A04_0040559329_Attach_0001_Specifications_LISQ_Modernize_ADA_Elevator.pdf

Division Section Title

PROCUREMENT AND CONTRACTING DOCUMENTS GROUP

DIVISION 00

00 01 07

- PROCUREMENT AND CONTRACTING REQUIREMENTS

SEALS PAGE

SPECIFICATIONS GROUP

General Requirements Subgroup

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 26 01 CONTRACT MODIFICATION PROCEDURES

01 27 00 DEFINITION OF CONTRACT LINE ITEMS

01 31 00 PROJECT MANAGEMENT AND COORDINATION

01 32 16 CONSTRUCTION SCHEDULE

01 33 23 SUBMITTAL PROCEDURES

01 35 23 SAFETY REQUIREMENTS

01 40 00 QUALITY REQUIREMENTS

01 42 00 REFERENCE STANDARDS

01 50 00 TEMPORARY FACILITIES AND CONTROLS

01 67 00 PRODUCT REQUIREMENTS

01 73 40 EXECUTION

01 74 19 CONSTRUCTION WASTE MANAGEMENT AND DISPOSAL

01 77 00 CLOSEOUT PROCEDURES

01 78 23 OPERATION AND MAINTENANCE DATA

01 79 00 DEMONSTRATION AND TRAINING

Facility Construction Subgroup

DIVISION 02 - EXISTING CONDITIONS

NOT APPLICABLE

DIVISION 03 - CONCRETE

NOT APPLICABLE

DIVISION 04 - MASONRY

NOT APPLICABLE

DIVISION 05 - METALS

NOT APPLICABLE

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

NOT APPLICABLE

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 84 13 PENETRATION FIRESTOPPING(5)

07 92 00 JOINT SEALANTS

DIVISION 08 - OPENINGS

08 71 00 DOOR HARDWARE

DIVISION 09 - FINISHES

09 91 23 INTERIOR PAINTING

DIVISION 10 - SPECIALTIES

NOT APPLICABLE

DIVISION 11 - EQUIPMENT

NOT APPLICABLE

DIVISION 12 - FURNISHINGS

NOT APPLICABLE

DIVISION 13 - SPECIAL CONSTRUCTION

NOT APPLICABLE

DIVISION 14 - CONVEYING EQUIPMENT

14 24 50 MODERNIZATION OF EXISTING HYDRAULIC ELEVATOR

DIVISION 15 - RESERVED

NOT APPLICABLE

DIVISION 16 - RESERVED

NOT APPLICABLE

DIVISION 17 - RESERVED

NOT APPLICABLE

DIVISION 18 - RESERVED

NOT APPLICABLE

DIVISION 19 - RESERVED

NOT APPLICABLE

Facility Services Subgroup

DIVISION 20 - RESERVED

DIVISION 21 - FIRE SUPPRESSION

DIVISION 22 - PLUMBING

22 05 13 COMMON MOTOR REQUIREMENTS FOR PLUMBING

EQUIPMENT

22 05 17 SLEEVES AND SLEEVE SEALS FOR PLUMBING PIPING

22 05 23.14 CHECK VALVES FOR PLUMBING PIPING

22 05 23.15 GATE VALVES FOR PLUMBING PIPING

22 05 29 HANGERS AND SUPPORTS FOR PLUMBING PIPING AND

22 05 53 IDENTIFICATION FOR PLUMBING PIPING AND EQUIPMENT

22 13 16 SANITARY WASTE AND VENT PIPING

22 13 19 SANITARY WASTE PIPING SPECIALTIES

22 14 29 SUMP PUMPS

DIVISION 23 - HEATING VENTILATING AND AIR CONDITIONING (HVAC)

23 05 13 COMMON MOTOR REQUIREMENTS FOR HVAC EQUIPMENT

23 05 17 SLEEVES AND SLEEVE SEALS FOR HVAC PIPING

23 05 18 ESCUTCHEONS FOR HVAC PIPING

23 05 29 HANGERS AND SUPPORTS FOR HVAC PIPING AND

23 05 53 IDENTIFICATION FOR HVAC PIPING AND EQUIPMENT

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC

23 07 19 HVAC PIPING INSULATION

23 23 00 REFRIGERANT PIPING

23 31 13 METAL DUCTS

23 33 00 AIR DUCT ACCESSORIES

23 34 16 CENTRIFUGAL HVAC FANS

23 81 26 SPLIT-SYSTEM AIR-CONDITIONERS

23 82 16.13 REFRIGERANT AIR COILS

DIVISION 24 - RESERVED

NOT APPLICABLE

DIVISION 25 - INTEGRATED AUTOMATION

NOT APPLICABLE

DIVISION 26 - ELECTRICAL

26 05 11 REQUIREMENTS FOR ELECTRICAL INSTALLATIONS

26 05 19 LOW-VOLTAGE ELECTRICAL POWER CONDUCTORS AND

CABLES

26 05 26 GROUNDING AND BONDING FOR ELECTRICAL SYSTEMS

26 05 29 HANGERS AND SUPPORTS FOR ELECTRICAL SYSTEMS

26 05 44 SLEEVES AND SLEEVE SEALS FOR ELECTRICAL RACEWAYS

AND CABLING

26 05 53 RACEWAYS AND BOXES FOR ELECTRICAL SYSTEMS

26 27 26 WIRING DEVICES

26 28 16 ENCLOSED SWITCHES AND CIRCUIT BREAKERS

DIVISION 27 - COMMUNICATIONS

NOT APPLICABLE

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

NOT APPLICABLE

DIVISION 29 - RESERVED

NOT APPLICABLE

Site and Infrastructure Subgroup

DIVISION 30 - RESERVED

NOT APPLICABLE

DIVISION 31 - EARTHWORK

NOT APPLICABLE

DIVISION 32 - EXTERIOR IMPROVEMENTS

NOT APPLICABLE

DIVISION 33 - UTILITIES

NOT APPLICABLE

DIVISION 34 - TRANSPORTATION

NOT APPLICABLE

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

NOT APPLICABLE

DIVISION 36 - RESERVED

NOT APPLICABLE

DIVISION 37 - RESERVED

NOT APPLICABLE

DIVISION 38 - RESERVED

NOT APPLICABLE

DIVISION 39 - RESERVED

Process Equipment Subgroup

DIVISION 40 - PROCESS INTERCONNECTIONS

DIVISION 41 - MATERIAL PROCESSING AND HANDLING EQUIPMENT

NOT APPLICABLE

DIVISION 42 - PROCESS HEATING, COOLING, AND DRYING EQUIPMENT

NOT APPLICABLE

DIVISION 43 - PROCESS GAS AND LIQUID HANDLING, PURIFICATION AND STORAGE

EQUIPMENT

NOT APPLICABLE

DIVISION 44 - POLLUTION CONTROL EQUIPMENT

NOT APPLICABLE

DIVISION 45 - INDUSTRY-SPECIFIC MANUFACTURING EQUIPMENT

NOT APPLICABLE

DIVISION 46 - WATER AND WASTE WATER TREATMENT

NOT APPLICABLE

DIVISION 47 - RESERVED

END OF TABLE OF CONTENTS

FOSU 258205

00 01 07 - 1

SEALS PAGE

DOCUMENT 00 01 07 - SEALS PAGE

1.1 DESIGN PROFESSIONALS OF RECORD

A. Architect:

1. Quinn Evans Architects, Inc.

2. Larry Barr, FAIA South Carolina License No. 8328.

3. Responsible for Divisions 01-49 Sections except where indicated as prepared by other design professionals of record.

B. HVAC/Plumbing Engineer:

1. Apogee Consulting Group, P.A.

2. Dorell Royster, South Carolina License No. 33219.

3. Responsible for Division 22 .

C. Electrical Engineer:

1. Apogee Consulting Group, P.A.

2. Kevin T. Kublank, South Carolina License No. 29468.

3. Responsible for Division 26.

END OF DOCUMENT 00 01 07

This page intentionally left blank.

01 11 00 - 1

SUMMARY OF WORK

SECTION 01 11 00 - SUMMARY OF WORK

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes the following:

1. Work Covered by Contract Documents

2. Contractor Use of Site

3. Public Use of Site

4. Occupancy Requirements for Buildings

5. Conduct of Operations

6. Work Restrictions

1.2 WORK COVERED BY CONTRACT DOCUMENTS

A. Project Location: 340 Concord St., Charleston, South Carolina

B. The Work consists of:

1. Modernization of the existing hydraulic elevator system.

2. Mechanical, electrical, and fire protection system improvements in the existing elevator machine room and hoistway.

3. Minor related improvements to elevator hoistway and machine room finishes and door hardware.

C. Project will be constructed under a single prime contract.

1.3 CONTRACTOR USE OF SITE

A. General: Contractor shall have limited use of site for construction operations. Limit use of premises to work in areas indicated on drawings. Do not disturb portions of Project site beyond areas in which the Work is indicated.

1. Limits: Confine constructions operations to areas immediately adjacent to elevator hoistway on ground level and machine room, as approved in writing by Contracting Officer .

B. Storage of Materials: Confine storage of materials to areas designated by Contracting Officer.

C. Parking: Confine parking to areas approved in writing by Contracting Officer.

D. Stockpiling: Confine stockpiling to areas approved in writing by Contracting Officer .

01 11 00 - 2

E. Driveways and Entrances: Keep driveways and entrances serving premises clear and available to Government employees, and emergency vehicles at all times. Do not use for parking or storage of materials.

1. Schedule deliveries to minimize use of driveways and entrances.

2. Schedule deliveries to minimize space and time requirements for storage of materials and equipment on-site.

F. Construction Camp: Establishment of a camp within park will not be permitted.

G. Hauling Restrictions: Comply with legal load restrictions in hauling of materials. Load restrictions on park roads are identical to state load restrictions with such additional regulations as may be imposed by the Park Superintendent. Information regarding rules and regulations for vehicular traffic on park roads may be obtained from the Office of the Park Superintendent. A special permit will not relieve Contractor of liability for damage which may result from moving of equipment.

1.4 PUBLIC USE OF SITE

A. Contractor shall conduct his operations to ensure the least inconvenience to public.

1.5 OCCUPANCY REQUIRMENTS FOR BUILDINGS

A. Existing Buildings

1. Full Government Occupancy: Government will occupy buildings under construction during the entire contract period. Cooperate with Government during construction operations to minimize conflicts and facilitate Government usage. Perform Work so as not to interfere with Government's day-to-day operations. Maintain existing exits, unless otherwise indicated.

a. Maintain access to existing walkways, corridors, and other adjacent occupied or used facilities. Do not close or obstruct walkways, corridors, or other occupied or used facilities without written permission from Contracting Officer.

b. Maintain existing building in weather tight condition throughout construction period. Repair damage caused by construction operations. Protect building and occupants during construction period.

1.6 CONDUCT OF OPERATIONS

A. Contractor shall conduct his operations in conformance with rules and regulations promulgated by the Secretary of the Interior for the National Park Service, and applicable park rules and regulations prescribed by Park Superintendent.

B. Work on Saturdays, Sundays, Federal holidays or at night may not be performed unless stated in the Work Restrictions below or without prior consent from the Contracting Officer. Submit requests 2 business days in advance of the work to the Contracting Officer for approval.

01 11 00 - 3

C. No signs or advertisements (except those specified herein) shall be displayed on the construction site or within the park unless approved by the Contracting Officer.

1.7 WORK RESTRICTIONS

A. On-Site Work Hours: Work shall be generally performed during normal business working hours of 8:00 a.m. to 5:00 p.m., Monday through Friday, except when otherwise indicated.

B. Existing Utilities

1. Contractor shall be responsible for locating and preventing damage to known utilities. If damage occurs, repair utility at no additional expense to the Government.

2. If damage occurs to an unknown utility, repair utility. An equitable adjustment will be made in accordance with the Changes clause of the contract.

C. Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by Government or others unless permitted under the following conditions and then only after arranging to provide temporary utility services according to requirements indicated:

1. Notify Contracting Officer not less than two business days in advance of proposed utility interruptions.

2. Do not proceed with utility interruptions without Contracting Officer’s written permission.

D. Nonsmoking Building/Tobacco Use/Vaping: Smoking is not permitted within building or within 25 feet of entrances, operable windows, or outdoor air intakes.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 11 00

01 26 01 - 1

CONTRACT MODIFICATION PROCEDURES

SECTION 01 26 01 - CONTRACT MODIFICATION PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. Section consists of administrative and procedural requirements for contract modifications.

1.2 DEFINITIONS AND ALLOWANCES

A. Home Office Overhead: Costs incurred in support of all of a contractor’s projects and not attributable to a specific job. The cost for home office overhead is only allowed as a percentage of all direct work excluding profit. The following items represent allowable home office overhead costs identified in Part 31 of the Federal Acquisition Regulation (FAR):

1. Rent

2. Utilities

3. Furnishings

4. Office equipment

5. Executive and management staff not exclusively assigned to the project

6. Support, accounting, and administrative staff

7. Preparation of cost proposals, estimating, and schedule analyses connected with

Modifications

8. Estimating and preconstruction services

9. Mortgage costs

10. Real estate and corporate taxes

11. Automobile maintenance and travel costs for home office personnel

12. Home office insurances i.e. structure, automotive, umbrella, flood, etc.

13. Depreciation of equipment and other assets

14. Home office supplies (paper, staples, etc.)

15. Legal services

16. Accounting and data processing

17. Professional fees/registration

B. General Conditions (Field Office Overhead): Management and administrative costs incurred on site for the designated project. Costs associated with preparation of modifications will not be allowed. Costs for these items are to be included only in the general conditions of the modification estimate. Only in the case of a contract time extension are additional general conditions included in modifications. The following items, if applicable, are considered allowable costs for calculating General Conditions:

1. Project Manager (PM), Assistant Project Manager

2. Superintendent, Assistant Superintendent

3. Quality Control, Safety Officer, Environmental Manager, etc.

4. Engineers

5. Travel, lodging, and per diem (as established by Federal Travel Regulations)

6. Scheduling

01 26 01 - 2

7. Field Office Trailers and associated temporary utilities

8. Field office supplies

a. Mailing and couriers

b. Reproduction costs

c. Storage

d. Phones

e. Computers

f. Copiers

9. Personal vehicles i.e. Superintendent Pickup trucks

C. General Requirements: Costs directly associated with the project and are necessary to perform the actual work of the modification. These costs shall be shown as direct costs in the estimate.

The following items, if applicable, are considered allowable costs for calculating General Requirements:

1. Hoisting

2. Material handling

3. Temporary fencing

4. Port-a-lets

5. Trash removal, dumpsters

6. Barricades

7. Small tools

8. Safety supplies

9. Scaffolding

10. Daily cleaning

11. Traffic control

12. Temporary signage

13. Temporary heating and power

D. Personnel Costs: Costs included in the modification must only be for General Conditions staff and workers actually present and working on project site. Modification costs for salaried workers are only allowed within the structure of a 40-hour week and no overtime or holiday pay will be allowed.

1. Worker Hourly Rates are costs directly associated with the individual worker and consist of the following:

a. Base Rate: The hourly rate paid directly to the worker

b. Labor Burden: Employer payments of all applicable burdens; includes insurance and taxes the business must pay on behalf of the worker to government entities and educational forums, such as:

1) Social Security

2) Medicare

3) Workers Compensation – Policy and company calculation to be made available.

4) Federal Unemployment Tax Act (FUTA) - Cap Rate and percentage to be proportionally allocated over one year.

5) State Unemployment Tax Act (SUTA) - Cap Rate and percentage to be proportionally allocated over one year.

6) Union agreement costs - Other costs required under an enforceable collective bargaining agreement.

c. Fringe Benefits: Various non-wage compensations provided to employees such as:

01 26 01 - 3

1) Health Care Insurance Premiums

2) Cell Phone

3) Clothing

4) 401K and Pensions

5) Vehicle allowances

6) Gas allowance

7) Life insurance premiums

8) Disability insurance

9) Other Fringe Benefits required under an enforceable collective bargaining agreement

E. Bonuses or Deferred Compensation: No Bonus or Deferred Compensation will be allowed within any components of pricing including Home Office Overhead, General Conditions, General Requirements, Hourly Worker Rates, or the direct costs of work.

F. General Liability Insurance: An insurance policy that protects Contractor from claims resulting from bodily injury or property damage to a third party. Include as a separate line item within all modification proposals and provide a current insurance quote upon request.

G. Performance and Payment Bonds: A performance bond is a surety bond issued by an insurance company or bank to guarantee satisfactory completion of a project. The Payment Bond guarantees the Contractor will pay the labor and material costs incurred. Banks and Insurance companies charge a premium for individual project based on a sliding scale related to the size of the project. Include as a separate line item in modification proposals and provide current company bonding rates upon request.

H. Builder’s Risk Insurance: Covers the contractor’s loss due to fire, high winds, or other natural forces. Not reimbursed by the National Park Service (NPS) and shall not be included in modification proposals.

1.3 MODIFICATION PROPOSAL PRICING REQUIREMENTS

A. General:

1. Proposal be received in the format and within the time frame specified in the Request for Proposal (RFP) letter. Costs or delays resulting from failure of contractor to submit within the time frame specified will not be compensable.

2. Proposal shall be detailed with itemized lists of equipment, materials, labor, production rates, overhead, profit, and bond markup for each item. Labor costs must be itemized by craft and hourly rate, including Fringe Benefits and Labor Burden. If the costs of Fringe Benefits and Labor Burden are not itemized, it is assumed they are included in the hourly rate shown, or contractor is not requesting reimbursement. Contractor may utilize the government provided Contractor Estimate Form, or their own form, provided that it contains the same information and level of detail as the Government’s form.

3. Requests for extensions of contract time as a result of change must be justified with a Time Impact Analysis (TIA). Refer to Section 01 32 16 "Construction Schedule", for time impact analysis requirements. TIA and associated costs shall be received with the proposal by the date shown within the Request for Proposal letter. Contractor’s failure to submit within the specified time frame will be construed as the Contractor waiving right for additional time and no time extension will be allowed.

01 26 01 - 4

4. All supporting documentation used to justify the proposed modification will be made available to the Contracting Officer (CO) upon request.

5. Contractor shall review and approve all subcontractor/supplier pricing in detail for proper format, scope, production rates, and pricing prior to submission to NPS. All delay costs associated with not reviewing and approving subcontractor/supplier pricing will be borne by the Contractor.

6. All pricing and production rates within the estimate must be based on fair and reasonable pricing and cannot include built-in contingency.

B. Labor:

1. Contractor shall estimate cost of labor by itemizing each craft involved, indicating worker hourly rate (base rate + labor burden + fringe benefits) for each and itemizing hours required for each craft directly engaged in modification work. Any work proposed requiring overtime work or premium pay shall be itemized separately. Rates shall be in accordance with the Davis-Bacon Act as incorporated herein. Labor Burden may include payroll taxes, Social Security, unemployment insurances, workers compensation insurance, Federal Insurance Contributions Act (FICA), FUTA, and other direct costs resulting from Federal, State or local laws.

2. Itemize labor costs for equipment operators separate from equipment costs.

3. Labor cost for foremen shall only be costs for related work required for the modification.

C. Materials:

1. Estimated cost for materials shall include quotes from multiple sources. Material prices shall include applicable fees and credits, including but not limited to, sales tax, freight and delivery charges, and tax rebates.

2. No markup shall be applied to any material provided by NPS.

D. Equipment:

1. Equipment used for the project must be appropriately sized for work being performed.

2. Do not include costs for "miscellaneous tools and equipment", in your proposal for a replacement value of $500 or less. Costs shown in excess of $500 shall be broken out separately.

3. Regardless of ownership, rates to be used in determining equipment rental costs shall be the lowest cost from one of the following sources:

a. United States (U.S.) Army Corps of Engineers, Ownership and Operating Expense

Schedule (use latest edition and applicable region)

b. Construction Blue Book

c. Local equipment rental rates, documented by actual invoice charges, or itemized vendor quotes.

4. Estimated equipment rates shall include operating costs of all fuel, oil, lubrication, supplies, small tools, necessary attachments, ground engaging components, tires and tracks, routine repairs and maintenance (cost of major repair and overhaul is not allowed per Federal Acquisition Regulation (FAR) 31.105(d)(2)), depreciation, storage, insurance, and all incidentals. Mobilization, if applicable, may be included for equipment solely used on the modification work but must be listed separately.

5. Estimate full rate for equipment only for duration that equipment will be utilized to accomplish work of the modification.

01 26 01 - 5

6. Standby unit rates used in accordance with paragraph 1.3, D, 2, above. If the U.S. Army Corp of Engineers is utilized then their standby rates prevail. If Bluebook or local equipment pricing is accepted, then 1/2 of equipment costs minus any operating costs, major repair and overhaul will be accepted.

7. If equipment is in standby mode due solely to a documented NPS delay, established standby rate shall apply from the first day of the delay.

8. Equipment not used and on job site for up to five consecutive days may be classified at standby rates, provided the equipment is or has been used solely to perform work on the modification and will be necessary to complete additional modification work. Equipment still on the jobsite but not in use after five consecutive days will not be considered in the modification pricing.

9. Requests for compensation for equipment stand by time must be justified, documented and itemized separately.

10. The estimated timeframe (daily, weekly, monthly) for use of the equipment must reflect the lowest cost to the Government.

E. Establishment and Application of Overhead and Profit Percentages:

1. Home Office Overhead and Profit (OH&P) shall be applied to direct costs only. Profit shall not be applied to overhead amounts; and overhead shall not be applied to profit.

Home office overhead shall contain only allowable, allocable, and reasonable costs per the contract documents and FAR Part 31. Profit percentages are based on risk factors found in FAR Part 31which have been applied to the specific type of work included in this project. Negotiated rates shall not exceed the following percentages for OH&P for contractor self-performed work:

a. Overhead………………10%

b. Profit………………7.25%

2. Total aggregate limit of markup (OH&P) for Contractor and Subcontractors on modification work shall not exceed 25%. The NPS will not be responsible for allocation of percentages between contractor and subcontractors at any tier.

3. If Contractors form a partnership, partnership may only receive home office overhead and profit in same amount as an individual Contractor (refer to paragraph 1.3,E,1 above).

It is the responsibility of the partners to decide on division of revenue.

4. Combined Increases and Decreases: On proposals involving both increases and decreases in the Contract Price, overhead and profit mark-ups are required on net increases and deducted on net decreases.

5. At no time can profit be calculated on Overhead or itself, it must be calculated on direct costs of work only.

PART 2 - PRODUCTS

PART 3 - EXECUTION

END OF SECTION 01 26 01

01 27 00 - 1

DEFINITION OF CONTRACT LINE ITEMS

SECTION 01 27 00 - DEFINITION OF CONTRACT LINE ITEMS

PART 1 - GENERAL

1.1 SUMMARY

A. Section explains in general, what is and is not included in a contract line item, and limits or cutoff points where one item ends and another begins.

B. If no contract line item exists for a portion of work, include costs in a related item.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION

3.1 LIST OF CONTRACT LINE ITEMS

A. Contract Line Item Number 0001 .

1. This item consists of the complete scope of work identified in the Contract Documents .

2. Measurement for payment: no separate measurement will be made for payment.

3. Payment will be made at the contract lump sum price.

END OF SECTION 01 27 00

01 31 00 - 1

PROJECT MANAGEMENT AND

COORDINATION

SECTION 01 31 00 - PROJECT MANAGEMENT AND COORDINATION

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes administrative provisions for coordinating construction operations on Project including, but not limited to, the following:

1. Definitions

2. Construction Coordination

3. Submittals

4. Coordination Drawings

5. Requests for Information (RFIs)

6. NPS/DSC Project Website

7. Project Meetings

8. Environmental Coordination

9. Permits

B. Related Requirements:

1. Section 01 32 16 "Construction Schedule" for preparing and submitting Contractor’s construction schedule.

2. Section 01 73 40 "Execution" for procedures for coordinating general installation and field-engineering services, including establishment of benchmarks and control points.

3. Section 01 77 00 "Closeout Procedures" for coordinating closeout of the Contract.

1.2 DEFINITIONS

A. Agency with JurisdictionAgency with Jurisdiction

B. Construction Permits – Contractor ProvidedConstruction Permits – Contractor Provided

C. Government Furnished PermitsGovernment Furnished Permits

1.3 CONSTRUCTION COORDINATION

A. Coordination: Coordinate construction operations included in different Sections of Specifications to ensure efficient and orderly installation of each part of the Work. Coordinate construction operations, included in different Sections, which depend on each other for proper installation, connection, and operation.

1. Schedule construction operations in sequence required to obtain best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

01 31 00 - 2

COORDINATION

2. Coordinate installation of different components with other Contractors to ensure maximum accessibility for required maintenance, service, and repair.

3. Make provisions to accommodate items scheduled for later installation.

4. Where availability of space is limited, coordinate installation of different components to ensure maximum performance and accessibility for required maintenance, service, and repair of components, including mechanical and electrical.

5. Properly plan construction operations to include permit requirements. Allow enough time to execute permit provisions to maintain work schedule, site visits, inspections, and reporting deadlines.

B. Prepare memoranda for distribution to each party involved, outlining special procedures required for coordination. Include such items as required notices, reports, and list of attendees at meetings.

C. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities and activities of other contractors to avoid conflicts and to ensure orderly progress of the Work. Such administrative activities include, but are not limited to:

1. Preparation of Contractor's Construction Schedule

2. Preparation of the Schedule of Values

3. Installation and removal of temporary facilities and controls

4. Delivery and processing of submittals

5. Progress meetings

6. Permit requirements

7. Pre-installation conferences

8. Project closeout activities

9. Commissioning activities

1.4 SUBMITTALS

A. Division 1 documents: The following items shall be submitted a minimum of one week prior to Preconstruction Conference. Contracting Officer will notify Contractor of tentative date for Pre- Construction Conference.

1. Letter designating Project Superintendent

2. Construction Schedule

3. A Comprehensive Schedule of Values

4. Accident Prevention Plan

5. A List of Subcontractors for this project

6. Written statements from Subcontractors certifying compliance with applicable labor standard clauses.

7. Certificates of Insurance or SF1413 for Contactor and all Subcontractors

8. Waste Management Plan

9. Quality Control Plan

10. List of Required Construction Permits. Include the following information for each permit:

a. Name of Permit

b. Agency(ies) with Jurisdiction issuing the permit

c. Information required from Government to complete permit application

01 31 00 - 3

COORDINATION

B. Provide items listed to Contracting Officer before Pre-Construction Conference. If all documents have not been received one week prior to scheduled Pre-Construction Conference date, conference may be cancelled, Notice to Proceed may not be issued, and Contracting Officer will consider other contractual remedies. Work shall not commence until written Notice to Proceed has been issued.

1.5 REQUESTS FOR INFORMATION (RFIs)

A. General: Immediately on discovery of the need for additional information or interpretation of Contract Documents, Contractor shall prepare and submit an RFI utilizing form created on NPS/DSC management software website.

1. Contracting Officer will not respond to RFIs submitted by other entities controlled by Contractor.

2. Coordinate and submit RFIs in a prompt manner to avoid delays in the work.

B. Content of RFI: Include detailed, legible description of item needing information or interpretation and the following:

1. RFI number, numbered sequentially

2. Date

3. RFI subject

4. Specification Section number and title and related paragraphs, as appropriate.

5. Drawing number and detail references, as appropriate.

6. Field dimensions and conditions, as appropriate.

7. Contractor's suggested resolution: If Contractor's suggested resolution impacts Contract

Time or Contract Sum, Contractor shall state impact in RFI.

8. Contractor's signature

9. Requested date for response

10. Attachments: Include sketches, descriptions, measurements, photos, Product Data, Shop

Drawings, coordination drawings, and other information necessary to fully describe items needing interpretation.

a. Include dimensions, thicknesses, structural grid references, and details of affected materials, assemblies, and attachments on attached sketches.

C. RFI Form: Complete RFI Form on NPS/DSC Project Website as follows:

1. Enter general information at the top of the form.

2. Under the "Action" section at the bottom of the form, select "Question" then select

"CMR" in drop-down of "Send to" box.

3. Enter details of question and attach related documents.

4. Select "Submit Form" at bottom of page.

D. Contracting Officer’s Action: Contracting Officer will review each RFI, determine action required, and respond. Contracting Officer will determine critical nature of each RFI and issue response accordingly.

1. The following are not considered to be RFIs and will receive no action:

a. Requests for approval of submittals.

b. Requests for approval of substitutions.

01 31 00 - 4

COORDINATION

c. Requests for approval of Contractor's means and methods.

d. Requests for coordination information already indicated in Contract Documents.

e. Requests for adjustments in Contract Time or Contract Sum.

f. Requests for interpretation of Architect's actions on submittals.

g. Incomplete RFIs or inaccurately prepared RFIs.

2. Contracting Officer's action may include a request for additional information; time for response will date from time of receipt of additional information.

3. Contracting Officer's action on RFIs may result in need for a change to Contract Time or Contract Sum. All contract changes will be processed following terms and conditions of contract.

1.6 PROJECT WEB SITE

A. Use NPS/DSC management software website for communication throughout contract period on:

1. Project directory

2. Project correspondence

3. Meeting agendas and minutes

4. Contract modifications forms and logs

5. RFI form and processing

6. Task and issue management

7. Baseline schedule, schedule updates and calendar management

8. Submittal form and processing

9. Payment coordination documentation

10. Drawing and specification document hosting, viewing, and updating

11. Online document collaboration

12. Reminder and tracking functions

13. Archiving functions

14. Notification of submittal and RFI statuses and current responsible party

15. Permits and addendums

B. Some documents are not suitable to be shared using the NPS/DSC management software website. Documents containing Personal Identifying Information (PII) (i.e. certified payrolls) shall not be shared using NPS/DSC management software website and shall be coordinated with Project team as appropriate.

C. Submit to Contracting Officer a list of employees who will need access to the website. Users will receive an invitation to register from Department of Interior (DOI). Once registered on DOI website, user will be given access to NPS/DSC management software website.

D. All users will be required to have the following software packages:

1. Internet Explorer version 7 or later.

2. Adobe Acrobat Professional (Pro) version 9 or later.

1.7 PROJECT MEETINGS

A. Preconstruction Conference: Before start of construction, Contracting Officer will arrange an onsite meeting with Contractor. Meeting agenda will include the following as a minimum:

01 31 00 - 5

COORDINATION

1. Roles & Responsibilities / Lines of Authority

2. Park rules and regulations

3. Jobsite Safety

4. Resolution of comments on required Division 1 documents

5. Coordination of Subcontractors

6. Labor law application

7. Modifications

8. Payments to Contractor

9. Payroll reports

10. Contract time

11. Liquidated damages

12. Contractor Performance Evaluation

13. Display of Hotline posters

14. Notice to proceed

15. Correspondence procedures

16. NPS/DSC Project website

17. Acceptance/rejection of work

18. Progress meetings

19. Submittal procedures

20. NPS Final Accessibility Inspection

21. Environmental requirements

22. Permit requirements

23. As-constructed drawings/operation and maintenance (O&M) manuals.

24. Saturday, Sunday, holiday and night work.

25. Reference materials

26. Value engineering

27. Schedule of Values

B. Progress Meetings: Contracting Officer will schedule weekly meetings with Contractor.

1. Attendees: In addition to Government Representatives, each Contractor, Subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented. Participants at meeting shall be familiar with Project and authorized to conclude matters relating to the Work.

2. Agenda: Review and correct or approve minutes of previous progress meeting. Review other items of significance that could affect progress. Meeting agenda will include:

a. Approval of minutes of previous meetings

b. Submittal status

c. Review of offsite fabrication and delivery schedules.

d. Requests for information (RFI) and other issues.

e. Modifications

f. Work in progress and projected.

1) Status of required inspections (Special Inspections, Accessibility, etc.)

g. Inspections of work in progress and projected (Special inspections, Accessibility, etc.)

h. Construction Schedule update (provide updated Critical Path Method (CPM)).

i. Status of Project Record Drawings and O&M manuals.

j. Other business relating to work.

k. Permit requirements

01 31 00 - 6

COORDINATION

1.8 ENVIRONMENTAL COORDINATION

A. Contractor’s Environmental Manager: Designate on-site party responsible for overseeing Contractor’s conformance to environmental goals for project and implementing procedures for environmental protection.

1. Qualifications: Minimum 3 years Construction experience on projects of similar size and scope; with environmental procedures similar to this project; familiar with environmental regulations applicable to construction operations.

2. Responsibilities: Responsibilities shall include:

a. Compliance with applicable Federal, State, and local environmental regulations, including maintaining required documentation.

b. Implementation of Waste Management Plan (WMP).

c. Present overview of environmental issues and summarize site specific procedures relating to management plans at Preconstruction conference.

d. Training for Contractor personnel in accordance with position requirements.

e. Monitoring and documentation of environmental procedures.

B. Perform project quality control in accordance with requirements specified in Related Sections, including:

1. Quality Requirements

2. Regulatory Requirements

3. Construction Waste Management

C. Contractor’s Environmental Training Program: Contractor shall provide environmental training for workers performing work on project site. Training shall include:

1. Overview of environmental issues related to building industry.

2. Overview of environmental issues related to Project.

3. Review of site-specific procedures and management plans:

a. Construction Waste Management

4. Compliance with environmental regulations: As specified in Regulatory Requirements.

Submit Contractor 40 CFR (Code of Federal Regulations) employee training records upon request of Contracting Officer.

D. Provide documentation for environmental procedures as specified herein and in accordance with approved Waste Management Plan.

1.9 PERMITS

A. General:

1. Permits and Responsibilities: Contractor shall, without additional expense to the Government, be responsible for obtaining necessary licenses and permits, and for complying with Federal, State and municipal laws, codes, and regulations applicable to the performance of the work. Contractor shall also be responsible for damages to persons or property that occur as a result of Contractor’s fault or negligence; and for materials delivered and work performed until completion and acceptance of the work.

01 31 00 - 7

COORDINATION

2. For the purpose of this contract, Contractor will not be considered an agent of the Government. Contractor shall comply with appropriate Federal, State and local laws.

B. Coordination with Agency(ies) with Jurisdiction Issuing Permits

1. Coordination: Contact the Agency(ies) with Jurisdiction as needed and sufficiently in advance to avoid delaying work: Coordinate meetings, reporting requirements, inspections, and other requirements.

C. Administrative Procedures:

1. Coordinate scheduling and timing of required administrative provisions of project permits with Agency(ies) with Jurisdiction, Construction Manager, and Park to avoid conflicts.

2. Supply needed information to Agency(ies) with Jurisdiction issuing permits, pay fees required and provide material needed to comply with permit’s conditions and provisions.

3. Upload permits to NPS/DSC management software website when permits are obtained.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 31 00

01 32 16 - 1

CONSTRUCTION SCHEDULE

SECTION 01 32 16 - CONSTRUCTION SCHEDULE

PART 1 - GENERAL

1.1 SUMMARY

A. Section consists of Construction Schedule requirements including:

1. Schedule of Values

2. Construction Schedule Requirements.

3. Construction Schedule Updates.

4. Time Impact Analysis.

B. Purpose: The Construction Schedule ensures adequate planning, coordination, scheduling, and reporting during execution of the work by the Contractor. It shall assist the Contractor and Contracting Officer (CO) in monitoring the progress of the work, evaluating proposed changes, and processing Contractor's monthly progress payments. It shall include the dates in the contract, phases, milestones, occupancies, holidays, weather consideration, a critical path, and the requirements of this section.

1.2 DEFINITIONS

A. Activity: A discrete part of a project identified for planning, scheduling, monitoring, and controlling the construction project. Activities included in a construction schedule consume time and resources.

1. Critical activities are activities on the critical path. They start and finish on the planned early start and finish times.

2. Predecessor Activity: An activity that precedes another activity in the network.

3. Successor Activity: An activity that follows another activity in the network.

B. Cost Loading: Allocation of the Schedule of Values for completion of an activity as scheduled.

The sum of costs for all activities must equal the total Contract Sum, unless otherwise approved by the Contracting Officer.

C. Critical Path Method (CPM): Method of planning and scheduling a construction project where activities are arranged based on activity relationships. Network calculations determine when activities can be performed and the critical path of Project.

D. Critical Path: Longest connected chain of interdependent activities through the network schedule that establishes minimum overall Project duration and contains no float.

E. Float: Measure of leeway in starting and completing an activity.

1. Float: Not for the exclusive use or benefit of the Government or Contractor but is jointly owned.

2. Free Float: Amount of time an activity can be delayed without adversely affecting the early start of the successor activity.

01 32 16 - 2

3. Total Float: Measure of leeway in starting or completing an activity without adversely affecting planned Project completion date.

F. Resource Loading: Allocation of manpower and equipment necessary for completion of an activity as scheduled.

G. Fragnet: A partial or fragmentary network that breaks down activities into smaller activities for greater detail.

1.3 SUBMITTALS

A. Electronic Copies: Schedules and reports submitted shall be posted on the NPS/DSC management software website in native electronic file formats. The intent of the Government is to limit the number of printed reports to those determined by the project team as essential.

B. Schedule of Values: After contract award and before Pre-Construction conference, submit schedule of dollar values based on Contract Price Schedule.

C. Construction Baseline Schedule: After contract award and before Pre-Construction conference, submit two paper copies of baseline schedule, large enough to show entire schedule for entire construction period. Utilize Schedule of Values in preparation of Construction Baseline Schedule.

D. Construction Schedule Updates: On or before 7th day preceding progress payment request date, submit estimates of percent completion of each schedule activity and necessary supporting data.

Provide two paper copies.

1.4 QUALITY ASSURANCE

A. Contractor shall meet with Contracting Officer on day of the preconstruction conference to go over:

1. Review software limitations, content and format for reports.

2. Verify availability of qualified personnel needed to develop and update schedule.

3. Discuss constraints, including partial Government occupancy/substantial completions.

4. Review delivery dates for Government-furnished products.

5. Review time required for review of submittals and re-submittals.

6. Review requirements for tests and inspections by independent testing and inspecting agencies.

7. Review time required for completion and startup procedures.

8. Review and finalize list of construction activities to be included in schedule.

9. Review baseline schedule comments, resolve issues and progress on incorporating them

10. Review procedures for updating schedule.

11. Discuss reporting requirements and establish protocol for naming and transmitting electronic schedules.

B. Contractor's Schedule Representative: Before the preconstruction conference, designate an authorized representative to be responsible for preparing and maintaining the Construction Schedule. Submit resume outlining qualifications of Scheduler to Contracting Officer for

01 32 16 - 3 acceptance. Scheduler shall have prepared and maintained at least 5 previous schedules of similar size and complexity similar to this Contract, demonstrating proficiency of using scheduling software. Authorized representative will be responsible for preparing the Baseline Schedule, required updates, revisions, Time Impact Analyses, and reports.

1.5 COORDINATION

A. Coordinate preparation and processing of schedules and reports with performance of construction activities and with scheduling and reporting of separate Contractors.

B. Coordinate Construction Baseline Schedule with Schedule of Values, list of subcontracts, Submittals Schedule, progress reports, payment requests, and other required schedules and reports.

1. In developing Construction Baseline Schedule, ensure Subcontractor’s work at all tiers, and prime Contractor’s work, is included and coordinated.

2. Secure time commitments for performing critical elements of work from parties involved.

3. Coordinate each construction activity in network with other activities and schedule in proper sequence.

PART 2 - PRODUCTS

2.1 SCHEDULE OF VALUES

A. Breakdown each lump-sum item into component work activities used in the schedule for which progress payments may be requested. Work activities broken out within schedule of values shall be integrated into and made a logical part of the construction baseline schedule. Total costs for the component work activities shall equal contract price for that lump-sum item. Contracting Officer may request data to verify accuracy of dollar values. Include mobilization, general condition costs, overhead and profit in the total dollar value of unit price items and in the component work activities for each lump-sum item. Do not include mobilization, general condition costs, overhead or profit as a separate item.

B. Do not break down unit price items. Use only the contract price for unit price items.

C. Total cost of all items shall equal the contract price. The Schedule of Values will form the basis for progress payments and the Construction Schedule.

2.2 CONSTRUCTION SCHEDULE REQUIREMENTS

A. Construction Baseline Schedule: Prepare Construction Baseline Schedule using a computerized, cost and resource-based, time-scaled Critical Path Method network analysis diagram for the Work.

1. Develop and finalize Construction Baseline Schedule so it can be accepted for use no later than 30 days after date established for the Notice of Award.

01 32 16 - 4

a. Failure to include any work item required for performance of this Contract shall not excuse Contractor from completing work within applicable completion dates, regardless of Governments acceptance of schedule.

2. Establish procedures for monitoring and updating Construction Baseline Schedule and for reporting progress. Coordinate procedures with progress meeting and payment request dates.

B. Construction Baseline Schedule Preparation: Prepare a list of all activities required to complete the Work. Using preliminary Critical Path Method network diagram, prepare a skeleton network to identify probable critical paths.

1. Activities: Indicate estimated duration, sequence requirements, and relationship of each activity in relation to other activities.

2. Critical Path Activities: Identify critical path activities, including those for interim completion dates. Scheduled start and completion dates shall be consistent with Contract milestone dates.

3. Processing: Process data to produce output data on a computer-drawn, time-scaled network. Revise data, reorganize activity sequences, and reproduce as often as necessary to produce the Critical Path Method schedule within the limitations of the Contract Time.

4. Show sequence and interdependence of activities required for completion of work.

Ensure work sequences are logical and Construction Baseline Schedule shows a coordinated plan of the work.

5. Resource loading of each activity shall include personnel by labor category and equipment type and capacity proposed to complete the activity in duration shown.

6. Consider seasonal weather conditions in planning and scheduling work influenced by high and low ambient temperatures, wind, or precipitation to ensure completion of work within contract time.

7. Time Frame: Proposed duration assigned to each activity shall be Contractor's best estimate of time required to complete activity considering the scope and resources planned for activity.

a. An early finish date may be shown but the late finish date shall be same date as last day of contract period. An early completion schedule shall contain:

1) Insert an activity titled "Project Float" as a successor to last activity in early project completion schedule network.

2) Add a milestone titled "Contract End Date" as a successor to the activity

"Project Float".

3) Add duration to the activity "Project Float" as required so the milestone

"Contract End Date" equals the last day of Contract Period.

b. Contract completion date shall not be changed by submission of a schedule that shows an early completion date.

c. Contractor shall limit use of lead or lag duration’s between schedule activities.

d. Project Calendars: Develop and incorporate the following calendars:

1) Administrative Calendar: Include calendar based on a 7-day week to be used on activities based on calendar days. Apply this calendar to administrative tasks or other tasks not affected by non-working days (Federal Holidays, weather, etc.).

2) Project Calendar: Include calendar based on planned work week for the project. Include Federal Holidays, weekends, and non-workdays indicated in contract documents. Apply this calendar to activities not anticipated to be affected by weather.

01 32 16 - 5

e. Activity Duration: Define so no activity is longer than 15 days, except for non-construction activities including mobilization, shop drawings and submittals, fabrication and delivery of materials and equipment.

f. Procurement Activities: Include procurement process activities for long lead items and major items, requiring a cycle of more than 60 calendar days, as separate activities in the schedule. Procurement cycle activities can include submittals, approvals, purchasing, fabrication, and delivery.

1) Elevator system components and equipment.

g. Submittal Review Time: Include review and re-submittal times indicated.

Coordinate submittal review times in Construction Baseline Schedule.

h. Substantial Completion: Allow time for Government administrative procedures necessary for certification of Substantial Completion. (For more information, refer to Specification 01 77 00 "Closeout Procedures.")

8. Constraints: Include constraints and work restrictions indicated in Contract Documents and as follows in schedule and show how the sequence of Work is affected.

a. Work Restrictions: Show effect of the following on the schedule:

1) Coordination with existing construction

2) Limitations of continued occupancies

3) Uninterruptible services

4) Partial occupancy before Substantial Completion

5) Use of premises restrictions

b. Work Stages: Indicate important stages of construction for each major portion of the Work.

1) Subcontract awards

2) Submittals

3) Fabrication

4) Installation

5) Tests and inspections

6) Adjusting

7) Curing

C. Joint Review, Revision, and Acceptance:

1. Within seven calendar days of receiving Contractor's proposed Construction Baseline Schedule, Contracting Officer shall review initial Construction Baseline Schedule.

2. Within seven calendar days after review, Contractor shall revise and resubmit Construction Baseline Schedule in accordance with comments presented from…