECTION F--DELIVERIES OR PERFORMANCE

F-1 CLAUSES INCORPORATED BY REFERENCE FAR 52.252 -2 (FEB 1998)

F-2 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK FAR 52.211 -10 (APR 1984)

December 01, 2015.December 01, 2015.

May 04, 2015.

F-3 SAMPLES AND CERTIFICATES (AGAR 452.236 -76) (FEB 1988)

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tear ing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray t he expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requireme nts, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full tex t. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed elec tronically at this/these address(es): https://www.acquisition.gov/comp/far/index.html

FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES

52.211 -18 Variation in Estimated Quantity (APR 1984)

52.242 -14 Suspension of Work (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after th e date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than The time stated for completion shall include final cleanup of the premises. Work is estimated to commence

When required by the specifications or the Contracting Officer, samples, certificates, and test data shall be submitted after award of the contract, prepaid, in time for proper action by the Contracting Officer or his/her designated representative. Certificates a nd test data shall be submitted in triplicate to show compliance of materials and construction specified in the contract performance requirements.

Samples shall be submitted in duplicate by the Contractor, except as otherwise specified, to show compliance with the contrac t requirements. Materials or equipment for which samples, certifications or test data are required shall not be used in the work until approved in writing by the Contracting Officer.