N6660420Q8489.pdf

1300865520

PROJECT TITLE AND DESCRIPTION: NUWCDIVNPT Bldg. 1319 Lobby Renovation Project

SITE VISIT: 16 July 2020, 10:00 AM, EST-See Section A for instructions. Please note-Due to current COVID-19 situation, all attendees should follow guidance f rom the Centers for Disease Control and Prevention. Please see attached questionaire that may assist you in determining w hether to attend the site visit. Also, please see attachmnet for face covering requirements on DoD installations. We may need to hold more than one visit depending on the number of attendees. These w ould be conduted back-to-back to minimize imact to an attendee's schedule.

PROPOSAL DUE:12 AUG 2020, 4:00 PM EST; E-mail to: leslie.brazil@navy.mil and michael.h.broomf ield@navy.mil

MAGNITUDE: IAW FAR 36.204, BETWEEN $100,000 AND $250,000.

THE METHOD OF PAYMENT WILL BE WIDE AREA WORKFLOW.

THIS IS A 100% SMALL BUSINESS SET ASIDE; NAICS 236220; $39.5 MII

MPORTANT: PLEASE NOTE THAT TECHNICAL INFORMATION IS REQUIRED WITH SUBMIISSION OF OFFEROR. SEE SECTIONS AND L AND M

FOR SPECIFIC REQUIREMENTS. OFFERORS NOT SUBMITTING THIS INFORMATION RISK BEING EXCLUDED FROM CONSIDERATION FOR

AWARD

MICHAEL H. BROOMFIELD 401-832-8469

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

09-Jul-2020

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

X

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________180 calendar days after receiving aw ard, notice to proceed. This performance period is mandatory, negotiable. (See _________________________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________12 Aug 2020 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

NAVAL UNDERSEA WARFARE CENTER

MICHAEL BROOMFIELD, CODE 0222

CONTRACTS DEPARTMENT

1176 HOWELL STREET, BLDG. 1258

NEWPORT RI 02841

N66604

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

04:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

401-832-4820FAX:TEL: 401-832-8469 TEL: FAX:

N6660420Q8489 41

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued)

(Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

N6660420Q8489

Section A - Solicitation/Contract Form

SITE VISIT

A Site Visit will be conducted on July 16, 2020 at 1000 AM, EST. Participants will meet at NUWCDIVNPT Building 80. Interested attendees must pre-register by e-mail to Michael.h.broomfield@navy.mil . Please provide the individual’s name, company, phone and e-mail address. Registrations will be accepted until 4:00 PM (EST) on July

13 2020. All prospective offerors are highly urged to attend this site visit.

The following rules apply for the site visit:

COVID-19 Requirements: Please review attachment #6 Covid Questionnaire, and follow the most up to date CDC guidelines in determining access to the Government Facility. Face coverings must be worn at all times, please refer to attachment #4. Additionally, if travelling from outside of a 60 mile radius of NUWCDIVNPT, participants must specify their departure location addresses (city/state).

Check-in will begin at 9:00 AM (EST) on 16 July 2020 in the lobby of NUWCDIVNPT Building 80, Newport, RI. Interested attendees must pre-register by e-mail to michael.h.broomfield@navy.mil and leslie.brazil@navy.mil.

Please provide the individual's name, company, phone and e-mail address.

Registrations will be accepted until 5:00 PM (EST) on 13 July 2020 .

The following rules apply for the site visit:

. This will be an Unclassified site visit

. The site visit will be scripted, no questions will be allowed during the tour

. Follow-up questions can be submitted via email to michael.h.broomfield@navy.mil and leslie.brazil@navy.mil.

. The use of any type of camera during the site visit is prohibited.

In addition to pre-registration and in order to participate in the Site Visit, participants MUST have an approved Visit Request. Instructions for submitting a visit request can be found at the following link:

http://www.navsea.navy.mil/Home/Warfare-Centers/NUWC-Newport/Contact-Us/Mandatory-Visit-Request/

Access to NUWC Division Newport WILL NOT be granted under any circumstances without a valid visit authorization request on file. Please list Leslie Brazil, Code 0232, as the Government POC when submitting the visit request.

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Bldg 1319 LOBBY RENOVATION

FFP

The Contractor shall provide all materials, equipment, labor, and supervision to renovate the lobby of NUWCDIVNPT Bldg. 1319 in accordance with the attached

Specifications and Drawings.

FY OF FUNDING: N/A; TYPE OF FUNDING: NUWCDIVNPT

Overhead: Sponsor & Technical Code: 1021

FOB: Destination

PURCHASE REQUEST NUMBER: 1300865520

PSC CD: Z2HB

NET AMT

Section C - Descriptions and Specifications

CLAUSES INCORPORATED BY FULL TEXT

C-228-H002 MINIMUM INSURANCE REQUIREMENTS (NAVSEA) (JAN 2019)

(a) In accordance with the clause(s) of this contract entitled "Insurance--Work On a Government Installation" (FAR

52.228-5) and “Liability and Insurance” (DFARS 252.217-7012), as applicable, the Contractor shall procure and maintain insurance, of at least the kinds and minimum amounts set forth below:

(i) Workers' compensation and employer’s liability coverage shall be at least $100,000, except as provided in

FAR 28.307-2(a), if applicable

(ii) Bodily injury liability insurance coverage shall be written on the comprehensive form of policy of at least

$500,000 per occurrence.

(iii) Automobile liability policies covering automobiles operated in the United States shall provide coverage of at least $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage. The amount of liability coverage on other policies shall be commensurate with any legal requirements of the locality and sufficient to meet normal and customary claims.

(b) To be approved by the Contracting Officer, insurance certificates must include the following cancellation policy statement: Prior to cancellation or material change in coverage, the contractor shall give 30 days written notice to the

Contracting Officer.

(c) Physical work cannot begin until the insurance certificate has been approved by the Contracting Officer. Failure to provide an acceptable insurance certificate will not remove the contractor’s responsibility to meet the delivery requirements outlined in Section F and FAR 52.211-11, Liquidated Damages – Supplies, Services, or Research and Development, if applicable.

(End of text)

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 180 dys. ADC 1 NAVAL STATION NEWPORT, N66604

RECEIVING OFFICER

47 CHANDLER STREET

NEWPORT RI 02841-1716

401-832-6150

FOB: Destination

N66604

CLAUSES INCORPORATED BY REFERENCE

52.247-34 F.O.B. Destination NOV 1991

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the

Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 180 days after contract award. The time stated for completion shall include final cleanup of the premises.

(End of clause)

Section G - Contract Administration Data

252.204-7006 Billing Instructions OCT 2005

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) Definitions. As used in this clause—

“Department of Defense Activity Address Code (DoDAAC)” is a six position code that uniquely identifies a unit, activity, or organization.

“Document type” means the type of payment request or receiving report available for creation in Wide Area

WorkFlow (WAWF).

“Local processing office (LPO)” is the office responsible for payment certification when payment certification is done external to the entitlement system.

“Payment request” and “receiving report” are defined in the clause at 252.232-7003, Electronic Submission of

Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-

7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall—

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training

Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data

Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

https://www.sam.gov/ https://wawf.eb.mil/ https://wawf.eb.mil/

(ii) For fixed price line items—

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

N/A

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the

Contracting Officer.

Invoice & Receiving Report (Combo)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF “combo” document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC N62846

Issue By DoDAAC N66604

Admin DoDAAC** N66604

Inspect By DoDAAC N66604

Service Acceptor (DoDAAC) N66604

(*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert

“See Schedule” or “Not applicable.”)

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the

DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition

Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity’s

WAWF point of contact.

Jerry Palmer at gerard.palmer@navy.mil or (401) 832-4964 or NAVSEA HQ WAWF Helpdesk at

WAWFHQ@navy.mil

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

NOTE: WAWF Email notifications: The Contractor shall enter the email address identified below in the “Send

Additional Email Notifications” field of WAWF once a document is submitted in the system.

G-232-H002 PAYMENT INSTRUCTIONS AND CONTRACT TYPE SUMMARY FOR PAYMENT

OFFICE (NAVSEA) (JUN 2018)

(a) The following table of payment office allocation methods applies to the extent indicated.

For Government Use Only

Contract/Order Payment

Clause

Type of Payment

Request

S u p p ly

S er v ic e

C o n st ru ct io n

Payment Office

Allocation Method

52.212-4 (Alt I), Contract

Terms and Conditions—

Commercial Items

52.216-7, Allowable Cost and Payment

52.232-7, Payments under

Time-and-Materials and

Labor-Hour Contracts

Cost Voucher X X N/A Line item specific proration. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated in the same proportion as the amount of funding currently unliquidated for each

ACRN on the deliverable line or deliverable subline item for which payment is requested.

52.232-1, Payments Navy

Shipbuilding

Invoice (Fixed

Price)

X N/A N/A Line Item specific by fiscal year. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated using the oldest funds. In the event of a deliverable line or deliverable subline item with two ACRNs with the same fiscal year, those amounts will be prorated to the available unliquidated funds for that year.

Contract/Order Payment

Clause

Type of Payment

Request

S u p v ic e

C o n st ru ct

52.232-1, Payments;

52.232-2, Payments under Fixed-Price Research and

Development Contracts;

52.232-3, Payments under

Personal Services Contracts;

52.232-4, Payments under

Transportation Contracts and

Transportation-Related

Services Contracts; and

52.232-6, Payments under

Communication Service

Contracts with Common

Carriers

Invoice X X N/A Line Item Specific proration. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated in the same proportion as the amount of funding currently unliquidated for each

ACRN on the deliverable line or deliverable subline item for which payment is requested.

52.232-5, Payments Under

Fixed-Price Construction

Contracts

Construction

Payment Invoice

N/A N/A X Line Item specific by fiscal year. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated using the oldest funds. In the event of a deliverable line or deliverable subline item with two ACRNs with the same fiscal year, those amounts will be prorated to the available unliquidated funds for that year.

52.232-16, Progress

Payments

Progress

Payment*

X X N/A Contract-wide proration. Funds shall be allocated in the same proportion as the amount of funding currently unliquidated for each ACRN. Progress Payments are considered contract level financing, and the “contract price” shall reflect the fixed price portion of the contract per FAR

32.501-3.

52.232-29, Terms for

Financing of Purchases of

Commercial Items;

52.232-30, Installment

Payments for Commercial

Items

Commercial Item

Financing*

X X N/A Specified in approved payment. The contracting officer shall specify the amount to be paid and the account(s) to be charged for each payment approval in accordance with FAR 32.207(b)(2) and

32.1007(b)(2).

52.232-32, Performance-

Based Payments

Performance-

Based Payments*

X X N/A Specified in approved payment. The contracting officer shall specify the amount to be paid and the account(s) to be charged for each payment approval in accordance with FAR 32.207(b)(2) and

32.1007(b)(2).

252.232-7002, Progress

Payments for Foreign

Military Sales Acquisitions

Progress

Payment*

X X N/A Allocate costs among line items and countries in a manner acceptable to the

Administrative Contracting Officer.

Contract/Order Payment

Clause

Type of Payment

Request

S u p v ic e

C o n st ru ct

*Liquidation of Financing Payments. Liquidation will be applied by the payment office against those ACRNs which are identified by the payment instructions for the delivery payment and in keeping with the liquidation provision of the applicable contract financing clause (i.e., progress payment, performance-based payment, or commercial item financing).

(b) This procurement contains the following contract type(s):

Item Type*

CLIN 0001 FP

* FP – Fixed Price

G-242-H001 GOVERNMENT CONTRACT ADMINISTRATION POINTS-OF-CONTACT AND

RESPONSIBILITIES (NAVSEA) (OCT 2018)

(a) The Government reserves the right to administratively substitute any of the points of contact listed below at any time.

(b) The contracting officer is the only person authorized to change this contract or orders issued thereunder. The Contractor shall not comply with any order, direction or request of Government personnel

- that would constitute a change - unless it is issued in writing and signed by the Contracting Officer or is pursuant to specific authority otherwise included as part of this contract. If, in the opinion of the contractor, an effort outside the existing scope of this contract is requested, the contractor shall promptly comply with the Notification of Changes clause of this contract.

(c) The points of contact are as follows:

(i) The Procuring Contracting Officer (PCO) is:

Leslie Brazil, Code 0232 Naval Undersea Warfare Center

Division Newport

Newport, RI 02841 leslie.brazil@navy.mil

401.832.2907

(ii) The Contract Specialist is:

Michael Broomfield, Code 0232

Naval Undersea Warfare Center

Division Newport

Newport, RI 02841 michael.h.broomfield@navy.mil

401.832.8469

(d) The Technical Point of Contact (TPOC) is the contracting officer’s representative for technical matters when a COR is not appointed. The TPOC is responsible for technical issues of contract administration, such as providing all items of Government Furnished Information (GFI), Government

Furnished Material (GFM) and Government Furnished Equipment (GFE) if specified in the contract as well as the inspection and acceptance of all contract deliverables.

The Technical Point of Contact (TPOC) is:

To be identifed at time of award

(e) The Competition Advocate will review complaints from the contractors and ensure that all contractors are afforded a fair opportunity to be considered, consistent with the procedures in the contract.

The Competition Advocate is:

Stephen Lamb, Code 02

Naval Undersea Warfare Center

Division Newport

N6660420R8176

Newport, RI 02841

401.832.8526;

Stephen.a.lamb1@navy.mil

(k) The Contractor's point of contact for performance under this contract is:

Name: [ * ]

Title: [ * ]

Address:

[ *Street ]

[ *City, State, Zip ]

Phone: (Area Code) xxx- [xxxx]; FAX: (Area Code) xxx- [xxxx]

E-mail: [ * ]

[ * ] To be completed at contract awardN/A mailto:Stephen.a.lamb1@navy.mil

Section H - Special Contract Requirements

CONTRACTOR REQUIREMENTS

CONTRACTOR REQUIREMENTS FOR PERFORMANCE ON A GOVERNMENT SITE

(a) Control of Contractor Personnel

The contractor shall comply with the requirements of NUWCDIVNPTINST 5500.4C regarding performance at Government facilities. All persons engaged in work while on Government property shall be subject to search of their persons and vehicles at any time by the Government, and shall report any known or suspected security violations to the Security Department of the contracting activity. Assignment, transfer, and reassignment of contractor personnel shall be at the discretion of the contractor. However, the contractor shall remove from contract performance any person who endangers life, property, or national security through improper conduct. Such removal shall not relieve the contractor from meeting its contractual obligations and shall not be considered an excusable delay as defined in FAR 52.249-14.

(b) Contract Personnel Administration

The contractor is responsible for managing its employees and guarding against any actions that are of the nature of personal services or give the perception that personal services are being provided. If the contractor feels that any actions constitute, or are perceived to constitute personal services, it is the contractor's responsibility to notify the PCO immediately in accordance with the clause FAR 52.243-7.

When on-site in Government office spaces, laboratories, test facilities, or ship assets, Contractor employees shall be clearly identified as a Contractor (e.g. utilizing Common Access Cards (CACs) and sign identifications in office spaces). In addition, Contractor employees shall identify themselves as

Contractor personnel when answering telephones and sending emails. Contractor personnel cannot lead/manage/supervise Government personnel. Contractor program /project managers/Senior Technical

Representative (STR) shall be clearly identified and known as such by Government employees. As circumstances permit, periodic meetings shall be conducted between the COR and the Contractor organization program manager/project manager.

(c) Early Dismissal and Closure of Government Facilities

When a Government facility is closed or Federal employees are dismissed early (due to severe weather, security threat, security exercise, or a facility related problem) that prevents personnel from working, onsite contractor personnel regularly assigned to work at that facility shall follow the same reporting and/or departure directions given to Government personnel. The contractor shall not direct charge to the contract for such time off, but shall follow parent company policies regarding taking leave (administrative or other). Non-essential contractor personnel, who are not required to remain at or report to the facility, shall follow their parent company policy regarding whether they should go/stay home or report to another company facility. Subsequent to an early dismissal and during periods of inclement weather, onsite contractors should monitor radio and television announcements before departing for work to determine if the facility is closed or operating on a delayed arrival basis. (d) When Federal employees are excused from work due to a holiday or a special event (that is unrelated to severe weather, a security threat, or a facility related problem), on site contractors shall continue working established work hours or take leave in accordance with parent company policy. Those contractor employees who take leave shall not direct charge the non- working hours to the contract. Contractors are responsible for predetermining and disclosing their charging practices for early dismissal, delayed openings, or closings in accordance with the FAR, applicable cost accounting standards, and company policy. Contractors shall follow their disclosed charging practices during the contract period of performance, and shall not follow any verbal directions to the contrary. The

Contracting Officer will make the determination of cost allowability for time lost due to facility closure in accordance with FAR, applicable Cost Accounting Standards, and the Contractor's established accounting policy.

(e) Training Requirements

(1) The contractor shall ensure that each contractor employee performing work at any NUWC Division Newport site take the following actions:

(A) Complete all required trainings as indicated on the following website:

https://newportalv3.nwpt.nuwc.navy.mil/10/101/Training/SitePages/TrainingWelcome.aspx

(B) Read the documents titled “Occupational Safety and Health Information for Contractors” and “NUWC Division

Newport Environmental Policy”, available at the following website, prior to performing any work:

http://www.navsea.navy.mil/Home/WarfareCenters/NUWCNewport/ContactUs/VisitorInformation.aspx

(C) Complete Environmental Awareness training, available at the following website, within 30 days of commencing performance:

http://www.navsea.navy.mil/Home/WarfareCenters/NUWCNewport/ContactUs/VisitorInformation.aspx

(2) The contractor shall email the following web address indicating completion of items (B) and (C) above upon completion of both: NWPT.NUWC_NPT_1023_Training@navy.mil

(f) Safety Requirements

(1) Prior to commencing any work that falls under the following areas, the contractor shall provide a complete listing of all qualified and trained employees who will perform the work on company letterhead to the Contracting Officer’s Representative (COR), or, if no COR is assigned, to the

NUWC Division Newport Safety Office:

(A) Permit required Confined Space Program

(B) Control of Hazardous Energy (Lock out / Tag out)

(C) Respiratory Protection

(D) Walking-Working Surfaces, Fall Protection Program and Scaffolding

(2) The contractor shall follow the posted provisions of the building’s Emergency Action Plan (EAP) for any mishap, incident, or emergency situation.

(3) The contractor shall report unsafe work conditions, safety hazards, and any mishaps (injury/property damage) to their supervisor, the COR, and the NUWC Division Newport Safety Office.

[End of Text] mailto:NWPT.NUWC_NPT_1023_Training@navy.mil

Section I - Contract Clauses

52.202-1 Definitions JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018

52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-23 Prohibition on Contracting for Hardware, Software, and

Services Developed or Provided by Kaspersky Lab and Other

Covered Entities.

JUL 2018

52.204-24 Representation Regarding Certain Telecommunications and

Video Surveillance Services or Equipment.

DEC 2019

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

AUG 2019

52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.214-35 Submission Of Offers In U.S. Currency APR 1991

52.215-8 Order of Precedence--Uniform Contract Format OCT 1997

52.219-6 Notice Of Total Small Business Set-Aside MAR 2020 52.219-28 Post-Award Small Business Program Rerepresentation MAY 2020

52.222-5 Construction Wage Rate Requirements--Secondary Site of the

Work

MAY 2014

52.222-6 Construction Wage Rate Requirements AUG 2018

52.222-7 Withholding of Funds MAY 2014

52.222-8 Payrolls and Basic Records AUG 2018

52.222-9 Apprentices and Trainees JUL 2005

52.222-10 Compliance with Copeland Act Requirements FEB 1988

52.222-11 Subcontracts (Labor Standards) MAY 2014

52.222-12 Contract Termination-Debarment MAY 2014

52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988

52.222-15 Certification of Eligibility MAY 2014

52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-50 Combating Trafficking in Persons JAN 2019 52.223-6 Drug-Free Workplace MAY 2001

52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

JUN 2020

52.227-4 Patent Indemnity-Construction Contracts DEC 2007

52.228-5 Insurance - Work On A Government Installation JAN 1997

52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014

52.232-23 Alt I Assignment of Claims (May 2014) - Alternate I APR 1984

52.232-27 Prompt Payment for Construction Contracts JAN 2017

52.232-38 Submission of Electronic Funds Transfer Information with

Offer

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013

52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.236-1 Performance of Work by the Contractor APR 1984

52.236-2 Differing Site Conditions APR 1984

52.236-3 Site Investigation and Conditions Affecting the Work APR 1984

52.236-5 Material and Workmanship APR 1984

52.236-6 Superintendence by the Contractor APR 1984

52.236-7 Permits and Responsibilities NOV 1991

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-11 Use and Possession Prior to Completion APR 1984

52.236-12 Cleaning Up APR 1984

52.236-13 Accident Prevention NOV 1991

52.236-14 Availability and Use of Utility Services APR 1984

52.236-15 Schedules for Construction Contracts APR 1984

52.236-16 Alt I Quantity Surveys (Apr 1984) - Alternate I APR 1984

52.236-17 Layout of Work APR 1984

52.236-21 Specifications and Drawings for Construction FEB 1997

52.236-26 Preconstruction Conference FEB 1995

52.236-27 Alt I Site Visit (Construction) (Feb 1995) - Alternate I FEB 1995

52.242-13 Bankruptcy JUL 1995

52.242-14 Suspension of Work APR 1984

52.243-5 Changes and Changed Conditions APR 1984

52.244-6 Subcontracts for Commercial Items JUN 2020

52.246-12 Inspection of Construction AUG 1996

52.246-21 Warranty of Construction MAR 1994 52.249-10 Default (Fixed-Price Construction) APR 1984

52.253-1 Computer Generated Forms JAN 1991

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013

252.203-7003 Agency Office of the Inspector General AUG 2019

252.204-7006 Billing Instructions OCT 2005

252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

DEC 2019

252.204-7015 Notice of Authorized Disclosure of Information for Litigation

Support

MAY 2016

252.204-7018 Prohibition on the Acquisition of Covered Defense

Telecommunications Equipment or Services

DEC 2019

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of

Terrorism

MAY 2019

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013

252.225-7002 Qualifying Country Sources As Subcontractors DEC 2017

252.225-7048 Export-Controlled Items JUN 2013

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7010 Levies on Contract Payments DEC 2006

252.236-7000 Modification Proposals-Price Breakdown DEC 1991

252.236-7001 Contract Drawings, and Specifications AUG 2000

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.247-7023 Transportation of Supplies by Sea FEB 2019

52.204-26 COVERED TELECOMMUNICATIONS EQUIPMENT OR SERVICES--REPRESENTATION (DEC

2019)

(a) Definitions. As used in this provision, “covered telecommunications equipment or services” has the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM)

(https://www.sam.gov) for entities excluded from receiving federal awards for “covered telecommunications equipment or services”.

(c) Representation. The Offeror represents that it [ ___ ] does, [ ___ ] does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

(End of provision)

52.213-4 TERMS AND CONDITIONS--SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL

ITEMS) (JUN 2020)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017)

(section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by

Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(iii) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or

Equipment. (AUG 2019) (Section 889(a)(1)(A) of Pub. L. 115-232).

(iv) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

(v) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(vi) 52.222-26, Equal Opportunity (SEPT 2016) (E.O. 11246).

(vii) 52.225-13, Restrictions on Certain Foreign Purchases (JUN 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(viii) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(ix) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78 (19 U.S.C. 3805 note).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (APR 1984).

(ii) 52.232-8, Discounts for Prompt Payment (FEB 2002).

(iii) 52.232-11, Extras (APR 1984).

(iv) 52.232-25, Prompt Payment (JAN 2017).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (JUN 2013).

(vi) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (DEC 2013).

(vii) 52.233-1, Disputes (MAY 2014).

(viii) 52.244-6, Subcontracts for Commercial Items (JUN 2020).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (MAR 2016) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of

Columbia)).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (JUN 2020) (Pub. L. 109-282)

(31 U.S.C. 6101 note) (Applies to contracts valued at or above the threshold specified in FAR 4.1403(a) on the date of award of this contract).

(ii) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (JAN 2020) (E.O. 13126) (Applies to contracts for supplies exceeding the micro-purchase threshold, as defined in FAR 2.101 on the date of award of this contract).

(iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment (JUN 2020) (41 U.S.C. chapter 65)

(Applies to supply contracts over the threshold specified in FAR 22.602 on the date of award of this contract, in the

United States, Puerto Rico, or the U.S. Virgin Islands).

(iv) 52.222-35, Equal Opportunity for Veterans (JUN 2020) (38 U.S.C. 4212) (Applies to contracts valued at or above the threshold specified in FAR 22.1303(a) on the date of award of this contract).

(v) 52.222-36, Equal Employment for Workers with Disabilities (JUN 2020) (29 U.S.C. 793) (Applies to contracts over the threshold specified in FAR 22.1408(a) on the date of award of this contract, unless the work is to be performed outside the United States by employees recruited outside the United States). (For purposes of this clause, ``United States'' includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

(vi) 52.222-37, Employment Reports on Veterans (JUN 2020) (38 U.S.C. 4212) (Applies to contracts valued at or above the threshold specified in FAR 22.1303(a) on the date of award of this contract).

(vii) 52.222-41, Service Contract Labor Standards (AUG 2018) (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United

States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S.

Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf).

(viii)(A) 52.222-50, Combating Trafficking in Persons (JAN 2019) (22 U.S.C. chapter 78 and E.O. 13627) (Applies to all solicitations and contracts).

(B) Alternate I (MAR 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (DEC 2015) (Executive Order 13658) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50

States and the District of Columbia)).

(x) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706) (Applies when 52.222-6 or

52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the

District of Columbia.))

(xi) 52.223-5, Pollution Prevention and Right-to-Know Information (MAY 2011) (E.O. 13423) (Applies to services performed on Federal facilities).

(xii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (June, 2016)

(E.O. 13693)(applies to contracts for products as prescribed at FAR 23.804(a)(1)).

(xiii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (JUN 2020) (42 U.S.C. 1792) (Applies to contracts greater than the threshold specified in FAR 26.404 on the date of award of this contract, that provide for the provision, the service, or the sale of food in the United States).

(xiv) 52.223-15, Energy Efficiency in Energy-Consuming Products (DEC 2007) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR ® Program or Federal Energy Management Program (FEMP) will be--

(A) Delivered;

(B) Acquired by the Contractor for use in performing services at a Federally-controlled facility;

(C) Furnished by the Contractor for use by the Government; or

(D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance).

(xv) 52.223-20, Aerosols (June, 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices).

(xvi) 52.223-21, Foams (June, 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent;

or contracts for construction of buildings or facilities.

(xvii) 52.225-1, Buy American--Supplies (MAY 2014) (41 U.S.C. chapter 67) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold, as defined in FAR 2.101 on the date of award of this contract, and the acquisition--

(A) Is set aside for small business concerns; or

(B) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $25,000).

(xviii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (JUN 2020) (42 U.S.C. 1792)

(Applies to contracts greater than the threshold specified in FAR 26.404 on the date of award of this contract, that provide for the provision, the service, or the sale of food in the United States).

(xix) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (OCT 2018) (Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the System for

Award Management (SAM) as its source of EFT information.)

(xx) 52.232-34, Payment by Electronic Funds Transfer--Other than System for Award Management (JUL 2013)

(Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information.)

(xxi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (FEB 2006) (46 U.S.C. App. 1241)

(Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d).)

(2) Listed below are additional clauses that may apply:

(i) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (June, 2016) (Applies to contracts when the contractor or a subcontractor at any tier may have Federal contract information residing in or transiting through its information system.

(ii) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or

Proposed for Debarment (JUN 2020) (Applies to contracts over the threshold specified in FAR 9.405-2(b) on the date of award of this contract).

(iii) 52.211-17, Delivery of Excess Quantities (SEP 1989) (Applies to fixed-price supplies).

(iv) 52.247-29, F.o.b. Origin (FEB 2006) (Applies to supplies if delivery is f.o.b. origin).

(v) 52.247-34, F.o.b. Destination (NOV 1991) (Applies to supplies if delivery is f.o.b. destination).

(c) FAR 52.252-2, Clauses Incorporated by Reference (FEB 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

www.aquisition.gov

(d) Inspection/Acceptance. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its postacceptance rights--

(1) Within a reasonable period of time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the

Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(f) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges that the Contractor can demonstrate to the satisfaction of the Government, using its standard record keeping system, have resulted from the termination.

The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred that reasonably could have been avoided.

(g) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(h) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance

Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

3.1% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract

Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from

Contractor to Contractor, or from project to…