RTA_Package-17-B-0010-CHGO_HARBOR_BREAKWATER-IFB.pdf

CHICAGO DISTRICT

LEADERS IN CUSTOMER CARE

CHICAGO HARBOR

BREAKWATER REPAIR

REACH C - FY17

CHICAGO, ILLINOIS

CONSTRUCTION SOLICITATION

AND SPECIFICATIONS

Certified Final Documents –

RTA W912P6-17-B-0010

August 17, 2017

Chicago Harbor Breakwater Repair Reach C - FY17 W912P6-17-B-0010

PROJECT TABLE OF CONTENTS

SECTION UU UUTITLE UU

DIVISION 00 - PROCUREMENT & CONTRACTING REQUIREMENTS

00010 SOLICITATION, OFFER AND AWARD (SF 1442)* & BIDDING SCHEDULE

00100 INSTRUCTIONS, CONDITIONS, AND NOTICES TO BIDDERS

00600 REPRESENTATIONS, CERTIFICATIONS, AND OTHER STATEMENTS OF BIDDERS

00700 CONTRACT CLAUSES

00800 SPECIAL CONTRACT REQUIREMENTS

WAGE RATES

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 31 00 PREVIOUS PROJECT REPORTS

DIVISION 01 - GENERAL REQUIREMENTS

01 10 00 GENERAL PROVISIONS

01 11 00 SUMMARY OF WORK

01 22 00.00 10 PRICE AND PAYMENT

01 32 17.00 20 COST LOADED NETWORK ANALYSIS SCHEDULES (NAS)

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 10 QUALITY CONTROL

01 45 00.15 10 RESIDNET MANAGEMENT SYSTEM CONTRACTOR MODE(RMS CM)

01 52 02 TEMPORARY CONSTRUCTION FACILITIES

01 57 20.01 ENVIRONMENTAL PROTECTION FOR ILLINOIS

01 78 00 CLOSEOUT SUBMITTALS

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

35 31 25 TIMBER CRIB BREAKWATER REPAIR

-- End of Project Table of Contents –

W81G6671708306

PROJECT TITLE: CHICAGO HARBOR BREAKWATER REPAIR - CHICAGO HARBOR, ILLINOIS

PROJECT DESCRIPTION: Under the contract, the government w ill require repairs to approximately 30 sections of the exisiting Breakw ater strucutre that consist of drilling and grouting. The structure is composed of sections that are approximately 34' in length. Chicago Harbor is located in the Chicago Harbor in Cook County Illinois.

COMPETITION FOR THIS ACQUISITION IS RESTRICTED TO CERTIFIED HUBZONE SMALL BUSINESSES.

The North American Industry Classif ication System Code (NAICS) is 237990, w ith a size standard of $36.5M

Estimated Cost for Construction is betw een $1M and $5M.

Applicable Wage Rates: Wage Rate Determination Number IL170018, dated 04/07/2017 and IL170009, dated 08/04/2017.

ELECTRONIC OR FAXED BIDS WILL NOT BE ACCEPTED.

IN THIS SOLICITATION, WHEREIN STATED "OFFER", IT MEANS "BID" OR WHERE STATED "OFFEROR", IT MEANS BIDDER.

X

KIMBERLY F HUBBARD (312) 846-5368

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

22-Aug-2017

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________365 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________SECTION 00700

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________22 Sep 2017 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

U. S. ARMY ENGINEER DISTRICT, CHICAGO

231 SOUTH LASALLE STREET SUITE 1500

CHICAGO IL 60604-1437

W912P6

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour) Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W912P617B0010 57

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued)

(Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W912P617B0010

Section 00010 - Solicitation Contract Form

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job

MOBILIZATION

FFP

Under this CLIN, the contractor is required to perform mobilization activities. The contractor will be compensated for the totality of its activities needed to mobilize its equipment and labor force to the project site.

Payment Provisions:

The Government will pay all costs for the mobilization of all of the Contractor's plant and equipment at the unit price for this item. The Contracting Officer or its Representative may require the Contractor to furnish cost data to justify its bid price for this item if the Contracting Officer deems there's no reasonable relationship to the cost of the work in this contract. Failure to justify the line item price to the satisfaction of the Contracting Officer will result in payment determined by the Contracting Officer of the actual costs, which is not subject to appeal.

PURCHASE REQUEST NUMBER: W81G6671708306

NET AMT

0002 1 Job

DEMOBILIZATION

FFP

Under this CLIN, the contractor is required to perform demobilization activities.

The contractor will be compensated for the totality of its activities needed to demobilize its equipment and labor force to the project site.

Payment Provisions:

The Government will pay all costs for the demobilization of all of the Contractor's plant and equipment at the unit price for this item. The Contracting Officer or its Representative may require the Contractor to furnish cost data to justify its bid price for this item if the Contracting Officer deems there's no reasonable relationship to the cost of the work in this contract. Failure to justify the line item price to the satisfaction of the Contracting Officer will result in payment determined by the Contracting Officer of the actual costs, which is not subject to appeal.

0003 625 Each

DRILL GROUT HOLES

FFP

0004 30 Each

DRILL CORE HOLES

0005 1,750 Cubic

Yard

GROUT - INTERIOR CRIB MIX

0006 650 Cubic

GROUT - SODIUM SILICATE MIX

0007 1 Lot

PERFORMANCE AND PAYMENT BOND

FFP

BONDS FOR LINE ITEMS 0001 THROUGH 0006

THIS IS A COST-REIMBURSABLE LINE ITEM –

The Government will reimburse the Contractor for the actual cost of acceptable performance and payments bonds, upon receiving evidence of payment (paid invoice) from the bonding company or agency, not to exceed the total amount of the contract line item. The Government will not pay more than the total line item amount for the performance and payment bonds. If the actual cost of the bonds is less than the line item amount, the contract will modified to adjust the line item accordingly. Adjustment(s) to the line item will also be made for any revisions to the actual bond costs associated with contract changes.

OPTION PRIORITY 1 WORK–BREAKWATER STABILIZATION

FFP

OPTION #1 BID ITEMS (PRIORITY #1 WORK ITEMS)

This is a Parent Line Item identifying the work related directly OPTION #1 BID ITEMS (PRIORITY 1 work items) which include Sub-Items 0008AA through 0008AE. The Sub-line items themselves identify the quantities required to perform said work. Therefore, the Contractor shall provide its pricing separately at Sub-items 0008AA through 0008AE.

0008AA 95 Each

OPTION DRILL GROUT HOLES

0008AB 5 Each

OPTION DRILL CORE HOLES

0008AC 260 Cubic

OPTION GROUT - INTERIOR CRIB MIX

0008AD 100 Cubic

OPTION GROUT - SODIUM SILICATE MIX

0008AE 1 Lot

OPTION PERFORMANCE AND PAYMENT BOND(PRIORITY 1)

BONDS FOR OPTION LINE ITEMS 0008AA THROUGH 0008AD

THIS IS A COST-REIMBURSABLE LINE ITEM - The Government will reimburse the Contractor for the actual cost of acceptable performance and payments bonds, upon receiving evidence of payment (paid invoice) from the bonding company or agency, not to exceed the total amount of the contract line item. The Government will not pay more than the total line item amount for the performance and payment bonds. If the actual cost of the bonds is less than the line item amount, the contract will modified to adjust the line item accordingly.

Adjustment(s) to the line item will also be made for any revisions to the actual bond costs associated with contract changes.

OPTION PRIORITY 2 WORK–BREAKWATER STABILIZATION

FFP

OPTION #2 BID ITEMS (PRIORITY #2 WORK ITEMS)

This is a Parent Line Item identifying the work related directly OPTION #2 BID ITEMS (PRIORITY 2 work items) which include Sub-Items 0009AA through 0009AE. The Sub-line items themselves identify the quantities required to perform items 0009AA through 0009AE.

0009AA 95 Each

0009AB 5 Each

0009AC 260 Cubic

0009AD 100 Cubic

0009AE 1 Lot

OPTION PERFORMANCE AND PAYMENT BOND(PRIORITY 2)

FFP

BONDS FOR OPTION LINE ITEMS 0009AA THROUGH 0009AD

THIS IS A COST-REIMBURSABLE LINE ITEM - The Government will reimburse the Contractor for the actual cost of acceptable performance and payments bonds, upon receiving evidence of payment (paid invoice) from the bonding company or agency, not to exceed the total amount of the contract line item. The Government will not pay more than the total line item amount for the performance and payment bonds. If the actual cost of the bonds is less than the line item amount, the contract will modified to adjust the line item accordingly.

OPTION PRIORITY 3 WORK–BREAKWATER STABILIZATION

FFP

OPTION #3 BID ITEMS (PRIORITY #3 WORK ITEMS)

This is a Parent Line Item identifying the work related directly OPTION #3 BID ITEMS (PRIORITY 3 work items) which include Sub-Items 0010AA through 0010AE. The Sub-line items themselves identify the quantities required to perform items 0010AA through 0010AE.

0010AA 95 Each

0010AB 5 Each

0010AC 260 Cubic

0010AD 100 Cubic

0010AE 1 Lot

OPTION PERFORMANCE AND PAYMENT BOND(PRIORITY3 )

FFP

BONDS FOR OPTION LINE ITEMS 0010AA THROUGH 0010AD

THIS IS A COST-REIMBURSABLE LINE ITEM - The Government will reimburse the Contractor for the actual cost of acceptable performance and payments bonds, upon receiving evidence of payment (paid invoice) from the bonding company or agency, not to exceed the total amount of the contract line item. The Government will not pay more than the total line item amount for the performance and payment bonds. If the actual cost of the bonds is less than the line item amount, the contract will modified to adjust the line item accordingly.

OPTION PRIORITY 4 WORK–BREAKWATER STABILIZATION

FFP

OPTION #4 BID ITEMS (PRIORITY #4 WORK ITEMS)

This is a Parent Line Item identifying the work related directly OPTION #4 BID ITEMS (PRIORITY 4 work items) which include Sub-Items 0011AA through 0011AE. The Sub-line items themselves identify the quantities required to perform items 0011AA through 0011AE.

0011AA 95 Each

0011AB 5 Each

0011AC 260 Cubic

0011AD 100 Cubic

0011AE 1 Lot

OPTION PERFORMANCE AND PAYMENT BOND(PRIORITY 4)

BONDS FOR OPTION LINE ITEMS 0011AA THROUGH 0011AD

THIS IS A COST-REIMBURSABLE LINE ITEM - The Government will reimburse the Contractor for the actual cost of acceptable performance and payments bonds, upon receiving evidence of payment (paid invoice) from the bonding company or agency, not to exceed the total amount of the contract line item. The Government will not pay more than the total line item amount for the performance and payment bonds. If the actual cost of the bonds is less than the line item amount, the contract will modified to adjust the line item accordingly.

BID PRICING:

SUM FOR BASE BID ITEMS 0001 THROUGH 0007

SUM FOR OPTION 1 BID ITEMS (PRIORITY 1 WORK ITEMS 0008AA THROUGH

0008AE)

SUM FOR OPTION 2 BID ITEMS (PRIORITY 2 WORK ITEMS 0009AA THROUGH

0009AE)

SUM FOR OPTION 3 BID ITEMS (PRIORITY 3 WORK ITEMS 0010AA THROUGH

0010AE)

SUM FOR OPTION 4 BID ITEMS (PRIORITY 4 WORK ITEMS 0011AA THROUGH

0011AE)

TOTAL OVERALL BID PRICE, ITEMS 0001 THROUGH 0011AE

(Inclusive of all biddable items and Sub-Items)

Section 00100 - Bidding Schedule/Instructions to Bidders

IMPORTANT NOTES TO BIDDERS

1. BID CONDITIONS:

a. The Contractor shall bid ALL items including the option items contained in the Bid Schedule, with no exceptions. Should a Contractor fail to fully complete the bid schedule, its bid may be considered non-responsive to the solicitation and In-eligible for the resultant contract award. Therefore, the bidder’s total price for the work shall be based on the TOTAL of all BID items included in the Bid Schedule. The Contractor shall enter both its unit prices and extended prices for each Bid Item and the Option Items.

b. The Government intends to award all Base Bid Items to the responsive, responsible bidder.

Award will be based upon the bidder submitting the lowest aggregate price for all items in the bid schedule, including the option items.

c. Split or multiple awards will not result from this solicitation.

2. OPTION PROVISIONS for Option Items 0008AA-0008AE (Priority 1 WORK ITEMS); 0009AA-0009AE (Priority 2 WORK ITEMS); 0010AA-0010AE (Priority 3 WORK ITEMS), AND 0011AA-0011AE (Priority 4

WORK ITEMS) -

AWARD OF PRIORITIZED OPTIONS: Options that are prioritized, if exercised, will be awarded in sequential order beginning with any Sub-Item included under Priority 1 Work Items (0008AA through 0008AE). Under this scenario, any Sub-Item within 0008AA through 0008AE would be awarded prior to all other options under the Bid Schedule. However, the government may award all options at once, but, in no case will the priorities be awarded out of sequence (e.g. if awarded by separate Contract modifications). If awarded simultaneously, priority 1 work shall be accomplished after the base work has been fully executed and shall proceed prior to any work being initiated for Priority 2 work, so forth and on until reaching Priority 4 work.

EXERCISE OF OPTION ITEMS: At the government's discretion, any, all or none of the Options Items under the Bid Schedule may be awarded NO LATER THAN 180 calendar days from the date the Contractor acknowledges the Notice to Proceed; this means, any option under the schedule must be awarded within this timeframe regardless of their priority. If any of the Options are awarded, no additional time or time extension would be added to the Contract performance period.

3. SUBMISSION OF BIDS:

a. BIDS OR MODIFICATIONS TO BIDS THAT ARE RECEIVED BY FACSIMILE OR TELETYPE WILL NOT BE CONSIDERED. All Sealed Bids must be submitted in accordance with the procedures set forth in Block No. 13 of Page 1 of this Solicitation Document and comply with all other instructions provided herein.

b. Bidders are required to acknowledge the receipt of all amendments to the Solicitation on the Standard Form 1442 in the space provided, by completing Blocks 8 and 15 of the Amendment (Standard Form 30), by separate letter, or by telegram prior to opening of bids.

c. SF 1442 BACK (Page 2 of the Solicitation): Bidders shall fully complete all the required areas located under the section designated as “OFFER” (refer to Items 14 through 20C)

d. Section 00600 (Representations and Certifications): The bidder must fully complete Section 00600 of this Solicitation and submit it along with all other documents required by this Solicitation. Bids received without this Section fully completed may be rejected, considered non-responsive and ineligible for award.

e. BID GUARANTEE: The bidder is required to submit a Bid Guarantee for this procurement. Any bidder failing to submit an authentic Bid Guarantee will be considered non-responsive to the Solicitation and ineligible for award. The Bid Guarantee shall be in the amount of 20% of the bidder’s price or $3,000,000.00, whichever is less.

f. PREAWARD SURVEY: See Attachment A, all contractors shall complete the enclosed form and furnish a completed copy with other deliverable required by this solicitation.

4. DELIVERY OF BIDS:

a. Sealed Bids: Regardless of the method of delivery (mailed or hand-carried), bids and all other documents called out in the Solicitation shall be enclosed and sealed in an envelope that is clearly marked “Bid” and shall include the assigned Solicitation Number, and the Bid Opening Date and Time.

b. Mailed Bids: It is the responsibility of each bidder to ensure that its Sealed Bid is received by the Chicago District’s – USACE Contracting Branch, located at 231 South LaSalle Street, Suite 1500, Chicago, IL 60604 prior to the date and time set for the opening of the bids – See Block 13A of Page 1 of the Solicitation.

c. Hand-carried Bids Delivered on the Day of the Bid Opening PRIOR TO NOON: For bids being hand-carried prior to 12: NOON on the date of the bid opening, the bidder shall CONTACT Kim F Hubbard at 312-846-5368, or Mike Jones at 312-846-5373 to retrieve its Bid from the Lobby Area of the USACE’s office location, which is located at 231 South LaSalle Street, Chicago, Illinois 60604

d. Hand-carried Bids Delivered on the Day of the Bid Opening AFTER 12:00 NOON: For bids being hand-carried after 12:noon on the date of the bid opening, the bidder shall be prepared to check in at the Security desk (see detailed instructions provided below at Paragraph 4) and from there, sign in at Suite 1500 wherein afterwards it will be directed to the designated Bid Opening Room to furnish its sealed bid.

5. BID OPENING ROOM:

a. The designated Bid Opening Room is located on the 16th floor at 231 South LaSalle Street, Suite 1500, Chicago, Illinois 60604.

b. In order to gain access, all interested participants must check in at the Security Desk in the lobby (Clark Street entrance) with a valid photo ID. The Security desk will issue an access card for gaining access to the USACE Main Office, Suite 1500.

c. Each visitor is required to check-in at the USACE Main Office, Suite 1500, where they will be asked to sign-in and will then be directed to the Bid Opening Room. All individuals intending to attend the Bid Opening must allow enough time to go through security and check in at the USACE office before being escorted to the Bid opening room.

6 . QUESTIONS: INTERESTED BIDDERS ARE HIGHLY ENCOURAGED TO SUBMIT THEIR CONTRACTING AND TECHNICAL INQUIRIES IN WRITING ON OR ABOUT SEPTEMBER 7, 2017 to Ms. Kim F. Hubbard at kimberly.f.hubbard@usace.army.mil. – BE SURE TO INCLUDE THE SOLICIATION NUMBER W912P6-17-

B-0010 AND PROJECT TITLE ON THE SUBJECT LINE OF YOUR EMAIL.

PRE‐BID MEETING & PROJECT SITE VISIT

A PRE-BID MEETING & PROJECT SITE VISIT will be held for this project beginning promptly at 10:00 am (CST) on September 12, 2017 at the following location:

Chicago Harbor Lock, 108 N. Streeter Drive Chicago, IL 60611.

Contact Numbers:

Project Site Phone No.: (312) 787-4795 Point of Contact: Adam Borelli at (312) 859-0063 Alternate Point of Contact: Carsten Western at (312) 623-4892

At the pre-bid meeting, government representatives will highlight specific contract requirements. The objective is to provide an information exchange between potential bidders and the Government to avoid the possibility of misinterpretation of the contract requirements.

The Corps of Engineers strongly encourages all potential bidders to attend the pre-bid meeting and, in the interest of making the meeting more meaningful, prospective bidders are urged to present any written questions concerning the project bid documents, bidding, and construction requirements or other related matters prior to the pre-bid meeting. Send written questions, by EMAIL to Kimberly F Hubbard at: kimberly.f.hubbard@usace.army.mil. (Please include the Solicitation Number W912P6-17-B-0010 in the subject line of your email).

Written questions may be submitted at the beginning of the meeting and oral questions may be submitted from the floor, will only be addressed if they are clarifications of information provided in the solicitation and in subsequent amendments issued before the scheduled prebid meeting and site visit. Answers, interpretations, and decisions made at the meeting will not mailto:kimberly.f.hubbard@usace.army.mil become official unless and until verified by an amendment to the solicitation issued prior to the receipt of bids.

Following the meeting, prospective bidders will be permitted to inspect the site where services are to be performed and to satisfy themselves as to all general and local conditions that may affect the cost of performance of the contract to the extent such information is reasonably obtained.

CLAUSES INCORPORATED BY REFERENCE

52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.204-22 Alternative Line Item Proposal JAN 2017 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.225-10 Notice of Buy American Requirement--Construction

Materials

MAY 2014

52.228-2 Additional Bond Security OCT 1997 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

CLAUSES INCORPORATED BY FULL TEXT

52.211-6 BRAND NAME OR EQUAL (AUG 1999)

(a) If an item in this solicitation is identified as “brand name or equal,” the purchase description reflects the characteristics and level of quality that will satisfy the Government's needs. The salient physical, functional, or performance characteristics that “equal” products must meet are specified in the solicitation.

(b) To be considered for award, offers of “equal” products, including “equal” products of the brand name manufacturer, must--

(1) Meet the salient physical, functional, or performance characteristic specified in this solicitation;

(2) Clearly identify the item by--

(i) Brand name, if any; and

(ii) Make or model number;

(3) Include descriptive literature such as illustrations, drawings, or a clear reference to previously furnished descriptive data or information available to the Contracting Officer; and

(4) Clearly describe any modifications the offeror plans to make in a product to make it conform to the solicitation requirements. Mark any descriptive material to clearly show the modifications.

(c) The Contracting Officer will evaluate “equal” products on the basis of information furnished by the offeror or identified in the offer and reasonably available to the Contracting Officer. The Contracting Officer is not responsible for locating or obtaining any information not identified in the offer.

(d) Unless the offeror clearly indicates in its offer that the product being offered is an “equal” product, the offeror shall provide the brand name product referenced in the solicitation.

(End of provision)

52.214-3 AMENDMENTS TO INVITATIONS FOR BIDS (DEC 2016)

(a) If this solicitation is amended, then all terms and conditions which are not modified remain unchanged.

(b) (1) Bidders shall acknowledge receipt of any amendment to this solicitation--

(i) By signing and returning the amendment;

(ii) By identifying the amendment number and date in space provided for this purpose on the form for submitting a bid;

(iii) By letter;

(iv) By facsimile, if facsimile bids are authorized in the solicitation; or

(v) By email, if email bids are authorized in the solicitation.

(2) The Government must receive the acknowledgement by the time and at the place specified for receipt of bids.

52.214-18 PREPARATION OF BIDS--CONSTRUCTION (APR 1984)

(a) Bids must be (1) submitted on the forms furnished by the Government or on copies of those forms, and (2) manually signed. The person signing a bid must initial each erasure or change appearing on any bid form.

(b) The bid form may require bidders to submit bid prices for one or more items on various bases, including--

(1) Lump sum bidding;

(2) Alternate prices;

(3) Units of construction; or

(4) Any combination of subparagraphs (1) through (3) above.

(c) If the solicitation requires bidding on all items, failure to do so will disqualify the bid. If bidding on all items is not required, bidders should insert the words "no bid" in the space provided for any item on which no price is submitted.

(d) Alternate bids will not be considered unless this solicitation authorizes their submission.

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a FIRM-FIXED PRICE CONSTRUCTION contract resulting from this solicitation.

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK (MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

19.6% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Illinois, Cook County, City of Chicago.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20% percent of the bid price or $3,000,000.00, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

Ms. Regina G. Blair Contracting Officer 231 S. LaSalle Street Suite 1500 Chicago, IL 60604

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Individual Site visits may be arranged during normal duty hours by contacting Mr. Adam Borelli at 312-859-0063.

ORGANIZED SITE VISIT: An organized site visit will immediately follow the Pre-Bid Meeting, which is scheduled as follows:

DATE and TIME: September 12, 2017 at 10:00am CST.

LOCATION:

108 N. Streeter Drive

Chicago, IL 60611 Lock Phone: (312) 787-4795

FOUNDATION REPORT : Prospective Bidders may request a copy of the Foundation Report referencing ER 1110-1-1901, Project Geotechnical and Materials Completion Report that documents work completed under Contract Number W912P6-09-C-0033 – Chicago Breakwater Repairs. IMPORTANT NOTE: This report is being made available for informational purposes. It “is not” mandatory for obtaining in order to place a bid for this project.

A copy may be obtained by requests made to:

Mr. Bill Rochford at Telephone: (312) 846-5450

Or, by mailing a request to Mr. Rochford at:

U.S. Army Corps of Engineer District Chicago Geotechnical and Survey Section 231 South LaSalle St., Suite 1500 Chicago, IL 60604

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://www.acquisition.gov

252.236-7008 CONTRACT PRICES - BIDDING SCHEDULES. (DEC 1991)

(a) The Government's payment for the items listed in the Bidding Schedule shall constitute full compensation to the Contractor for --

(1) Furnishing all plant, labor, equipment, appliances, and materials; and

(2) Performing all operations required to complete the work in conformity with the drawings and specifications.

(b) The Contractor shall include in the prices for the items listed in the Bidding Schedule all costs for work in the specifications, whether or not specifically listed in the Bidding Schedule.

http://www.acquisition.gov/

Section 00600 - Representations & Certifications

52.203-19 Prohibition on Requiring Certain Internal Confidentiality

Agreeements or Statements

JAN 2017

52.204-19 Incorporation by Reference of Representations and Certifications.

DEC 2014

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2017)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237990.

(2) The small business size standard is $36,500,000.00.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding elinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.222-57, Representation Regarding Compliance with Labor Laws (Executive Order 13673). This provision applies to solicitations expected to exceed $50 million which are issued from October 25, 2016 through April 24, 2017, and solicitations expected to exceed $500,000, which are issued after April 24, 2017.

Note to paragraph (c)(1)(xvi): By a court order issued on October 24, 2016, 52.222-57 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,533, the provision with its Alternate II applies.

(D) If the acquisition value is $77,533 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

X (i) 52.204-17, Ownership or Control of Offeror.

X (ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

https://www.acquisition.gov/

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2015)

Substitute the following paragraphs (d) and (e) for paragraph (d) of the provision at FAR 52.204-8:

(d)(1) The following representations or certifications in the System for Award Management (SAM) database are applicable to this solicitation as indicated:

https://www.acquisition.gov/

(i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.222-7007, Representation Regarding Combating Trafficking in Persons,…