W912P920R0060 - Attachment 4 - Specifications - Amendment 0002.pdf

Amendment 0002

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 08 00

SPECIAL CONTRACT REQUIREMENTS

PART 1 GENERAL

1.1 PAY REQUESTS

1.2 RIGHT-OF-WAY

1.3 PUBLIC UTILITIES AND PRIVATE IMPROVEMENTS

1.4 DAMAGE TO WORK.

1.5 QUANTITY SURVEYS

1.6 PARTIAL PAYMENT

1.7 CERTIFICATES OF COMPLIANCE

1.8 PURCHASE ORDERS

1.9 SAFETY AND HEALTH REQUIREMENTS MANUAL EM 385-1-1

1.10 ACCIDENT INVESTIGATIONS AND REPORTING

1.11 <SUB>ACCIDENT PREVENTION PROGRAM</SUB>

1.12 DAILY INSPECTIONS

1.13 ENVIRONMENTAL LITIGATION

1.14 SUBCONTRACTS

1.15 REQUIRED INSURANCE - WORK ON A NON-GOVERNMENT INSTALLATION.

1.16 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.17 SEVERE WEATHER LIMITATIONS

1.18 PROTECTION OF MATERIAL AND WORK

1.19 CONTAMINATION OF WATER

1.20 COMMERCIAL WARRANTY

1.21 ORDER AND COORDINATION OF WORK

1.22 SUBMITTALS

1.23 STONE SOURCES

1.24 CONTRACTOR PERFORMANCE EVALUATIONS

1.25 SECURITY REQUIREMENTS

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

DOCUMENT 00 08 00 Page 1

SECTION 00 08 00

SPECIAL CONTRACT REQUIREMENTS

PART 1 GENERAL

1.1 PAY REQUESTS

Pay requests authorized in the Contract Clause entitled "Payments Under Fixed-Price Construction Contracts", will be paid pursuant to the clause entitled "Prompt Payment for Construction Contracts". Pay requests shall be submitted on ENG Form 93 and 93a, "Payment Estimate-Contract Performance" and "Continuation", respectively. All information and substantiation required by the identified contract clauses shall be submitted with the ENG Form 93, and the required certification shall be included on the last page of the ENG Form 93a, signed by an authorized official of the Contractor and dated when signed. The designated billing office is the Office of the Area Engineer.

1.2 RIGHT-OF-WAY

Right-of-way for construction purposes will be furnished by the Government without cost to the Contractor. Where right-of-way for access to a work site is not available over existing public roads, access through private lands as shown on the contract drawings will be furnished by the Government without cost to the Contractor. The Contractor will be required at its own expense to do all work necessary to make such right-of-way suitable for traveling to and from the work site without interrupting the existing drainage. Upon completion of the contract work, any such access roadway and right-of-way furnished by the Government shall be left in a condition satisfactory to the Contracting Officer.

1.3 PUBLIC UTILITIES AND PRIVATE IMPROVEMENTS

a. Unless otherwise specified, shown on the drawings, or stated in writing by the Contracting Officer, the Contractor shall not move or disturb any public utilities or private improvements. Such removals, alterations, and/or relocations, where necessary, will be made by others. The locations shown on the drawings for underground utilities are approximate only. The exact locations of such utilities shall be determined by the Contractor in the field prior to commencing construction operations in their vicinity.

b. The attention of the Contractor is directed to the possibility that public utilities or private improvements may be encountered within the construction limits, some of which may be buried, and the existence of which is presently not known. Should any such utilities or improvements be encountered, the Contractor shall immediately notify the Contracting Officer so that a determination may be made as to whether they shall be removed, relocated, or altered. After such determination is made, the Contractor shall, if so directed by the Contracting Officer, remove, relocate, or alter them as required and an equitable adjustment will be made. In the event the Contracting Officer arranges for such removals, alterations, or relocations to be performed by others, the Contractor shall cooperate with such others during the latters' removal, alteration, or relocation operations.

DOCUMENT 00 08 00 Page 2

1.4 DAMAGE TO WORK.

The responsibility for damage to any part of the permanent work shall be as set forth in the Contract Clause entitled "Permits and Responsibilities." However, if in the judgment of the Contracting Officer any part of the permanent work performed by the Contractor is damaged by flood or earthquake, which damage is not due to the failure of the Contractor to take reasonable precautions or to exercise sound engineering and construction practices in the conduct of the work, the Contractor shall make the repairs as ordered by the Contracting Officer and full compensation for such repairs will be made at the applicable contract unit or job prices as fixed and established in the contract. If in the opinion of the Contracting Officer there are no contract unit or lump sum prices applicable to any part of such work, an equitable adjustment pursuant to the Contract Clause entitled, "Changes," of the contract will be made as full compensation for the repairs of that part of the permanent work for which there are no applicable contract unit or lump sum prices. Except as herein provided, damage to all work (including temporary construction), utilities, materials, equipment, and plant shall be repaired to the satisfaction of the Contracting Officer at the Contractor's expense, regardless of the cause of such damage.

1.5 QUANTITY SURVEYS

The Contractor shall have a Professional Land Surveyor registered in the state the work is being accomplished conduct original and final earthwork surveys. Surveys shall be performed in the presence of the Contracting Officer and all field survey notes be initialed by the Government Representative and furnished to the Government within 24 hours unless directed otherwise by the Contracting Officer.

1.6 PARTIAL PAYMENT

At the discretion of the Contracting Officer, partial payment will be made for equipment delivered and stored on site or off site providing such storage is in accordance with the provisions of these specifications and the Contractor furnishes satisfactory evidence that title to such equipment has been acquired and that it will be utilized on the work covered by these specifications. Partial payment is defined as the invoice amount plus shipping costs. If the equipment is stored off site, the Government shall have the right to inspect the equipment.

1.7 CERTIFICATES OF COMPLIANCE

Any certificates required for demonstrating proof of compliance of materials with specification requirements shall include the signature and title of an official authorized to certify in behalf of the manufacturing company and shall contain the name and address of the Contractor, the project name and location, and the quantity and date or dates of shipment or delivery to which the certificates apply. Copies of laboratory test reports submitted with certificates shall contain the name and address of the testing laboratory and the date or dates of the tests to which the report applies. Certification shall not be construed as relieving the Contractor from responsibility for furnishing satisfactory material if, after tests are performed on selected samples, the material is found not to meet the specific requirements.

DOCUMENT 00 08 00 Page 3

1.8 PURCHASE ORDERS

Purchase orders for other than stock materials showing the firm names and addresses and list of material shall be furnished to the Contracting Officer or an authorized representative as soon as issued.

1.9 SAFETY AND HEALTH REQUIREMENTS MANUAL EM 385-1-1

The Safety and Health Requirements Manual EM 385-1-1 forms a part of these specifications. EM 385-1-1 and its changes are available at http://www.publications.usace.army.mil/USACEPublications/Engineer-Manuals/ .

Contractor shall be responsible for complying with the current edition and all changes posted on the web as of the effective date of this solicitation.

1.10 ACCIDENT INVESTIGATIONS AND REPORTING

Refer to EM 385-1-1, Paragraph 01.D. Accidents, involving contractor and/or subcontractor employees performing any work or related work on a USACE project, shall be investigated and reported immediately to the Contracting Officer or authorized Contracting Officer's representative.

This reporting requirement applies to on-site or off-site accidents. Upon receipt of the initial accident report notification, the Contracting Officer shall issue additional guidance concerning continuing project operations which may include a "cease work" directive. If a cease work directive is issued, the Contractor will not be allowed to resume work related to the accident until all conditions of the "cease work" directive are met. After the initial notification, the Contractor shall ensure a formal investigation is conducted and reports are completed by the immediate supervisor of the employee(s) involved and reported to the Contracting Officer or an authorized representative within one working day after the accident occurs. The accident Investigation report shall be made on ENG Form 3394.

1.11 ACCIDENT PREVENTION PROGRAM

Refer to Contract Clause FAR 52.236-13 entitled, "Accident Prevention".

Within 5 days after receipt of Notice to Proceed of the contract, and at least 7 days prior to the prework conference, the original and one copy of the Accident Prevention Program shall be submitted to the Contracting Officer for review. See EM 385-1-1 Appendix A (2014 Edition) and checklist included at the end of this section for guidance in creating the Accident Prevention Plan.

The program shall also include a copy of company policy statement of accident prevention and any other guidance statements normally provided new employees. Each company employee shall be required to sign the company policy statement of accident prevention to verify that all employees have been informed of the safety program, and such signed statements shall be maintained at the project site.

When marine plant and equipment are in use under this contract, the requirements of EM 385-1-1, Section 19 shall be met.

The Contractor shall not commence physical work at the site until the program has been reviewed and found acceptable by the Contracting Officer, or an authorized representative. The Contractor shall submit for approval the Activity Hazard Analysis for each phase of construction prior to the beginning of work in each phase. Also refer to Section 1 of EM 385-1-1.

DOCUMENT 00 08 00 Page 4

1.12 DAILY INSPECTIONS

The Contractor shall perform daily safety inspections and record them in RMS. Reports of daily inspections shall be maintained at the job site.

The reports shall be records of the daily inspections and resulting actions. Each report shall include, as a minimum, the following:

a. Phase(s) of construction underway during the inspection.

b. Locations of areas inspections were made.

c. Results of inspection, including nature of deficiencies observed and corrective actions taken, or to be taken, date, and signature of the person responsible for its contents.

1.13 ENVIRONMENTAL LITIGATION

a. If the performance of all or any part of the work is ordered by a court of competent jurisdiction to be suspended, delayed, or interrupted as a result of environmental litigation, as defined below, the Contracting Officer, at the request of the Contractor, shall determine whether the order is due in any part to the acts or omissions of the Contractor or a Subcontractor at any tier not required by the terms of this contract. If it is determined that the order is not due in any part to acts or omissions of the Contractor or a Subcontractor at any tier other than as required by the terms of this contract, such suspension, delay, or interruption shall be considered as if ordered by the Contracting Officer in the administration of this contract under the terms of the Contract Clause entitled "Suspension of Work".

b. The term "environmental litigation", as used herein, means a lawsuit alleging that the work will have an adverse effect on the environment or that the Government has not duly considered, either substantively or procedurally, the effect of the work on the environment.

1.14 SUBCONTRACTS

In accordance with the Contract Clause entitled "Subcontracts", the Contractor shall, within seven days after the award of any subcontract by the Contractor or a Subcontractor, deliver to the Contracting Officer an electronic copy of a completed Standard Form 1413 with the original signatures of both parties.

1.15 REQUIRED INSURANCE - WORK ON A NON-GOVERNMENT INSTALLATION.

a. The Contractor shall, at its own expense, provide and maintain during the entire performance period of this contract at least the kinds and minimum amounts of insurance required in the following schedule:

(1) Workmen's Compensation . Amounts required by applicable jurisdictional statutes.

(2) Employer's Liability Insurance . $100,000

(3) Comprehensive General Liability Insurance .

DOCUMENT 00 08 00 Page 5

Bodily Injury - $500,000 per occurrence

(4) Comprehensive Automobile Insurance .

Bodily Injury - $200,000 each person $500,000 each accident Property Damage - $ 20,000 each accident

b. Within 15 days after receipt of Notice of Award and before commencing work under this contract, the Contractor shall notify the Contracting Officer in writing that the required insurance has been obtained. The policies evidencing required insurance shall contain an endorsement to the effect that any cancellation or any material change adversely affecting the Government's interest shall not be effective

(1) for such period as the laws of the State in which this contract is to be performed prescribe, or (2) until 30 days after the insurer or the Contractor gives written notice to the Contracting Officer, whichever period is longer.

c. The Contractor shall insert the substance of this clause, including this paragraph c, in subcontracts under this contract and shall require subcontractors to provide and maintain the insurance required in paragraph a above. The Contractor shall maintain a copy of all subcontractor's proofs of required insurance, and shall make copies available to the Contracting Officer upon request.

d. Statements of required insurance should be submitted to the following address:

Department of the Army St. Louis District, Corps of Engineers Central Area Office; CEMVS-EC-CA 1222 Spruce Street St. Louis, Missouri 63103

1.16 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the Contract Clause entitled, "Default (Fixed-Price Construction)". In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

b. Upon acknowledgement of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor shall record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled work day. The delay must be beyond the control

DOCUMENT 00 08 00 Page 6 and without the fault or negligence of the Contractor. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous day), be calculated chronologically from the first to the last day of each month, and be recorded as full days. The Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a time extension modification in accordance with the FAR Clause 52.249-10 entitled "Default (Fixed Price Construction)".

1.17 SEVERE WEATHER LIMITATIONS

When construction operations are prevented due to severe weather conditions and/or site flooding, the Contracting Officer will determine the extent of the delay to the work as a whole, and the time fixed for completion of the contract will be extended for the period of such delay.

1.18 PROTECTION OF MATERIAL AND WORK

The Contractor shall at all times protect and preserve all materials, supplies, and equipment of every description (including property which may be Government-furnished or owned) and all work performed. All reasonable requests of the Contracting Officer to enclose or specially protect such property shall be complied with. If, as determined by the Contracting Officer, material, equipment, supplies, and work performed are not adequately protected by the Contractor, such property may be protected by the Government and the cost thereof may be charged to the Contractor or deducted from any payments due to the Contractor.

1.19 CONTAMINATION OF WATER

In addition to the requirements set forth in SECTION 01 11 30, paragraph Protection of Water Resources, the Contractor shall take positive protective measures to prevent spillage of potential pollutant materials such as fuel, emulsion materials, chemicals etc., from storage containers or equipment, into lakes or tributary waters. Such positive protective measures may include, but are not limited to, the following:

(1) A berm enclosure of sufficient capacity to contain such materials.

(2) Security measures to prevent acts of vandalism which could result in spillage of such materials (fences, guards, etc.).

(3) Storage of such materials in an area where the terrain would preclude leakage into lake or tributary waters.

(4) Utilization of secure Government storage areas if the Contracting Officer indicates such space is available. No storage past immediate needs (2 days) without the consent of the Contracting Officer.

The Contractor shall submit its proposals for implementing the above provisions in accordance with SECTION 01 11 30, paragraph Environmental Protection Plan.

1.20 COMMERCIAL WARRANTY

The Contractor agrees that the standard commercial equipment furnished under this contract shall be covered by the most favorable commercial warranties the manufacturer gives to any customer for such equipment, and

DOCUMENT 00 08 00 Page 7 that the rights and remedies provided herein are in addition to and do not limit any rights afforded to the Government by any other clause of this contract. The Contractor shall furnish 2 hard copies or an electronic copy of the warranties to the Contracting Officer.

1.21 ORDER AND COORDINATION OF WORK

The Contractor may start and complete the work in such order and sequence as desired subject to compliance with the following paragraphs:

(a) General.

(1) The Contractor shall order construction activities to ensure efficient scheduling of resources, subject to Approval of the Construction Schedule in accordance with SECTION 01 13 20. Many construction activities are likely to require concurrent operations to efficiently complete work, maintain construction access, and reuse materials on site as described in the Plans and Specifications.

(2) The contractor shall sequence construction to prevent damage due to flooding of incomplete features of work to the extent practicable.

(3) The failing stream banks may present a specific hazard when working nearby, and require preliminary Sloping and/or Benching, offsets, and other actions to conform to EM 385-1-1.

(b) Access and Staging Areas.

(1) Access routes, haul routes, and staging areas shall be video-recorded prior to the start of work to capture the pre-construction condition.

(2) The contractor shall surface and dress all existing driveways used for access with appropriate sized crushed limestone material to facilitate construction access and restore for landowner use.

(3) All temporary access routes and staging areas will be surfaced or covered to prevent rutting, piping, pumping or other forms of damage to the underlying soil. These areas shall be returned to the pre-construction conditions unless approved in writing by the contracting officer. USACE will coordinate with the appropriate landowner for such determinations.

(c) Prevention of Spread of Invasive Species.

(1) Inspect and remove weed seeds, plant parts, and/or zebra mussels on all construction equipment, vehicles, and trailers prior to bringing them onto the job site. Wash, including the undercarriage, if necessary.

(2) Inspect and remove weed seeds, plant material and/or zebra mussels on all construction equipment before being taken off the job site. If necessary use an air compressor to blow clean this material. This should be done where equipment is unloaded or loaded, or at areas that can be easily monitored such as a road, trail head, or parking lot.

(3) Do not clean equipment, vehicles, or trailers in waterways.

DOCUMENT 00 08 00 Page 8

(d) If conditions threaten to flood the construction area, the Contracting Officer may direct the Contractor to temporarily cease operations. In the event of a cease of work caused by flooding, the Contracting Officer will determine the extent of the delay to the work due to high river stages, and the time fixed for completion of the contract will be extended for the period of the time delay, in accordance with Section 00700, Contract Clause entitled, "Default".

(e) Coordination with USEPA and the landowners should be through USACE and the following point of contact:

Greg Bach Remedial Project Manager Superfund Division, EPA Region 7 bach.greg@epa.gov 913/551-7291

(f) Environmental Limitations.

(1) Archaeological Monitoring. See SECTION 01 11 30 for archaeological monitoring requirements.

(2) Indiana and Northern long-eared Bat Habitat. Clearing of trees greater than 3 inch diameter at breast height shall not be performed during the period between 1 April and 31 October unless otherwise approved by the Contracting Officer. Approval by the Contracting Officer may be granted after appropriate coordination by St. Louis District with the U.S. Fish and Wildlife Service has been conducted, and it is determined that clearing can be performed without impacting trees suitable for Indiana bat habitat. In the event bats or habitat could be impacted, the time fixed for completion of the contract will be extended for the period of the time delay for Government mitigation of the presence of bats or habitat.

(3) Bald Eagle Roosts. There are no known Bald Eagle nests in close proximity to the project area. Should bald eagle nesting activity be observed, the Contractor shall contact the Contracting Officer immediately to determine if any buffer zones or access restrictions will be required for construction operations. The time fixed for completion of the contract will be extended for the period of the time delay for work impacted by any restrictions. Should nesting activity be found in the vicinity of work, the following restrictions will be required:

(i) The contractor shall inform the contracting officer of any potential nesting activity within the construction footprint, or if a nest appears to no longer be active or is not occupied by April 15th;

the contracting officer shall provide written determination of any additional nesting trees or any reduction to current limitations.

(ii) If any new roosting trees are found within the construction limits, avoid damaging the critical root zone of the bald eagle nest tree as defined by the circle around the ground corresponding to the drip line of the bald eagle nest tree, or out to a distance of 1.5 feet per inch of diameter at breast height (DBH), whichever is greater. Where possible, leave mature roosting trees intact.

DOCUMENT 00 08 00 Page 9

(iii) No construction equipment shall be staged within 330 feet of the bald eagle nest tree. Sequence project activities in a manner where work within the 330 foot buffer of the bald eagle nest can be completed as quickly as possible.

(iv) Where possible, equipment will drive past the bald eagle nest tree without stopping and at a constant speed.

(v) Plastic netting shall not be used for any activities -including erosion control - to prevent bald eagle entanglement.

(vi) During bald eagle breeding season (November 15 through August 31), project work within the 330 foot buffer around the bald eagle nest will not start until 1 hour after sunrise and will end 1 hour before sunset to reduce ambient temperatures effect on bald eaglets if their parents flush. This measure is no longer necessary if high temperature for the day reaches 50 degrees F for two days in a row or the bald eagle nest is confirmed not active any given year (as evidenced by an absence of bald eagles from their nests for ten consecutive days during the bald eagle breeding season).

(g) Final Survey. The contractor shall provide surveys of completed features prior to final acceptance. Such surveys will be used to document the as-built condition and ensure features are within design tolerances.

1.22 SUBMITTALS

Additional submittals for this contract that are not listed within individual technical provisions are listed below. Government approval is required for submittals with a "G" designation; submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 - SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Accident Prevention Program; G Statements of Required Insurance; G

SD-06 Test Reports

Ledge Testing; G

1.23 STONE SOURCES

a. On the basis of information and data available to the Contracting Officer, stone meeting the quality requirements of these specifications has been produced from the sources listed at the end of these Special Clauses.

b. Stone may be furnished from any of the currently listed sources or, at the option of the Contractor, may be furnished from any other source designated by the Contractor and accepted by the Contracting Officer, subject to the conditions hereinafter stated.

c. It is the Contractor's responsibility to determine that the stone source or combination of sources selected are capable of supplying the

DOCUMENT 00 08 00 Page 10 quantities and gradation needed and at the rate needed to maintain the scheduled progress of the work.

d. After the award of the contract, the Contractor shall designate in writing only one source or one combination of sources from which stone will be furnished. If the Contractor proposes to furnish stone from a source not currently listed, only a single additional source for stone may be designated. Samples for acceptance testing shall be provided as required by SECTION 31 37 00.00 09. If a source for stone so designated by the Contractor is not accepted for use by the Contracting Officer, the Contractor may not propose other sources but shall furnish the stone from a source listed at no additional cost to the Government.

e. Acceptance of a source of stone is not to be construed as acceptance of all material from that source. The right is reserved to reject materials from certain localized areas, zones, strata, or channels when such materials are unsuitable for stone as determined by the Contracting Officer. Materials produced from a listed or unlisted source shall meet all the requirements of SECTION 31 37 00.00 09, of the Technical Provisions of these specifications.

f. If the Contractor proposes to furnish stone from a source or sources listed, he shall submit Department of transportation ledge testing information from within the past 12 months. Selected ledge or ledges for producing crushed stone shall meet the following MINIMUM requirements: Stone shall weigh more than 155 lbs/cubic foot. The stone shall also have an absorption less than 2 percent. The Contractor shall also schedule a site visit to the quarry to inspect the proposed ledge(s) that stone will be produced. The Government shall be included in the scheduling of the site visit and a minimum 72-hour notice shall be given.

1.24 CONTRACTOR PERFORMANCE EVALUATIONS

In accordance with the provisions of Subpart 36.201(Evaluation of Contractor Performance) of the Federal Acquisition Regulation (FAR), construction contractor's performance shall be evaluated throughout the performance of the contract. The United States Army Corps of Engineers (USACE) follows the procedures outlined in Engineering Regulation 415-1-17 to fulfill this FAR requirement. For construction contracts awarded at or above $100,000.00, the USACE will evaluate contractor's performance and prepare a performance report using the Contractor Performance Assessment Reporting System (CPARS), which is a web-based system. After an evaluation (interim or final) is written up by the USACE, the contractor will have the ability to access, review and comment on the evaluation for a period of 30 days. Accessing and using CPARS requires specific software, called PKI certification, which is installed on the user's computer. The certification is a Department of Defense requirement and was implemented to provide security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and is purchased from an External Certificate Authorities (ECA) vendor.

Current information about the PKI certification process and for contacting vendors can be found on the web site: http://www.cpars.navy.mil/. If the Contractor wishes to participate in the performance evaluation process, access to CPARS and PKI certification is the sole responsibility of the Contractor.

DOCUMENT 00 08 00 Page 11

1.25 SECURITY REQUIREMENTS

a. All contractor and all associated sub-contractors employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative). The contractor shall also provide all information required for background checks to meet installation/facility access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9, Personal Identity Verification of Contractor Personnel) as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any installation or facility change, the Government may require changes in contractor security matters or processes.

b. The contractor and all associated sub-contractors shall receive a brief/training (provided by the RA) on the local suspicious activity reporting program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the project manager, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the COR NLT 5 calendar days after the completion of the training.

c. The Contractor must pre-screen Candidates using the E-verify Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

DOCUMENT 00 08 00 Page 12