S02 - Project 607-19-101 - Volume 1 Specifications.pdf

PROJECT SPECIFICATIONS

FOR 100% CONSTRUCTION DOCUMENTS

Volume 1 Specifications (Div: 00- 14)

PROJECT TITLE: Relocate Pharmacy Compounding Area

VA PROJECT NO.: Project 607-19-101

Wm S. Middleton VA Medical Center Madison, Wisconsin

01-01-20

00 01 10-1

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

SECTION NO. DIVISION AND SECTION TITLES DATE

DIVISION 00 - SPECIAL SECTIONS

00 01 15 List of Drawing Sheets 07-15

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 12-18 01 32 16.15 Project Schedules (Small Projects – Design/Bid/Build 02-15 01 33 23 Shop Drawings, Product Data, and Samples 05-17 01 35 26 Safety Requirements 02-17 01 42 19 Reference Standards 09-19 01 45 00 Quality Control 03-19 01 74 19 Construction Waste Management 09-13

DIVISION 02 – EXISTING CONDITIONS

02 41 00 Demolition 08-17 02 82 11 Traditional Asbestos Abatement 04-19 02 82 13.13 Glovebag Asbestos Abatement 09-15 02 82 13.19 Asbestos Floor Tile and Mastic Abatement 09-15 02 82 13.31 Asbestos Transite Abatement 09-15

DIVISION 05 – METALS

05 12 00 Structural Steel Framing 11-18 05 50 00 Metal Fabrications 08-18 05 51 00 Metal Stairs 10-15

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 01 50.19 Preparation for Re-Roofing 02-16 07 21 13 Thermal Insulation 10-17 07 53 23 Ethylene-Propylene-Diene-Monomer Roofing 02-16 07 60 00 Flashing and Sheet Metal 07-14 07 84 00 Firestopping 02-16 07 92 00 Joint Sealants 10-17 07 95 13 Expansion Joint Cover Assemblies 02-16

DIVISION 08 - OPENINGS

08 11 13 Hollow Metal Doors and Frames 08-16 08 14 00 Interior Wood Doors 02-16 08 31 13 Access Doors and Frames 02-16 08 41 13 Aluminum-Framed Entrances and Storefronts 08-16 08 71 00 Door Hardware 01-20 08 71 13.11 Low Energy Power Assist Door Operators 08-16

00 01 10-2

SECTION NO. DIVISION AND SECTION TITLES DATE

08 80 00 Glazing 10-15

DIVISION 09 – FINISHES

09 05 16 Subsurface Preparation for Floor Finishes 02-15 09 22 16 Non-Structural Metal Framing 06-18 09 29 00 Gypsum Board 06-18 09 51 00 Acoustical Ceilings 12-18 09 65 13 Resilient Base and Accessories 02-16 09 65 16 Resilient Sheet Flooring 05-18 09 68 00 Carpeting 10-15 09 91 00 Painting 01-16

DIVISION 10 – SPECIALTIES

10 14 00 Signage 10-15

10 26 00 Wall and Door Protection 10-15 10 44 13 Fire Extinguisher Cabinets 08-18

DIVISION 12 – FURNISHINGS

12 24 00 Window Shades 08-17

DIVISION 21- FIRE SUPPRESSION

21 13 13 Wet-Pipe Sprinkler Systems 06-15

DIVISION 22 – PLUMBING

22 05 11 Common Work Results for Plumbing 07-16 22 05 23 General-Duty Valves for Plumbing Piping 09-15 22 07 11 Plumbing Insulation 09-19 22 11 00 Facility Water Distribution 11-19 22 13 00 Facility Sanitary and Vent Piping 09-15 22 14 00 Facility Storm Drainage 09-15 22 40 00 Plumbing Fixtures 09-15

DIVISION 23 – HEATING, VENTILATING, AND AIR

CONDITIONING (HVAC)

23 05 11 Common Work Results for HVAC 08-17 23 05 12 General Motor Requirements for HVAC and Steam

Generation Equipment 08-17

23 05 41 Noise and Vibration Control for HVAC Piping and Equipment

02-15

23 05 93 Testing, Adjusting, and Balancing for HVAC 02-15 23 07 11 HVAC and Boiler Plant Insulation 02-15 23 08 00 Commissioning of HVAC Systems 11-16 23 09 23 Direct-Digital Control System for HVAC 09-11 23 21 13 Hydronic Piping 08-17

00 01 10-3

SECTION NO. DIVISION AND SECTION TITLES DATE

23 22 13 Steam and Condensate Heating Piping 08-17 23 23 00 Refrigerant Piping 02-15 23 25 00 HVAC Water Treatment 02-15 23 31 00 HVAC Ducts and Casings 03-13 23 34 00 HVAC Fans 02-15 23 36 00 Air Terminal Units 02-15 23 37 00 Air Outlets and Inlets 02-15 23 40 00 HVAC Air Cleaning Devices 02-12 23 74 13 Packaged, Outdoor, Central-Station Air-Handling Units 04-11 23 81 00 Decentralized Unitary HVAC Equipment 02-11 23 82 00 Convection Heating and Cooling Units 04-11 23 82 16 Air Coils 04-11

DIVISION 25 – INTEGRATED AUTOMATION

25 13 10 _Building Automation System (BAS) Integration 02-10

DIVISION 26 – ELECTRICAL

26 05 11 Requirements for Electrical Installations 01-16 26 05 19 Low-Voltage Electrical Power Conductors and Cables 01-17 26 05 26 Grounding and Bonding for Electrical Systems 01-17 26 05 33 Raceway and Boxes for Electrical Systems 01-18 26 09 23 Lighting Controls 01-18 26 24 16 Panelboards 01-18 26 27 26 Wiring Devices 01-18 26 29 11 Motor Controllers 01-18 26 29 21 Enclosed Switches and Circuit Breakers 01-17 26 51 00 Interior Lighting 01-18

DIVISION 27 – COMMUNICATIONS

27 05 11 Requirements for Communications Installations 09-19 27 05 26 Grounding and Bonding for Communications Systems 06-15 27 05 33 Raceways and Boxes for Communications Systems 10-18 27 10 00 Control, Communication and Signal Wiring 06-15 27 15 00 Communications Structured Cabling 01-16 27 51 16 Public Address and Mass Notification Systems 10-18

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

28 05 00 Common Work Results for Electronic Safety and Security 04-18 28 05 13 Conductors and Cables for Electronic Safety and

Security 10-18

28 05 28.33 Conduits and Backboxes for Electronic Safety and Security

09-11

28 13 00 Physical Access Control System 10-11 28 23 00 Video Surveillance 09-11 28 31 00 Fire Detection and Alarm 10-11

07-01-15

00 01 15 - 1

SECTION 00 01 15

LIST OF DRAWING SHEETS

The drawings listed below accompanying this specification form a part of the contract.

Drawing No. Title

Volume 1 General

G001 Title Sheet

G002 Architectural Legend, Typ. Mounting Heights

G003 Life Safety Floor Plan

G004 Phasing Plans

Environmental HA101 First Floor- C-Wing & Ground Floor G Wing

Asbestos Abatement

ARCHITECTURAL

AD101 Demolition Floor Plan

A101 Construction Floor Plan

A201 Reflected Ceiling Plan

A601 Interior Elevations

A701 Finish Plan

A721 Finish Legend and Schedule

A751 Equipment Plan

A900 Partition Types, Door Schedule and Details

A901 Wall Penetration Details

Structural S001 Structural General Notes, Symbols and

Abbreviations

S100 1st Floor G- Wing Roof Plan - Structural General Arrangement

S101 Structural Framing Plan and Elevations

S500 Structural Details

S501 Structural Details

S502 Structural Details

00 01 15 - 2

Volume 2 Fire Protection

FP000 Fire Protection Notes, Symbols and Abbreviations

FP100 First Floor Plan Fire Protection Demolition and New Work Plans

Plumbing

P000 Plumbing Details, Notes, Symbols and Abbreviations

P101 First Floor Plan Plumbing Demolition and New Work Plans

MECHANICAL

MOOO Mechanical Notes, Symbols and Abbreviations

MD101 First Floor- C-Wing HVAC Ductwork Demolition

MDP101 First Floor- C-Wing HVAC Piping Demolition

M101 First Floor- C-Wing HVAC Ductwork

MP101 First Floor- C-Wing HVAC Piping

M300 Mechanical Sections

M500 Mechanical Details

M501 Mechanical Details

M600 Mechanical Controls

M700 Mechanical Schedules

Electrical E001 Symbols, Abbreviations and Notes (Electrical)

ED100 First Floor – Electrical Power, Commm, Special System and Lighting Demolition Plans

E10GB Basement and Ground Floor Electrical Power Plans

EP100 First Floor – Electrical Power New Work Plan

EL100 First Floor – Lighting New Work Plan

ET100 First Floor – Electrical Communications and Security System New Work Plan

EP500 Electrical Details

EP501 Electrical Details

ET500 Electrical Communication and Special Systems Details

EP600 Electrical Power Demolition and New One Line Diagrams

EP601 Electrical Lighting, Motor and Panel Distribution

00 01 15 - 3

Schedules

FA100 First Floor – Electrical Fire Alarm Plan

- - - E N D - - -

12-01-18 i

SECTION 01 00 00

GENERAL REQUIREMENTS

TABLE OF CONTENTS

1.1 SAFETY REQUIREMENTS

1.2 GENERAL INTENTION

1.3 STATEMENT OF BID ITEM(S)

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

1.5 CONSTRUCTION SECURITY REQUIREMENTS

1.6 OPERATIONS AND STORAGE AREAS

1.7 ALTERATIONS

1.8 DISPOSAL AND RETENTION

1.9 RESTORATION

1.10 PHYSICAL DATA

1.11 LAYOUT OF WORK

1.12 AS-BUILT DRAWINGS

1.13 USE OF ROADWAYS

1.14 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

1.15 TEMPORARY USE OF EXISTING ELEVATORS

1.16 AVAILABILITY AND USE OF UTILITY SERVICES

1.17 TESTS

1.18 INSTRUCTIONS

1.19 GOVERNMENT-FURNISHED PROPERTY

1.22 RELOCATED EQUIPMENT ITEMS

1.21 PHOTOGRAPHIC DOCUMENTATION

SECTION 01 00 00

GENERAL REQUIREMENTS

1.1 SAFETY REQUIREMENTS

Refer to section 01 35 26, SAFETY REQUIREMENTS for safety and infection control requirements.

1.2 GENERAL INTENTION

A. In accordance with the information provided within these construction documents, the Contractor shall provide all labor, material and supervision to renovate approximately 3,100 sq ft of space on 1st floor

C-Wing – Pharmacy for the relocation of new compounding area and USP

797 and 800 Compliance. Major work elements include phasing, demolition; hazardous material removal and disposal; carpentry;

interior finishes, window and door installations; pneumatic tube system modifications, plumbing, fire protection; HVAC ductwork and piping, controls, new air handling units; electrical power and lighting, intercom, CCTV, fire alarm and security systems, and telecommunications at the William S. Middleton Memorial Veterans Hospital, Madison, WI.

Additionally, this project will involve installation of a rolling fire door and removal and replacement of window tinting located on the south and east side of B-wing building 1, see 01 00 00 Attachment at the end of this section. The new AHU controls in this project shall communicate with Hospital's Tridium BAS system and rebalance the impacted spaces.

B. Visits to the site by Bidders may be made only by appointment with the Medical Center Engineering Officer.

C. Offices of USFIN DEVELOPMENT LLC, as Architect-Engineers, will render certain technical services during construction. Such services shall be considered as advisory to the Government and shall not be construed as expressing or implying a contractual act of the Government without affirmations by Contracting

Officer or his duly authorized representative.

D. All employees of general contractor and subcontractors shall comply with VA security management program and obtain permission of the VA police, be identified by project and employer, and restricted from unauthorized access.

01 00 00 -1

01 00 00 -2

1.3 STATEMENT OF BID ITEM(S)

A. SEE BID SCHEDULE

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. Drawings and contract documents may be obtained from the website where the solicitation is posted. Additional copies will be at

Contractor's expense,.

B. The drawings indicate overall intent, scope and functionality of the project. They are based on known discernable information available during the design phase. Specific details uncovered during the construction contractor may not be shown on the drawings. The contractor shall have provisions for such and make adjustments to accommodate such details within the overall scope and intent of the job. All such adjustments shall be geared towards bringing equal or greater functionality within the intent and scope of job.

C. Material and equipment catering for the architectural, mechanical, electrical, plumbing and other requirements of the project are only shown schematically and may not indicate all the required components for a completely functioning system at the site. The contractor shall follow manufacturer’s instructions for complete installation within the scope.

1.5 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The General Contractor is responsible for assuring that all sub-contractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

01 00 00 -3

1. General Contractor’s employees shall not enter the project site without appropriate badge. They may also be subject to inspection of their personal effects when entering or leaving the project site.

2. Before starting work the General Contractor shall give one week’s notice to the Contracting Officer so that security can be provided for the employees. This notice is separate from any notices required for utility shutdown described later in this section.

3. No photography of VA premises is allowed without written permission of the Contracting Officer.

4. VA reserves the right to close down or shut down the project site and order General Contractor’s employees off the premises in the event of a national emergency. The General Contractor may return to the site only with the written approval of the

Contracting Officer.

C. Key Control:

1. The General Contractor shall provide duplicate keys and lock combinations to the Contracting officers representative (COR) for the purpose of security inspections of every area of project including tool boxes and parked machines and take any emergency action.

2. The General Contractor shall turn over all permanent lock cylinders to the VA locksmith for permanent installation. See

Section 08 71 00, DOOR HARDWARE and coordinate.

D. Document Control:

1. Before starting any work, the General Contractor/Sub

Contractors shall submit an electronic security memorandum describing the approach to following goals and maintaining confidentiality of “sensitive information”.

01 00 00 -4

2. The General Contractor is responsible for safekeeping of all drawings, project manual and other project information. This information shall be shared only with those with a specific need to accomplish the project.

3. Certain documents, sketches, videos or photographs and drawings may be marked “Law Enforcement Sensitive” or

“Sensitive Unclassified”. Secure such information in separate containers and limit the access to only those who will need it for the project. Return the information to the Contracting

Officer upon request.

4. These security documents shall not be removed or transmitted from the project site without the written approval of

Contracting Officer.

5. All paper waste or electronic media such as CD’s and diskettes shall be shredded and destroyed in a manner acceptable to the

VA.

6. Notify Contracting Officer and Site Security Officer immediately when there is a loss or compromise of “sensitive information”.

7. All electronic information shall be stored in specified location following VA standards and procedures using an

Engineering Document Management Software (EDMS).

a. Security, access and maintenance of all project drawings, both scanned and electronic shall be performed and tracked through the EDMS system.

b. “Sensitive information” including drawings and other documents may be attached to e-mail provided all VA encryption procedures are followed.

E. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitted

01 00 00 -5

24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

2. A limited number of one permit shall be issued for

General Contractor and its employees for parking in designated areas only.

1.6 OPERATIONS AND STORAGE AREAS

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the Contracting Officer. The Contractor shall hold and save the Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

B. The Contractor shall, under regulations prescribed by the

Contracting Officer, use only established roadways, or use temporary roadways constructed by the Contractor when and as authorized by the Contracting Officer. When materials are transported in prosecuting the work, vehicles shall not be loaded beyond the loading capacity recommended by the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the

Contractor shall protect them from damage. The Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

(FAR 52.236-10)

C. Working space and space available for storing materials shall be as determined by the COR.

D. Workers are subject to rules of Medical Center applicable to their conduct.

01 00 00 -6

E. Execute work so as to interfere as little as possible with normal functioning of Medical Center as a whole, including operations of utility services, fire protection systems and any existing equipment, and with work being done by others. Use of equipment and tools that transmit vibrations and noises through the building structure, are not permitted in buildings that are occupied, during construction, jointly by patients or medical personnel, and Contractor's personnel, except as permitted by COR where required by limited working space.

1. Do not store materials and equipment in other than assigned areas.

2. Schedule delivery of materials and equipment to immediate construction working areas within buildings in use by

Department of Veterans Affairs in quantities sufficient for not more than two work days. Provide unobstructed access to

Medical Center areas required to remain in operation.

3. Where access by Medical Center personnel to vacated portions of buildings is not required, storage of Contractor's materials and equipment will be permitted subject to fire and safety requirements.

F. Phasing:

The Medical Center must maintain its operation 24 hours a day 7 days a week. Therefore, any interruption in service must be scheduled and coordinated with the COR to ensure that no lapses in operation occur. It is the CONTRACTOR'S responsibility to develop a work plan and schedule detailing, at a minimum, the procedures to be employed, the equipment and materials to be used, the interim life safety measure to be used during the work, and a schedule defining the duration of the work with milestone subtasks. The work to be outlined shall include, but not be limited to:

01 00 00 -7

To ensure such executions, Contractor shall furnish the COR with a schedule of approximate phasing dates on which the Contractor intends to accomplish work in each specific area of site, building or portion thereof. In addition, Contractor shall notify the COR two weeks in advance of the proposed date of starting work in each specific area of site, building or portion thereof.

Arrange such phasing dates to ensure accomplishment of this work in successive phases mutually agreeable to COR and

Contractor, as follows:

See Phasing Plan G004 and outlined below:

Phase 1 - New Compounding/ Partial General Pharmacy

Space - AHU installation. See H below, this section.

a. Duration- 4 months demolition and construction

(NTP- final construction

b. Abatement between phases considerations time frame - one week

c. Certification - one month

d. Total Duration Phase 1 - 5 months (NTP-occupancy)

Phase 2 - Existing General Pharmacy/ Existing

Compounding demolition- Setup remainder new General

Pharmacy

a. Duration - 2 months

b. Abatement between phases considerations time frame - week between one and two and 5 days phase

2 and 3

c. Additional time may be needed for set up, installation, programming and training of medication carousel.

Phase 3 - Admin Space- Duration - 8 weeks

a. Additional time may be needed for shutdown and planning of LS-C1L Panel and tie over work. See

01 00 00 -8

ED-100, EP-100 and EP-600. Coordinate circuit routing for distribution to circuits in any of the above 2 phases.

G. Floor 1st Part of Bldg. 1C Wing will be vacated by Government in accordance with above phasing beginning after notification and receipt of Notice to Proceed and turned over to Contractor.

H. Ground Floor Part of Bldg. 13 -G Wing is a research lab. All work shall be conducted nights and weekends. Two week notice to be provided for any work above ceiling and in space. Additionally, the installation of AHU, Exhaust Fans and all ancillary work, including structural, shall be planned around research lab activities. Abatement work shall be pre planned and coordinated with Mechanical Installation work prior to Phase 1.

I. Utilities Services: Maintain existing utility services for

Medical Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services. Where necessary to cut existing water, steam, gases, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR.

1. No utility service such as water, gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior approval of COR

[Chief Engineer][Chief of Facilities Management]. Electrical work shall be accomplished with all affected circuits or equipment de-energized. When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without a detailed work plan, the Medical

Center Director’s prior knowledge and written approval. Refer

01 00 00 -9 to specification Sections 26 05 11, REQUIREMENTS FOR

ELECTRICAL INSTALLATIONS, 27 05 11 REQUIREMENTS FOR

COMMUNICATIONS INSTALLATIONS and 28 05 00, COMMON WORK RESULTS

FOR ELECTRONIC SAFETY AND SECURITY for additional requirements.

2. Contractor shall submit a request to interrupt any such services to COR, in writing, 7 days n advance of proposed interruption. Request shall state reason, date, exact time of, and approximate duration of such interruption.

3. Contractor will be advised (in writing) of approval of request, or of which other date and/or time such interruption will cause least inconvenience to operations of Medical

Center. Interruption time approved by Medical Center may occur at other than Contractor's normal working hours.

4. Major interruptions of any system must be requested, in writing, at least 15 calendar days prior to the desired time and shall be performed as directed by the COR.

5. In case of a contract construction emergency, service will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

6. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas or steam, payment of such fee shall be the responsibility of the Government and not the Contractor.

J. Abandoned Lines: All service lines such as wires, cables, conduits, ducts, pipes and the like, and their hangers or supports, which are to be abandoned but are not required to be entirely removed, shall be sealed, capped or plugged at the main, branch or panel they originate from. The lines shall not be capped in finished areas, but shall be removed and sealed, capped or plugged in ceilings, within furred spaces, in unfinished

01 00 00 -10 areas, or within walls or partitions; so that they are completely behind the finished surfaces.

K. To minimize interference of construction activities with flow of

Medical Center traffic, comply with the following:

1. Keep roads, walks and entrances to grounds, to parking and to occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles.

2. Method and scheduling of required cutting, altering and removal of existing roads, walks and entrances must be approved by the COR.

L. Coordinate the work for this contract with other construction operations as directed by COR. This includes the scheduling of traffic and the use of roadways, as specified in Article, USE OF

ROADWAYS.

1.7 ALTERATIONS

A. Survey: Before any work is started, the Contractor shall make a thorough survey with the COR areas of buildings in which alterations occur and areas which are anticipated routes of access, and furnish a report, signed by the Contracting Officer.

This report shall list by rooms and spaces:

1. Existing condition and types of resilient flooring, doors, windows, walls and other surfaces not required to be altered throughout affected areas of buildings.

2. Existence and conditions of items such as plumbing fixtures and accessories, electrical fixtures, equipment, venetian blinds, shades, etc., required by drawings to be either reused or relocated, or both.

3. Shall note any discrepancies between drawings and existing conditions at site.

01 00 00 -11

4. Shall designate areas for working space, materials storage and routes of access to areas within buildings where alterations occur and which have been agreed upon by Contractor and COR.

B. Any items required by drawings to be either reused or relocated or both, found during this survey to be nonexistent, or in opinion of COR and/or Supply Representative, to be in such condition that their use is impossible or impractical, shall be furnished and/or replaced by Contractor with new items in accordance with specifications which will be furnished by

Government. Provided the contract work is changed by reason of this subparagraph B, the contract will be modified accordingly, under provisions of clause entitled "DIFFERING SITE CONDITIONS"

(FAR 52.236-2) and "CHANGES" (FAR 52.243-4 and VAAR 852.243-70).

C. Re-Survey: Thirty days before expected partial or final inspection date, the Contractor and COR together shall make a thorough re-survey of the areas of buildings involved. They shall furnish a report on conditions then existing, of resilient flooring, doors, windows, walls and other surfaces as compared with conditions of same as noted in first condition survey report:

1. Re-survey report shall also list any damage caused by

Contractor to such flooring and other surfaces, despite protection measures; and, will form basis for determining extent of repair work required of Contractor to restore damage caused by Contractor's workers in executing work of this contract.

D. Protection: Provide the following protective measures:

1. Wherever existing roof surfaces are disturbed they shall be protected against water infiltration. In case of leaks, they shall be repaired immediately upon discovery.

01 00 00 -12

2. Temporary protection against damage for portions of existing structures and grounds where work is to be done, materials handled and equipment moved and/or relocated.

3. Protection of interior of existing structures at all times, from damage, dust and weather inclemency. Wherever work is performed, floor surfaces that are to remain in place shall be adequately protected prior to starting work, and this protection shall be maintained intact until all work in the area is completed.

1.8 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work removed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

1. Reserved items which are to remain property of the Government are noted on drawings or in specifications as items to be stored. Items that remain property of the Government shall be removed or dislodged from present locations in such a manner as to prevent damage which would be detrimental to re-installation and reuse. Store such items where directed by

COR.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from Medical Center

3. Items of portable equipment and furnishings located in rooms and spaces in which work is to be done under this contract shall remain the property of the Government. When rooms and spaces are vacated by the Department of Veterans Affairs during the alteration period, such items which are NOT required by drawings and specifications to be either relocated or reused will be removed by the Government in advance of work to avoid interfering with Contractor's operation.

01 00 00 -13

1.9 RESTORATION

A. Remove, cut, alter, replace, patch and repair existing work as necessary to install new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, and do not disturb any ducts, plumbing, steam, gas, or electric work without approval of the COR. Existing work to be altered or extended and that is found to be defective in any way, shall be reported to the COR before it is disturbed. Materials and workmanship used in restoring work, shall conform in type and quality to that of original existing construction, except as otherwise shown or specified.

B. Upon completion of contract, deliver work complete and undamaged.

Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, lawns, paving, roads, walks, etc.) disturbed or removed as a result of performing required new work, shall be patched, repaired, reinstalled, or replaced with new work, and refinished and left in as good condition as existed before commencing work.

C. At Contractor's own expense, Contractor shall immediately restore to service and repair any damage caused by Contractor's workers to existing piping and conduits, wires, cables, etc., of utility services or of fire protection systems and communications systems

(including telephone) which are not scheduled for discontinuance or abandonment.

D. Expense of repairs to such utilities and systems not shown on drawings or locations of which are unknown will be covered by adjustment to contract time and price in accordance with clause entitled "CHANGES" (FAR 52.243-4 and VAAR 852.243-70) and

"DIFFERING SITE CONDITIONS" (FAR 52.236-2).

1.10 PHYSICAL DATA

A. Data and information furnished or referred to below is for the

Contractor's information. The Government shall not be responsible

01 00 00 -14 for any interpretation of or conclusion drawn from the data or information by the Contractor.

1. The indications of physical conditions on the drawings and in the specifications are the result of site investigations by

USFin Development and its architects and engineers.

(FAR 52.236-4)

B. Government does not guarantee that other materials will not be encountered nor that proportions, conditions or character of several materials will not vary from those indicated by explorations. Bidders are expected to examine site of work and logs of borings; and, after investigation, decide for themselves character of materials and make their bids accordingly. Upon proper application to Department of Veterans Affairs, bidders will be permitted to make subsurface explorations of their own at site.

1.11 LAYOUT OF WORK

A. The Contractor shall lay out the work from Government established base lines and bench marks, indicated on the drawings, and shall be responsible for all measurements in connection with the layout. The Contractor shall furnish, at Contractor's own expense, all stakes, templates, platforms, equipment, tools, materials, and labor required to lay out any part of the work.

The Contractor shall be responsible for executing the work to the lines and grades that may be established or indicated by the

Contracting Officer. The Contractor shall also be responsible for maintaining and preserving all stakes and other marks established by the Contracting Officer until authorized to remove them. If such marks are destroyed by the Contractor or through

Contractor's negligence before their removal is authorized, the

01 00 00 -15

Contracting Officer may replace them and deduct the expense of the replacement from any amounts due or to become due to the

Contractor.

(FAR 52.236-17)

B. Whenever changes from contract drawings are made in line or grading requiring certificates, record such changes on a reproducible drawing bearing the registered land surveyor or registered civil engineer seal, and forward these drawings upon completion of work to COR

1.12 AS-BUILT DRAWINGS

A. The contractor shall maintain two full size sets of as-built drawings which will be kept current during construction of the project, to include all contract changes, modifications and clarifications.

B. All variations shall be shown in the same general detail as used in the contract drawings. To ensure compliance, as-built drawings shall be made available for the COR review, as often as requested.

C. Contractor shall deliver two approved completed sets ofas-built drawings in the electronic version (scanned PDF) to the COR

[Chief Engineer][Chief of Facilities Management] within 15 calendar days after each completed phase and after the acceptance of the project by the COR

D. Paragraphs A, B, & C shall also apply to all shop drawings.

1.13 USE OF ROADWAYS

A. For hauling, use only established public roads and roads on

Medical Center property and, when authorized by the COR such

01 00 00 -16 temporary roads which are necessary in the performance of contract work. Temporary roads shall be constructed and restoration performed by the Contractor at Contractor's expense.

When necessary to cross curbing, sidewalks, or similar construction, they must be protected by well-constructed bridges.

1.14 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

A. Use of new installed mechanical and electrical equipment to provide heat, ventilation, plumbing, light and power will be permitted subject to written approval and compliance with the following provisions:

1. Permission to use each unit or system must be given by COR in writing. If the equipment is not installed and maintained in accordance with the written agreement and following provisions, the COR will withdraw permission for use of the equipment.

2. Electrical installations used by the equipment shall be completed in accordance with the drawings and specifications to prevent damage to the equipment and the electrical systems, i.e. transformers, relays, circuit breakers, fuses, conductors, motor controllers and their overload elements shall be properly sized, coordinated and adjusted.

Installation of temporary electrical equipment or devices shall be in accordance with NFPA 70, National Electrical Code, (2014 Edition), Article 590, Temporary Installations. Voltage supplied to each item of equipment shall be verified to be correct and it shall be determined that motors are not overloaded. The electrical equipment shall be thoroughly cleaned before using it and again immediately before final inspection including vacuum cleaning and wiping clean interior and exterior surfaces.

3. Units shall be properly lubricated, balanced, and aligned.

Vibrations must be eliminated.

01 00 00 -17

4. Automatic temperature control systems for preheat coils shall function properly and all safety controls shall function to prevent coil freeze-up damage.

5. The air filtering system utilized shall be that which is designed for the system when complete, and all filter elements shall be replaced at completion of construction and prior to testing and balancing of system.

6. All components of heat production and distribution system, metering equipment, condensate returns, and other auxiliary facilities used in temporary service shall be cleaned prior to use; maintained to prevent corrosion internally and externally during use; and cleaned, maintained and inspected prior to acceptance by the GovernmentB. Prior to final inspection, the equipment or parts used which show wear and tear beyond normal, shall be replaced with identical replacements, at no additional cost to the Government.

C. This paragraph shall not reduce the requirements of the mechanical and electrical specifications sections.

D. Any damage to the equipment or excessive wear due to prolonged use will be repaired replaced by the contractor at the contractor’s expense.

1.15 TEMPORARY USE OF EXISTING ELEVATORS

A. Contractor will be allowed the use of existing freight elevator

#5 only during the times not used by “Dietetics”. These times are posted at the elevator.

A. Use of existing elevators for handling building materials and

Contractor's personnel will be permitted subject to following provisions:

1. Contractor makes all arrangements with the COR for use of elevators. The CORwill ascertain that elevators are in proper condition. Contractor may use elevators Nos. ___5____ in

01 00 00 -18

Building Nos. ___1___ for exclusive use for daily use between the hours of _8am-4pm_______. and for special nonrecurring time intervals when permission is granted.

Personnel for operating elevators will not be provided by the

Department of Veterans Affairs.

2. Contractor covers and provides maximum protection of following elevator components:

a. Entrance jambs, heads soffits and threshold plates.

b. Entrance columns, canopy, return panels and inside surfaces of car enclosure walls.

c. Finish flooring.

1.16 AVAILABILITY AND USE OF UTILITY SERVICES

A. The Government shall make all reasonably required amounts of utilities available to the Contractor from existing outlets and supplies, as specified in the contract. The amount to be paid by the Contractor for chargeable electrical services shall be the prevailing rates charged to the Government. The Contractor shall carefully conserve any utilities furnished without charge.

B. Contractor shall install meters at Contractor's expense and furnish the Medical Center a monthly record of the Contractor's usage of electricity as hereinafter specified.

C Heat: Furnish temporary heat necessary to prevent injury to work and materials through dampness and cold. Use of open salamanders or any temporary heating devices which may be fire hazards or may smoke and damage finished work, will not be permitted. Maintain minimum temperatures as specified for various materials:

1. Obtain heat by connecting to Medical Center heating distribution system.

01 00 00 -19

D. Electricity (for Construction and Testing): Furnish all temporary electric services.

1. Obtain electricity by connecting to the Medical Center electrical distribution system.

E. Water (for Construction and Testing): Furnish temporary water service.

1. Obtain water by connecting to the Medical Center water distribution system. Provide reduced pressure backflow preventer at each connection as per code. Water is available at no cost to the Contractor.

2. Maintain connections, pipe, fittings and fixtures and conserve water-use so none is wasted. Failure to stop leakage or other wastes will be cause for revocation (at COR discretion) of use of water from Medical Center's system.

1.17 TESTS

A. As per specification section 23 05 93 the contractor shall provide a written testing and commissioning plan complete with component level, equipment level, sub-system level and system level breakdowns. The plan will provide a schedule and a written sequence of what will be tested, how and what the expected outcome will be. This document will be submitted for approval prior to commencing work. The contractor shall document the results of the approved plan and submit for approval with the as built documentation.

B. Pre-test mechanical and electrical equipment and systems and make corrections required for proper operation of such systems before requesting final tests. Final test will not be conducted unless pre-tested.

C. Conduct final tests required in various sections of specifications in presence of an authorized representative of the

Contracting Officer. Contractor shall furnish all labor, 01 00 00 -20 materials, equipment, instruments, and forms, to conduct and record such tests.

D. Mechanical and electrical systems shall be balanced, controlled and coordinated. A system is defined as the entire system which must be coordinated to work together during normal operation to produce results for which the system is designed. For example, air conditioning supply air is only one part of entire system which provides comfort conditions for a building. Other related components are return air, exhaust air, steam, chilled water, refrigerant, hot water, controls and electricity, etc. Another example of a system which involves several components of different disciplines is a boiler installation. Efficient and acceptable boiler operation depends upon the coordination and proper operation of fuel, combustion air, controls, steam, feedwater, condensate and other related components.

E. All related components as defined above shall be functioning when any system component is tested. Tests shall be completed within a reasonably period of time during which operating and environmental conditions remain reasonably constant and are typical of the design conditions.

F. Individual test result of any component, where required, will only be accepted when submitted with the test results of related components and of the entire system.

1.18 INSTRUCTIONS

A. Contractor shall furnish Maintenance and Operating manuals (hard copies and electronic) and verbal instructions when required by the various sections of the specifications and as hereinafter specified.

B. Manuals: Maintenance and operating manuals and one compact disc

(four hard copies and one electronic copy each) for each separate piece of equipment shall be delivered to the COR coincidental with the delivery of the equipment to the job site. Manuals shall

01 00 00 -21 be complete, detailed guides for the maintenance and operation of equipment. They shall include complete information necessary for starting, adjusting, maintaining in continuous operation for long periods of time and dismantling and reassembling of the complete units and sub-assembly components. Manuals shall include an index covering all component parts clearly cross-referenced to diagrams and illustrations. Illustrations shall include "exploded" views showing and identifying each separate item. Emphasis shall be placed on the use of special tools and instruments. The function of each piece of equipment, component, accessory and control shall be clearly and thoroughly explained. All necessary precautions for the operation of the equipment and the reason for each precaution shall be clearly set forth. Manuals must reference the exact model, style and size of the piece of equipment and system being furnished. Manuals referencing equipment similar to but of a different model, style, and size than that furnished will not be accepted.

C. Instructions: Contractor shall provide qualified, factory-trained manufacturers' representatives to give detailed training to assigned Department of Veterans Affairs personnel in the operation and complete maintenance for each piece of equipment.

All such training will be at the job site. These requirements are more specifically detailed in the various technical sections.

Instructions for different items of equipment that are component parts of a complete system, shall be given in an integrated, progressive manner. All instructors for every piece of component equipment in a system shall be available until instructions for all items included in the system have been completed. This is to assure proper instruction in the operation of inter-related systems. All instruction periods shall be at such times as scheduled by the COR and shall be considered concluded only when the COR is satisfied in regard to complete and thorough coverage. The contractor shall submit a course outline with associated material to the COR for review and approval prior to

01 00 00 -22 scheduling training to ensure the subject matter covers the expectations of the VA and the contractual requirements. The

Department of Veterans Affairs reserves the right to request the removal of, and substitution for, any instructor who, in the opinion of the COR , does not demonstrate sufficient qualifications in accordance with requirements for instructors above.

1.19 GOVERNMENT-FURNISHED PROPERTY

A. The Government shall deliver to the Contractor, the

Government-furnished property shown on the Schedule drawings .

B. Equipment furnished by Government to be installed by Contractor will be furnished to Contractor at the Medical Center.

C. Storage space for equipment will be provided by the Government and the Contractor shall be prepared to unload and store such equipment therein upon its receipt at the Medical Center

D. Notify Contracting Officer in writing, 60 days in advance, of date on which Contractor will be prepared to receive equipment furnished by Government. Arrangements will then be made by the

Government for delivery of equipment.

1. Immediately upon delivery of equipment, Contractor shall arrange for a joint inspection thereof with a representative of the Government. At such time the Contractor shall acknowledge receipt of equipment described, make notations, and immediately furnish the Government representative with a written statement as to its condition or shortages.

2. Contractor thereafter is responsible for such equipment until such time as acceptance of contract work is made by the

Government.

E. Equipment furnished by the Government will be delivered in a partially assembled (knock down) condition in accordance with

01 00 00 -23 existing standard commercial practices, complete with all fittings, fastenings, and appliances necessary for connections to respective services installed under contract. All fittings and appliances (i.e., couplings, ells, tees, nipples, piping, conduits, cables, and the like) necessary to make the connection between the Government furnished equipment item and the utility stub-up shall be furnished and installed by the contractor at no additional cost to the Government.

F. Completely assemble and install the Government furnished equipment in place ready for proper operation in accordance with specifications and drawings.

G. Furnish supervision of installation of equipment at construction site by qualified factory trained technicians regularly employed by the equipment manufacturer.

1.20 RELOCATED EQUIPMENT ITEMS

A. Contractor shall disconnect, dismantle as necessary, remove and reinstall in new location, all existing equipment and items indicated by symbol "R" or otherwise shown to be relocated by the

Contractor.

B. Perform relocation of such equipment or items at such times and in such a manner as directed by the COR .

C. Suitably cap existing service lines, such as steam, condensate return, water, drain, gas, air, vacuum and/or electrical, at the main whenever such lines are disconnected from equipment to be relocated. Remove abandoned lines in finished areas and cap as specified herein before under paragraph "Abandoned Lines".

D. Provide all mechanical and electrical service connections, fittings, fastenings and any other materials necessary for assembly and installation of relocated equipment; and leave such equipment in proper operating condition.

01 00 00 -24

E. All service lines such as noted above for relocated equipment shall be in place at point of relocation ready for use before any existing equipment is disconnected. Make relocated existing equipment ready for operation or use immediately after reinstallation.

1.21 PHOTOGRAPHIC DOCUMENTATION

A. During the construction period through completion, furnish the

VA's COR an average of 25 views of digital color images per month.

These digital views shall be taken of the exterior and/or interior depending on the location of the progress made during the construction. The subject matter of these pictures shall be representative of the work being done during the construction period through to the end of the construction. Provide the photos taken for the month to the COR electronically, or on a CD. A CD that contains all of the photos taken for the project is also required at the end of the project. Note: Ensure that no patients, license plates, VA employees or personal identifiable information are in the pictures.

B. Upon completion of the project, final copies of the documentation

(the “Permanent Record”) with the indexing and navigation system embedded (and active) shall be provided in an electronic media format, typically a DVD or external hard-drive. Permanent Record shall have Building Information Modeling (BIM) interface capabilities. On-line access terminates upon delivery of the

Permanent Record.

Rolling Fire Door Replacement

• Contractor shall provide labor, equipment, materials and tools for all job requirements.

• All work shall be scheduled, coordinated and approved with the COR.

• Contractor shall demo existing soffit and rolling fire door assembly system.

• Contractor shall install new VA provided rolling fire door assembly system in the ceiling to meet all NFPA 80 requirements.

• Contractor shall build new soffit around new fire door assembly.

• Contractor shall paint new soffit to match existing.

• Contractor shall provide certification of the new fire door assembly, a rolling fire door inspection report with drop test results and certification tag.

Demo Existing Rolling

Fire Door and install VA

Provided Rolling Fire

Door between VA and

UW Hospital here.

01 00 00 - Attachment

2B Window Tint Replacement

• Contractor shall provide labor, equipment, materials and tools for all job requirements.

• All work shall be scheduled, coordinated and approved with the COR.

• Contractor shall completely remove existing window tint and/or adhesive on the exterior of the south and east 2B Windows. This will include:

o (11) 18”x 60” Windows o (7) 60” x 60” Windows o (3) 24” x 60” Windows o (1) 48” x 60” Window

• Contractor shall verify size/quantity of windows

• Contractor shall prep existing windows for new replacement window tint

• Contractor shall install new Solar Zone Silver 20 Xtra window tint or approved equal to match existing on the same 2B windows from the exterior

South Side

East

Side

01 00 00 - Attachment

02-01-15

01 32 16.15 - 1

SECTION 01 32 16.15

PROJECT SCHEDULES

(SMALL PROJECTS – DESIGN/BID/BUILD)

PART 1- GENERAL

1.1 DESCRIPTION:

A. The Contractor shall develop a Critical Path Method (CPM) plan and schedule demonstrating fulfillment of the contract requirements

(Project Schedule), and shall keep the Project Schedule up-to-date in accordance with the requirements of this section and shall utilize the plan for scheduling, coordinating and monitoring work under this contract (including all activities of subcontractors, equipment vendors and suppliers). Conventional Critical Path Method (CPM) technique shall be utilized to satisfy both time and cost applications.

1.2 CONTRACTOR'S REPRESENTATIVE:

A. The Contractor shall designate an authorized representative responsible for the Project Schedule including preparation, review and progress reporting with and to the Contracting Officer's Representative (COR).

B. The Contractor's representative shall have direct project control and complete authority to act on behalf of the Contractor in fulfilling the requirements…