Attach L - Amend A00002 to Solicitation 70Z08524QLREP0002_18DEC2023.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)2. AMENDMENT/MODIFICATION NO.

A00002

3. EFFECTIVE DATE

12/18/2023

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

USCG Surface Forces Logistics Center Attn: Kiku Khan 2401 Hawkins Point Road, Bldg 3

Baltimore, MD 21226 E-mail: kiku.k.khan@uscg.mil

8. NAME AND ADRESS OF CONTRACTOR (no., street, county, State and ZIP Code) 9.A AMENDMENT OF SOLICITATION NO.

70Z08524QLREP0002

9B. DATE (SEE ITEM 11)

01/04/2024

10A. MODIFICATION OF CONTRACT/ORDER

NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended. Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods: (a) By completing Items 8 and 15, and returning 1 copy of the amendment; (b) By acknowledging receipt of this amendment on each copy of the Offer submitted: or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEGEMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT/.ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc) SET FORTH IN ITEM 14, PURSUANT TO AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority).

E. IMPORTANT: Contractor is not, is required to sign this document and return 1 copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

HAMILTON DS FY2 FQ3

See next page.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remain unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

BY

(Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070 30-105 STANDARD FORM 30 (REV. 10-83)

)PREVIOUS EDITION UNUSABLE Prescribed by GSA, FAR (48 CFR) 53.

CONTINUATION OF SF 30 – BLOCK 14

70Z08524QLREP0002 is hereby amended (70Z08524QLREP0002A00002) as follows:

1. The purpose of this amendment is to provide responses to the Requests for Clarifications (Attachment C):

Responses to Requests for Clarifications

1. Question: Requesting of the 21 items requested which one do the Government consider Critical Path Items?

Government Response: The critical path(s) is defined as the longest path through the project, comprised of tasks that cannot absorb delays without risking delay of the overall project completion as planned. The government does not dictate which Work Items are to be indicated as the critical path; the determination is based on the vendor’s proposed schedule and what work items (or combination of work items) result in the longest duration from start to finish.

2. All other terms and conditions of Solicitation 70Z08524QLREP0002 remain unchanged as a result of amendment A00002.