Tab_C-6_Attachment_07_Liquidated_Damages.xlsx
XLSX spreadsheet 106 KB Posted
- Attached to
- Small Parcel Sorter and Conveyor Project. Federal contract opportunity
- Solicitation number
- SP330017R5007
- Issued by
- Defense Logistics Agency Distribution
About this file
Attachment 07 Liquidated Damages
View the file
Other files for this federal contract opportunity
| File | Type | Posted |
|---|---|---|
| Amendment_0006.pdf | ||
| Tab_C-6_Attachment_03_Drawing_and_Photos_.pdf | ||
| Amendment_0005.pdf | ||
| Amendment_0004.pdf | ||
| Amendment_0003.pdf | ||
| Tab_C-6_Attachment_12_SPS-2.dwg | DWG drawing | |
| Tab_C-6_Attachment_02_Statement_of_Work.pdf | ||
| Tab_C-6_Attachment_11_SPS-1.dwg | DWG drawing | |
| Amendment_0002.pdf | ||
| Tab_C-6_Attachment_03_Drawing_and_Photos_.pdf | ||
| Tab_C-6_Attachment_09_Subcontracting_Plan_Template.pdf | ||
| Tab_C-6_Attachment_05_Contract_Data_Requirements_List.pdf | ||
| Tab_C-6_Attachment_04_Site_Map.pdf | ||
| Tab_C-6_Attachment_08_Past_Performance_Questionnaire_.pdf | ||
| Tab_C-6_Attachment_06_Data_Item_Description_.pdf | ||
| Tab_C-6_Attachment_02_Statement_of_Work.pdf | ||
| Tab_C-6_Attachment_01_Schedule_of_Supplies.pdf | ||
| Tab_C-6_Attachment_10_SB_Participation_Plan_Template.pdf | ||
| Solicitation.pdf |
Show all 19
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Instructions
| Instruction for completing the liquidated damages sheets. |
| I have made it easy for you. Complete the following questions and I will magically take care of |
| everything else. |
No 1. What is the Project No? (Put it in block F6)
No 2. What is the Project Title? (Put in block F-8)
No 4. Type the C.O.'s Name (Put in block F-12)
| No 5. Total Liquidated Damages from CES | Dollars/per day | |
| (Figures obtained from Tab A1) |
No. 6 Type the Contract Specialist Name (put in Block F16)
| No 7. On the sheet entitled "Determination" there are some inputs that you may/may not need. |
| They are located in blocks E-36 to E-42. These blocks are not locked and you make inputs |
| directly into them. |
| As you will notice we now have 2 LD rates, one for the first day (because legal is |
| involved only on the first day) and one for each day after. These two rates need to both be |
| identified to your contractor. |
| SOURCE SELECTION INFORMATION |
| SEE FAR 2.101 AND 3.104 |
Contracting Personnel
| MEMORANDUM FOR RECORD | ||||
| SUBJECT: Liquidated Damages formula for Contracting Personnel | ||||
| Project No: | 0 | |||
| Title: | 0 | |||
| 1. Liquidated Damages for contracting personnel under subject project were determined in the following | ||||
| manner; multiplied by a rate of 1.33.2% to account for benefits (percentage obtained from OSD memo | ||||
| dated 1 Oct 2015). Civilian/Military rates were obtained from OPM website www.opm.gov | ||||
| at average rate for position title. | ||||
| HOURLY | ||||
| TITLE | NAME | RATE ($) | ||
| Contracting Officer | 0 |
Contract Administrators 0
| 2. In determining the hourly rate for a contract administrator, the average hourly rate was used for liquidated |
| damages. A firm amount cannot be determined prior to issuance of the solicitation because it is not known which |
| administrator will be working with the project after award. The average hourly rate is determined to be the most |
| fair and reasonable method in computing liquidated damages for Operational Contracting personnel. |
| SOURCE SELECTION INFORMATION | |
| SEE FAR 2.101 AND 3.104 | 0 |
| Contracting Officer | |
| Date: |
COR ENG
| MEMORANDUM FOR RECORD | ||||
| SUBJECT: Liquidated Damages formula for COR / Engineering Personnel | ||||
| Project No: | 0 | |||
| Title: | 0 | |||
| 1. Liquidated Damages for Contracting Officer's Representative and Engineering personnel under subject | ||||
| project were determined in the following manner; multiplied by a rate of 1.35% to account for | ||||
| benefits (percentage obtained from Civilian Personnel at 480-2137). Civilian/Military rates were | ||||
| obtained from finance websites www.hq.af.mil/SAFFM/FMC/a31-1 (civilian) and a32-1 (military). | ||||
| HOURLY | ||||
| TITLE | NAME | RATE ($) | ||
| Engineer | Steve Toomey | 42.22 |
| COR | Douglas Betz |
| ACOR | David Tank |
Transportation Cost
Benfits @ 33.2% of Personnel cost
**Total (to Determination tab)
| 2. In determining the hourly rate for a contract administrator, the average hourly rate was used for liquidated | |
| damages. A firm amount cannot be determined prior to issuance of the solicitation because it is not known which | |
| administrator will be working with the project after award. The average hourly rate is determined to be the most | |
| fair and reasonable method in computing liquidated damages for Operational Contracting personnel. | |
| SOURCE SELECTION INFORMATION | |
| SEE FAR 2.101 AND 3.104 | |
| 0 | |
| Contracting Officer | |
| Date: |
Legal
| MEMORANDUM FOR RECORD | ||||
| SUBJECT: Liquidated Damages formula for Staff Judge Advocate | ||||
| Project No: | 0 | |||
| Title: | 0 | |||
| 1. Liquidated Damages for staff judge advocate personnel on construction projects were determined | ||||
| in the following manner: multiplied by a rate of 1.33.2% to account for benefits (percentage | ||||
| obtained from OSD memo dated 1 Oct 2015). Civilian/Military rates were obtained from OPM website | ||||
| www.opm.gov at average rate for position title. | ||||
| HOURLY | ||||
| TITLE | NAME | RATE ($) | ||
| Staff Judge Advocate | 0.00 | |||
| Legal Assistant | 0.00 |
AVERAGE $ - 0 *
| 2. In determining the hourly rate for a staff judge advocate, the average hourly rate was used for |
| liquidated damages. A firm amount cannot be determined prior to issuance of the solicitation |
| because it is not known which of the above individuals will be reviewing the solicitation/contract. |
| The average hourly rate is determined to be the most fair and reasonable method in computing |
| liquidated damages for the staff judge advocate. |
| SOURCE SELECTION INFORMATION | |
| SEE FAR 2.101 AND 3.104 | 0 |
| Contracting Officer | |
| Date: |
Determination
LIQUIDATED DAMAGES DETERMINATION
| SUBJECT: | Project No: | 0 |
| Title: | 0 |
| 1. In accordance with FAR 36.206 and DOD FAR Sup 236.206, liquidated damages (LDs) will be | |||
| assessed for each calendar day of delay required to complete work on subject contract. | |||
| As a minimum, LDs in the amount of | $ - 0 | for the first day and | $ - 0 |
| for each day thereafter will be changed, based upon the following: |
a. The contractor has complete control of the pace of work.
| b. The contract provides for liquidated damages for delay of work for each calendar day |
| of the contract. |
c. Considering the requirement, the rate of assessment is reasonable.
| 0 |
| Contracting Officer |
| Date: |
| LEGAL | ||||||
| Staff Judge Advocate | 0.0 | hours @ | 0.00 | = | 0.00 | |
| (first day only - if applicable) |
| COR / ENGINEERING | ||||
| COR | hours @ | - 0 | 0.00 | |
| ACOR | hours @ | - 0 | 0.00 | |
| Engineer | hours @ | 42.22 | 0.00 | |
| Addition for Benfits of Personnel @ 33.2% | 0.00 |
Total COR / Engineering Cost/Day per day 0.00
CONTRACTING
| Contracting Officer | hours @ | 0.00 | = | 0.00 |
| Acquisition Specialist | hours @ | 0.00 | = | 0.00 |
| Vehicle Costs | 0.00 | |||
| Addition for Benfits of Personnel @ 33.2% | 0.00 |
Total Contracting Cost/Day per day 0.00
ADDITIONAL DAMAGES
| Loss of Use of Runways/Taxiways | $ - 0 | per day | |||
| Loss of Use of Building | $ - 0 | per day | |||
| Other | $ - 0 | per day | |||
| SOURCE SELECTION INFORMATION | |||||
| SEE FAR 2.101 AND 3.104 | Total Other Costs/Day | 0.00 |
File details come from the government source that posted it. Updated .