REQUEST FOR PROPOSAL (RFP)

2026-RFP-016

STREET BANNERS (CITY BRANDING)

City of Lake Forest

100 Civic Center Dr.

Lake Forest, CA 92630

RELEASE DATE: May 13, 2026

DEADLINE FOR QUESTIONS: May 20, 2026

RESPONSE DEADLINE: June 3, 2026, 4:00 pm

RESPONSES MUST BE SUBMITTED ELECTRONICALLY TO:

https://secure.procurenow.com/portal/lakeforestca https://secure.procurenow.com/portal/lakeforestca

City of Lake Forest

REQUEST FOR PROPOSAL (RFP)

Street Banners (City Branding)

I. Introduction II. General Information

III. RFP - Proposal Requirements IV. Scope of Work V. Evaluation Details

VI. Evaluation Phases VII. General Provisions

VIII. Pricing Proposal IX. Vendor Questionnaire

Attachments:

A - LAKE FOREST_ MODEL Maintenance Services Documents 2022

Request for Proposal (RFP) #2026-RFP-016 Title: Street Banners (City Branding)

1. Introduction

1.1. Summary

Street Banners (City Branding)

Banner Printing and Installation Services for the City Branding Project

The City of Lake Forest is seeking qualified vendors to provide Street Banner Printing and Installation

Services. The Scope of Services for Banner Printing and Installation Services includes provisions for the design, fabrication, installation, maintenance, removal, storage and in some instances the cleaning and return of banners.

1.2. Background

About the City

The City of Lake Forest is located in southern Orange County, California, in the area commonly referred to as the Saddleback Valley, with a population of approximately 85,000. It is the County's thirty-first city and the second largest city within the Saddleback Valley, encompassing 16.6 square miles. The City of

Lake Forest's fiscal year begins on July 1 and ends on June 30.

The City was incorporated in 1991, operates under the Council/Manager form of government and is considered a contract city. The five members of the City Council are elected by district. They serve staggered four-year terms, with the Mayor being selected annually from among the Council Members.

The Council meets on the first and third Tuesdays of each month.

City Hall is located at 100 Civic Center Drive, Lake Forest, California 92630. The telephone number is

(949) 461-3400, and the fax is (949) 461-3511. The City website address is http://www.lakeforestca.gov.

Project Description

The City is seeking Banner Printing and Installation Services for the City Branding Project .

The services are expected to be completed within three years from contract award. The City anticipates awarding a contract with an initial term of July 1, 2026 to June 30, 2029. The City will have the option, at its sole discretion, to extend the agreement for up to two (2) additional one year terms. If the parties are unable to reach an agreement, the City, at its sole discretion, will not move forward with the renewal option and shall re-procure the work.

1.3. Contact Information

Nidia Ruelas

Assistant to the City Manager

100 Civic Center Drive

Lake Forest, CA 92630 http://www.lakeforestca.gov/

Email: nruelas@lakeforestca.gov

Phone: (949) 461-3437

Department:

City Manager

1.4. Timeline

The following timeline shows the anticipated schedule for the RFP. The City expects, but does not guarantee, the the contract award will be made by the City Council on the date indicated below. All schedules and timelines are subject to related and required approvals.

Release Project Date May 13, 2026

Pre-proposal Requests for Clarification May 20, 2026, 5:00pm

Proposal Submission Deadline June 3, 2026, 4:00pm

Anticipated Council Date/City Manager

Approval

June 16, 2026

Anticipated Project Start July 1, 2026 mailto:nruelas@lakeforestca.gov tel:(949)461-3437

2. General Information

2.1. GENERAL REQUIREMENTS

The City of Lake Forest ("City") seeks proposals ("Proposals") from qualified firms ("Respondents") for

Street Banners (City Branding).

Responses must conform with the requirements of this Request for Proposal ("RFP"). The City reserves the right to waive any irregularity in any proposal or to reject any proposal which does not comply with this RFP. Modifications to the RFP, including, but not limited to the scope of work, can be made only by written addendum issued by the City. Selection of the proposer will be made solely by the City on criteria determined by the City.

The successful Respondent will be required to enter into an Agreement (incorporated herein as

Attachment A) which will include the requirements of this RFP as well as other requirements. By submitting a Proposal, the Respondent agrees to all of the terms of the RFP and Agreement. The City reserves the right to reject any proposal(s) exceptions or changes to the Agreement or Request for

Proposal.

2.2. PROJECT DESCRIPTION

Project Description

The City is seeking Banner Printing and Installation Services for the City Branding Project .

The services are expected to be completed within three years from contract award. The City anticipates awarding a contract with an initial term of July 1, 2026 to June 30, 2029. The City will have the option, at its sole discretion, to extend the agreement for up to two (2) additional one year terms. If the parties are unable to reach an agreement, the City, at its sole discretion, will not move forward with the renewal option and shall re-procure the work.

2.3. PRE-PROPOSAL MEETING

No Pre-Proposal Meeting

There will be no pre-proposal meeting for this RFP.

2.4. REQUESTS FOR CLARIFICATIONS

All questions, requests for interpretations or clarifications, either administrative or technical must be requested via the City's eProcurement Q&A feature.

All written questions will be answered in writing and conveyed to all interested firms. Oral statements regarding this RFP by any persons should be considered unverified information unless confirmed in writing. To ensure a response, questions must be received before 5:00 pm on Wednesday, May 20, 2026.

2.5. SCOPE OF REQUIRED SERVICES

Scope of Work

A detailed Scope of Work is provided under the Scope of Work section. The Respondent will be expected to fulfill, at a minimum, the services and technical requirements described in the Scope of Work. Upon final selection, the Scope of Work may be modified and refined during negotiations with the City.

https://procurement.opengov.com/portal/lakeforestca/projects/255735/document?section=2447086 https://procurement.opengov.com/portal/lakeforestca/projects/255735/document?section=2447086

3. RFP - Proposal Requirements

3.1. PROPOSAL CONTENT

Respondent's Proposal shall be clear, accurate, and comprehensive. Excessive or irrelevant materials will not be favorably received. The content and sequence of the information contained in each copy of the proposal shall be as follows:

1. Summary Sheet o Include a fully-completed copy of the Summary Sheet included with this RFP (To be completed as part of the Vendor Questionnaire).

2. Table of Contents o Include a clear identification of the material by section and by page number.

3. Letter of Transmittal o Identify Respondent's legal name and contact information, including corporate office and local office address, telephone number, fax number, web site address, and e-mail address.

o Summarize key elements of the proposal. The letter should stipulate that the cost proposal will remain valid for a period of at least 180 days. The letter shall be signed by an individual or individuals authorized to execute legal documents on behalf of the Respondent.

4. Key Personnel o Identify the names and specific qualifications, experience, and appropriate licenses held, if applicable, of the primary staff to be assigned to the project. Include a resume for all primary staff, as applicable. Include any subconsultants which Respondent proposes to use for any portion of the services.

o Respondent shall also identify a Management Contact (Representative authorized to sign an agreement for your firm) and a Project Manager (person responsible for day-to-day management of he project). The successful Respondent may only change the Management

Contact, Project Manager, and other supporting staff and specialists with prior written permission of the City.

5. Project Management/Schedule o Provide a conceptual plan for services to the City that you believe are appropriate for the services in the solicitation. Indicate features, skills and/or services which distinguish your firm and make it the better choice for the City. Indicate how the resources of your firm (e.g., number and type of personnel allocated by hours) will be allocated for this project, as applicable. A proposer may customize the resource allocation accordingly.

6. Scope of Work o Provide a detailed scope of services which reflects the Scope of Work described in this RFP.

Proposals should address all items set forth in Scope of Work section. Additional information which, in your opinion, should be included must be clearly identified.

7. Experience

1. List of Representative Projects - List of representative projects undertaken by Respondent in the last 5 years demonstrating experience in each category of the project. Identify the names of organizations, and names and telephone numbers of persons who can be contacted with regard to the services you have provided.

2. Current City Contracts - Identify all previous and current contracts with the City of Lake

Forest. Include a contact name, description of services, and dates of services performed.

3. Terminated Contracts - List all public agencies for which contracts were terminated in the last three years. Show names of organizations and names and telephone numbers of persons who can be contacted. Firms may provide a brief explanation of the reason(s) for termination(s).

8. Certificate of Proposal o Include a fully-completed copy of the Certificate of Proposal included with this RFP (To be completed as part of the Vendor Questionnaire).

9. Cost Proposal o Include a detailed cost proposal for each phase of work inclusive of all hourly rates, anticipated travel, and other incidental costs and charges. The cost proposal shall be submitted in a separate, sealed manner and marked "Cost Proposal” with Respondents name and shall be submitted electronically using the Cost Proposal submission feature using the City’s eProcurement site as identified in the Proposal Format Instructions below. If requested, the successful Respondent may be required to submit an electronic copy of the cost proposal using the eProcurement site Pricing Table feature, MS Word, Excel, or other format acceptable to the City.

Proposal Format

Proposals shall be organized to reflect the order presented above. Proposals should include page numbers for all pages in the proposal.

3.2. SUBMITTAL INSTRUCTIONS

Proposals must be received via the City's eProcurement Portal at https://procurement.opengov.com/portal/lakeforestca no later than 4:00 pm on Wednesday, June 3, 2026.

https://procurement.opengov.com/portal/lakeforestca

4. Scope of Work

4.1. Street Banner Printing and Installation Services for the City Branding Project

Project Overview

The City of Lake Forest displays decorative banners on street light poles at a variety of locations throughout the year. The banners include seasonal greetings, celebratory messages, and honors for local military members. The City is seeking a qualified firm to design, install, remove, and store City banners displaying the City's new City Brand along major city thoroughfares, in neighborhoods, at parks, and throughout the City.

Tasks associated with the banner program may include:

Design/Manufacture/Install

• Contractor shall be able to perform the following tasks, which will include but not limited to the following:

• Design, manufacture, and install on hundred (100) banners for the City Branding Project. Banners will be left up for one year, at which time, the chosen vendor will remove, clean, and return the banners to the City. Install in July/August each year.

• Design, manufacture, and install fifty (50) neighborhood banners for the City Branding Project.

Banners will be left up for one year, at which time, the chosen vendor will remove, clean, and return the banners to the City. Install in January each year.

• Specifications for manufacturing of new banners and as needed: Vutek-Role, flexible eight foot by three foot Vinyl Block-out 15 ounce, DF:S:Sewing, 4CP FL:Sewing, Sewing-Pole Pockets three feet, FM Grommets in Brass, Regular Portrait with two sided images.

• Work with City’s project manager to determine possible new locations for banner installation throughout the City.

• In the case of weather damage (as needed) manufacture additional banners. Re-install newly manufactured banners in their former location.

General Schedule Information

City Brand Banners are left up year-round.

Maintenance

• Ability to re-manufacture and re-install damaged or replacement banners within 48 hours following notification from the City.

• Ability to re-install damaged hardware within 48 hours following notification from the City.

Remove/Store/Clean

• Remove banners pursuant to the City’s schedule.

• Store approximately 150 banners at contractor's facility year-round, when not in use, during the agreement term.

• Clean banners prior to installation, reinstallation, and/or return to the City.

Miscellaneous Requirements/Consultant Tasks

• Contractor may be required to work with City staff to determine new locations for banner installation.

• Provide high quality hardware to install banners.

• Contractor will be required to give the City’s contact at least two weeks’ notice of the installation and removal of banners.

• Contractor will be required to give the City’s contact confirmation the installation and banner removal has been finished within 24 hours of completion.

• Contractor is required to provide the City with a 24-hour emergency number for contact outside normal working hours. The response to an emergency call-out by the Contractor shall not be more than two (2) hours.

• Contractor is responsible for any landscape, irrigation, and hardscape damage.

• Contractor shall notify City of any tree trimming necessary to install or remove banners; contractor is not responsible for any tree trimming associated with the landscape area around the banner install areas.

• Contractor shall provide pedestrian access on sidewalks or provide alternate routes with appropriate signage.

• Provide or process all required permits, insurance, tools, and equipment, and delineation for public safety (including arrow board vehicles as per American Public Works Association (APWA) Southern California Chapter Work Area Control Handbook specifications) necessary to complete the entire project.

• Traffic control shall be provided during the installation and removal of street light pole banners. The traffic control requirements shall conform to the standards and specifications of the California Manual on Uniform Traffic Control Devices (MUTCD) of the Work Area Traffic Control Handbook

(WATCH).

• Remove and dispose of property, at the Contractor’s expense, all litter and debris generated by the Contractor during performance of on-site work. Do not allow or permit any litter or other debris to be blown or swept on private property, storm drains, or streets.

• Tour the work area with the Inspector for the purpose of determining compliance with the specifications or to discuss required work. Perform additional work as may be required to bring all deficient work into full compliance with specifications and Inspector’s determinations.

• Encroachment Permits are required by the Public Works Department for the installation and removal of street light pole banners; contractor must obtain the necessary Encroach Permits prior to the installation and removal of the banners and notify the City’s contract administrator that the correct permits have been obtained. Encroachment Fees will be waived.

• Specifications for manufacturing of new banners and as needed: Vutek-Role, flexible eight foot by three foot Vinyl Block-out 15 ounce, DF:S:Sewing, 4CP FL:Sewing, Sewing-Pole Pockets three feet, FM Grommets in Brass, Regular Portrait with two sided images.

• Contractor shall not subcontract with any other entity to perform in whole or in part the services described herein without City expressed written approval.

• The chosen vendor's contract and all related services will be overseen by one of the City’s Assistant to the City Manager.

Ownership of Produced Banners and Hardware Installed

• All hardware and physical banners produced, procured, and installed during the life of this agreement shall be property of the City.

• Designs, logos, brands, and rights to those digital materials may be used only with the express permission of the City to produce the banners. All logos, brands, and digital materials provided by the City may not be used, duplicated, or manipulated by the Contractor for purposes other than those expressly permitted by the City and enumerated in this Scope of Work without express written permission by the City Manager.

• The City shall provide all branding and design guidelines to ensure authenticity and accuracy in all brand representations.

• At the end of the Agreement term, all hardware and materials uninstalled may be requested to be returned to the City, as directed by the City.

• As City-owned property: City retains the right to request inventory list of hardware and banners produced, their locations, and condition to keep its asset management records up to date.

5. Evaluation Details

5.1. Evaluation Criteria

Selection Committee comprised of City staff will evaluate and rank the proposals. Proposals will be evaluated according to the Evaluation Phases.

5.2. Respondent Presentations/Interviews

The City may, at its discretion, invite a shortlist of Respondents to participate in a panel interview to be held at the City. To be considered for an interview, a Respondent must receive an average score of 60 points (60%) or higher on the qualitative proposal portion of the evaluation. The City may require that

Respondents prepare a presentation as part of the interview. No Respondent shall be entitled to or otherwise guaranteed an interview.

5.3. Contract Award

If awarded, the contract will be awarded on the basis of the evaluation criteria set forth herein. The City reserves the right to reject all proposals and to contract for services in the manner that most benefits the City including awarding more than one contract if desired.

5.4. Protests

In order to be considered, a protest must satisfy the following requirements: Protests based on the content of the RFP shall be submitted to the City Representative no later than ten (10) calendar days prior to the scheduled proposal submittal deadline. If necessary, the proposal submittal deadline may be extended pending a resolution of the protest.

Any respondent protesting the recommended award on any ground not based upon the content of the request for proposals must file a protest with the City within three (3) calendar days after the issuance of a notice of recommendation for award. Any protest shall contain a full and complete written statement specifying in detail the grounds of the protest and the facts supporting the protest.

The procedure and time limits set forth in this section are mandatory and are the sole and exclusive remedy in the event of a protest of this procurement. Failure to comply with these protest procedures shall constitute a failure to exhaust administrative remedies and a waiver of any right to further pursue the protest, including filing a Government Code Claim or legal proceedings.

6. Evaluation Phases

EVALUATION PROCEDURES

1. Selection Committee o Proposals submitted will be evaluated by a Selection Committee, appointed by the City

Manager.

2. Review of Proposals o The Selection Committee will use a weighted point formula during the review process to individually score Project Proposals, as outlined in the “Project Proposal Evaluation

Criteria” and the Evaluation Phases below. The Selection Committee will then be convened to review and discuss these evaluations and combine the individual scores to arrive at an average composite Project Proposal score for each firm. Firms that do not meet “Mandatory

Elements” listed in Section 6.3.1 below shall be eliminated from further consideration.

o After the composite Project Proposal score for each firm has been established based upon the “Qualitative Evaluation” criteria listed in Section 6.3.2, the Selection Committee may request oral presentation/interviews from those firms with a minimum average score of 60 points (60%). The Selection Committee may also schedule a site visit, if applicable. The oral presentation/interview will be evaluated based upon the “Oral Presentation/Interview

Evaluation” criteria listed in Section 6.3.3. The sealed Cost Proposal of firms receiving a minimum average score of 60 points on the qualitative review will be opened to ensure that the Cost Proposal is reasonable. A summary of all Project Proposals, qualifying on the basis of the qualitative review, interview, and Cost Proposal evaluation as calculated in Section C4 will be submitted to the City Council or City Manager for final determination.

3. Project Evaluation Criteria - Proposals will be evaluated using three (3) sets of criteria.

1. Mandatory Elements (Pass/Fail)

▪ Firms meeting the mandatory elements will have their proposals evaluated and scored. The following represent the principal selection criteria which will be considered during the evaluation process.

2. Qualifying Proposal Evaluation (Pass/Fail; Maximum Points = 100, Minimum average of 60% of points or 60 points required to proceed to Interview)

▪ In order to be considered for an oral interview/presentation the proposer must achieve at least a minimum average of 60 points from the Qualitative Evaluation. Scores are calculated using weighted criteria.

3. Presentation/Interview Evaluation (Maximum Points =160, 80%) and Cost Proposal

Evaluation (Maximum Points = 40, 20%)

▪ During the evaluation process, the Selection Committee may request oral presentations from firms with a minimum average score of 60 points (60%). Oral presentations will provide firms with an opportunity to answer any questions the Selection Committee may have on a firm’s Project Proposal. The oral presentation will be scored using weighted criteria.

▪ At the conclusion of each of the interviews, the Purchasing Coordinator shall offer each interviewed firm the opportunity to submit a “revised” cost proposal. The intent of this step is not to require the Project Manager to enter into contract negotiations but rather is intended to provide each firm an opportunity to refine its cost proposal subsequent to oral presentations. Each firm will have three to five (3-5) calendar days from the date of the interview to submit a “revised” cost proposal, or indicate in writing that its original cost proposal is to be opened and reviewed.

▪ The interview process is a valuable tool to assess the communication skills and professional demeanor of proposed project personnel. The interview score is arrived at independently from the qualitative proposal score and the two may differ significantly.

The interview portion allows staff greater flexibility to choose a qualified firm with strong communication skills and technical expertise.

4. Rating Definitions o The rating scale establishes standards by which points are assigned to the proposals and oral interviews and it ensures the Selection Committees evaluate each proposal with consistency.

o The following table is a rating scale that is utilized based on a 0-10 scale:

5. Final Selection o The Selection Committee scoring will be provided to the Department Director. The firm must fully execute the Agreement prior to staff recommendation of the contract award to

City Council or City Manager. The City, through the Department Director, reserves the right to negotiate the price, terms, and scope of work with the successful proposer prior to making a recommendation to the City Council.

6.1. Mandatory Elements

No. Evaluation Criteria Scoring Method Weight (Points)

1. The firm is independent and properly licensed to practice in California.

Pass / Fail 1

(25% of Total)

2. The firm has no scope conflict with regard to any other work performed by the firm for the

City.

Pass / Fail 1 (25% of Total)

3. The firm adheres to the instructions in this

RFP on preparing and submitting the proposal.

Pass / Fail 1 (25% of Total)

4. The firm included a Letter of Transmittal in the Project Proposal.

Pass / Fail 1

(25% of Total)

6.2. Qualifying Technical Proposal Evaluation

No

Evaluation Criteria Scoring

Metho d

Weight

(Points

1. Key Personnel

1. The quality of the firm’s professional personnel assigned to the engagement and the quality of the firm’s management support personnel to be available for technical consultation.

2. References relative to personnel assigned to the engagement.

0-10

Points

(15% of

Total)

2. Project Management/Schedule

1. Allocation of resources to the project and project schedule

2. Appropriate timeframes for banner design, manufacturing, and installation

3. Project management tools/resources utilized by the vendor to ensure accurate and timely delivery of project

(20% of

3. Scope of Services

1. Understanding of work to be done and detailed in scope of work.

2. Appropriateness of services to the requirements of the City.

3. Distinguishing features, skills and/or services.

(40% of

4. Experience

1. The vendor’s past experience and performance on comparable private/government engagements.

2. Vendor’s statement on why it believes itself to be best qualified.

(15% of

5. Proposal Quality

1. Vendor’s thoroughness and accuracy in the proposal document including presentation of information, grammar, spelling, and other errors.

(10% of

6.3. Presentation/ Interview Evaluation and Cost Proposal Evaluation

No

Evaluation Criteria Scoring

Metho d

Weigh t

(Points

1. Vendor’s Communication

1. Ability of firm’s assigned team to clearly communicate information to the Selection

Committee

2. Interpersonal communication between firm members and the Selection Committee

3. Vendor team thoroughly and completely answers questions asked by the Selection

Committee

4. Communication plan to carry out services and interface with the City

(16% of

2. Project Understanding

1. Demonstration of understanding of the project by key personnel

2. Demonstration of relevant experience to RFP requirements beyond the written proposal

3. Appropriate service timeframes

(20%

3. Technical Knowledge

1. Demonstration and communication of technical understanding of the required services related to the project

2. Demonstrate ability to convey technical information without use of jargon or overly specialized language

3. Assigned vendor staff has sufficient subject matter knowledge to complete project

(16%

4. Key Personnel

1. Communication and interpersonal skills of key personnel including thoroughness in answering questions and demonstration of problem solving skills

2. Attendance of key personnel assigned to the project at the interview

(20%

5. Meeting Preparation

1. Vendor's preparedness to answer questions and present relevant information

2. Research of the City or the Project

3. Adhering to meeting timeline instructions, good time management of interview

(8% of

6. Cost Proposal Evaluation

The Cost Proposal, either the originally submitted proposal or “revised” proposal, is opened for each firm who has received an average score of at least 60 points after the qualitative review and participated in the oral presentation. The Cost Proposal is valued at 40 points for the firm with the lowest responsive cost. The remaining firms will earn a percentage of the 40 available points based on their cost relationship to the lowest cost proposal. This is calculated by dividing the lowest cost proposal by the cost of the proposal being rated, and then multiplying the results by the maximum points. The result is the awarded points. Cost proposals remain confidential and are not disclosed to proposers during the proposal process.

The Purchasing Coordinator calculates the points for the cost proposal which are included in the final point summary provided to the Department Director to recommend a vendor for contract award.

Points

Based

(20%

7. General Provisions

7.1. Amendments to RFP

The City reserves the right to amend the RFP or issue to all Respondents a Notice of Addendum to answer questions for clarification.

7.2. No Commitment to Award

Issuance of this RFP and receipt of proposals does not commit the City to award a contract. The City expressly reserves the right to postpone the RFP process for its own convenience, to accept or reject any or all proposals received in response to this RFP, to negotiate with more than one Respondent concurrently, or to cancel all or part of this RFP.

7.3. Right to Request Additional Information

During the evaluation process, the City reserves the right, where it may serve the City's best interest, to request additional information or clarifications from proposers, or to allow corrections of errors or omissions. At the discretion of the City, firms submitting proposals may be requested to make oral presentations as part of the evaluation process.

7.4. Amendments to Proposals

Unless specifically requested by the City, no amendment, addendum or modification will be accepted after the deadline stated herein for receiving Proposals. Respondent may modify or amend its Proposal only if the City receives the amendment prior to the deadline stated herein for receiving Proposals.

7.5. Non-Responsive Proposals

A Proposal may be considered non-responsive if conditional, incomplete, or if it contains alterations of form, additions not called for, or other irregularities that may constitute a material change to the

Proposal.

7.6. Late Proposals

The City expects proposals to be submitted via the City's eProcurement Portal at:

https://procurement.opengov.com/portal/lakeforestca. However, the Ctiy will not be responsible for

Proposals that are delinquent, lost, incorrectly marked, sent to an address other than that given herein, or sent by mail or courier service and not signed for by the City.

7.7. Costs for Preparing

The City will not compensate any Respondent for the cost of preparing any Proposal, and all materials submitted with a Proposal shall become the property of the City. The City will retain all Proposals submitted and may use any idea in a Proposal regardless of whether that Proposal is selected.

7.8. Alternative Proposals

Only one final proposal is to be submitted by each Proposer. Multiple proposals will result in rejection of all proposals submitted by the Respondent.

https://procurement.opengov.com/portal/lakeforestca

7.9. Public Documents

All Proposals and all evaluation and/or scoring sheets shall be available for public inspection at the conclusion of the selection process.

7.10. No Exceptions

Submission of a Proposal constitutes acceptance by Respondent of the conditions contained in this RFP and the Maintenance Services Agreement (attached as Attachment A), should Respondent be selected.

7.11. Conflict of Interest

By submitting a Proposal, the Respondent declares and warrants that no elected or appointed official, officer or employee of the City has been or shall be compensated, directly or indirectly, in connection with the award of the Agreement or any work for the proposed project. For the term of the Agreement, no elected or appointed official, officer or employee of the City, during the term of his/her service with the City and for two (2) years following his/her termination of office or employment with the City, shall have any direct interest in the Agreement, or obtain any present, anticipated or future material benefit arising therefrom.

7.12. Confidential Information

Those elements of each Proposal that are trade secrets, as the term is defined in Civil Code Section

3426.1(d) or otherwise exempt by law from disclosure and which are prominently marked as TRADE

SECRET, CONFIDENTIAL or PROPRIETARY may not be subject to disclosure ("Proprietary Information").

This may include private financial information about a Respondent, but does not include the proposed price submitted as part of the Proposal. The City will refrain from releasing Respondent's Proprietary

Information unless the City's legal counsel determines that the release of the Proprietary Information is required by the California Public Records Act or other applicable state or federal law, or order of a court of competent jurisdiction, in which case the City shall notify Respondent of its intention to release

Proprietary Information. Respondent shall have five (5) working days after receipt of such notice to give

City written notice of Respondent's objection to the City's release of Proprietary Information.

Respondent shall indemnify, defend and hold harmless the City, and its officers, directors, employees, and agents from and against all liability, loss, cost or expense (including attorney's fees) arising out of a legal action brought to compel the release of Proprietary Information.

8. Pricing Proposal

CITY BRAND STREET BANNERS (YEAR-ROUND) YEAR 1

Note: All hardware and physical banners produced, procured, and installed during the life of this agreement shall be property of the City. Please indicate if sales tax is already included in your cost, otherwise the system will apply it to items that are marked taxable in each table.

Line Item Description Quantity Unit of

Measure Unit Cost Total

1 City Brand Banners -

Design/Fabricate/Install [*] 75 Street

Banner

2 City Brand Banners - Removal 75 Street

3 City Brand Banners - Hardware [*] 75 Street

4 Neighborhood Banners -

Design/Fabricate/Install [*] 35 Street

5 Neighborhood Banners - Removal 35 Street

6 Neighborhood Banners - Hardware [*] 35 Street

7 Storage/Cleaning of all Banners

(When asked for removal) 110 Street

[*] Denotes item is taxable

Sales Tax (@ 7.75%)

TOTAL

CITY BRAND STREET BANNERS (YEAR-ROUND) YEAR 2

Note: All hardware and physical banners produced, procured, and installed during the life of this agreement shall be property of the City. Please indicate if sales tax is already included in your cost, otherwise the system will apply it to items that are marked taxable in each table.

Line Item Description Quantity Unit of

Measure Unit Cost Total

1 City Brand Banners -

Design/Fabricate/Install [*]

CITY BRAND STREET BANNERS (YEAR-ROUND) YEAR 3

Note: All hardware and physical banners produced, procured, and installed during the life of this agreement shall be property of the City. Please indicate if sales tax is already included in your cost, otherwise the system will apply it to items that are marked taxable in each table.

Line Item Description Quantity Unit of

Measure Unit Cost Total

1 City Brand Banners -

Design/Fabricate/Install [*]

Line Item Description Quantity Unit of

Measure Unit Cost Total

9. Vendor Questionnaire

9.1. Technical Proposal *

Please upload your Technical Proposal WITHOUT ANY cost information.

*Response required

9.2. Cost Proposal *

Please upload your Cost Proposal here.

*Response required

9.3. Proposer Summary Information

Please complete the following questions to submit key information about your business and relevant to your proposal submission.

9.3.1. Business Name*

Include complete business name including DBA name

*Response required

9.3.2. Business Firm Parent or Ownership*

Please include the name of the parent company and list any relevant ownership information.

It is also appropriate to list the structure of your business and state of incorporation ( e.g. a California sole-proprietorship, a Minnesota corporation, a Florida Limited Partnership, etc.)

*Response required

9.3.3. Business Address*

Please include your primary place of business.

*Response required

9.3.4. Business Telephone Number*

*Response required

9.3.5. Business Fax Number

9.3.6. Number of Years in Existence*

*Response required

9.3.7. Management Contact*

Please provide the full name and title of the person responsible for direct contact with the City and the services required for this Request for Proposals.

*Response required

9.3.8. Management Contact Email*

*Response required

9.3.9. Management Contact Telephone Number*

9.3.10. Management Contact Fax

9.3.11. Project Manager*

Please provide the full name and title of the person responsible for day-to-day services in this Request for Proposals.

*Response required

9.3.12. Project Manager Email*

*Response required

9.3.13. Project Manager Telephone Number*

*Response required

9.3.14. Project Manager Fax

9.3.15. Types of Services Performed by the Business*

Please provide a brief description for the type of services performed by the business entity.

*Response required

9.3.16. W9 Form.*

Please upload a current, signed copy of your firm’s W-9 form.

*Response required

9.4. Confirmation and Certifications

Please complete the following required certifications below to complete your proposal submission.

9.4.1. Certification of Proposal to the City of Lake Forest *

1. The undersigned hereby submits its proposal and, by doing so, agrees to furnish services to the City in accordance with the Request for Proposal (RFP), dated and issued Wednesday, May 13, 2026, and to be bound by the terms and conditions of the RFP.

2. This firm has carefully reviewed its proposal and understands and agrees that the City is not responsible for any errors or omissions on the part of the proposer and that the proposer is responsible for them.

3. It is understood and agreed that the City reserves the right to accept or reject any or all proposals and to waive any informality or irregularity in any proposal received by the City.

4. The proposal includes all of the commentary, figures and data required by the Request for Proposal, dated and issued Wednesday, May 13, 2026, including any addenda issued thereafter.

5. This firm has carefully read and fully understands all of the items contained in Section titled: General

Requirements. This firm agrees to all of the general requirements except for those disclosed by the firm in project proposal, listed on an attachment.

6. The proposal shall be valid for 180 days from the date submitted to the City.

☐ Please confirm