A.07.24_W9127N-17-R-0003_Amendment_0002.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

PROJECT TITLE: THE DALLES ARC FLASH HAZARD REDUCTION PROGRAM

SEE CONTINUATION PAGES

1. CONTRACT ID CODE PAGE OF PAGES

J 1 13

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 06-Sep-2017

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W9127N-17-R-0003

X 9B. DATED (SEE ITEM 11)

10-Aug-2017

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

06-Sep-2017

CODE

USACE PORTLAND DISTRICT

333 SW 1ST AVE

PORTLAND OR 97204-3440

W9127N 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W9127N-17-R-0003

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

The following items are applicable to this modification:

SECTION 00100 - BIDDING SCHEDULE / INSTRUCTIONS TO BIDDERS

AMENDMENT 0002

1. This Amendment is issued to update the technical specifications.

2. Section 00010 is updated to reserve CLIN 0002. Offerors shall fill out the bid schedule included with this amendment and submit it with the Volume II - Price Proposal.

3. FAR 52.211-10 has been deleted. FAR 52.211-10 Alt I has been included.

4. Division 01 Section 01 10 10.00 25, Subpart 1.4 has been updated.

5. Division 01 Section 01 10 10.00 25, Subpart 1.5 has been updated.

6. Division 01 Section 01 11 00.00 25, Subpart 1.3 has been updated.

7. Division 01 Section 01 22 00.00 25, Subpart 1.5.2 has been updated.

8. Division 01 Section 01 45 00.00 25, Subpart 3.8.1 has been updated.

9. The proposal due date is extended from 11 September 2017 to 25 September 2017 at 4:00 PM.

10. All other terms and conditions remain unchanged.

REVISED BID SCHEDULE

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Mobilization/Demobilization

FFP

Mobilization/Demobilization in accordance with the contract documents.

FOB: Destination

NET AMT

[RESERVED]

FFP

0003 1 Job Replacement of 480VAC Circuit Breakers

FFP

Replacement of 480VAC Circuit Breakers in accordance with the contract documents.

0004 1 Job Replacement of 125VDC Circuit Breakers

FFP

Replacement of 125VDC Circuit Breakers in accordance with the contract

0005 1 Job Removal of Battery Disconnect Switches

FFP

Removal of Battery Disconnect Switches in accordance with the contract

0006 1 Job Removal of Warehouse Cable

FFP

Removal of Warehouse Cable in accordance with the contract documents.

0007 1 Job Replacement of Manual Operators

FFP

Replacement of Manual Operators for the High Voltage Disconnect Ground switches in accordance with the contract documents.

0008 1 Job Installation of DC Switchboard

FFP

Installation of DC Switchboard in accordance with the contract documents.

0009 1 Job Installation of Breaker Maintenance

FFP

Installation of Breaker Maintenance Swtiches in accordance with the contract

0010 1 Job Installation of 5kV Switchgear

FFP

Installation of 5kV Switchgear in accordance with the contract documents.

0011 1 Job Installation of Surge Arresters

FFP

Installation of Surge Arresters in accordance with the contract documents.

0012 1 Job Installation of Warehouse Cable

FFP

Installation of Warehouse Cable in accordance with the contract documents.

TOTAL PROPOSED PRICE

TOTAL PROPOSED PRICE FOR ALL LINE ITEMS

SUMMARY OF CHANGES

SECTION 00010 - SOLICITATION CONTRACT FORM

The required response date/time has changed from 11-Sep-2017 04:00 PM to 25-Sep-2017 04:00 PM.

SECTION 00100 - BIDDING SCHEDULE / INSTRUCTIONS TO BIDDERS

CLIN 0002

The CLIN type priced has been deleted.

The CLIN description has changed from Final Record Drawings to [RESERVED].

The CLIN extended description has changed from:

Final Record Drawings in accordance with the contract documents.

To:

The pricing detail quantity 1.00 has been deleted.

The unit of issue Job has been deleted.

The FOB Destination has been deleted.

The FSC code Z2KA has been deleted.

The PROG code C20 has been deleted.

The WSC Equipment code 000 has been deleted.

The NAICS code 238210 has been deleted.

The MDAP/MAIS Code 000 has been deleted.

The Acceptance/Inspection Schedule for CLIN 0002 has been changed from:

INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

N/A N/A N/A Government

To:

INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

N/A N/A N/A N/A

SECTION 00800 - SPECIAL CONTRACT REQUIREMENTS

The following have been added by full text:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

a. The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than:

(1) CONSTRUCTION START DATE FOR ONSITE ACTIVITIES: 01 April 2018.

All construction work related to demolition of the existing electrical systems or installation of the new electrical systems will not be permitted onsite until April 01, 2018. Pre-construction activities including submittals, procurement of materials and equipment, and survey of existing conditions may begin following Notice to Proceed.

(2) FINAL CONSTRUCTION PHYSCIAL COMPLETION DATE: 17 June 2019.

(3) CONTRACT END DATE: 17 August 2019.

b. The time stated for FINAL CONSTRUCTION PHYSICAL COMPLETION DATE: includes physical completion of all site work, site cleanup, and demobilization.

c. The time stated for CONTRACT END DATE includes submission and approval of all final remaining work documents. (See Section 01 33 00 SUBMITTAL PROCEDURES, paragraphs OPERATIONS AND MAINTENANCE DATA, and PROJECT RECORD DOCUMENTS for final work document requirements.)

(End of clause)

The following have been modified:

SPECIAL CONTRACT REQUIREMENTS

00800

SPECIAL CONTRACT REQUIREMENTS

NUMBER DESCRIPTION

A. CONTRACT ADMINISTRATION

B. UNAUTHORIZED INSTRUCTIONS FROM GOVERNMENT OR OTHER

PERSONNEL

C. PERFORMANCE OF WORK BY CONTRACTOR CERTIFICATION

D. IDENTIFICATION OF EMPLOYEES

E. OTHER WORK

F. SUBMITTING PAY ESTIMATES AND PAYMENTS TO THE CONTRACTOR

G. IMPLEMENTING EQUIPMENT GUARANTEES

H. SAFEGUARDING OF INFORMATION

I. INSURANCE – WORK ON A GOVERNMENT INSTALLATION

J. PUBLIC RELEASE OF INFORMATION

K. CONTRACTOR PERFORMANCE EVALUATIONS

52.211-10 Alt I COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK – ALTERNATE I

52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION

52.236-4 PHYSICAL DATA

5152.222-9000 CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR PAYROLLS (APR 2011)

5152.231-9000 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE (MAR 1995)

5152.232-9001 SPECIAL CONTINUING CONTRACT FOR CIVIL WORKS PROJECT MANAGED BY

THE UNITED STATES ARMY CORPS OF ENGINEERS [DEVIATION]

5152.236-9009 PARTNERING (FEB 2000)

A. CONTRACTADMINISTRATION

This contract will be administered by:

U.S. Army Corps of Engineers, Portland District Bonneville Resident Office

P.O. Box 70 Cascade Locks, OR 97014-0070

Name: M. Violet Albright Telephone: (541) 414-7963

A Contracting Officer’s Representative has not yet been assigned to this project. The successful offeror will be notified in writing by the Contracting Officer when the appointment is made.

(End of Requirement)

B. UNAUTHORIZED INSTRUCTIONS FROM GOVERNMENT OR OTHER PERSONNEL

The Contractor shall not accept instruction issued by any person employed by the U.S. Government or otherwise, other than the Contracting Officer or the authorized representative of the Contracting Officer acting within the limits of his authority.

C. PERFORMANCE OF WORK BY CONTRACTOR CERTIFICATION

For purposes of determining the contractor’s compliance with clause 52.236-1, Performance of work by Contractor, the Government will require the contractor to provide the following certified information with each monthly progress payment. This information will allow the Government to verify that the contractor is in compliance with the requirement for performance of work on site with its forces. Failure to provide the certification may result in rejection of the progress payment. The contractor may use the dollar amount of paid costs for on-site labor or the number of on-site man hours worked to meet this requirement.

The following certification will be provided:

Progress Payment Reference Number:

A) Value/hours of total on-site labor previously paid/incurred:

B) Value/hours of prime contractor on-site labor forces previously paid/incurred:

C) Value/hours of all on-site Labor in this progress payment:

D) Value/hours of on-site labor in this payment performed by prime contractor forces:

E) Total value/hours of all on-site labor for contract (A + C):

F) Total Value/hours of on-site labor by prime contractor forces for contract (B + D):

Percentage of work performed by contractor to date: (F divided by E): % I certify that the above information is current, accurate and complete to the best of my knowledge and that I have the authority to provide the information requested on this form.

DATE NAME

POSITION, COMPANY

(End of Certification)

D. IDENTIFICATION OF EMPLOYEES

The Contractor shall be responsible for furnishing to each employee engaged on the work to display such identification as may be approved and directed by the Contracting Officer. All prescribed identification shall immediately be delivered to the Contracting Officer for cancellation upon the release of any employee. When required by the Contracting Officer, the Contractor shall obtain and submit fingerprints of all persons employed or to be employed on the project.

E. OTHER WORK

The Contractor shall fully cooperate with other Contractors, utility companies, and Government employees engaged in other work on and/or adjacent to the work to be performed under this contract. The Contractor shall coordinate the work herein and the use of haul roads, aggregate sources, and utilities that become a joint responsibility. Any damage resulting from the use of facilities of other Contractors shall immediately be repaired to the satisfaction of, or as directed by the Contracting Officer.

F. SUBMITTING PAY ESTIMATES AND PAYMENTS TO THE CONTRACTOR

The Contractor shall use Engineer Form 93 (ENG 93), Payment Estimate – Contract Performance, as its request for payment. The ENG Form 93 shall be sent to the Contracting Officer’s Representative for certification that the work invoiced has been performed. His mailing address for submission of the ENG Form 93 will be provided immediately upon appointment. The Contracting Officer’s Representative or Administrative Contracting Officer is responsible for ensuring acceptance and approval for payment. Advance payments will not be made.

Original Invoice to:

Department of the Army, Portland District Corps of Engineers

Bonneville Resident Office P.O. Box 70 Cascade Locks, OR 97014-0070

Name: M. Violet Albright Telephone: (541) 414-7963

The Contractor must submit the certification at FAR Clause 52.232-5, paragraph (c) along with each request for progress payments.

G. IMPLEMENTING EQUIPMENT GUARANTEES

When the completed facility or part of a facility is accepted by the Contracting Officer, and the work includes equipment covered by a guarantee which exceeds the warranty of construction period as specified, the Contractor shall furnish the following information to the Contracting Officer:

a. A list of all items with make and model numbers.

b. A copy of manufacturer's or vendor's guarantee documents which extend beyond the warranty of construction period.

c. The date during which the Contractor's guarantee is in effect under the properly identified individual section and paragraph of the Technical Provisions each item of equipment on the list, indicating for each item the date of acceptance for the beginning of the guarantee period, either for beneficial use or final acceptance, whichever is earlier, and the expiration date of the guarantee period.

d. Name of an authorized representative of the Prime Contractor with complete address and telephone number, and the names, addresses, and telephone numbers of all subcontractors and/or equipment suppliers or manufacturers specifically designated in writing by the Prime Contractor for direct contact by the United States Army Corps of Engineers for implementing the guarantee after transfer of the equipment.

H. SAFEGUARDING OF INFORMATION

The personnel employed on this contract may, in the performance of their assigned duties, have access to data and information pertaining to location of goods, supplies, parts, equipment, and vehicles.

Knowledge of this nature is considered restricted security information. This information shall be protected and safeguarded against disclosure to any unauthorized person or party and shall be furnished or used on an official "need to know" basis only. Safeguarding of information is extended to dependents and guests of employees who may, in any manner, obtain any of the above-specified knowledge.

I. INSURANCE – WORK ON A GOVERNMENT INSTALLATION

a. The Contractor shall, at its own expense, provide and maintain during the entire performance period of this contract, at least the kinds and minimum amounts of insurance required by this Clause as follows:

TYPE AMOUNT

1) Workman's Compensation and Employer's Liability (including Federal Longshoremen . and Harbor Worker's Insurance)

As legally required by the State wherein the work is being performed.

2) Comprehensive General Liability Insurance Personal Injury Liability:

$1 million per person $1 million per occurrence

Property Damage (may be included in general aggregate limits or combined single unit coverage):

$1 million per occurrence

3) Automobile Liability Personal Injury Liability:

$1 million per person $1 million per occurrence

Property Damage (may be included in general aggregate limits or combined single unit coverage):

$1 million per occurrence

4) If single general aggregate limits or combined single unit coverage is obtained for General Liability and/or Automobile Liability coverage, minimum amounts shall be the sum of the personal injury and property damage coverage required above. Umbrella Form Excess Liability insurance coverage shall be added to general liability and automobile liability coverage to determine if minimum insurance limits are met.

b. Before commencing work under this contract, the Contractor shall certify to the Contracting Officer in writing that the required insurance has been obtained. The policies evidencing required insurance shall contain an endorsement to the effect that any cancellation or any material change adversely affecting the Government's interest shall not be effective (1) for such period as the laws of the State in which this contract is to be performed prescribe, or (2) until 30 days after the insurer or the Contractor gives written notice to the Contracting Officer, whichever period is longer.

c. The Contractor shall insert the substance of this clause, including this paragraph (c), in subcontracts under this contract that require work on a Government installation and shall require subcontractors to provide and maintain the insurance required in the Schedule or elsewhere in the contract. The Contractor shall maintain a copy of all subcontractors' proofs of required insurance, and shall make copies available to the Contracting Officer upon request.

d. "Government Installation" for this clause includes government vessels.

J. PUBLIC RELEASE OF INFORMATION

The contractor shall coordinate with the Portland District of the U.S. Army Corps of Engineers for release of information to the public concerning this contract or any program related to this contract. This clause covers Media Relations and Printed Materials.

1. Media Relations

The contractor is permitted to speak to news media representatives in accordance with his firm’s public relations policies and in conjunction with applicable U.S. government or Army Corps of Engineers’ guidelines on release of information related to the specific program for which the contract was awarded. The contractor is required to inform the Portland District of significant media contacts. The contractor is encouraged to coordinate directly with Portland District’s Public Affairs Officer, as necessary, when the media call is being responded to; however, this shall not preclude the contractor from responding to media requests in a timely manner. The contractor shall respond to inquiries that directly fall within his domain; he shall not speak for the Army or the Corps.

2. Printed Materials

a. The contractor shall not release to anyone outside the contractor’s organization any unclassified information, regardless of medium, pertaining to this contract, unless:

i. The Portland District has given written approval, either by the Public

Affairs Officer or by the Contracting Officer;

ii. Or the information is otherwise in the public domain before the date of release.

b. The contractor shall obtain approval from the Portland District prior to the dissemination of any briefings or speeches, news releases, articles, fact sheets, advertisements, or any other informational materials intended for public release that are the result of work performed or to be performed under this contract. This review is intended to insure that public release of material does not violate government policy.

c. Requests for approval shall identify the specific information to be released, the medium to be used, and the purpose for release. This material shall be submitted to the Public Affairs Officer and to the Contracting Officer at the Portland District. The contractor shall strive to provide five working days for such approvals. Materials to be released within a shorter period of time will require special handling procedures, and the contractor shall request special consideration directly to the Public Affairs Officer or to the Contracting Officer.

d. The Contractor agrees to include a similar requirement in each subcontract under this contract. Subcontractors shall submit requests for authorization to release through the prime contractor to the government (the Public Affairs Officer and the Contracting Officer), assuring the government that the prime contractor is knowledgeable of the action and concurs.

Nothing in the foregoing section on public release of information shall affect compliance with the clause of the contract entitled, “Security Requirements.”

K. CONTRACTOR PERFORMANCE EVALUATIONS

In accordance with UAI 5142.1502-100 and the Engineering Regulation 415-1-17, Construction Contractor Performance Evaluations, dated 24 January 2012, It is USACE policy that the Procuring Contracting Officer (PCO), or designated representative of the construction office responsible for monitoring contractor performance, will evaluate construction contractor’s performance and prepare a performance evaluation report in the Contractor Performance Assessment Reporting System (CPARS). The Contractor shall be briefed of the CPARS process at the time of the Preconstruction Conference.

The following have been deleted:

52.211-10

(End of Summary of Changes)

The Dalles Arc Flash Hazard Reduction Project

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 10 00.00 25 CONTRACT ADMINISTRATION DATA

01 10 10.00 25 CONTRACTOR'S OPERATIONS AND REQUIREMENTS

01 11 00.00 25 SUMMARY OF WORK

01 22 00.00 25 MEASUREMENT AND PAYMENT

01 32 01.00 25 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 35 26.00 25 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 25 QUALITY CONTROL

01 45 00.15 25 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 57 20.00 25 ENVIRONMENTAL PROTECTION

01 78 23.00 25 OPERATION AND MAINTENANCE DATA

01 78 39.00 25 PROJECT RECORD DOCUMENTS

DIVISION 02 - EXISTING CONDITIONS

02 82 14.00 25 ASBESTOS ABATEMENT WORK

02 83 13.00 20 LEAD IN CONSTRUCTION

DIVISION 03 - CONCRETE

03 60 00.00 26 CONCRETE DEMOLITION, REPAIR OF CONCRETE SURFACES, AND

EQUIPMENT FOUNDATIONS

DIVISION 13 - SPECIAL CONSTRUCTION

13 48 00.00 26 SEISMIC RESTRAINT FOR MECHANICAL AND ELECTRICAL EQUIPMENT

DIVISION 26 - ELECTRICAL

26 05 00.00 26 ELECTRICAL EQUIPMENT AND WORK

26 05 19.00 26 INSULATED WIRE AND CABLE

26 05 26.00 26 GROUNDING

26 08 01.00 26 FIELD TESTING

26 13 13.00 26 METAL CLAD SWITCHGEAR

26 28 00.00 26 SWITCHBOARDS

DIVISION 33 - UTILITIES

33 72 33.14 26 POWER SYSTEM RELAY PROTECTION AND METERING

33 75 10.00 26 MOTOR OPERATORS FOR HIGH VOLTAGE GROUND DISCONNECT SWITCH

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 1

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 10 10.00 25

CONTRACTOR'S OPERATIONS AND REQUIREMENTS

PART 1 GENERAL

1.1 DESCRIPTION OF WORK

1.2 REFERENCES

1.3 SUBMITTALS

1.4 SCHEDULE FOR CONSTRUCTION

1.5 INTERIM CONSTRUCTION COMPLETION DATES

1.6 PERMITS AND RESPONSIBILITIES

1.7 INCLEMENT WEATHER CONSTRUCTION

1.8 NOTIFICATION OF EQUIPMENT OUTAGE

1.9 LINE OUTAGE REQUEST

1.10 WORK BY THE GOVERNMENT CONCURRENT WITH CONTRACTOR WORK

1.11 WEEKLY COORDINATION MEETINGS

1.12 CONTRACTOR EMPLOYEES

1.13 PAGERS

1.14 ACCESS AGREEMENTS AND WORK AREAS

1.14.1 Access Agreements

1.14.2 Work Areas

1.14.3 Employee Access and Parking

1.15 SECURITY PROCEDURES

1.15.1 Project Security

1.15.2 Contractor's General Personnel

1.15.3 Identification of Employees

1.15.4 Foreign Born Employees

1.15.5 Identification of Contractor Vehicles

1.15.6 Use of Private Vehicles

1.16 SUPPLEMENTAL SECURITY REQUIREMENTS

1.16.1 Personnel Risk Assessment

1.16.2 Authorized Unescorted Access Requirements

1.16.3 Security Programs

1.16.3.1 Quarterly Security Awareness Program

1.16.3.2 Annual NERC Mandated Cyber Infrastructure Protection

Training Program

1.17 ANNUAL ANTITERRORISM AND OPERATIONS SECURITY TRAINING

1.18 DECK ACCESS RESTRICTIONS

1.19 CONSTRUCTION PROJECT IDENTIFICATION SIGN

1.20 UTILITIES

1.20.1 Sanitary Facilities

1.20.2 Electrical Power

1.20.2.1 General

1.20.2.2 Temporary Electrical Wiring

1.20.3 Telephone

1.20.4 Water

1.21 CONTRACTOR'S EQUIPMENT

1.21.1 Contractor's Planned Equipment Methods

1.21.2 Plant and Equipment List

1.21.3 Movement of Equipment by the Contractor

1.22 CONTRACTOR USE OF GOVERNMENT CRANES

SECTION 01 10 10.00 25 Page 1

29 CFR 1926.101 Hearing Protection

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 70 (2014; AMD 1 2013; Errata 1 2013; AMD 2 2013; Errata 2 2013; AMD 3 2014; Errata 3-4 2014; AMD 4-6 2014) National Electrical Code

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. Submit the following in accordance with Section 01 33 00, SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Schedule for Construction; G

Line Outage Request

Access Agreements and Work Areas; G

Security Procedures; G

Personnel Risk Assessment; G

Quarterly Security Awareness Program; G

Annual NERC Mandated Cyber Infrastructure Protection Training Program; G

Annual Antiterrorism and Operations Security Training; G

Temporary Electrical Wiring Plan; G

Contractor's Planned Equipment Methods; G

Plant and Equipment List; G

Loading Diagram; G

Lifting Diagram; G

Loading Plan for Cranes and Heavy Equipment; G

Gas, Vapor, Fume, Dust, and Mist Control Program; G

Disposal Plan; G

1.4 SCHEDULE FOR CONSTRUCTION

In accordance with Section 00700 Contract Clause 52.236-15, SCHEDULES FOR CONSTRUCTION CONTRACTS, submit a schedule for accomplishing the work in this Contract. The schedule will not be used by the Government to select a Contractor; rather it will be used to ensure that the Contractor is capable of accomplishing the necessary work in the allotted time periods. The schedule must be consistent with the completion dates as specified in

SECTION 01 10 10.00 25 Page 4

Section 00800 Contract Clause 52.211-10 Alt I, COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK - ALTERNATE I. Other Contractor's work must also be coordinated in accordance with Contract Clause 52.236-8, OTHER CONTRACTS.

1.5 INTERIM CONSTRUCTION COMPLETION DATES

Complete all contract requirements by the completion date as specified in Section 00800 Contract Clause 52.211-10 Alt I, COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK - ALTERNATE I. Refer to Section 01 11 00.00 25, SUMMARY OF WORK for interim construction completion dates.

1.6 PERMITS AND RESPONSIBILITIES

Obtain all permits and licenses for the work as required under Section 00700 Contract Clause 52.236-7, PERMITS AND RESPONSIBILITIES (Nov 1991).

1.7 INCLEMENT WEATHER CONSTRUCTION

The Contractor's schedule must reflect adverse weather days in all weather dependent activities as defined in Contract Clause 52.236-4, PHYSICAL DATA. Protect work areas from inclement weather, wind damage, and precipitation so that no delay in the prosecution of critical work items, or damage to USACE property occurs. No time extensions will be authorized for materials, work in place, or equipment damaged due to negligence during periods of inclement weather.

1.8 NOTIFICATION OF EQUIPMENT OUTAGE

When an outage is required to work on the equipment covered under this contract, notify the Government 30 days in advance of the work. This will allow the Government to de-energize the equipment for Contractor access.

1.9 LINE OUTAGE REQUEST

a. Schedule work to hold outages to a minimum.

b. Requests for line outages must be made in writing to the CO at least 45 calendar days in advance of the time required. Each request must include the approximate duration of outage and the nature of work involved.

c. Outage required for Line one is permitted only during the dates of 1 December - 15 February.

1.10 WORK BY THE GOVERNMENT CONCURRENT WITH CONTRACTOR WORK

The Government will limit interference with the Contractor's work to the maximum reasonable extent and the Government and Contractor shall coordinate as necessary.

1.11 WEEKLY COORDINATION MEETINGS

Weekly coordination meetings must be held between the Contractor and the Government. This meeting will be used to discuss Contractor's safety, Quality Control Program, submittals, deficiencies, Contract administration, schedule, actual progress in the last week, and work planned in the upcoming two weeks. Any work requiring Project support or potential impacts to Project operations or maintenance must be noted. During the Preconstruction Meeting, the Government will determine responsibility of

SECTION 01 10 10.00 25 Page 5

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00.00 25

SUMMARY OF WORK

PART 1 GENERAL

1.1 SUMMARY

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

1.2.2 Location

1.3 INTERIM CONSTRUCTION COMPLETION DATE

1.4 CONTRACT DRAWINGS

1.5 OCCUPANCY OF PREMISES

1.6 EXISTING WORK

PART 2 PRODUCTS - NOT USED

PART 3 EXECUTION - NOT USED

-- End of Section Table of Contents --

SECTION 01 11 00.00 25 Page 1 switches. Installation of cable and conduit for control of the MOD's from the SCADA system in the station service bay.

f. Installation of a DC switchboard in the battery charging room (El.

90'). The switchboard will include two 125V DC 2-pole breakers with matching breakers for testing. The switchboard will include one 3-pole 250V DC breaker and matching breaker for testing. The DC breakers will be equipped with remote trip and close coil functionality. A breaker control panel with six selector switches for each battery breaker will be installed in the charging room with wiring to the breakers and will control opening and closing of the breakers.

An additional control panel, located in the battery room will also be installed. The control panel in the battery room will only have the breaker trip functionality.

g. Installation of 33 new maintenance switches, blue indicating lights, and associated wiring. The maintenance switches will reduce the arc flash hazard at the main breakers in the following locations: SUA Bus 1 and 2, SU1 bus 1 and 2, SU2 bus 1 and 2, SU3 bus 1 and 2, SU4 bus 1 and 2, SQ0 bus 1 and 2, SQ1 bus 1 and 2, SQ2 bus 1 and 2, SP3, SP5, DQ5, SH1, SH2, SH3, XPSRA, XPSR1, XPSR2, XPSR3, XPSR4 and DQ3. Installation of all cables and conduit connecting maintenance switches to associated relay. The installation of maintenance switches in the SR boards will be completed by others, contractor is only responsible for wiring to the SR boards. A means will be provided to lock the maintenance switch in maintenance mode to prevent unintended switching back to normal mode during equipment maintenance.

h. Installation of digital trip breakers into the following nineteen

(19) 480V load center locations: CQ24-Inferred Heater, SU15-1C, SU15-3C, SU16-1C, SU16-3C, SU17-1C, SU17-3C, SU18-1C, SU18-3C, SU19-1C, SU19-3C, SU20-1C, SU20-3C, SU21-1C, SU21-3C, SU22-1C, SU22-3C, SH1-1, SH2-16.

i. Installation of 5kV DP1 switchgear with one 350 Amp main breaker, one 350 Amp feeder breaker and three spare cubicles in the warehouse near DQ6. The switchgear will be provided with a UPS and protective relays.

j. Installation of 3-1/C No. 4/0 cable from the XPWH switch to DP1.

Installation 3-1/C No. 4/0 cable from DP1 to DQ5 and DQ6.

k. Installation of 12 surge arrestors (one per phase) and surge capacitors onto the primary winding of transformers in DQ5 and DQ6 (bus 1 and bus 2) and DQ6A.

l. Installation of the following six 225A 2-Pole DC breakers: SB1A-17, SB1A-18, SB3A-17, SB3A-18, SB1B-18 and SB3B-17. Each breaker will be equipped with a single mount connector kit.

1.2.2 Location

The work site is located at The Dalles Dam, OR. Contractor access to the work site is from the Oregon side of the Columbia River via Interstate 84.

1.3 INTERIM CONSTRUCTION COMPLETION DATE

In accordance with Section 00800 Contract Clause 52.211-10 Alt I and 52.211-12, work must be completely finished to the points specified for

SECTION 01 11 00.00 25 Page 3 each of the dates.

1.4 CONTRACT DRAWINGS

a. The Drawings that accompany these Specifications are a part thereof.

b. One set of full size Contract drawings, maps, and Specifications will be furnished to the Contractor without charge per Section 00700 Contract Clause 252.236-7001, CONTRACT DRAWINGS AND SPECIFICATIONS.

Reference publications will not be furnished.

c. Contractor must immediately check furnished Drawings and notify the Government of any discrepancies.

1.5 OCCUPANCY OF PREMISES

a. Building(s) will be occupied during performance of work under this Contract.

b. Before work is started, the Contractor must arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.6 EXISTING WORK

In addition to Section 00700 Contract Clause 52.236-9, PROTECTION OF

EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND IMPROVEMENTS:

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portion of the existing work to remain.

b. Upon completion of the work, repair or replace portions of existing work, which have been damaged by Contractor's operations, to preconstruction conditions at the expense of the Contractor.

PART 2 PRODUCTS - NOT USED

PART 3 EXECUTION - NOT USED

-- End of Section --

SECTION 01 11 00.00 25 Page 4

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 22 00.00 25

MEASUREMENT AND PAYMENT

PART 1 GENERAL

1.1 GENERAL INFORMATION

1.2 SUBMITTALS

1.3 UNIT PRICE PAYMENT ITEMS

1.4 JOB PAYMENT ITEMS

1.5 MEASUREMENT AND PAYMENT

1.5.1 Mobilization and Demobilization, CLIN 0001

1.5.2 Reserved, CLIN 0002

1.5.3 Replacement of 480VAC Circuit Breakers, CLIN 0003

1.5.4 Replacement of 125VDC Circuit Breakers, CLIN 0004

1.5.5 Removal of Battery Disconnect Switches, CLIN 0005

1.5.6 Removal of Warehouse cable, CLIN 0006

1.5.7 Replacement of Manual operators for the High Voltage Disconnect

Ground switches, CLIN 0007

1.5.8 Installation of DC Switchboard, CLIN 0008

1.5.9 Installation of Breaker Maintenance Switches, CLIN 0009

1.5.10 Installation of 5kV Switchgear, CLIN 0010

1.5.11 Installation of Surge Arresters, CLIN 0011

1.5.12 Installation of Warehouse Cable, CLIN 0012

PART 2 PRODUCTS - NOT USED

PART 3 EXECUTION - NOT USED

SECTION 01 22 00.00 25 Page 1

Provide a schedule of values for job items prior to the first pay request.

Update with each subsequent payment request.

MANDATORY ITEMS

1.5 MEASUREMENT AND PAYMENT

1.5.1 Mobilization and Demobilization, CLIN 0001

a. Measurement: Measurement will be made as a job for mobilizing and demobilizing all plant, equipment, fuel, supplies, materials, and personnel to and from the job site. This Contract Line Item Number (CLIN) applies to the Prime Contractor and all subcontractor mobilization and demobilization.

b. Payment: Payment will be made as stated in Contract Clause 252.236-7004, PAYMENT FOR MOBILIZATION AND DEMOBILIZATION (Dec 1991).

Submit a schedule of mobilization and demobilization costs prior to submitting the first request for payment.

1.5.2 Reserved, CLIN 0002

1.5.3 Replacement of 480VAC Circuit Breakers, CLIN 0003

a. Measurement: Measurement will be made as a job for providing all labor, equipment, materials, parts, and incidentals for the removal and disposal of 19 480V circuit breakers: CQ24-Infrared Heater, SU15-1C, SU15-3C, SU16-1C, SU16-3C, SU17-1C, SU17-3C, SU18-1C, SU18-3C, SU19-1C, SU19-3C, SU20-1C, SU20-3C, SU21-1C, SU21-3C, SU22-1C, SU22-3C, SH1-1, SH2-16, and the replacement with digital trip breakers.

b. Payment: Payment will be made at the Contract amount under CLIN 0003.

1.5.4 Replacement of 125VDC Circuit Breakers, CLIN 0004

a. Measurement: Measurement will be made as a job for providing all labor, equipment, materials, parts, and incidentals for the removal and disposal of six 125VDC circuit breakers: SB1A-17, SB1A-18, SB3A-17, SB3A-18, SB1B-18 and SB3B-17 and the replacement with 225A 2-Pole DC breakers.

b. Payment: Payment will be made at the Contract amount under CLIN 0004.

1.5.5 Removal of Battery Disconnect Switches, CLIN 0005

a. Measurement: Measurement will be made as a job for providing all labor, equipment, materials, parts, and incidentals for the removal and disposal of two battery disconnect switches, BAT-B1 DISC, BAT-B3 DISC, and three battery test disconnect switches, BAT-B1 DISC TEST, BAT-B2 DISC TEST, BAT-B3 DISC TEST, for Battery Banks 1, 2 and 3 and associated cable and conduit. This also includes the removal of the breaker in battery disconnect BAT-B2.

b. Payment: Payment will be made at the Contract amount under CLIN 0005.

SECTION 01 22 00.00 25 Page 3

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 45 00.00 25

QUALITY CONTROL

PART 1 GENERAL

1.1 REFERENCES

1.2 SUBMITTALS

1.3 LABORATORY VALIDATION

1.4 PAYMENT

PART 2 PRODUCTS - NOT USED

PART 3 EXECUTION

3.1 GENERAL REQUIREMENTS

3.1.1 Quality Control System

3.1.2 Project Superintendent

3.2 CONTRACTOR QUALITY CONTROL PLAN

3.2.1 Content of the CQC Plan

3.2.2 Acceptance of CQC Plan

3.2.3 Notification of Changes

3.3 COORDINATION MEETING

3.4 QUALITY CONTROL ORGANIZATION

3.4.1 Personnel Requirements

3.4.2 CQC System Manager Qualifications

3.4.3 CQC Specialized Personnel

3.4.4 Construction Quality Management for Contractors

3.4.5 Organizational Changes

3.5 SUBMITTALS AND DELIVERABLES

3.6 QUALITY CONTROL

3.6.1 Preparatory Phase

3.6.2 Initial Phase

3.6.3 Follow-up Phase

3.6.4 Additional Preparatory and Initial Phases

3.7 TESTS

3.7.1 Testing Procedure

3.7.2 Testing Laboratories

3.7.3 Onsite Laboratory

3.7.4 Furnishing or Transportation of Samples for Testing

3.8 COMPLETION INSPECTION

3.8.1 Punch-Out Inspection

3.8.2 Pre-Final Inspection

3.8.3 Final Acceptance Inspection

3.9 DOCUMENTATION

3.10 NOTIFICATION OF NONCOMPLIANCE

SECTION 01 45 00.00 25 Page 1

The Contractor is cautioned that the validation process is lengthy and that it requires immediate action. Keep the CO informed about the validation process as it proceeds in a timely manner.

3.7.3 Onsite Laboratory

The Government reserves the right to utilize the Contractor's control testing laboratory and equipment to make assurance tests, and to check the Contractor's testing procedures, techniques, and test results at no additional cost to the Government.

3.7.4 Furnishing or Transportation of Samples for Testing

Costs incidental to the transportation of samples or materials must be borne by the Contractor. Samples of materials for test verification and acceptance testing by the Government must be delivered to the Portland District contract commercial Laboratory in the District area. Coordination for each specific test, exact delivery location, and dates must be made through the Portland District Resident Office.

3.8 COMPLETION INSPECTION

3.8.1 Punch-Out Inspection

The CQC Manager must conduct an inspection of the work near the end of the work, or any increment of the work established by a time stated in the specifications, or the Contract Clause 52.211-10 Alt I, COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK - ALTERNATE I. As required by paragraph DOCUMENTATION, prepare and include in the CQC documentation a punch list of items which do not conform to the approved drawings and specifications. Include within the list of deficiencies the estimated date by which the deficiencies will be corrected. The CQC System Manager or staff must make a second inspection to ascertain that all deficiencies have been corrected. Once this is accomplished, notify the Government that the facility is ready for the Government Pre-Final inspection.

3.8.2 Pre-Final Inspection

The Government will perform the pre-final inspection to verify that the work is complete. A Government Pre-Final Punch List may be developed as a result of this inspection. The Contractor's CQC System Manager must ensure that all items on this list have been corrected before notifying the Government, so that a Final inspection with the customer can be scheduled.

Correct any items noted on the Pre-Final inspection in a timely manner.

These inspections and any deficiency corrections required by this paragraph must be accomplished within the time slated for completion of the entire work or any particular increment of the work if the project is divided into increments by separate completion dates.

3.8.3 Final Acceptance Inspection

The Contractor's Quality Control Inspection personnel, plus the superintendent or other primary management person, and the CO must be in attendance at the final acceptance inspection. Additional Government personnel including, but not limited to, those from Base/Post Civil Facility Engineer user groups and major commands may also be in attendance. The final acceptance inspection will be formally scheduled by the CO based upon results of the Pre-Final inspection. Notify the CO at least 14 days prior to the final acceptance inspection and include the

SECTION 01 45 00.00 25 Page 10