6973GH-25-R-00214.pdf

SOLICITATION, OFFER AND AWARD

3. SOLICITATION TYPE1. CONTRACT NO. 2. SOLICITATION NUMBER

6. ISSUED BY CODE 7. ADDRESS OFFER TO (If other than Item 6)

5. REQUISITION/PURCHASE NUMBER

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder"

NEGOTIATED BID (RFP)

SEALED BID (IFB)

4. DATE ISSUED

PAGE OF PAGES

1 68

C. E-MAIL ADDRESS

EXT.NUMBERAREA CODE

B. TELEPHONE (NO COLLECT CALLS)A. NAME

9. FOR

INFORMATION

CALL

CAUTION: LATE Submissions, Modifications and Withdrawals. All offers are subject to all terms and conditions contained in this solicitation.

(Date)(Hour) local timeuntildepository located in copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 7, or if hand carried, in the

SOLICITATION

8. Sealed offers in original and

PART IV - REPRESENTATIONS AND INSTRUCTIONS

OTHER STATEMENTS OF OFFERORS

EVALUATION FACTORS FOR AWARD

INSTR., CONDS., AND NOTICES TO OFFERORS

REPRESENTATIONS, CERTIFICATIONS AND

LIST OF ATTACHMENTS

CONTRACT CLAUSES

PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACH.

I

J

K

L

M SPECIAL CONTRACT REQUIREMENTS

CONTRACT ADMINISTRATION DATA

DELIVERIES OR PERFORMANCE

INSPECTION AND ACCEPTANCE

PACKAGING AND MARKING

DESCRIPTION/SPECS./WORK STATEMENT

SUPPLIES OR SERVICES AND PRICE/COST

SOLICITATION/CONTRACT FORM

PART II - CONTRACT CLAUSESPART I - THE SCHEDULE

H

G

F

E

D

C

B

A

SEC. DESCRIPTION PAGE(S) (X) DESCRIPTION SEC. (X)

10. TABLE OF CONTENTS

17. OFFER DATE16. SIGNATURE

SUCH ADDRESS IN SCHEDULE.

IS DIFFERENT FROM ABOVE - ENTER

14C. CHECK IF REMITTANCE ADDRESS

EXT.NUMBERAREA CODE

14B. TELEPHONE NUMBER

(Type or print)AND

ADDRESS

OF

OFFEROR

CODE FACILITY

15. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER14A. NAME

DATEAMENDMENT NO.DATEAMENDMENT NO.

and related documents numbered and dated):

amendments to the SOLICITATION for offerors

(The offeror acknowledges receipt of

13. ACKNOWLEDGEMENT OF AMENDMENTS

CALENDAR DAYS (%)30 CALENDAR DAYS (%)20 CALENDAR DAYS (%)10 CALENDAR DAYS (%)12. DISCOUNT FOR PROMPT PAYMENT the designated point(s), within the time specified in the schedule.

by the offeror) from the date for receipt of offers specified above , to furnish any or all items upon which prices are offered at the price set opposite each item , delivered at

11. In compliance with the above, the undersigned agrees, if this offer is accepted within ______________ calendar days (60 calendar days unless a different period is inserted

NOTE: Item 11 does not apply if the solicitation includes Minimum Bid Acceptance Period .

OFFER (Must be fully completed by offeror)

IMPORTANT - Award will be made on this Form, or by other authorized official written notice.

27. AWARD DATE

(Signature of Contracting Officer)

26. CONTRACT AUTHORITY

24. PAYMENT WILL BE MADE BY

25. NAME OF CONTRACTING OFFICER (Type or print)

CODE 23. ADMINISTERED BY (If other than Item 6)

ITEM

(4 copies unless otherwise specified)

22. SUBMIT INVOICES TO ADDRESS SHOWN IN21. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

20. ACCOUNTING AND APPROPRIATION19. AMOUNT18. ACCEPTED AS TO ITEMS NUMBERED

AWARD (To be completed by CONTRACT AUTHORITY)

CODE

AC-25-04675

X

AAQ730-AFN

AAQ-730 FAC. & AVIATION SAFETY ACQ

PO BOX 25082

BLDG 014-AHQ, ROOM 233A

OKLAHOMA CITY OK 73125

1500 CS 09/10/2025

Kimberly D. Sites 405 Kimberly.Sites@faa.gov

954-7755

X

X

X

X

X

X

X

X

X

X

X

X

X

PAGE(S)

Kimberly D. Sites

6973GH-25-R-00214

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 68

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

6973GH-25-R-00214

The Line Items listed on this SF30 (cover and continuation pages) are for Government use only.

Please reference Section B/Pricing of this instrument for the contract line items.

Delivery: 160 Days After Receipt Of Order

Delivery Location Code: A6973E3M

A6973E3M

6973E3 DOT FAA AAM 600

CIVIL AEROSPACE MEDICAL RESEARCH

PO BOX 25082 DIV RM 102 M

OKLAHOMA CITY OK 731250082 US

Period of Performance: 10/20/2025 to 05/20/2026

00001 The Biodynamics Research team seeks to acquire this High-Speed Lighting Array to perform research on aircraft seats and restraints. CAMI seeks to purchase a modern High Speed Lighting

Array to interface with existing high speed video capture system (2,000 frame per second), interface with existing crane system and planned crane improvements, as well as any training and annual maintenance needed.

Section A - Solicitation/Contract Form

Section B - Supplies or Services/Prices Section B - Schedule

Line Item Description Described in Qty Total Amount

1 Project Management SOW Para 3.1 1 $

2 Site Survey/Preparation SOW Para 3.2.4 and 3.2.5 1 $

3 Design Review and Acceptance SOW Para 3.2.1 and 3.2.3 1 $

4 Decommissioning of Equipment SOW Para 3.7 1 $

Material Procurement and Delivery SOW Para 3.4 1 $

6 Site Installation and Integration SOW Para 3.2.2, 3.5 and

3.6 1 $

7 Training and Support SOW Para 3.8 1 $

Total Estimated Potential Contract Value $

This is a standalone Firm Fixed Price Contract.

Clause List

The remainder of this page has been intentionally left blank.

Section C - Description/Specifications Scope of Work

This document defines the required configuration, delivery, installation, setup, testing, and support of a High-Speed Camera Lighting Array for the Federal Aviation Administration (FAA) Civil Aerospace Medical Institute (CAMI) located on the FAA Mike Monroney Aeronautical Center (MMAC) in Oklahoma City, Oklahoma. (See attached Statement of Work (SOW) listed in Section J)

Clause List

AC4563 EMERGENCY SITUATIONS AND EXERCISES DURING CONTRACT PERFORMANCE

AT THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (NOV 2015)

(a) Emergency situations and exercises are temporary exceptions to the prohibition of contractor personnel being subject to the direction and control of Government personnel when performing non-personal contract services in Government facilities.

(b) All contractor personnel at a Government work site or facility during an actual emergency must conform to the procedures posted or directed by Government officials responsible for emergency response at that site or facility.

Such officials include evacuation wardens/monitors, security personnel, Emergency Readiness Officers, management, Contracting Officer’s Representative (COR), etc.

(c) Contractor personnel must participate in all emergency exercises, including evacuations, as part of performance under this contract. On rare occasions, based on advance arrangements that are then announced at the time of an exercise, contractor personnel may be excused from evacuations.

(d) Contractor management/site supervisors must ensure that each contractor employee assigned to work in Government facilities possesses a general awareness of emergency and evacuation procedures at all locations where the employees might be during an emergency or exercise. Contractor Management/Site Supervisors are responsible for accounting for their employees during an actual emergency or exercise, and are subsequently required to report this information to their COR as soon as practical based on the situation. Information on emergency procedures may be requested from the COR or a designated Government contact point at the work site.

(e) When there are disruptions to Government operations at the Mike Monroney Aeronautical Center, Contractor Management/Site Supervisor should ensure that all employees are aware of the following methods of obtaining the Center’s status:

The Center Status website: https://employees.faa.gov/org/centers/mmac/employee_services/facility_status/

Status Phone number; 954-0040, and local TV/Radio news channels.

(f) If the Center is OPEN during inclement weather, it’s business as usual. Any need for unscheduled leave is between the contractor employee and their contractor management, not the FAA.

(g) When the Center is OPEN with a Delayed Arrival Time, contractors may allow their employees to arrive at the worksite in accordance with the Delayed Arrival Time under which the Center is operating. However, the government will not pay for hours not worked on other than firm fixed price type contracts and discussions on accounting for time on any other contract type should be between Contractor Management/Site Supervisor and COR or CO.

(h) When the Center is CLOSED, contractor employees should not report to the Center unless they have been informed in advance that they are considered ‘mission critical’ employees or their contractor management/site supervisor has provided other direction. The government will not pay for hours not worked on other than firm fixed price type contracts. Any discussions on accounting for time on any other contract type should be between the contractor management/site supervisor and the COR or CO.

(i) If an alternative duty location is activated that includes contractor employees, all contractor employees will be made aware of that location through their contractor management/site supervisor.

Section D - Packaging and Marking Clause List

Section E - Inspection and Acceptance Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.10.4-1 CONTRACTOR INSPECTION REQUIREMENTS (APR 1996)

3.10.4-2 INSPECTION OF SUPPLIES - FIXED PRICE (NOV 1997)

3.10.4-4 INSPECTION OF SERVICES - BOTH FIXED-PRICE & COST REIMBURSEMENT (APR

1996)

3.10.4-16 RESPONSIBILITY FOR SUPPLIES (APR 1996)

AC1908 INSPECTION AND ACCEPTANCE AT DESTINATION (JUN 2015)

(a) Final inspection and acceptance shall be at destination.

(b) Although source inspection by the Government is not anticipated under this contract, the provisions of this clause shall in no way be construed to limit the rights of the Government under the clause entitled 3.10.4-2 INSPECTION OF SUPPLIES - FIXED PRICE (NOV 1997) & 3.10.4-4 - Inspection of Services - Both Fixed-Price & Cost Reimbursement (APR 1996)

Section F - Deliveries or Performance Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.10.1-9 STOP-WORK ORDER (APR 2025)

3.11-34 F.O.B. DESTINATION (APR 1999)

Section G - Contract Administration Data Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.10.1-22 CONTRACTING OFFICER'S REPRESENTATIVE (APR 2012)

(a) The Contracting Officer may designate other Government personnel (known as the Contracting Officer's Representative) to act as his or her authorized representative for contract administration functions which do not involve changes to the scope, price, schedule, or terms and conditions of the contract. The designation will be in writing, signed by the Contracting Officer, and will set forth the authorities and limitations of the representative(s) under the contract. Such designation will not contain authority to sign contractual documents, order contract changes, modify contract terms, or create any commitment or liability on the part of the Government different from that set forth in the contract.

(b) The Contractor shall immediately contact the Contracting Officer if there is any question regarding the authority of an individual to act on behalf of the Contracting Officer under this contract.

(End of Clause)

AC2604 INCREMENTAL FUNDING (JAN 1997)

(a) The Government reserves the right to incrementally fund this contract on a periodic basis to promote efficiency in the utilization of fiscal allotments through the routine budget process or the use of interim funding measures such as under congressional ""continuing resolution"" procedures.

(b) Delivery orders will be periodically issued to provide a not-to-exceed amount of funds. Such amount will be sufficient to cover contract performance for the period specified in the order, plus an estimated cost for terminating the contract should additional funds not be available to continue performance under the contract.

(c) This clause becomes inoperative when the contract period is fully funded.

AC4529 WARRANTY - COMMERCIAL PRODUCTS AND SERVICES (JUN 2006)

The contractor’s standard commercial warranty shall be deemed to be a part of this contract unless otherwise specified. If the contractor does not have a standard warranty, the warranty provisions of UCC Article 2 shall apply.

AC4550 DELIVERIES TO THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (JUL

2015)

(a) Security procedures at the MMAC require that all mail, materials, packages or parcels of any kind be delivered to a central screening point, for inspection by the FAA. This affects mail and other deliveries destined for all organizations located on MMAC property, including government organizations, contractors and permit holders.

After passing security inspection, the mail or material may be handled and delivered by the FAA. FAA will make every reasonable effort to conduct inspections and handle items in a careful manner so as to avoid damage or delay.

(b) This inspection is for the benefit of the FAA only. The FAA makes no representation that any material passing inspection is without hazard, poses no threat, or that it conforms in form, fit, function or quantity to the expectations of the intended recipient.

(c) The FAA shall not be liable for any 1) loss, damage or shortage of any mail or materials, 2) injury, or 3) delay in performance resulting from such inspection and handling, unless liable under the Federal Tort Claims Act (28 U.S.C. 2671-2680).

(d) Any item destined for the contractor that fails to pass inspection remains the property of the contractor, who is responsible for its disposition and coordination with law enforcement agencies as necessary.

Section H - Special Contract Requirements Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.1.9-1 ELECTRONIC COMMERCE AND SIGNATURE (JUL 2020)

(a) The Electronic Signatures in Global and National Commerce Act (E-SIGN) establishes a legal equivalence between:

(1) Contracts written on paper and contracts in electronic form;

(2) Pen-and-ink signatures and electronic signatures; and

(3) Other legally-required written records and the same information in electronic form.

(b) With the submission of an offer, the offeror acknowledges and accepts the utilization of electronic commerce as part of the requirements of this solicitation and the resultant contract.

(c) Certain documents may need to be provided or maintained in original form, such as large-scale drawings impractical to convert to electronic format or a document with a raised seal signifying authenticity. This clause does not change or affect any other requirements that a document must be in paper format to satisfy legal requirements such as for certain real estate transactions.

(d) The use of electronic signature technology is authorized under this solicitation and the resulting contract.

(e) Contractors must not digitally sign any documents with software that uses the Secure Hash Algorithm 1 (SHA- 1). All digitally signed documents and contracts sent to the FAA must use a SHA-256 or higher hash algorithm. This is based on the National Institute of Standards and Technology (NIST) Policy Statement on Hash Functions dated August 5, 2015. Further guidance on the use of SHA-256 is in NIST Special Publication (SP) 800-57 Part 1, section

5.6.2 as amended and SP 800-131A, Revision 1 dated November 6, 2015. Additional guidance on the use of SHA-3 is in NIST SP 800-185 as amended.

(f) Contractors do not have to update documents previously digitally signed using SHA-1 hash algorithms unless the document requires updating. The FAA and contractors may continue to use SHA-1 for the following applications:

Verifying old digital signatures and time stamps, generating and verifying hash-based message authentication codes (HMACs), key derivation functions (KDFs), and random bit/number generation.

(End of Clause)

AC0090 ENVIRONMENTAL, SAFETY AND HEALTH (JULY 2016)

(a) The Contractor shall ensure that no person employed on this contract works in surroundings or under conditions that are unsanitary, hazardous, or dangerous to their health or safety. The contractor shall also ensure that all employees receive appropriate and required training for safety, health, environmental, and equipment operations. In fulfilling these requirements, the Contractor shall comply with:

(1) Applicable Federal, State, and local environmental and safety requirements. This includes, but is not limited to, requirements contained in the U.S. Code of Federal Regulations (e.g. 29 CFR, 40 CFR, and 42 CFR) and/or requirements issued by the Oklahoma Department of Environmental Quality and the Oklahoma Corporation Commission.

(2) Supplemental Federal and FAA environmental, safety and health requirements contained in Executive Orders, FAA, and Mike Monroney Aeronautical Center (MMAC) Environmental, Safety and Health Orders, or elsewhere in the contract. Other standards used by the FAA include those sponsored by the National Fire Protection Association (NFPA), the American National Standards Institute (ANSI), the American Society of Testing and Materials (ASTM), etc. This list of standards or laws is not inclusive.

(3) The MMAC Environmental, Occupational Safety and Health Policy states:

-The FAA Mike Monroney Aeronautical Center is fully committed to excellence and leadership in protecting the environment, and the health and safety of our employees and neighbors. It is our policy to ensure that employees, contractors, students, and visitors are provided with workplaces that are free from recognized hazards that may cause death, illness, or injury. Additionally, we will accomplish our mission in a manner that will minimize environmental consequences. All organizations at the Aeronautical Center are responsible to ensure that environmental, safety, and health considerations are integrated into their daily activities and operations. In keeping with this commitment, we will implement, maintain, and continually improve our environmental, safety, and health performance by utilizing a comprehensive Environmental, Occupational Safety and Health Management System which:

-Ensures compliance with all applicable environmental, occupational safety, and health requirements

-Establishes environmental, occupational safety and health metrics

-Prevents injury and illness

-Minimizes pollution and waste; conserves natural resources and improves energy efficiency

-Identifies hazards, assesses risks, and implements controls

Aeronautical Center personnel demonstrate their commitment to this policy by providing products and services in a manner that demonstrates our good stewardship of the environment, and in a manner that ensures a safe and healthy work environment for employees, contractors, students, and visitors.

(4) The environmental requirements of the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) are modeled after the specifications found in the International Standard for Environmental Management, ISO 14001: 2004. The health and safety requirements of the MMAC Environmental, Occupational Safety and Health System (EOSHMS) are modeled after the specifications found in the Occupational Health and Safety Assessment Series, BS OHSAS 18001: 2007. The MMAC EOSHMS requires that all contractors that provide goods and services that can affect MMAC's environmental, occupational safety and health programs shall, prior to start of performance of work under this contract:

(i) Ensure that all employees supporting the contract work activities are:

-Aware of the MMAC Environmental, Occupational Safety and Health Policy as set forth in paragraph (a)(3) above;

-Aware of and conform with the Operational Control documents referenced as attachments in Section J of this solicitation/contract;

-Competent to perform assigned job functions and maintain appropriate records of training or equivalent experience as identified in the above referenced Operational Control documents. Such records shall be made available to the CO or COR upon request.

(ii) Ensure that employees requiring unescorted access to the site have received the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) General Awareness Briefing, eLMS course # FAA30050017. This training is available on-line at:

https://ksn2.faa.gov/arc/amc/amp/amppublic/SitePages/Training%20-%20Mandatory%20Training.aspx .

(iii) Complete and sign the 'Certification of Contractor Conformance to the MMAC EOSHMS' included in Section K of this solicitation/contract. Contractor's signature of this certification certifies that the contractor has verified that all MMAC EOSHMS requirements have been or will be met and that work performed hereunder shall be in conformance with the MMAC EOSHMS. Submission of this certification is a prerequisite for contract award.

(b) If the Contractor works more than 1000 employee-hours in one quarter on the MMAC Campus, the Contractor shall prepare and submit an annual report of injury and illness information regarding this workforce as specified in 29 CFR 1904. The report shall be submitted to the Contracting Officer not later than November 30 of each year and contain the following information (Note: the following references to fiscal year refer to the Governmental fiscal year, October 1 through September 30):

(1) The number of employee-hours worked during the preceding fiscal year;

(2) The number of OSHA recordable cases (defined as mishaps that result in fatalities, lost workdays, medical treatment, restricted workdays or a loss of consciousness) that occurred during the preceding fiscal year;

(3) The number of cases which resulted in days away and/or restricted/transferred duty that occurred during the preceding fiscal year.

(c) If there are conflicts between any of the requirements referenced in this contract, the more stringent requirement will prevail.

(d) If the Contractor fails or refuses to promptly comply with any environmental, safety or health requirements stated in this Clause, the Contracting Officer's Representative (COR) will notify the Contractor of any such noncompliance and the Contractor shall take immediate corrective action. Such notice, whether oral or written, when served on the Contractor or any of its employees at the site of the work, shall be deemed sufficient. All oral notices will be followed up with a written notice to the Contractor. If the Contractor fails or refuses to promptly correct the condition, the COR may stop all or any portion of the work. When satisfactory corrective action has been taken, the contractor shall request permission to resume work from the COR. No time extension or additional costs, resulting from the directive to stop work shall be allowed. Failure of the COR to provide notice of noncompliance or to stop work shall not relieve the Contractor of its responsibility for the safe performance of the work.

(e) The Contractor shall require contract personnel to wear personal protective equipment when it is necessary because of the hazards on the job and in most instances will provide the equipment and corresponding training, except that which has been specified to be furnished by FAA. All personal protective equipment worn by contractors shall comply with applicable industry standards.

(f) Contractors shall include a clause in all subcontracts to require subcontractors to comply with this clause.

AC1051 CONTRACT SHUTDOWN PROCEDURES PENDING APPROPRIATIONS FOR NEW

FISCAL YEAR (JAN 1997)

(a) In the event no continuing resolution or permanent appropriation is in place at the outset of the new fiscal year (FY), contractor employees are expected to report for their assigned duties the first workday of that new FY. Absent an appropriation, contract services that are determined by the Government to be non-essential will be shutdown as soon as practical. To implement the shutdown, the Contracting Officer may require the contractor to stop all, or any part, of the work called for under the contract pursuant to AMS clause 3.10.1-9, Stop-Work Order. (b) This clause does not limit the Government's rights provided by AMS 3.10.6-4, Default, or AMS 3.10.6-1, Termination for Convenience of the Government, clause of the contract.

AC3402 FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (MAY 2019)

FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (APR 2016) CLA.3402

Contractor personnel, including employees of subcontractors at any tier, suppliers, etc., working at or visiting the FAA Mike Monroney Aeronautical Center (MMAC) facility, shall abide by all applicable regulations in effect at the MMAC facility governing their conduct, including, but not limited to, those regulations pertaining to traffic, parking, security, and airport matters. A non-inclusive list of such regulations is provided below. The full text of these are available at the website shown or can be obtained by contacting your Contracting Officer (CO)/Contracting Officer's Representative (COR).

FAA ORDERS/DIRECTIVES

*Contractor & Industrial Security Program FAA Order 1600.72A https://www.faa.gov/documentLibrary/media/Order/ND/1600.72A.pdf

Note: All contractors with access to government computer systems are required to take annual Security Awareness Virtual Initiative (SAVI) training. Information on how to accomplish this training is located at:

https://my.faa.gov/org/linebusiness/ash/programs/savi.html

*Accountability Board FAA Order 1110.125B https://www.faa.gov/documentLibrary/media/Order/FAA_Order_1110.125B.pdf

*FAA Occupational Safety & Health Policy FAA Order 3900.19C https://www.faa.gov/documentLibrary/media/Order/FAA_Order_3900.19C.pdf

*FAA Information Security and Privacy Program and Policy FAA Order 1370.121 https://employees.faa.gov/documentLibrary/media/Order/1370.121.pdf

*Ground Vehicle Operations to include Taxiing, or Towing Aircraft on Airports

Advisory Circular AC 150/5210-20A https://www.faa.gov/airports/resources/advisory_circulars/index.cfm/go/document.information/documentID/102808

*Parking and Traffic AC 1600.21 H Chapter 7 https://ksn2.faa.gov/arc/amc/amp/amppublic/Traffic%20Safety/Forms/AllItems.aspx

*Documents are only available by request from the Contracting Officer.

AC4555 NOTICE OF CONTRACTOR TESTIMONY (SEP 2006)

(a) The contractor shall notify the Contracting Officer promptly in writing of its intention, or the intention of its employees, subcontractors of any tier, or subcontractor employees, either voluntarily or under compulsion of competent authority, to provide sworn testimony on any matter related to or arising under the work required by and/or performed under, this contract. Such written notification at a minimum shall consist of the date and time of the testimony, identification of the court, board, or other body before which the testimony is made, the nature of the testimony to be given to the extent it is known at the time of this report, the nature of the contractor’s involvement in the proceeding and any other circumstances related to the work performed under or related to the contract and the proceeding in which the testimony will be taken.

(b) The contractor shall include the substance of this clause, including this paragraph (b), in all subcontracts executed under this contract and shall require all subcontractors to provide the required report to the contractor.

AC4556 PERSONNEL AND SUPERVISION (JUL 2015)

The contractor shall designate sufficient supervisory personnel to meet task outcomes. Contract supervisors will provide day-to-day supervision of contract personnel including, but not limited to, work monitoring, payroll records, leave, etc. At no time will FAA personnel assume any responsibility for the supervision of contractor personnel.

Government assistance will be available to provide technical and policy guidance through the assigned Contracting Officer’s Representative (COR).

AC4557 STRIKES OR PICKETING

Notwithstanding any other provision hereof, the Contractor is responsible for delays arising out of labor disputes, including but not limited to strikes, if such strikes are reasonably avoidable. A delay caused by a strike or by picketing which constitutes an unfair labor practice is not excusable unless the Contractor takes all reasonable and appropriate action to end such a strike or picketing, such as the filing of a charge with the National Labor Relations Board, the use of other available Government procedures, and the use of private boards or organizations for the settlement of disputes.

Section I - Contract Clauses Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.1.7-2 ORGANIZATIONAL CONFLICTS OF INTEREST (JAN 2023)

3.2.2.3-42 DIFFERING SITE CONDITIONS (APR 2024)

3.2.2.3-43 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 2024)

3.2.2.3-46 SUPERVISING THE CONTRACT WORK (JUL 2024)

3.2.2.3-54 PREVENTING ACCIDENTS (JUL 2024)

3.2.2.3-83 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC

CORPORATIONS (OCT 2015)

3.2.2.7-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (APR 2023)

3.2.2.7-8 DISCLOSURE OF TEAM ARRANGEMENTS (APR 2008)

3.2.2.8-1 MATERIAL REQUIREMENT (OCT 2019)

3.2.5-1 OFFICIALS NOT TO BENEFIT (OCT 2024)

3.2.5-3 GRATUITIES OR GIFTS (OCT 2024)

3.2.5-4 CONTINGENT FEES (OCT 2024)

3.2.5-8 WHISTLEBLOWER PROTECTION FOR CONTRACTOR EMPLOYEES (APR 2024)

3.3.1-1 PAYMENTS (JUL 2018)

3.3.1-6 DISCOUNTS FOR PROMPT PAYMENT (JUL 2018)

3.3.1-8 EXTRAS (OCT 2024)

3.3.1-9 INTEREST (APR 2023)

3.3.1-15 ASSIGNMENT OF CLAIMS (JUL 2018)

3.3.1-17 PROMPT PAYMENT (OCT 2024)

3.3.1-20 PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS

(OCT 2012)

3.3.1-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER- SYSTEM FOR AWARD

MANAGEMENT (OCT 2024)

3.4.1-12 INSURANCE (OCT 2019)

3.4.2-8 FEDERAL, STATE, AND LOCAL TAXES - FIXED PRICE CONTRACT (APR 2025)

3.5-18 COMMERCIAL COMPUTER SOFTWARE LICENSE (JAN 2009)

3.6.2-4 WALSH-HEALEY PUBLIC CONTRACTS ACT (APR 2025)

3.6.2-12 EQUAL OPPORTUNITY FOR VETERANS (APR 2022)

3.6.2-13 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (APR 2022)

3.6.2-16 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (APR 2025)

3.6.2-39 TRAFFICKING IN PERSONS (OCT 2024)

3.6.2-44 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS

ACT (APR 2025)

3.6.4-5 FAA BUY AMERICAN PREFERENCE - STEEL AND MANUFACTURED GOODS (APR

2022)

3.6.4-8 BUY AMERICAN ACT AND FAA BUY AMERICAN PREFERENCE - USMCA

IMPLEMENTATION ACT - BALANCE OF PAYMENTS PROGRAM (JAN 2024)

3.6.4-10 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JAN 2010)

3.6.6-1 DRUG FREE WORKPLACE (APR 2023)

3.6.6-2 SEAT BELT USE BY CONTRACTOR EMPLOYEES (APR 2023)

3.6.6-3 CONTRACTOR POLICY TO BAN TEXT MESSAGING WHILE DRIVING (JUL 2023)

3.8.9-2 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND

VIDEO SURVEILLANCE SERVICES OR EQUIPMENT (JUL 2023)

3.10.1-7 BANKRUPTCY (APR 1996)

3.10.1-12 CHANGES - FIXED-PRICE (APR 1996)

3.10.1-25 NOVATION AND CHANGE-OF-NAME AGREEMENTS (OCT 2007)

3.10.1-28 CHANGES REQUIRED BY AMS (JAN 2024)

3.10.6-1 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED PRICE) (OCT

1996)

3.10.6-4 DEFAULT (FIXED-PRICE SUPPLY AND SERVICE) (JAN 2020)

3.11-62 PREFERENCE FOR PRIVATELY OWNED U.S. FLAG COMMERCIAL VESSELS (APR

2025)

3.2.2.3-33 ORDER OF PRECEDENCE (APR 2024)

The order of precedence is:

(a) The Schedule (excluding the specifications);

(b) Representations;

(c) Contract clauses;

(d) Other documents, exhibits, and attachments;

(e) The specifications; and

(f) The drawings.

(End of clause)

3.2.2.3-50 PROPERTY PROTECTION (JUL 2024)

(a) The Contractor must construct and maintain any temporary fences, gates and other facilities needed to preserve crops, control livestock, and protect property. Before cutting a fence, the Contractor must take necessary precautions to prevent livestock from straying. The Contractor must prevent loss of tension in or damage to adjacent portions of the fence. The Contractor must immediately replace all fencing and gates cut, removed, damaged, or destroyed with new materials to the original standard. Undamaged gates may be reused.

(b) The Contractor must comply with the property owner's requests to leave gates open or closed.

(c) The Contractor must use all necessary precautions to avoid destroying surveying markers such as section corners, witness trees, property corners, mining claim markers, bench markers, triangulation stations, and the like. If the Contractor must destroy any marker, the Contractor must first notify the agency responsible for the marker, as well as the Contracting Officer's (CO) representative, and replace the markers.

(d) The Contractor must use care to prevent unnecessary damage to property in or near the work area caused by the Contractor's work. Unnecessary damage is that which the Contractor can avoid through efficient and careful performance of the work, considering the Contractor's land rights. If the Contractor damages any property, the Contractor must at once notify the owner or custodian and make or arrange to make prompt and full restitution.

(e) Maps and specifications the FAA provides may not give the location of all water supply, drainage, irrigation, and other underground facilities. Before entering a tract of land for contract purposes, the Contractor must determine from the property owner (or other reasonably available source) the location of any irrigation system, domestic water system, source of water, and drainage system existing on the property, whether serving that property or other property. The Contractor must avoid damaging or obstructing these facilities or polluting water supplies.

(f) The Contractor must hold the FAA harmless from any and all suits, actions, and claims for damages, including environmental impairment, to property arising from any of the Contractor's acts or omissions, the Contractor's subcontractors, or any of the Contractor's employees or subcontractor employees, in any way related to the work or operations under this contract.

(g) The Contractor must indemnify and hold harmless the property owners or parties lawfully in possession against all claims or liabilities asserted by third parties, including all governmental agencies, resulting directly or indirectly from the Contractor's wrongful or negligent acts or omissions.

(End of clause)

3.2.5-7 DISCLOSURE REGARDING PAYMENTS TO INFLUENCE CERTAIN FEDERAL

TRANSACTIONS (OCT 2024)

(a) Definitions.

(1) "The Act," as used in this clause, means section 1352, title 31, United States Code.

(2) "Agency," as used in this clause, means executive agency, within the meaning of 5 U.S.C. 101, 102, and 104(I), and any wholly owned Government corporation within the meaning of 31 U.S.C. 9101.

(3) "Covered Federal action," as used in this clause, means any of the following Federal actions:

(i) The awarding of any Federal contract.

(ii) The making of any Federal grant.

(iii) The making of any Federal loan.

(iv) The entering into of any cooperative agreement.

(v) The extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement.

(4) "Indian tribe" and "tribal organization," as used in this clause, have the meaning provided in section 4 of the Indian Self-Determination and Education Assistance Act (25 U.S.C. 5304) and include Alaskan Natives.

(5) "Influencing or attempting to influence," as used in this clause, means making, with the intent to influence, any communication to or appearance before an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with any covered Federal action.

(6) "Local government," as used in this clause, means a unit of government in a State and, if chartered, established, or otherwise recognized by a State for the performance of a governmental duty, including a local public authority, a special district, an intrastate district, a council of governments, a sponsor group representative organization, and any other instrumentality of a local government.

(7) "Officer or employee of an agency," as used in this clause, includes the following individuals who are employed by an agency:

(i) An individual who is appointed to a position in the Government under title 5, United States Code, including a position under a temporary appointment.

(ii) A member of the uniformed services, as defined in subsection 101(3), title 37, United States Code.

(iii) A special Government employee, as defined in section 202, title 18, United States Code.

(iv) An individual who is a member of a Federal advisory committee, as defined by the Federal Advisory Committee Act, title 5, United States Code, appendix 2.

(8) "Person," as used in this clause, means an individual, corporation, company, association, authority, firm, partnership, society, State, and local government, regardless of whether such entity is operated for profit, or not for profit. This term excludes an Indian tribe, tribal organization, or any other Indian organization with respect to expenditures specifically permitted by other Federal law.

(9) "Reasonable compensation," as used in this clause, means, with respect to a regularly employed officer or employee of any person, compensation that is consistent with the normal compensation for such officer or employee for work that is not furnished to, not funded by, or not furnished in cooperation with the Federal Government.

(10) "Reasonable payment," as used in this clause, means, with respect to professional and other technical services, a payment in an amount that is consistent with the amount normally paid for such services in the private sector.

(11) "Recipient," as used in this clause, includes the Contractor and all subcontractors. This term excludes an Indian tribe, tribal organization, or any other Indian organization with respect to expenditures specifically permitted by other Federal law.

(12) "'Regularly employed," as used in this clause, means, with respect to an officer or employee of a person requesting or receiving a Federal contract, an officer or employee who is employed by such person for at least 130 working days within 1 year immediately preceding the date of the submission that initiates agency consideration of such person for receipt of such contract. An officer or employee who is employed by such person for less than 130 working days within 1 year immediately preceding the date of the submission that initiates agency consideration of such person must be considered to be regularly employed as soon as the officer or employee is employed by such person for 130 working days.

(13) "State," as used in this clause, means a State of the United States, the District of Columbia, the

Commonwealth of Puerto Rico, a territory or possession of the United States, an agency or instrumentality of a State, and multi-State, regional, or interstate entity having governmental duties and powers.

(b) Prohibitions. The offeror, by signing its offer, hereby certifies to the best of his or her knowledge and belief that:

(1) No Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on his or her behalf in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment or modification of any Federal contract, grant, loan, or cooperative agreement;

(2) If any funds other than Federal appropriated funds (including profit or fee received under a covered Federal action) have been paid, or will be paid, to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on his or her behalf in connection with the screening information request (SIR), the offeror must complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to the Contracting Officer; and

(3) The offeror will include the language of this clause in all subcontract awards at any tier and require that all recipients of subcontract awards in excess of $150,000 must disclose accordingly.

(4) This certification and disclosure is a prerequisite for making or entering into this contract imposed by the Act. Any person who makes a prohibited expenditure or fails to file or amend a disclosure form, must be subject to a civil penalty of not less than $10,000 and not more than $100,000, for each such failure.

(c) The prohibitions of the Act do not apply under the following conditions:

(1) Agency and legislative liaison by its own employees.

(i) The prohibition on the use of appropriated funds, in subparagraph (b)(1) of this clause, does not apply in the case of a payment of reasonable compensation made to an officer or employee of a person requesting or receiving a covered Federal action if the payment is for agency and legislative liaison activities not directly related to a covered Federal action.

(ii) For purposes of subdivision (c)(1)(i) of this clause, providing any information specifically requested by an agency or Congress is permitted at any time.

(iii) The following agency and legislative liaison activities are permitted at any time where they are not related to a specific solicitation for any covered Federal action:

(A) Discussing with an agency the qualities and characteristics (including individual demonstrations) of the person's products or services, conditions or terms of sale, and service capabilities.

(B) Technical discussions and other activities regarding the application or adaptation of the person's products or services for an agency's use.

(iv) The following agency and legislative liaison activities are permitted where they are prior to the Screening Information Request (SIR) of any covered Federal action:

(A) Providing any information not specifically requested but necessary for an agency to make an informed decision about initiation of a covered Federal action;

(B) Technical discussions regarding the preparation of an unsolicited proposal prior to its official submission; and

(C) Capability presentations by persons seeking awards from an agency pursuant to the provisions of a law authorizing such actions;

(2) Professional and technical services.

(i) The prohibition on the use of appropriated funds, in subparagraph (b)(1) of this clause, does not apply in the case of:

(A) A payment of reasonable compensation made to an officer or employee of a person requesting or receiving a covered Federal action or an extension, continuation, renewal, amendment, or modification of a covered Federal action, if payment is for professional or technical services rendered directly in the preparation, submission, or negotiation of submittal/offer or application for that Federal action or for meeting requirements imposed by or pursuant to law as a condition for receiving that Federal action.

(B) Any reasonable payment to a person, other than an officer or employee of a person requesting or receiving a covered Federal action or an extension, continuation, renewal, amendment, or modification of a covered Federal action if the payment is for professional or technical services rendered directly in the preparation, submission, or negotiation of any submittal/offer or application for that Federal action or for meeting requirements imposed by or pursuant to law as a condition for receiving that Federal action. Persons other than officers or employees of a person requesting or receiving a covered Federal action include consultants and trade associations.

(ii) For purposes of subdivision (c)(2)(i) of this clause, 'professional and technical services' must be limited to advice and analysis directly applying any professional or technical discipline. For example, drafting of a legal document accompanying a submittal/offer by a lawyer is allowable.

Similarly, technical advice provided by an engineer on the performance or operational capability of a piece of equipment rendered directly in the negotiation of a contract is allowable. However, communications with the intent to influence made by a professional (such as a licensed lawyer) or a technical person (such as a licensed accountant) are not allowable under this section unless they provide advice and analysis directly applying their professional or technical expertise and unless the advice or analysis is rendered directly and solely in the preparation, submission or negotiation of a covered Federal action. Thus, for example, communications with the intent to influence made by a lawyer that do not provide legal advice or analysis directly and solely related to the legal aspects of his or her client's submittal/offer, but generally advocate one proposal over another are not allowable under this section because the lawyer is not providing professional legal services.

Similarly, communications with the intent to influence made by an engineer providing an engineering analysis prior to the preparation or submission of a submittal/offer are not allowable under this section since the engineer is providing technical services but not directly in the preparation, submission or negotiation of a covered Federal action.

(iii) Requirements imposed by or pursuant to law as a condition for receiving a covered Federal award include those required by law or regulation and any other requirements in the actual award documents.

(iv) The reporting requirements herein must not apply with respect to payments of reasonable compensation made to regularly employed officers or employees of a person.

(3) Only those communications and services expressly authorized by paragraphs (c)(1) and (2) of this clause are permitted under this clause.

(d) Disclosure.

(1) If the Contractor, who requests or receives from an agency a Federal contract, has made or has agreed to make any payment using non-appropriated funds (to include profits from any Covered Federal action), to any person for the purpose of influencing or attempting to influence an officer or employee of any Agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on his or her behalf in connection with a Covered Federal action, the Contractor must file with that agency a disclosure form, OMB Standard Form LLL, Disclosure of Lobbying Activities..

(2) The Contractor must file a disclosure form at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the information contained in any disclosure form previously filed by such person under subparagraph (d)(1) of this clause. An event that materially affects the accuracy of the information reported includes:

(i) A cumulative increase of $25,000 or more in the amount paid or expected to be paid for influencing or attempting to influence a covered Federal action; or

(ii) A change in the person(s) or individual(s) influencing or attempting to influence a covered

Federal action; or

(iii) A change in the officer(s), employee(s), or Member(s) contacted to influence or attempt to influence a covered Federal action.

(3) The Contractor must require the certification, and if required, a disclosure form by any person who requests or receives any subcontractor exceeding $150,000 under the Federal contract.

(4) All subcontractor disclosure forms must be forwarded from tier to tier until received by the prime Contractor. The prime Contractor must submit all disclosures to the Contracting Officer at the end of the calendar quarter in which the disclosure form is submitted by the subcontractor.

(e) Agreement. The Contractor agrees not to make any payment prohibited by this clause.

(f) Penalties.

(1) Any person who makes an expenditure prohibited under paragraph (b) of this clause or fails to file or amend the disclosure form to be filed or amended by paragraph (b) must be subject to civil penalties as provided for by 31 U.S.C. 1352. An imposition of a civil penalty does not prevent the Government from seeking any other remedy that may be applicable.

(2) Contractors may rely without liability on the representations made by their subcontractors in the certification and in the disclosure form.

(g) Cost allowability.