W912EP18B0009_Amendment_0001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

CANAVERAL HARBOR SAND BYPASS SYSTEM PHASE V BREVARD COUNTY, FLORIDA

A. AMENDMENT ISSUED TO RESCHEDULE THE SITE VISIT DATE TO 28 AUG 2018 (SEE ATTACHED REVISED FAR CLAUSE 52.236-27 IN SECTION 00100) AND TO RESCHEDULE THE PRE-PROPOSAL TELECONFERENCE TO 29 AUG 2018 AT 10:00 AM LOCAL TIME

(SEE ATTACHED REVISED STANDARD FORM 1442).

B. THE BID OPENING DATE REMAINS UNCHANGED @ SEPTEMBER 11, 2018 @ 2:00 P.M. LOCAL TIME .

ALL OTHER TERMS AND CONDITIONS REMAIN UNCHANGED

1. CONTRACT ID CODE PAGE OF PAGES

1 34

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912EP18B0009

X 9B. DATED (SEE ITEM 11)

08-Aug-2018

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

17-Aug-2018

CODE

USA ENGINEER DISTRICT, JACKSONVILLE

CONTRACTING DIVISION

701 SAN MARCO BLVD

JACKSONVILLE FL 32207-8175

W912EP 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912EP18B0009

CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00100 - INSTRUCTIONS TO OFFERORS

The following have been modified:

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) (ALTERNATE I) (FEB 1995) (CESAJ ADAPTATION)

DELETE Standard Form 1442 and Replace with REVISED Standard Form 1442

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

W912EP18B0009

2. TYPE OF SOLICITATION 3. DATE ISSUED PAGE OF PAGES

X SEALED BID (IFB)

NEGOTIATED (RFP)

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

7. ISSUED BY CODE W912EP 8. ADDRESS OFFER TO (If Other Than Item 7) CODE

USA ENGINEER DISTRICT, JACKSONVILLE

CONTRACTING DIVISION

701 SAN MARCO BLVD

JACKSONVILLE FL 32207-8175

TEL: FAX:

See Item 7

TEL: FAX:

9. FOR INFORMATION

CALL:

A. NAME

WILLIAM WALLACE

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date):

CANAVERAL HARBOR SAND BYPASS SYSTEM PHASE V BREVARD COUNTY, FLORIDA

DESCRIPTION OF WORK: REFER TO SECTION 01 11 00 FOR COMPLETE PROJECT DESCRIPTION DRAWINGS: SEE DFARS CLAUSE

252.236-7001, IN SECTION 00700.

MAGNITUDE OF CONSTRUCTION IS BETWEEN $15,500,000 - $26,000,000.00.

THIS IS AN UNRESTRICTED SOLICITATION. ALL RESPONSIBLE OFFERORS ARE ENCOURAGED TO PARTICIPATE. THE NAICS CODE IS 237990

AND THE SIZE STANDARD IS $27.5 MILLION.

***BLOCK 11 - SEE SECTION 00700, CLAUSE 52.211-10 FOR PERIOD OF PERFORMANCE A SITE VISIT WILL BE HELD. SEE FAR CLAUSE

52.236-27 IN SECTION 00100FOR DETAILS.

A PRE-PROPOSAL TELECONFERENCE HAS BEEN SCHEDULED FOR 29 Aug 2018 AT 10:00 AM. PLEASE CALL: 877-402-9753, ACCESS

CODE: 6546236 SECURITY CODE: 2873

YOU MUST BE REGISTERED IN SAM IN ORDER TO RECEIVE AN AWARD FROM THIS SOLICITION. THE SAM WEBSITE IS LOCATED AT WWW.SAM.GOV.

11. The Contractor shall begin performance w ithin 30 calendar days and complete it w ithin 211 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See Section 00700 .)

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

12B. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and 4 copies to perform the w ork required are due at the place specified in Item 8 by 2:00 PM (hour) local time 11 Sept 18 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than 90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA FAR (48 CFR) 53.236-1(e)

Amendment 0001 http://www.sam.gov/

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

OFFER (M ust be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14)

See Item 14

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specified below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY: CODE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this 29. AWARD (Contractor is not required to sign this document.)

document and return copies to issuing office.) Contractor agrees to f urnish and deliv er all items or perf orm all work, requisitions identif ied on this f orm and any continuation sheets f or the consideration stated in this contract. The rights and obligations of the parties to this contract shall be gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-summates the contract, which consists of (a) the Gov ernment solicitation and y our of f er, and (b) this contract award. No f urther contractual document is necessary .

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED

TO SIGN (Type or print)

31A. NAME OF CONTRACTING OFFICER (Type or print)

TEL: EMAIL:30B. SIGNATURE 30C. DATE

31B. UNITED STATES OF AMERICA

BY

31C. AWARD DATE

NSN 7540-01-155-3212 STANDARD FORM 1442 BACK (REV. 4-85)

Amendment 0001

SECTION 00100 - INSTRUCTIONS TO OFFERORS

52.204-7 System for Award Management OCT 2016 52.211-2 Availability of Specifications, Standards, and Data

Item Descriptions Listed in the Acquisition Streamlining and Standardization Information System (ASSIST)

APR 2014

52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals NOV 1999 of Bids 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.216-1 Type Of Contract APR 1984 52.217-5 Evaluation Of Options JUL 1990 52.222-5 Construction Wage Rate Requirements--Secondary MAY 2014

Site of the Work 52.222-23 Notice of Requirement for Affirmative Action to

Ensure Equal Employment Opportunity for Construction

FEB 1999

52.222-38 Compliance With Veterans' Employment Reporting FEB 2016 Requirements

52.222-59 Compliance with Labor Laws (Executive Order 13673)

52.225-12 Notice of Buy American Requirement - Construction Materials Under Trade Agreements

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-- Representation and Certifications.

52.233-2 SERVICE OF PROTEST (SEP 2006) (CESAJ

ADAPTATION)

52.236-27 (Alt I) SITE VISIT (CONSTRUCTION) (FEB

1995) (ALTERNATE I) (FEB 1995)

(CESAJ ADAPTATION)

DEC 2016

MAY 2014

OCT 2015

OCT 2006

MAY 2003

W912EP18B0009 00100-1 Amendment 0001

52.252-5 Authorized Deviations In Provisions APR 1984 252.204-7008 Compliance With Safeguarding Covered Defense OCT 2016

Information Controls 252.225-7031 Secondary Arab Boycott Of Israel JUN 2005

999.204-1 HAND-DELIVERING OFFERS TO THE MAY 2004

PRUDENTIAL OFFICE BUILDING IN

JACKSONVILLE

999.204-2 PUBLIC ATTENDANCE AT PUBLIC BID FEB 2010

OPENINGS

999.204-4003 DISTRIBUTINGSOLICITATION AUG 2016

AMENDMENTS VIA FEDBIZOPPS.GOV

999.209-1 NATIONAL DREDGING QUALITY JUL 2010

MANAGEMENT PROGRAM SYSTEM –

SPECIAL STANDARD OF RESPONSIBILITY

999.209-4005 SEAGOING BARGE ACT - SPECIAL DEC 1999

STANDARD OF RESPONSIBILITY

999.209-4006 STANDARD OF RESPONSIBILITIY FOR OCT 2001

DREDGINGCONTRACTORS

999.214-4000 OBTAINING INFORMATION REGARDING DEC 1999

THIS SOLICITATION

999.214-4018 BIDDER'S CHECKLIST -- DEC 1999

CONSTRUCTION/DREDGING CONTRACTS

999.214-4020 NOTIFICATION TO UNSUCCESSFUL SEP 2006

BIDDERS

999.219-4003 SOURCES FOR ASSISTANCE IN LOCATING DEC 1999

SMALL BUSINESS SUBCONTRACTORS

W912EP18B0009 00100-2 Amendment 0001

SECTION 00100 - INSTRUCTIONS TO OFFERORS

52.204-7 SYSTEM FOR AWARD MANAGEMENT (OCT 2016)

(a) Definitions. As used in this provision--

Electronic Funds Transfer (EFT) indicator means a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for Award Management records for identifying alternative EFT accounts (see subpart 32.11) for the same entity.

Registered in the System for Award Management (SAM) database means that--

(1) The Offeror has entered all mandatory information, including the unique entity identifier and the EFT indicator, if applicable, the Commercial and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see subpart 4.14) into the SAM database;

(2) The offeror has completed the Core, Assertions, and Representations and Certifications, and Points of Contact sections of the registration in the SAM database;

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The offeror will be required to provide consent for TIN validation to the Government as a part of the SAM registration process;

and

(4) The Government has marked the record ``Active''.

Unique entity identifier means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers.

(b)(1) By submission of an offer, the Offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation ``Unique Entity Identifier'' followed by the unique entity identifier that identifies the Offeror's name and address exactly as stated in the offer. The Offeror also shall enter its EFT indicator, if applicable. The unique entity identifier will be used by the Contracting Officer to verify that the Offeror is registered in the SAM database.

W912EP18B0009 00100-3 Amendment 0001

(c) If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for establishment of the unique entity identifier directly to obtain one. The Offeror should be prepared to provide the following information:

(1) Company legal business name.

(2) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(3) Company physical street address, city, state, and Zip Code.

(4) Company mailing address, city, state and Zip Code (if separate from physical).

(5) Company telephone number.

(6) Date the company was started.

(7) Number of employees at your location.

(8) Chief executive officer/key manager.

(9) Line of business (industry).

(10) Company headquarters name and address (reporting relationship within your entity).

(d) If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror.

(e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) Offerors may obtain information on registration at https://www.acquisition.gov.

(End of clause)

52.211-2 AVAILABILITY OF SPECIFICATIONS, STANDARDS, AND DATA ITEM

DESCRIPTIONS LISTED IN THE ACQUISITION STREAMLINING AND

STANDARDIZATION INFORMATION SYSTEM (ASSIST) (APR 2014)

(a) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites:

(1) ASSIST (https://assist.dla.mil/online/start/);

W912EP18B0009 00100-4 Amendment 0001 http://www.acquisition.gov/

(2) Quick Search (http://quicksearch.dla.mil/);

(3) ASSISTdocs.com(http://assistdocs.com).

(b) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by--

(1) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm);

(2) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST;

or

(3) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone (215) 697-2667/2179, Facsimile (215) 697-1462.

(End of provision)

52.214-3 AMENDMENTS TO INVITATIONS FOR BIDS (DEC 2016)

(a) If this solicitation is amended, then all terms and conditions which are not modified remain unchanged.

(b) (1) Bidders shall acknowledge receipt of any amendment to this solicitation--

(i) By signing and returning the amendment;

(ii) By identifying the amendment number and date in space provided for this purpose on the form for submitting a bid;

(iii) By letter;

(iv) By facsimile, if facsimile bids are authorized in the solicitation; or

(v) By email, if email bids are authorized in the solicitation.

(2) The Government must receive the acknowledgement by the time and at the place specified for receipt of bids.

52.214-4 FALSE STATEMENTS IN BIDS (APR 1984)

Bidders must provide full, accurate, and complete information as required by this solicitation and

W912EP18B0009 00100-5 Amendment 0001 http://quicksearch.dla.mil/)%3B its attachments. The penalty for making false statements in bids is prescribed in 18 U.S.C. 1001.

52.214-5 SUBMISSION OF BIDS (DEC 2016)

(a) Bids and bid modifications shall be submitted in sealed envelopes or packages (unless submitted by electronic means) (1) addressed to the office specified in the solicitation, and (2) showing the time and date specified for receipt, the solicitation number, and the name and address of the bidder.

(b) Bidders using commercial carrier services shall ensure that the bid is addressed and marked on the outermost envelope or wrapper as prescribed in subparagraphs (a)(1) and (2) of this provision when delivered to the office specified in the solicitation.

(c) Facsimile bids, modifications, or withdrawals, will not be considered unless authorized by the solicitation.

(d) Bids submitted by electronic commerce shall be considered only if the electronic commerce method was specifically stipulated or permitted by the solicitation.

52.214-6 EXPLANATION TO PROSPECTIVE BIDDERS (APR 1984)

Any prospective bidder desiring an explanation or interpretation of the solicitation, drawings, specifications, etc., must request it in writing soon enough to allow a reply to reach all prospective bidders before the submission of their bids. Oral explanations or instructions given before the award of a contract will not be binding. Any information given a prospective bidder concerning a solicitation will be furnished promptly to all other prospective bidders as an amendment to the solicitation, if that information is necessary in submitting bids or if the lack of it would be prejudicial to other prospective bidders.

52.214-7 LATE SUBMISSIONS, MODIFICATIONS, AND WITHDRAWALS OF BIDS

(NOV 1999)

(a) Bidders are responsible for submitting bids, and any modifications or withdrawals, so as to reach the Government office designated in the invitation for bids (IFB) by the time specified in the IFB. If no time is specified in the IFB, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that bids are due.

W912EP18B0009 00100-6 Amendment 0001

(b)(1) Any bid, modification, or withdrawal received at the Government office designated in the IFB after the exact time specified for receipt of bids is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late bid would not unduly delay the acquisition; and--

(i) If it was transmitted through an electronic commerce method authorized by the IFB, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of bids; or

(ii) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of bids and was under the Government's control prior to the time set for receipt of bids.

(2) However, a late modification of an otherwise successful bid that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(c) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the bid wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(d) If an emergency or unanticipated event interrupts normal Government processes so that bids cannot be received at the Government office designated for receipt of bids by the exact time specified in the IFB and urgent Government requirements preclude amendment of the IFB, the time specified for receipt of bids will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(e) Bids may be withdrawn by written notice received at any time before the exact time set for receipt of bids. If the IFB authorizes facsimile bids, bids may be withdrawn via facsimile received at any time before the exact time set for receipt of bids, subject to the conditions specified in the provision at 52.214-31, Facsimile Bids. A bid may be withdrawn in person by a bidder or its authorized representative if, before the exact time set for receipt of bids, the identity of the person requesting withdrawal is established and the person signs a receipt for the bid.

52.214-18 PREPARATION OF BIDS--CONSTRUCTION (APR 1984)

(a) Bids must be (1) submitted on the forms furnished by the Government or on copies of those forms, and (2) manually signed. The person signing a bid must initial each erasure or change appearing on any bid form.

(b) The bid form may require bidders to submit bid prices for one or more items on various bases, including--

(1) Lump sum bidding;

W912EP18B0009 00100-7 Amendment 0001

(2) Alternate prices;

(3) Units of construction; or

(4) Any combination of subparagraphs (1) through (3) above.

(c) If the solicitation requires bidding on all items, failure to do so will disqualify the bid. If bidding on all items is not required, bidders should insert the words "no bid" in the space provided for any item on which no price is submitted.

(d) Alternate bids will not be considered unless this solicitation authorizes their submission.

52.214-19 CONTRACT AWARD--SEALED BIDDING--CONSTRUCTION (AUG 1996)

(a) The Government will evaluate bids in response to this solicitation without discussions and will award a contract to the responsible bidder whose bid, conforming to the solicitation, will be most advantageous to the Government, considering only price and the price-related factors specified elsewhere in the solicitation.

(b) The Government may reject any or all bids, and waive informalities or minor irregularities in bids received.

(c) The Government may accept any item or combination of items, unless doing so is precluded by a restrictive limitation in the solicitation or the bid.

(d) The Government may reject a bid as nonresponsive if the prices bid are materially unbalanced between line items or subline items. A bid is materially unbalanced when it is based on prices significantly less than cost for some work and prices which are significantly overstated in relation to cost for other work, and if there is a reasonable doubt that the bid will result in the lowest overall cost to the Government even though it may be the low evaluated bid, or if it is so unbalanced as to be tantamount to allowing an advance payment.

(End of provison)

52.214-34 SUBMISSION OF OFFERS IN THE ENGLISH LANGUAGE (APR 1991)

Offers submitted in response to this solicitation shall be in the English language. Offers received in other than English shall be rejected.

W912EP18B0009 00100-8 Amendment 0001

52.214-35 SUBMISSION OF OFFERS IN U.S. CURRENCY (APR 1991)

Offers submitted in response to this solicitation shall be in terms of U.S. dollars. Offers received in other than U.S. dollars shall be rejected.

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

52.217-5 EVALUATION OF OPTIONS (JUL 1990)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE

WORK (MAY 2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

W912EP18B0009 00100-9 Amendment 0001

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE

EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

Goals for minority participation for each trade

Goals for female participation for each trade

Nassau County, FL.

21.8%

Camden County, GA.

22.2%

W912EP18B0009 00100-10 Amendment 0001

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Nassau County, Florida and Camden County, Georgia.

52.222-38 COMPLIANCE WITH VETERANS' EMPLOYMENT REPORTING

REQUIREMENTS (FEB 2016)

By submission of its offer, the offeror represents that, if it is subject to the reporting requirements of 38 U.S.C. 4212(d) (i.e., if it has any contract containing Federal Acquisition Regulation clause 52.222-37, Employment Reports on Veterans), it has filed the most recent VETS-4212 Report required by that clause.

52.222-59 COMPLIANCE WITH LABOR LAWS (EXECUTIVE ORDER 13673) (DEC 2016)

(a) Definitions. As used in this clause--

Administrative merits determination means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

Agency labor compliance advisor (ALCA) means the senior official designated in accordance with E.O. 13673. ALCAs are listed at www.dol.gov/fairpayandsafeworkplaces.

Arbitral award or decision means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award ordecision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

W912EP18B0009 00100-11 Amendment 0001 http://www.dol.gov/fairpayandsafeworkplaces

Civil judgment means any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

DOL Guidance means the Department of Labor (DOL) Guidance entitled: ``Guidance for Executive Order 13673, `Fair Pay and Safe Workplaces' ''. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

Enforcement agency means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for--

(i) Section 503 of the Rehabilitation Act of 1973;

W912EP18B0009 00100-12 Amendment 0001

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

Labor compliance agreement means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

Labor laws means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

W912EP18B0009 00100-13 Amendment 0001

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html.)

Labor law decision means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of ``labor laws''.

Pervasive violations in the context of E.O. 13673, Fair Pay and Safe Workplaces, means labor law violations that bear on the assessment of a contractor's integrity and business ethics because they reflect a basic disregard by the contractor for the labor laws, as demonstrated by a pattern of serious and/or willful violations, continuing violations, or numerous violations. To determine whether violations are pervasive it is necessary to consult the DOL Guidance section III.A.4. and associated Appendix D.

Repeated violation in the context of E.O. 13673, Fair Pay and Safe Workplaces, means a labor law violation that bears on the assessment of a contractor's integrity and business ethics because the contractor had one or more additional labor law violations of the same or a substantially similar requirement within the prior 3 years. To determine whether a particular violation(s) is repeated it is necessary to consult the DOL Guidance section III.A.2. and associated Appendix B.

Serious violation in the context of E.O. 13673, Fair Pay and Safe Workplaces, means a labor law violation that bears on the assessment of a contractor's integrity and business ethics because of the number of employees affected; the degree of risk imposed, or actual harm done by the violation; the amount of damages incurred or fines or penalties assessed; and/or other similar criteria. To determine whether a particular violation(s) is serious it is necessary to consult the DOL Guidance section III.A.1. and associated Appendix A.

Willful violation in the context of E.O. 13673, Fair Pay and Safe Workplaces, means a labor law violation that bears on the assessment of a contractor's integrity and business ethics because the contractor acted with knowledge of, reckless disregard for, or plain indifference to the matter of whether its conduct was prohibited by one or more requirements of labor laws. To determine whether a particular violation(s) is willful it is necessary to consult the DOL Guidance section III.A.3. and associated Appendix C.

(b) Prime contractor updates. Contractors are required to disclose new labor law decisions and/or updates to previously disclosed labor law decisions in SAM at www.sam.gov, semiannually. The Contractor has

W912EP18B0009 00100-14 Amendment 0001 http://www.osha.gov/dcsp/osp/approved_state_plans.html.)

flexibility in establishing the date for the semiannualupdate. (The contractor may use the six-month anniversary date of contract award, or may choose a different date before that six-month anniversary date. In either case, the contractor must continue to update its disclosures semiannually.) Registrations in SAM are required to be maintained current, accurate, and complete (see 52.204-13, System for Award Management Maintenance). If the SAM registration date is less than six months old, this will be evidence that the required representation and disclosure information is updated and the requirement is met. The Contractor shall provide--

(1) The following in SAM for each disclosed labor law decision. This information will be publicly available in the Federal Awardee Performance and Integrity Information System

(FAPIIS):

(i) The labor law violated.

(ii) The case number, inspection number, charge number, docket number, or other unique identification number.

(iii) The date rendered.

(iv) The name of the court, arbitrator(s), agency, board, or commission that rendered the determination or decision;

(2) The administrative merits determination, arbitral award or decision, or civil judgment document to the Contracting Officer, if the Contracting Officer requires it;

(3) In SAM, such additional information as the Contractor deems necessary, including mitigating factors and remedial measures such as contractor actions taken to address the violations, labor compliance agreements, and other steps taken to achieve compliance with labor laws.

Contractors may provide explanatory text and upload documents. This information will not be made public unless the Contractor determines that it wants the information to be made public;

(4) The information in paragraphs (b)(1) and (b)(3) to the Contracting Officer, if the Contractor meets an exception to SAM registration (see 4.1102(a)).

(c) Subcontractor responsibility. (1) This paragraph (c) applies--

(i) To subcontracts with an estimated value that exceeds $500,000 for other than commercially available off-the-shelf items; and

(ii) When the provision 52.222-58, Subcontractor Responsibility Matters Regarding Compliance with Labor Laws (Executive Order 13673), is in the contract and the prospective subcontractor responded affirmatively to paragraph (b) of that provision, and the Contractor initiates a responsibilitydetermination.

W912EP18B0009 00100-15 Amendment 0001

(2) The Contractor shall consider subcontractor labor law violation information when assessing whether a prospective subcontractor has a satisfactory record of integrity and business ethics with regard to compliance with labor laws, when determining subcontractor responsibility.

Disclosure of labor law decision(s) does not automatically render the prospective subcontractor nonresponsible. The Contractor shall consider the prospective subcontractor for subcontract award notwithstanding disclosure of one or more labor law decision(s).

The Contractor should encourage prospective subcontractors to contact DOL for a preassessment of their record of labor law compliance (see DOL Guidance Section VI, Preassessment). The Contractor shall complete the assessment--

(i) For subcontracts awarded within five days of the prime contract award or that become effective within five days of the prime contract award, no later than 30 days after subcontract award; or

(ii) For all other subcontracts, prior to subcontract award. However, in urgent circumstances, the assessment shall be completed within 30 days of subcontract award.

(3)(i) The Contractor shall require a prospective subcontractor to represent to the best of the subcontractor's knowledge and belief whether there have been any administrative merits determinations, arbitral awards or decisions, or civil judgments, for any labor law violation(s) rendered against the subcontractor during the period beginning on October 25, 2015 to the date of the subcontractor's offer, or for three years preceding the date of the subcontractor's offer, whichever period is shorter.

(ii) When determining subcontractor responsibility, the Contractor shall require the prospective subcontractor to disclose to DOL, in accordance with paragraph (c)(3)(iv) of this clause, for each covered labor law decision, the following information:

(A) The labor law violated.

(B) The case number, inspection number, charge number, docket number, or other unique identification number.

(C) The date rendered.

(D) The name of the court, arbitrator(s), agency, board, or commission that rendered the determination or decision.

(iii) The Contractor shall inform the prospective subcontractor that the prospective subcontractor may provide information to DOL, in accordance with paragraph (c)(3)(iv) of this clause, on mitigating factors and remedial measures, such as subcontractor actions taken to address the violations, labor compliance agreements, and other steps taken to achieve compliance with labor laws.

W912EP18B0009 00100-16 Amendment 0001

(iv) The Contractor shall require subcontractors to provide information required by paragraph (c)(3)(ii) and discussed in paragraph (c)(3)(iii) of this clause to DOL through the DOL Web site at www.dol.gov/fairpayandsafeworkplaces.

(4) The Contractor, in determining subcontractor responsibility, may find that the prospective subcontractor has a satisfactory record of integrity and business ethics with regard to compliance with labor laws if--

(i) The prospective subcontractor provides a negative response to the Contractor in its representation made pursuant to paragraph (c)(3)(i) of this clause; or

(ii) The prospective subcontractor--

(A) Provides a positive response to the Contractor in its representation made pursuant to paragraph (3)(i);

(B) Represents, to the Contractor, to the best of the subcontractor's knowledge and belief that it has disclosed to DOL any administrative merits determinations, arbitral awards or decisions, or civil judgments for any labor law violation(s) rendered against the subcontractor during the period beginning on October 25, 2015 to the date of the offer, or for three years preceding the date of the offer, whichever period is shorter;

(C) Provides the following information concerning DOL review and assessment of subcontractor-disclosedinformation--

(1) The subcontractor has been advised by DOL that it has no serious, repeated, willful, and/or pervasive labor law violations;

(2) The subcontractor has been advised by DOL that it has serious, repeated, willful, and/or pervasive labor law violations; and

(i) DOL has advised that a labor compliance agreement is not warranted because, for example, the subcontractor has initiated and implemented its own remedial measures;

(ii) The subcontractor has entered into a labor compliance agreement(s) with an enforcement agency and states that it has not been notified by DOL that it is not complying with its agreement; or

(iii) The subcontractor has agreed to enter into a labor compliance agreement or is considering a labor compliance agreement(s) with an enforcement agency to address all disclosed labor law violations that DOL has determined to be serious, willful, repeated, and/or pervasive labor law violations and has not been notified by DOL that it has not entered into an agreement in a reasonable period; or

W912EP18B0009 00100-17 Amendment 0001

(3) The subcontractor disagrees with DOL's advice (e.g., that a proposed labor compliance agreement is warranted), or with DOL's notification that it has not entered into a labor compliance agreement in a reasonable period or is not complying with the agreement, and the subcontractor has provided the Contractor with--

(i) Information about all the disclosed labor law violations that have been determined by DOL to be serious, repeated, willful, and/or pervasive;

(ii) Such additional information that the subcontractor deems necessary to demonstrate its responsibility, including mitigating factors, remedial measures such as subcontractor actions taken to address the labor law violations, labor compliance agreements, and other steps taken to achieve compliance with labor laws;

(iii) A description of DOL's advice or a description of an enforcement agency's proposed labor compliance agreement; and

(iv) An explanation of the basis for the subcontractor's disagreement with DOL.

(5) If the Contractor determines that the subcontractor has a satisfactory record of integrity and business ethics based on the information provided pursuant to paragraph (c)(4)(ii)(C)(3), or the Contractor determines that due to a compelling reason the contractor must proceed with subcontract award, the Contractor shall notify the Contracting Officer of the decision and provide the following information in writing:

(i) The name of the subcontractor.

(ii) The basis for the decision, e.g., relevancy to the requirement, urgent and compelling circumstances, to prevent delays during contract performance, or when only one supplier is available to meet the requirement.

(6) If DOL does not provide advice to the subcontractor within three business days of the subcontractor's disclosure of labor law decision information pursuant to paragraph (c)(3)(ii) and DOL did not previously advise the subcontractor that it needed to enter into a labor compliance agreement to address labor law violations, the Contractor may proceed with making a responsibility determination using available information and business judgment.

(d) Subcontractor updates.

(1) The Contractor shall require subcontractors to determine, semiannually, whether labor law decision disclosures provided to DOL pursuant to paragraph (c)(3)(ii) of this clause are current, accurate, and complete. If the information is current, accurate, and complete, no action is required. If the information is not current, accurate, and complete, subcontractors must provide revised information to DOL, in accordance with paragraph (c)(3)(iv) of this clause, and make a new

W912EP18B0009 00100-18 Amendment 0001 representation and provide information to the Contractor pursuant to paragraph (c)(4)(ii) of this clause to reflect any advice provided by DOL or other actions taken by the subcontractor.

(2) The Contractor shall further require the subcontractor to disclose during the course of performance of the subcontract any notification by DOL, within 5 business days of such notification, that it has not entered into a labor compliance agreement in a reasonable period or is not complying with a labor compliance agreement, and shall allow the subcontractor to provide an explanation and supporting information for the delay or non-compliance.

(3) The Contractor shall consider, in a timely manner, information obtained from subcontractors pursuant to paragraphs (d)(1) and (2) of this clause, and determine whether action is necessary.

(4) If the Contractor has been informed by the subcontractor of DOL's assessment that the subcontractor has not demonstrated compliance with labor laws, and the Contractor decides to continue the subcontract, the Contractor shall notify the Contracting Officer of its decision to continue the subcontract and provide the following information in writing:

(i) The name of the subcontractor; and

(ii) The basis for the decision, e.g., relevancy to the requirement, urgent and compelling circumstances, to prevent delays during contract performance, or when only one supplier is available to meet the requirement.

(e) Consultation with DOL and other enforcement agencies. The Contractor may consult with DOL and enforcement agency representatives, using DOL Guidance at www.dol.gov/fairpayandsafeworkplaces, for advice and assistance regarding assessment of subcontractor labor law violation(s), including whether new or enhanced labor compliance agreements are warranted. Only DOL and enforcement agency representatives are available to consult with Contractors regarding subcontractor information. Contracting Officers or Agency Labor Compliance Advisors may assist with identifying the appropriate DOL and enforcement agency representatives.

(f) Protections for subcontractor misrepresentations. A contractor or subcontractor, acting in good faith, is not liable for misrepresentations made by its subcontractors about labor law decisions or about labor compliance agreements.

(g) Subcontractor flowdown. If the Government's solicitation included the provision at 52.222- 58, the Contractor shall include the substance of paragraphs (a), (c), (d), (e), (f) and (g) of this clause, in…