Renovate Temporary Guard Shack for Entrance Ave

GENERAL INFORMATION

NOTE TO OFFERORS: Bids will be accepted via mail (i.e. USPS, FedEx, UPS, DHL, etc.) or hand delivered.

FAXED OR E-MAILED BIDS WILL NOT BE ACCEPTED.

The sealed envelope/package used to submit your bids must show the solicitation number and name and address of offeror.

MAILING ADDRESS: 914 MSG/PK, 2720 Kirkbridge Dr., Bldg 800, Room 1024, Niagara Falls ARS, NY 14304, ATTN: Jason Topick

HAND DELIVERED: 2720 Kirkbridge Dr., Bldg 800, Room 1024, Niagara Falls ARS, NY 14304.

To obtain base access you will need to e-mail name, date of birth, driver licenses number and citizenship to Jason Topick at jason.topick.1@us.af.mil, in advance of when base access is needed. Driver's license, current registration and proof of vehicle insurance is required to drive on base.

Offerors are cautioned that Niagara Falls Air Reserve Station has visitor control procedures requiring individuals not affiliated with the installation to obtain a visitor pass prior to entrance. SOME DELAY SHOULD BE ANTICIPATED WHEN HANDCARRYING BIDS. Offerors should allow sufficient time to obtain a visitor pass and deliver the bid PRIOR to the time specified for receipt. Late bids will be process accordance with FAR 14.304 "Submissions, modifications and withdrawl of Bids."

CONTRACTOR QUALIFICATION

In accordance with FAR 9.104-1, prior to award, the lowest priced bidder must be determined to be responsible by the Contracting Officer. In order to do so, that bidder may be requested to submit additional documentation for review. Information includes, but is not limited to:

a.) Financial ability to perform the contract, including the availability of necessary working capital and credit. Offeror shall furnish a copy of its current financial statement and obtain statements from its bank or banks and/or lending institutions with whom it does business as to its credit and other data deemed pertinent regarding its ability to perform the work;

b.) Business and financial reputation and integrity. Offeror shall furnish Points of Contact, phone numbers, company names and addresses of four or more commercial firms for whom work has been performed recently or is under construction. A brief description of the projects and dollar value of same shall also be furnished. Data on work performed which is similar to the proposed work is preferred.

This information is necessary for determining your responsibility and will not be released outside the Government or made available for inspection by individuals, firms or trade organizations. Prior to determination of responsibility, such data may be discussed with you as deemed necessary prior to award.

.

Niagara Falls Air Reserve Station has a requirement for a Construction project, Renovate Temporary Guard Shack for Entrance Ave.

NOTICE TO OFFERORS: THE GOVERNMENT RESERVES THE RIGHT TO CANCEL THIS SOLICITATION, EITHER BEFORE OR AFTER THE CLOSING DATE. IN THE EVENT THE GOVERNMENT CANCELS THIS SOLICITATION, THE GOVERNMENT HAS NO OBLIGATION TO REIMBURSE AN OFFEROR FOR ANY COSTS.

Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, Renovate Temporary Guard Shack for Entrance Avenue (RVKQ 18-0739), to include the following: The project involves placing and providing electrical service for the project; the Contractor will provide a submittal sketch and narrative description of work to be preformed which will include location and proposed concrete pad to place and anchor the existing over-watch guard building, and provide electrical service from the nearest on base existing source suitable to operate the lights, air conditioner and heater for the structure.

Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY.

Performance time is 60 calendar days.

A single Firm Fixed-Price construction contract will be awarded.

This solicitation is set-aside 100% for Small Businesses (SB).

The estimated magnitude of construction is Less than $25,000.

The NAICS code is 238210 and the Small Business Size Standard is $15,000,000.

Bid, Payment and Performance Bonds will be required.

Liquidated damages will be identified in the solicitation and placed under the proposed contract.

All applicable provisions and clauses will be included in the actual solicitation.

Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit.

The complete solicitation will only be available electronically at http://www.fedbizopps.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates.

Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities.

Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil

This notice does not obligate the Government to award a contract nor does it obligate the Government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned.

Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized. For questions, please contact Jason P. Topick at Jason.topick.1@us.af.mil

.

Niagara Falls Air Reserve Station has a requirement for a Construction project, Renovate Temporary Guard Shack for Entrance Ave.

NOTICE TO OFFERORS: THE GOVERNMENT RESERVES THE RIGHT TO CANCEL THIS SOLICITATION, EITHER BEFORE OR AFTER THE CLOSING DATE. IN THE EVENT THE GOVERNMENT CANCELS THIS SOLICITATION, THE GOVERNMENT HAS NO OBLIGATION TO REIMBURSE AN OFFEROR FOR ANY COSTS.

Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, Renovate Temporary Guard Shack for Entrance Avenue (RVKQ 18-0739), to include the following: The project involves placing and providing electrical service for the project; the Contractor will provide a submittal sketch and narrative description of work to be preformed which will include location and proposed concrete pad to place and anchor the existing over-watch guard building, and provide electrical service from the nearest on base existing source suitable to operate the lights, air conditioner and heater for the structure.

Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY.

Performance time is 60 calendar days.

A single Firm Fixed-Price construction contract will be awarded.

This solicitation is set-aside 100% for Small Businesses (SB).

The estimated magnitude of construction is Less than $25,000.

The NAICS code is 238210 and the Small Business Size Standard is $15,000,000.

Bid, Payment and Performance Bonds will NOT be required.

Liquidated damages will be identified in the solicitation and placed under the proposed contract.

All applicable provisions and clauses will be included in the actual solicitation.

Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit.

The complete solicitation will only be available electronically at http://www.fedbizopps.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates.

Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities.

Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil

This notice does not obligate the Government to award a contract nor does it obligate the Government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned.

Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized. For questions, please contact Jason P. Topick at Jason.topick.1@us.af.mil

.

This is a Pre-Solicitation Notice. This notice does NOT constitute a request for proposal, request for quote or invitation for bid.

Estimated issue date for the solicitation is on or after 16 August 2018, with the solicitation closing approximately 15 days thereafter. It will be issued electronically at the Federal Business Opportunities website http://www.fbo.gov under the reference number FA6670-18-B-0005.

Niagara Falls Air Reserve Station has a requirement for a Construction project, Renovate Temporary Guard Shack for Entrance Ave.

Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, Renovate Temporary Guard Shack for Entrance Avenue (RVKQ 18-0739), to include the following: The project involves placing and providing electrical service for the project; the Contractor will provide a submittal sketch and narrative description of work to be preformed which will include location and proposed concrete pad to place and anchor the existing over-watch guard building, and provide electrical service from the nearest on base existing source suitable to operate the lights, air conditioner and heater for the structure.

Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY.

Performance time is 60 calendar days.

A single Firm Fixed-Price construction contract will be awarded.

This solicitation is set-aside 100% for Small Businesses (SB).

The estimated magnitude of construction is Less than $25,000.

The NAICS code is 238210 and the Small Business Size Standard is $15,000,000.

Bid, Payment and Performance Bonds will NOT be required.

Liquidated damages will be identified in the solicitation and placed under the proposed contract.

All applicable provisions and clauses will be included in the actual solicitation.

Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit.

The complete solicitation will only be available electronically at http://www.fedbizopps.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates.

Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities.

Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil

This notice does not obligate the Government to award a contract nor does it obligate the Government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned.

Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized. For questions, please contact Jason P. Topick at Jason.topick.1@us.af.mil

.