A.07.24_Solicitation_Amendment_(W912EF18Q00230004).pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to clarify the CLIN schedule. See Summary of Changes.

All other terms and conditions remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

1 25

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 11-Sep-2018

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912EF18Q0023

X 9B. DATED (SEE ITEM 11)

10-Aug-2018

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

11-Sep-2018

CODE

USAED, WALLA WALLA - CONTRACTING DIV.

ANDREW J SPRYS

201 N. THIRD AVENUE

WALLA WALLA WA 99362-1876

W912EF 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912EF18Q0023

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 1449 - CONTINUATION SHEET

SUPPLIES OR SERVICES AND PRICES

CLIN 0001

The CLIN extended description has changed from:

Base Year - Period of Performance 15-OCT-2018 through 15-JAN-2019.In accordance with the Performance Work Statement.

To:

Base Year - Period of Performance 15-OCT-2018 through 01-FEB-2019.In accordance with the Performance Work Statement.

SUBCLIN 0001AA

In accordance with the Technical Specifications.

In accordance with the Technical Specifications.One Cylinder.

SUBCLIN 0001AB

CLIN 0002

The CLIN description has changed from Recondition Hydraulic Cylinders to Recondition Hydraulic Cylinder.

The CLIN extended description has changed from:

Technical Specifications.

SUBCLIN 0002AA

Recondition Hydraulic Cylinder.

SUBCLIN 0002AB

Recondition Hydraulic Cylinder.

CLIN 0003

CLIN 0004

Technical Specifications.

The pricing detail quantity has increased by 4.00 from 8.00 to 12.00.

CLIN 0005

Base Year - Period of Performance 15-OCT-2018 through 01-FEB-2019.Quantities identified as Estimated (“Est”) in the bid schedule are subject to FAR Clause 52.211-18, VARIATION IN ESTIMATED QUANTITY, located in the Contract Clauses.In accordance with the Technical Specifications.

The pricing detail quantity has increased by 3,000.00 from 1,000.00 to 4,000.00.

CLIN 0006

Base Year - Period of Performance 15-OCT-2018 through 01-FEB-2019.Quantities identified as Estimated (“Est”) in the bid schedule are subject to FAR Clause 52.211-18, VARIATION IN ESTIMATED QUANTITY, located in the Contract Clauses.In accordance with the Technical Specifications.

The pricing detail quantity has decreased by 2,000.00 from 3,000.00 to 1,000.00.

CLIN 1001

Option Year One - Period of Performance 15-OCT-2019 through 15-JAN-2020.In accordance with the Technical Specifications.

Option Year One - Period of Performance 15-OCT-2019 through 01-FEB-2020.In accordance

SUBCLIN 1001AA

SUBCLIN 1001AB

CLIN 1002

Option Year One - Period of Performance 15-OCT-2019 through 101-FEB-2020.In accordance

SUBCLIN 1002AA

Recondition Hydraulic Cylinder.

SUBCLIN 1002AB

Recondition Hydraulic Cylinder.

CLIN 1003

Option Year One - Period of Performance 15-OCT-2019 through 01-FEB-2020..In accordance

CLIN 1004

Option Year One - Period of Performance 15-OCT-2019 through 01-FEB-2020.In accordance

CLIN 1005

Option Year One - Period of Performance 15-OCT-2019 through 01-FEB-2020.Quantities identified as Estimated (“Est”) in the bid schedule are subject to FAR Clause 52.211-18, VARIATION IN ESTIMATED QUANTITY, located in the Contract Clauses.This is an Estimated Quantity.

CLIN 1006

Option Year One - Period of Performance 15-OCT-2019 through 01-FEB-2020.Quantities identified as Estimated (“Est”) in the bid schedule are subject to FAR Clause 52.211-18, VARIATION IN ESTIMATED QUANTITY, located in the Contract Clauses.This is an Estimated Quantity.

CLIN 2001

Option Year Two - Period of Performance 15-OCT-2020 through 15-JAN-2021.In accordance

Option Year Two - Period of Performance 15-OCT-2020 through 01-FEB-2021.In accordance

SUBCLIN 2001AA

SUBCLIN 2001AB

CLIN 2002

SUBCLIN 2002AA

Recondition Hydraulic Cylinder.

SUBCLIN 2002AB

Recondition Hydraulic Cylinder.

CLIN 2003

CLIN 2004

with the Technical Specifications.

CLIN 2005

with the Technical Specifications.Quantities identified as Estimated (“Est”) in the bid schedule are subject to FAR Clause 52.211-18, VARIATION IN ESTIMATED QUANTITY, located in the Contract Clauses.

CLIN 2006

with the Technical Specifications.Quantities identified as Estimated (“Est”) in the bid schedule are subject to FAR Clause 52.211-18, VARIATION IN ESTIMATED QUANTITY, located in the Contract Clauses.

CLIN 3001

Option Year Three - Period of Performance 15-OCT-2021 through 15-JAN-2022.In accordance

Option Year Three - Period of Performance 15-OCT-2021 through 01-FEB-2022.In accordance

SUBCLIN 3001AA

SUBCLIN 3001AB

CLIN 3002

SUBCLIN 3002AA

Recondition Hydraulic Cylinder.

SUBCLIN 3002AB

Recondition Hydraulic Cylinder.

CLIN 3003

CLIN 3004

with the Technical Specifications.

CLIN 3005

with the Technical Specifications.Quantities identified as Estimated (“Est”) in the bid schedule are subject to FAR Clause 52.211-18, VARIATION IN ESTIMATED QUANTITY, located in the Contract Clauses.

CLIN 3006

with the Technical Specifications.Quantities identified as Estimated (“Est”) in the bid schedule are subject to FAR Clause 52.211-18, VARIATION IN ESTIMATED QUANTITY, located in the Contract Clauses.

DELIVERIES AND PERFORMANCE

The following Delivery Schedule item for CLIN 0004 has been changed from:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

POP 04-SEP-2018 TO

03-SEP-2019

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671 FOB: Destination

960200

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

POP 04-SEP-2018 TO

03-SEP-2019

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

The following Delivery Schedule item for CLIN 0005 has been changed from:

CAGE

POP 04-SEP-2018 TO

03-SEP-2019

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

CAGE

POP 04-SEP-2018 TO

03-SEP-2019

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

The following Delivery Schedule item for CLIN 0006 has been changed from:

CAGE

POP 04-SEP-2018 TO

03-SEP-2019

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

POP 04-SEP-2018 TO

03-SEP-2019

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

The following Delivery Schedule item for CLIN 1004 has been changed from:

CAGE

POP 04-SEP-2019 TO

03-SEP-2020

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

CAGE

POP 04-SEP-2019 TO

03-SEP-2020

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

The following Delivery Schedule item for CLIN 1005 has been changed from:

CAGE

POP 04-SEP-2019 TO

03-SEP-2020

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

POP 04-SEP-2019 TO

03-SEP-2020

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

The following Delivery Schedule item for CLIN 1006 has been changed from:

CAGE

POP 04-SEP-2019 TO

03-SEP-2020

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

CAGE

POP 04-SEP-2019 TO

03-SEP-2020

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

The following Delivery Schedule item for CLIN 2004 has been changed from:

CAGE

POP 04-SEP-2020 TO

03-SEP-2021

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

POP 04-SEP-2020 TO

03-SEP-2021

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

The following Delivery Schedule item for CLIN 2005 has been changed from:

CAGE

POP 04-SEP-2020 TO

03-SEP-2021

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

CAGE

POP 04-SEP-2020 TO

03-SEP-2021

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

The following Delivery Schedule item for CLIN 2006 has been changed from:

CAGE

POP 04-SEP-2020 TO

03-SEP-2021

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

CAGE

POP 04-SEP-2020 TO

03-SEP-2021

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

The following Delivery Schedule item for CLIN 3004 has been changed from:

CAGE

POP 04-SEP-2021 TO

03-SEP-2022

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

CAGE

POP 04-SEP-2021 TO

03-SEP-2022

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

The following Delivery Schedule item for CLIN 3005 has been changed from:

CAGE

POP 04-SEP-2021 TO

03-SEP-2022

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

CAGE

POP 04-SEP-2021 TO

03-SEP-2022

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

The following Delivery Schedule item for CLIN 3006 has been changed from:

CAGE

POP 04-SEP-2021 TO

03-SEP-2022

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

CAGE

POP 04-SEP-2021 TO

03-SEP-2022

N/A ARMY CORPS OF ENGINEERS

ADMINISTRATIVE OFFICER

LUCKY PEAK PROJECT

9723 E HIGHWAY 21

BOISE ID 83716

208-343-0671

TABLE OF CONTENTS

The Table of Contents has changed from:

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

Attachment 1 Technical Specifications 24-JUL-2018 Attachment 2 Drawings/Plans 24-JUL-2018 Attachment 3 Revised Technical

Specifications (Amendment 00002) to:

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

Attachment 1 Revised Technical

Specifications (Amendment 00002)

The following have been added by full text:

52.211-9 DESIRED AND REQUIRED TIME OF DELIVERY (JUN 1997)

(a) The Government desires delivery to be made according to the following schedule:

DESIRED DELIVERY SCHEDULE

- Funding will allow for up to 2 cylinders per year

- No more than 2 slide gates will be taken out of service at one time

- The order of precedence is cylinder 4, cylinder 3, cylinder 2, cylinder 1, cylinder 6, and cylinder 5.

- All repair periods will begin the 3rd full week of October and end no later than 1 February

If the offeror is unable to meet the desired delivery schedule, it may, without prejudicing evaluation of its offer, propose a delivery schedule below. However, the offeror's proposed delivery schedule must not extend the delivery period beyond the time for delivery in the Government's required delivery schedule as follows:

REQUIRED DELIVERY SCHEDULE

[Contracting Officer insert specific details]

WITHIN DAYS

ITEM NO. QUANTITY AFTER DATE

OF CONTRACT

Offers that propose delivery of a quantity under such terms or conditions that delivery will not clearly fall within the applicable required delivery period specified above, will be considered nonresponsive and rejected. If the offeror proposes no other delivery schedule, the desired delivery schedule above will apply.

OFFEROR'S PROPOSED DELIVERY SCHEDULE

WITHIN DAYS

ITEM NO. QUANTITY AFTER DATE

OF CONTRACT

(b) Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed or otherwise furnished to the successful offeror results in a binding contract. The Government will mail or otherwise furnish to the offeror an award or notice of award not later than the day the award is dated. Therefore, the offeror shall compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the Contracting Officer through the ordinary mails. However, the Government will evaluate an offer that proposes delivery based on the Contractor's date of receipt of the contract or notice of award by adding (1) five calendar days for delivery of the award through the ordinary mails, or (2) one working day if the solicitation states that the contract or notice of award will be transmitted electronically. (The term "working day" excludes weekends and U.S. Federal holidays.) If, as so computed, the offered delivery date is later than the required delivery date, the offer will be considered nonresponsive and rejected.

(End of clause)

52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

The following have been modified:

INSTRUCTIONS TO OFFERS

INSTRUCTIONS TO OFFERORS

This is a request for quote for the recondition of six (6) hydraulic cylinders in accordance with the Performance Work Statement for the U.S. Army Corps of Engineers, Walla Walla District, at Lucky Peak Dam, Boise, ID.

Registration at www.sam.gov is required. Failure to register in the SAM database will make an offeror ineligible for award. Effective 29 April 2018, the notarized letter process is now mandatory on all CURRENT registrants at SAM who have a requirement to update data on their SAM record. The notarized letter is mandatory and is required in order for the GSA Federal Service Desk (FSD) to activate the entity's registration. Both Federal Assistance entities and all non-Federal entities must mail the original, signed copy of the notarized letter to the Federal Service Desk.

Failure to do so within 30 days of activation may result in the registration no longer being active. Mail the completed, signed, notarized letter to:

FEDERAL SERVICE DESK

ATTN: SAM.GOV REGISTRATION PROCESSING

460 INDUSTRIAL BLVD

LONDON, KY 40741-7285

UNITED STATES OF AMERICA

Completion of the required FAR 52.212-3, Offeror Representations and Certifications – Commercial Items is required. When you complete your SAM registration, the link to complete your Representations and Certifications is also available. Please do not hesitate to contact Andrew J. Sprys, or the SAM web site for assistance or have questions.

TO ENSURE RECEIPT OF YOUR QUOTE, PLEASE SEND TO THE ATTENTION OF ANDREW

SPRYS AT andrew.j.sprys@usace.army.mil OR SARA EDWARDS AT Sara.Edwards@usace.army.mil

If you have any questions or concerns regarding the Request for Quote, please contact Andrew Sprys by Telephone 509-527-7232; or send an email to andrew.j.sprys@usace.army.mil

Please return all pages of this request for quote. Be sure to also complete Blocks 17a, 30a, 30b, and 30c on page 1.

Name: _____________________________________________________________

Contact Telephone Number: ____________________________________________

Email Address: __________________________________________________________________

Company’s Federal Tax Identification Number: ____________________________________________

CAGE CODE: _________________________ DUNS Number ________________________________

The System for Award Management (SAM) is online. SAM replaces CCR/FedReg, ORCA, and EPLS.

If you have been using those systems, you should now go to www.sam.gov to find your information.

Completion of FAR 52.212-3 Offeror Representations and Certifications–Commercial Items – Alternate 1 (May 2014). Electronic completion is encouraged (see http://farsite.hill.af.mil to download Representations and Certifications).

An offeror shall complete only paragraph (b) of this provision if the offeror has completed the annual representations and certifications electronically via https://www.acquisition.gov. If an offeror has not completed the annual representations and certifications electronically at the ORCA website, the offeror shall complete only paragraphs (b) through (i) of this provision.

In accordance with FAR Part 29.3 – State and Local Taxes, and per Title 4 of US Code 104-107, the Government is exempt from paying state and local taxes. Exempt tax identification number 91-0828090.

ADDENDUM TO FAR 52.212-1 INSTRUCTIONS TO OFFERORS – COMMERCIAL ITEMS

Submission of Price Quote – Offeror shall submit 1 copy of the following:

1. Signed and dated Standard Form 1449 (Solicitation/Contract/Order for Commercial Items)

2. Signed and dated Standard Form 30, if applicable, for any Amendments to the Solicitation

3. Completed schedule (pricing information) for all contract line item numbers

4. Completed Clause 52.212-3 and Alt I, “Offeror Representations and Certifications—Commercial Items” as noted above.

5. Any information required to evaluate the quote, as stated in FAR Clause 52.212-2.

PRICES QUOTED MUST BE VALID FOR 30 DAYS. Solicitation shall result in a firm-fixed-price contract.

All pricing shall include shipping FOB destination (include shipping cost in price).

BUSINESS HOURS: The standard business hours for the Walla Walla District, Corps of Engineers are Monday through Friday from 8:00 a.m. to 4:00 p.m., excluding federal holidays.

BASIS FOR AWARD

The Government will award one contract resulting from this solicitation in accordance with FAR 13.106 to the responsible offeror meeting or exceeding all solicitation requirements and representing the best value based on price.

With the offer, electronically submit evidence showing that the offeror, including key personnel performing the work, has successfully performed hydraulic cylinder refurbishment of cylinders comparable in size, type and complexity in the last five (5) years. Qualifications shall be submitted in résumé format for approval.

The purpose of the Third (3rd) Option Year is in case the government does not have funding in place to repair a Cylinder in a previous contract year. The government has every intention of rehabilitating two (2) cylinders a year and executing a contract as soon as possible.

The following have been deleted:

52.211-8

(End of Summary of Changes)