RFP 47PM1023R0013-2023-05-22.pdf

SPECIFICATION

AND

REQUEST FOR

PROPOSAL

PROJECT:

LOCATION:

SITE VISIT:

CONTACT PERSON:

ISSUING OFFICE:

PHASE 1 PROPOSAL

DUE DATE PLACE

AND TIME:

SOLICITATION NO.:

NEOB Long Wing 6th & 7th Floor Modernization

(DC0105ZZ) 725 17th Street NW Washington DC

Keona Singletary 202-740-2393 E-mail: keona.singletary@gsa.gov

General Services Administration National Capital Region (NCR) Office of Acquisitions, 1800 F ST NW, Room Washington, DC 20405-0001

May 29, 2023 keona.singletary@gsa.gov GSA, National Capital Region, PBS 1800 F ST NW, Room 4040 Washington, DC 20405-0001 11:00 A.M. local time (EST)

RFP: 47PM1023R0013

GENERAL SERVICES ADMINISTRATION

THIS PROCUREMENT HAS BEEN SET-ASIDE FOR

SMALL BUSINESSES

RFP: 47PM1023R0013

TABLE OF CONTENTS

RFP INCLUDES

(1) The Solicitation – Phase 1

(2) Offeror Representations and Certifications Form

(3) Standard Form (SF) 1442 – Solicitation Offer and Award

(4) Draft of the Agreement

(5) The Scope of Work, Specifications, Drawing Exhibits and other Attachments to the Agreement.

ADDITIONAL FORMS TO BE SUBMITTED WITH PHASE 2

(1) Contractor's Qualifications & Financial Information (GSA FORM 527)

(2) Bid Bond

(3) Technical Factors: (Design Concept, Management Approach & Key Personnel, Proposed Technical Solutions)

GSA Solicitation No. 47PM1023R0013

Document: DB201-1-SB/MARCH 2023 (The Solicitation)

Design Build Contract for: NEOB Long Wing 6th and 7th Floor Modernization

The Solicitation, Phase 1 – Request for Qualifications

Table of Contents

I. General Information A. The Project B. The Solicitation and Contract C. List of Phase 1 Solicitation Documents D. Authorized Representatives E. Pre-Proposal Conference F. Estimated Price Range G. Questions Regarding Phase 1 H. Receipt of Qualifications

II. Proposals

A. Proposal Contents B. Proposal Format C. Technical Approach D. Other Requirements E. Requirements of Joint Venture Off

III. General Provisions

A. Availability of Funds B. Requests for Clarification or Interpretation C. Notice to Small Business Firms D. Information Concerning the Disclosure of Solicitation Results E. Affirmative Procurement Program F. Notice Concerning Preparation of Proposals G. Bond Requirements H. Contractor Performance Information I. Safeguarding and Dissemination of Controlled Unclassified Information

(CUI) Building Information

IV. FAR/GSAR Solicitation Provisions To be issued in Phase 2 A. GSAR 552.252-5 Authorized Deviations in Provisions (Nov 2021)

(DEVIATION FAR 52.252-5)

V. Additional Solicitation Provisions and Instructions A. Additional Provisions

VI. Method Of Award

A. Evaluation of Phase 1 B. Evaluation of Phase 2 C. Determination of Responsibility D. Price Reasonableness E. Unbalanced Price F. Total Evaluated Price

G. Non-Price Factors H. Evaluation of Joint Ventures

Notice of Commercial Package Carriers

Because of increased security standards, commercial package carriers may experience delays in making deliveries to the address designated for receipt of offers. United States Mail delivered to Government offices in the Washington, DC area is subject to irradiation, significantly delaying deliveries and potentially damaging or defacing mail contents. Offerors should take these facts into consideration when determining how and when to transmit offers to the office designated for receipt.

I. General Information

I.A. The Project This project is for the design and construction of Modernization of the long wing on the 6th and 7th Floors at NEOB along 17th Street. The scope includes demo, abatement, design, and construction. See Section 2.1 of the Scope of Work for detailed project requirements.

The project is a change in use of space.

The project is a change in occupancy. The hallway and office configurations are being reorganized.

The D/B Contractor shall coordinate work and gain approvals required in this Statement of Work (SOW) with the Contracting Officer (CO) and Contracting Officer’s Representative/Project Manager (COR/PM) as required.

I.B. the Solicitation and Contract

(1) This procurement is being conducted using the two-phase selection process found in FAR 36.3. Qualification proposals will be evaluated in Phase One to determine which offerors will submit proposals for Phase Two. One contract will be awarded using competitive negotiation. In Phase 1, GSA will select a short list of the most highly qualified offerors and request that those offerors submit Phase 2 proposals. All responsible sources may submit a Phase 1 proposal. A maximum of 3 firms will be selected to submit Phase 2 proposals. Only those selected offerors are authorized to submit Phase 2 proposals. Those offerors not selected for participation in Phase 2 will be notified in accordance with FAR 15.503(a).

(2) This Solicitation is set-aside for Small Businesses, in accordance with FAR 19. This Solicitation sets forth requirements for Phase 1 qualifications proposals and the evaluation factors for Phase 2 proposals for a Contract to construct the Project.

Proposals conforming to the Solicitation requirements will be evaluated in accordance with the Method of Award set forth herein. The Government will award the Contract to the selected Offeror, subject to the conditions set forth herein.

(3) Neither the Solicitation nor any part of an Offeror's proposal shall be part of the Contract except to the extent expressly incorporated therein by the Contracting Officer.

I.C. List of Phase 1 Solicitation Documents

The Solicitation Documents are comprised of:

(1) The Solicitation – Phase 1

(2) Offeror Representations and Certifications Form

(3) Standard Form (SF) 1442 – Solicitation Offer and Award

(4) Draft of the Agreement

(5) The Scope of Work, Specifications, Drawing Exhibits, and other Attachments to the Agreement.

I.D. Authorized Representatives

The following individuals are designated as the authorized GSA representatives under this Solicitation:

Authorized Representative Information:

Contracting Officer’s Information

Name: Jordan Tomczik

Address: 1800 F St. NW, Rm. 4040, Washington DC

Telephone: 773-707-9751

Email: Jordan.tomczik@gsa.gov

Alternate POC Information

Name: Keona Singletary

Address: 1800 F St NW, Rm. 4040, Washington, DC

Telephone: 202-740-2393

Email: keona.singletary@gsa.gov

I.E. Pre-Proposal Conference mailto:Jordan.tomczik@gsa.gov mailto:keona.singletary@gsa.gov

Date: TBD Time: TBD Location: TBD

I.F. Estimated Price Range The estimated price range for the Project is between $5,000,000.00 and $10,000,000.00

I.G. Questions Regarding Phase 1

Submit all questions regarding the Phase 1 to the Contracting Officer on or before May 24, 2023. Any responses provided by GSA will be posted on the Governmentwide Point of Entry (GPE) as an Amendment to the Solicitation.

I.H. Receipt of Qualifications

(1) In order to be considered for Phase 2 and award, Phase 1 qualifications proposals conforming to the requirements of the Solicitation must be received at the following office no later than 11:00 am local time on the following date and at the following address.

Date: May 29, 2023 Address: email: keona.singletary@gsa.gov and Jordan.tomczik@gsa.gov , Physical address: General Services Administration, NCR, Office of Acquisition (WPH1DA), 1800 F St. NW, Rm. 4040, Washington, DC 20405

II. Proposals

II.A. Proposal Contents

Proposals shall consist of the following documents, completed, and executed in accordance with this Solicitation:

1. Technical Approach (but not detailed design)

2. Other Documents as Required

II.B. Proposal Format One copy of each document listed in Section II.A. must be submitted.

II.C. Technical Approach mailto:keona.singletary@gsa.gov mailto:Jordan.tomczik@gsa.gov

Proposals must address the technical approach, technical qualifications, and the other Phase 1 questions stated herein. Any proposal not meeting all the following criteria may result in not being further considered for award.

(1) Technical Approach (general approach) This factor is concerned with the Offeror’s understanding of the project requirements and the management approach. The Offeror shall submit a written plan addressing the following:

● Offerors shall describe their approach to managing and delivering a project of the magnitude and complexity of THIS project under budgetary and time constraints.

The description shall include a discussion of the offeror's approach to managing the project to meet or exceed performance criteria, on schedule, and within budget. Offerors should include discussions of how the schedule for the project will be met while, at the same time, managing any changes that may occur.

Offerors previous experience in managing to achieve LEEDS certification shall also be presented. Offerors must address the capability to perform the work.

● Offerors shall identify what they believe are the most significant risks associated with this project. Such risks should include matters that jeopardize performance within budget and schedule limitations, problems created by working on an occupied building with severely limited site access, and change orders. Offerors shall provide a description of how they propose to manage and mitigate those risks. Offerors shall describe examples of successfully managing similar risks on previous projects. Offerors shall also describe their long-range plans for securing and maintaining the resources necessary to complete the project. Resources discussed should include key manpower, availability of personnel having current security clearance, equipment, and material. Discussion should indicate if these resources will come from in-house or from major subcontractors for foundations, selective demolition, structural, mechanical, and electrical portions of the work.

● Offerors shall provide an organization chart for their team for this project showing organizational positions – only key personnel names are required. This chart shall show lines of authority within the project team, between the project team and its corporate organizations, and between the project team and the Government.

(2) Phase I questions

(a) Does your company have a Top-Secret Facility Clearance for the White House Complex and experience building SCIF?

(b) What is your company size? How many employees?

(c) Where is your company located?

(d) Does your company have a vertically integrated corporate structure?

Please explain and provide an organizational chart to show structure.

(e) Does your company have extensive experience in the following trades? Please provide project examples and a past performance reference for each trade listed.

1. Office Buildouts

2. AV/IT

3. Mechanical

4. Millwork

(f) What is your small business classification?

II.D. Other Requirements

(1) Representations and Certifications

Offerors are reminded their SAM registration status must be “Active”, at the time their offer is submitted, to be considered for award (see 52.204-7). Offerors submitting a proposal in response to this Solicitation shall complete electronic Annual Representations and Certifications in conjunction with required Entity registration in System for Award Management (SAM), accessed via System for Award Management.

Offerors shall also submit with their proposal, the Annual Representations and Certifications (FAR 52.204-8), using the attached Offeror’s Representations and Certifications (C301).

(2) Proof of Bonding [typically 3%]

(3) GSA 527-Financial Information

II.E. Requirements of Joint Venture Offerors

(1) All offers submitted by joint ventures must include a copy of an executed joint venture agreement (with original signatures) which fully discloses the legal identity of each member of the joint venture, the relationship between the members, the form of ownership of each member, and any limitations on liability or authority for each member.

(2) An authorized representative of each member of the joint venture must sign the SF 1442 accompanying an offer regardless of any agency relationship established between the members.

(3) In the case of corporations that are joint venture members, the corporation secretary must certify that the corporation is authorized to participate in the joint venture, either by certifying in the joint venture agreement, or by submitting a separate certification to the Government. The joint venture must also provide a certificate that https://www.sam.gov/ identifies a principal representative of the joint venture with full authority to bind the joint venture.

(4) Representations and certifications, financial information, and past performance information must be submitted for each member of the joint venture.

III. General Provisions

III.A. Availability of Funds

Issuance of this Solicitation does not warrant that funds are presently available for award of a Contract. Award of the contract shall be subject to the availability of appropriated funds, and the Government shall incur no obligation under this Solicitation in advance of such time as funds are made available to the Contracting Officer for the purpose of contract award.

III.B. Requests for Clarification or Interpretation

The Government will attempt to answer all requests for clarifications or interpretations of the Solicitation Documents prior to the date set for receipt of offers, but do not warrant that all such requests will be answered within 15 calendar days. Prospective Offerors should make such requests not less than 15 calendar days prior to the date set for receipt of offers.

III.C. Notice to Small Business Firms

A program for the purpose of assisting qualified small business concerns in obtaining certain bid, payment, or performance bonds that are otherwise not obtainable is available through the Small Business Administration (SBA) (Small Business Administration). For information concerning SBA's surety bond guarantee assistance, contact your SBA District Office.

III.D. Information Concerning the Disclosure of Solicitation Results

This acquisition is being conducted under the provisions of FAR Part 15 as a negotiated procurement. In accordance with FAR 3.104 and FAR 15.207, after receipt of proposals, no information regarding the identity of those submitting offers, the number of offers received, or the information contained in such offers will be made available until after award except as provided by FAR 15.503.

III.E. Affirmative Procurement Program

GSA has implemented an Affirmative Procurement Program (APP) intended to maximize the use of recovered materials, environmentally preferable, and bio-based products. Offerors should familiarize themselves with the requirements for using and http://www.sba.gov/ http://www.sba.gov/ reporting on the use of such materials in performance as set forth in the Agreement.

Refer to Clause FAR 52.223-10 encouraging vendors to practice waste reduction.

III.F. Notice Concerning Preparation of Proposals

Offerors are cautioned to carefully read the entire Solicitation and the Agreement to be included in the Contract contemplated by the Solicitation in order to be fully aware of all requirements and clauses in the contemplated Contract. Verify that all blanks requiring information to be supplied in an Offer have been properly filled out, that all pricing and other numerical data is accurately calculated, and that all copies of the Offer contain the same information.

III.G. Bond Requirements (Phase 2 Requirements)

If a bid guarantee is required to be submitted with your offer, any contract awarded will require a performance bond and payment bond as specified in the Agreement. Offerors who utilize individual sureties should note the requirement for a certified, audited, financial statement for each person acting as an individual surety under clause FAR 52.228-1 Bid Guarantee and the requirements of clause FAR 52.228-11 Pledge of Assets.

III.H. Contractor Performance Information

(1) Evaluating Contractor Performance: The General Services Administration is using the Contractor Performance Assessment Reporting System (CPARS) module as the secure, confidential, information management tool to facilitate the performance evaluation process. CPARS enables a comprehensive evaluation by capturing comments from both GSA and the contractor. The website for CPARS is Contractor Performance Assessment

Completed CPARS evaluations may then be used by the Federal acquisition community for use in making source selection decisions. CPARS assists acquisition officials by serving as the single source for contractor past performance data.

(2) CPARS Registration: Each award requiring an evaluation must be registered in CPARS. The contractor will receive several automated emails. Within thirty days of award, the contractor will receive an e-mail that contains user account information, as well as the applicable contract and order number(s) assigned. Contractors will be granted one user account to access all evaluations.

(3) Contractor CPARS Training: Contractors may sign up for CPARS training. A schedule of classes will be posted to the CPARS training site (CPARS Training) and updated as needed.

(4) Contractor Representative (CR) Role: All evaluations will be sent to the Contractor Representative (CR) named on your award. The CR will be able to access CPARS to review and comment on the evaluation. If your CR is not already in the CPARS system, the contracting officer will http://www.cpars.gov/ http://www.cpars.gov/ https://www.cpars.gov/lc.htm request the name and email address of the person that will be responsible for the CR role on your award.

Once an evaluation is ready to be released the CR will receive an email alerting them the evaluation is ready for their review and comment. The email will indicate the time frame the CR has to respond to the evaluation; however, the CR may return the evaluation earlier than this date.

GSA shall provide for review at a level above the contracting officer (i.e., contracting director) to consider any disagreement between GSA and the contractor regarding GSA’s evaluation of the contractor. Based on the review, the individual at a level above the contracting officer will issue the conclusion on the performance evaluation.

Copies of the evaluations, contractor responses, and review comments, if any, will be retained as part of the contract file.

III.I. Safeguarding and Dissemination of Controlled Unclassified Information (CUI) Building Information

Certain information contained in the Solicitation Documents may have been designated as Controlled Unclassified Information (CUI) building information. With respect to such information, Offerors shall agree to the terms for receipt of such information, as set forth in the provision “Administrative Matters” in Section III of the Agreement, as a condition.

IV. FAR/GSAR Solicitation Provisions

To be issued with Phase 2 Solicitation.

V. Additional Solicitation Provisions and Instructions

VI. Method of Award

VI.A. Evaluation of Phase 1 Proposals

The Government will evaluate Phase 1 proposals based on the following evaluation factors and shortlist a maximum of three offerors to submit Phase 2 proposals.

(1) Technical Approach (general approach)

(2) Phase I Questions

VI.B. Evaluation of Phase 2 Proposals

The Government will award a contract resulting from this Solicitation to the responsible Offeror whose offer conforming to the Solicitation will be most advantageous to the Government, Total Evaluated Price and other factors considered. In addition to Total

Evaluated Price, the following Phase 2 non-price factors shall be used to evaluate offers:

(1) Design Concept

(2) Management Approach and Key Personnel

(3) Proposed Technical Solutions

VI.C. Determination of Responsibility In order to be considered responsible, an Offeror must demonstrate that it meets the requirements of FAR 9.104-1. The Contracting Officer's determination of an Offeror's responsibility or non-responsibility may be based upon any information obtained by the Contracting Officer and is independent of the evaluation of offers set forth herein.

VI.D. Price Reasonableness The proposed prices will be evaluated for reasonableness. Price reasonableness determines whether an Offeror’s price is too high. Analysis of price proposals will be performed using one or more of the techniques defined in FAR 15.404 in order to determine price reasonableness. Normally, price reasonableness is established through adequate price competition, but may also be determined through price analysis techniques as described in FAR 15.404-1. Notwithstanding anything to the contrary in this solicitation and for the avoidance of doubt, the Government will not perform a price realism analysis of the Offeror’s proposal.

VI.E. Unbalanced Prices Offers must include balanced prices. Unbalanced pricing may increase performance risk and could result in payment of unreasonably high prices. Unbalanced pricing exists when, despite an acceptable total evaluated price, the price of one or more contract line items is significantly over or understated as indicated by the application of price analysis techniques. All offers with separately priced line items or subline items shall be analyzed to determine if the prices are unbalanced. If price analysis techniques indicate that an offer is unbalanced, the contracting officer shall: (i) Consider the risks to the Government associated with the unbalanced pricing in determining the competitive range and in making the source selection decision; and (ii) Consider whether award of the contract will result in paying unreasonably high prices for contract performance. An offer may be rejected if the contracting officer determines that the lack of balance poses an unacceptable risk to the Government.

VI.F. Total Evaluated Price

Total Evaluated Price shall be calculated using the prices indicated in the Phase 2 Price Proposal using the formula in the Phase 2 Solicitation.

VI.G. Non-Price Factors

(1) Design Concept- Offerors shall provide a Design and Construction Quality Control Plan (QCP) tailored to This Project. The QCP shall contain Offeror’s methodology for controlling quality during both design and construction. The Plan shall also demonstrate the Offeror’s understanding of the high level of quality expected due to the nature of the historically significant building and the means by which the Design-Build Contractor will attain the quality throughout both the design and construction portions of the Work.

(2) Management Approach and Key Personnel- Offerors shall provide a Management Plan for the Project that explains how the various team members will work together and the methodology and processes for managing this entire Project. The Plan shall describe the process during design for solving the technical, functional, and constructability issues while maintaining the design intent and obtaining approvals. The Plan shall discuss the method of coordination with GSA. The Plan shall refer to the use of schedules and cost control systems. The Plan shall also discuss how the Offeror will ensure that Government and other necessary permits and approvals are received for this Project in a timely manner so that the completion date of the construction is not delayed.

(3) Proposed Technical Solutions- Offeror shall provide a project schedule narrative and a project schedule of 200 to 400 activities in CPM network format. The proposed schedule will run from the contract award date through the required date for substantial completion of construction and all punch list items. The network logic shall be linked, and the logic shall show the general management approach to designing and construction the Project.

VI.H. Evaluation of Joint Venture Offerors In the evaluation of responsibility and non-price factors, information submitted for a party to the joint venture will only be evaluated to the extent that the terms of the joint venture agreement do not limit such party's performance or financial obligations as a party to the Contract contemplated by this Solicitation.

GSA Solicitation No. 47PM1023R0013________________

Document: C301/ MARCH 2023 (Offeror Representations and Certifications) Page 1 of 15

Offeror Representations and Certifications

1. FAR 52.204-8 Annual Representations and Certifications (DEC 2022)

(a) (1) The North American Industry Classification System (NAICS) code for this acquisition is 236220 (Commercial and Institutional Building Construction) .

(2) The small business size standard is $39.5 million average annual receipts.

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees if the acquisition—

(i)Is set aside for small business and has a value above the simplified acquisition threshold;

(ii)Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii)Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b) (1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

[_] (i) Paragraph (d) applies.

[_] (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

https://www.acquisition.gov/far/52.204-7#FAR_52_204_7 https://www.acquisition.gov/far/52.204-7#FAR_52_204_7

(Offeror Representations and Certifications) Page 2 of 15

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless–

(A) The acquisition is to be made under the simplified acquisition procedures in part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that-

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services- Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations-Representation.

(viii) 52.209-5, CertificationRegarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

https://www.acquisition.gov/far/52.203-2#FAR_52_203_2 https://www.acquisition.gov/far/part-13#FAR_Part_13 https://www.acquisition.gov/far/52.203-11#FAR_52_203_11 https://www.acquisition.gov/far/52.203-18#FAR_52_203_18 https://www.acquisition.gov/far/52.204-3#FAR_52_204_3 https://www.acquisition.gov/far/52.204-7#FAR_52_204_7 https://www.acquisition.gov/far/52.204-5#FAR_52_204_5 https://www.acquisition.gov/far/52.204-26#FAR_52_204_26 https://www.acquisition.gov/far/52.209-2#FAR_52_209_2 https://www.acquisition.gov/far/52.209-5#FAR_52_209_5

(Offeror Representations and Certifications) Page 3 of 15

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance-Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans’ Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial products or commercial services.

https://www.acquisition.gov/far/52.209-11#FAR_52_209_11 https://www.acquisition.gov/far/52.214-14#FAR_52_214_14 https://www.acquisition.gov/far/52.215-6#FAR_52_215_6 https://www.acquisition.gov/far/52.219-1#FAR_52_219_1 https://www.acquisition.gov/far/part-19#FAR_Part_19 https://www.acquisition.gov/far/19.000#FAR_19_000 https://www.acquisition.gov/far/52.219-2#FAR_52_219_2 https://www.acquisition.gov/far/part-19#FAR_Part_19 https://www.acquisition.gov/far/19.000#FAR_19_000 https://www.acquisition.gov/far/52.222-22#FAR_52_222_22 https://www.acquisition.gov/far/52.222-26#FAR_52_222_26 https://www.acquisition.gov/far/52.222-25#FAR_52_222_25 https://www.acquisition.gov/far/52.222-26#FAR_52_222_26 https://www.acquisition.gov/far/52.222-38#FAR_52_222_38

(Offeror Representations and Certifications) Page 4 of 15

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA–designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA–designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals-Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American-Free Trade Agreements-Israeli Trade Act Certificate. (Basic, Alternates II and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $50,000, the basic provision applies.

(B) If the acquisition value is $50,000 or more but is less than $92,319, the provision with its Alternate II applies.

(C) If the acquisition value is $92,319 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan-Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-Representation and Certifications.

This provision applies to all solicitations.

https://www.acquisition.gov/far/52.223-1#FAR_52_223_1 https://www.acquisition.gov/far/52.223-2#FAR_52_223_2 https://www.acquisition.gov/far/52.223-4#FAR_52_223_4 https://www.acquisition.gov/far/52.223-22#FAR_52_223_22 https://www.acquisition.gov/far/52.204-7#FAR_52_204_7 https://www.acquisition.gov/far/52.225-2#FAR_52_225_2 https://www.acquisition.gov/far/52.225-1#FAR_52_225_1 https://www.acquisition.gov/far/part-52#FAR_52_225_4 https://www.acquisition.gov/far/part-52#FAR_52_225_3 https://www.acquisition.gov/far/52.225-6#FAR_52_225_6 https://www.acquisition.gov/far/52.225-5#FAR_52_225_5 https://www.acquisition.gov/far/52.225-20#FAR_52_225_20 https://www.acquisition.gov/far/52.225-25#FAR_52_225_25

(Offeror Representations and Certifications) Page 5 of 15

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

__ (i) 52.204-17, Ownership or Control of Offeror.

__ (ii) 52.204-20, Predecessor of Offeror.

__ (iii) 52.222-18, Certification Regarding Knowledge of Child Labor for

Listed End Products.

__ (iv) 52.222-48, Exemption from Application of the Service Contract

Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment- Certification.

__ (v) 52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Certification.

__ (vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA–Designated Products (Alternate I only).

__ (vii) 52.227-6, Royalty Information.

__ (A) Basic.

__ (B) Alternate I.

__ (viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically in SAM website accessed through https://www.sam.gov. After reviewing the SAM information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change https://www.acquisition.gov/far/52.226-2#FAR_52_226_2 https://www.acquisition.gov/far/52.204-17#FAR_52_204_17 https://www.acquisition.gov/far/52.204-20#FAR_52_204_20 https://www.acquisition.gov/far/52.222-18#FAR_52_222_18 https://www.acquisition.gov/far/52.222-48#FAR_52_222_48 https://www.acquisition.gov/far/52.222-52#FAR_52_222_52 https://www.acquisition.gov/far/52.223-9#FAR_52_223_9 https://www.acquisition.gov/far/52.227-6#FAR_52_227_6 https://www.acquisition.gov/far/52.227-15#FAR_52_227_15 https://www.acquisition.gov/far/4.1201#FAR_4_1201

(Offeror Representations and Certifications) Page 6 of 15

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

2. FAR 52.204-16 COMMERCIAL AND GOVERNMENT ENTITY CODE REPORTING (AUG 2020)

(a) Definition. As used in this provision –

“Commercial and Government Entity (CAGE) code” means–

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity by unique location; or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

(b) The Offeror shall provide its CAGE code with its offer with its name and location address or otherwise include it prominently in its proposal. The CAGE code must be for that name and location address. Insert the word ‘‘CAGE’’ before the number.

The CAGE code is required prior to award.

(c) CAGE codes may be obtained via–

(1) Registration in the System for Award Management (SAM) at www.sam.gov. If the Offeror is located in the United States or its outlying areas and does not already have a CAGE code assigned, the DLA Commercial and Government Entity (CAGE) Branch will assign a CAGE code as a part of the SAM registration process. SAM registrants located outside the United States and its outlying areas shall obtain a NCAGE code prior to registration in SAM (see paragraph (c)(3) of this provision).

(Offeror Representations and Certifications) Page 7 of 15

(2) The DLA Contractor and Government Entity (CAGE) Branch. If registration in SAM is not required for the subject procurement, and the Offeror does not otherwise register in SAM, an Offeror located in the United States or its outlying areas may request that a CAGE code be assigned by submitting a request at https://cage.dla.mil.

(3) The appropriate country codification bureau. Entities located outside the United States and its outlying areas may obtain an NCAGE code by contacting the Codification Bureau in the foreign entity's country if that country is a member of NATO or a sponsored nation. NCAGE codes may be obtained from the NSPA at https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx if the foreign entity’s country is not a member of NATO or a sponsored nation.

Points of contact for codification bureaus, as well as additional information on obtaining NCAGE codes, are available at http://www.nato.int/structur/AC/135/main/links/contacts.htm.

(d) Additional guidance for establishing and maintaining CAGE codes is available at https://cage.dla.mil.

(e) When a CAGE code is required for the immediate owner and/or the highest-level owner by Federal Acquisition Regulation (FAR) 52.204–17 or 52.212–3(p), the Offeror shall obtain the respective CAGE code from that entity to supply the CAGE code to the Government.

(f) Do not delay submission of the offer pending receipt of a CAGE code.

(g) If the solicitation includes FAR clause 52.204–2, Security Requirements, a subcontractor requiring access to classified information under a contract shall be identified with a CAGE code on the DD Form 254. The Contractor shall require a subcontractor requiring access to classified information to provide its CAGE code with its name and location address or otherwise include it prominently in the proposal. Each location of subcontractor performance listed on the DD Form 254 is required to reflect a corresponding unique CAGE code for each listed location unless the work is being performed at a Government facility, in which case the agency location code shall be used. The CAGE code must be for that name and location address. Insert the word ‘‘CAGE’’ before the number. The CAGE code is required prior to award.

(End of provision)

3. FAR 52.209-7 Information Regarding Responsibility Matters. (OCT 2018)

(a) Definitions. As used in this provision— https://cage.dla.mil/ https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx http://www.nato.int/structur/AC/135/main/links/contacts.htm https://cage.dla.mil/

(Offeror Representations and Certifications) Page 8 of 15

“Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings).

This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

“Federal contracts and grants with total value greater than $10,000,000” means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

“Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror has does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in–

(Offeror Representations and Certifications) Page 9 of 15

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed viahttps://www.sam.gov (see 52.204-7).

(End of provision)

4. FAR 52.209-13 Violation of Arms Control Treaties or Agreements-Certification

(NOV 2021)

(a) This provision does not apply to acquisitions at or below the simplified acquisition threshold or to acquisitions of commercial products and commercial services as defined in Federal Acquisition Regulation 2.101.

(b) Certification. [Offeror shall check either (1) or (2).]

__ (1) The Offeror certifies that–

(i) It does not engage and has not engaged in any activity that contributed to or was a significant factor in the President's or Secretary of State's determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act ( 22 U.S.C. 2593a). The report is available at https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/; and https://www.sam.gov/ https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063838 https://www.acquisition.gov/far/2.101#FAR_2_101 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title22-section2593a&num=0&edition=prelim https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/ https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/

(Offeror Representations and Certifications) Page 10 of 15

(ii) No entity owned or controlled by the Offeror has engaged in any activity that contributed to or was a significant factor in the President's or Secretary of State's determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act ( 22 U.S.C. 2593a). The report is available at https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/; or

__ (2) The Offeror is providing separate information with its offer in accordance with paragraph (d)(2) of this provision.

(c) Procedures for reviewing the annual unclassified report (see paragraph (b)(1) of this provision). For clarity, references to the report in this section refer to the entirety of the annual unclassified report, including any separate reports that are incorporated by reference into the annual unclassified report.

(1) Check the table of contents of the annual unclassified report and the country section headings of the reports incorporated by reference to identify the foreign countries listed there. Determine whether the Offeror or any person owned or controlled by the Offeror may have engaged in any activity related to one or more of such foreign countries.

(2) If there may have been such activity, review all findings in the report associated with those foreign countries to determine whether or not each such foreign country was determined to be in violation of its obligations undertaken in an arms control, nonproliferation, or disarmament agreement to which the United States is a party, or to be not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. For clarity, in the annual report an explicit certification of non-compliance is equivalent to a determination of violation. However, the following statements in the annual report are not equivalent to a determination of violation:

(i) An inability to certify compliance.

(ii) An inability to conclude compliance.

(iii) A statement about compliance concerns.

http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title22-section2593a&num=0&edition=prelim https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/ https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/

(Offeror Representations and Certifications) Page 11 of 15

(3) If so, determine whether the Offeror or any person owned or controlled by the Offeror has engaged in any activity that contributed to or is a significant factor in the determination in the report that one or more of these foreign countries is in violation of its obligations undertaken in an arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. Review the narrative for any such findings reflecting a determination of violation or non-adherence related to those foreign countries in the report, including the finding itself, and to the extent necessary, the conduct giving rise to the compliance or adherence concerns, the analysis of compliance or adherence concerns, and efforts to resolve compliance or adherence concerns.

(4) The…