Final Solicitation.pdf

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

���� #$��%&'(�)'%(�*#�++��$,-&�.$(/%(0�&)$ )�+$&1�(�1�2*��&1�)%0.+$'$�-'�3-'#-& )�+$&1�(�1�2*��/'$(�($)$-4-&, &%'-)$�'%�.(%)$$1��� #-*�.$(/%(0�&)$�.$(-%1�-*�3�(15 0�&1�'%(2 &$,%'-��+$������� ��

�������������� �7

1� �//$(*�.(%4-1-&,�+$**�'#�& )�+$&1�(�1�2*�/%(��%4$(&0$&'��))$.'�&)$��/'$(�'#$�1�'$�%//$(*��($�18$�3-++�&%'��$�)%&*-1$($1��&1�3-++��$

($9$)'$1�

++�%//$(*��($�*8�9$)'�'%�'#$�"�:�3%(;�($<-8($0$&'*5��&1�"�:�%'#$(�.(%4-*-%&*��&1�)+�8*$*�-&)%(.%(�'$1�-&�'#$�*%+-)-'�'-%&�-&�/8++�'$='�%(��2

&�%//$(�,8�(�&'$$ -*5 -*�&%'�($<8-($1�

�����$�+$1�%//$(*�-&�%(-,-&�+��&1 )%.-$*�'%�.$(/%(0�'#$�3%(;�($<8-($1��($�18$��'�'#$�.+�)$�*.$)-/-$1�-&��'$0����2 ���� �

+%)�+�'-0$ "1�'$:����/�'#-*�-*���*$�+$1��-1�*%+-)-'�'-%&5�%//$(*�3-++��$�.8�+-)+2�%.$&$1��'�'#�'�'-0$����$�+$1�$&4$+%.$*

)%&'�-&-&,�%//$(*�*#�++��$�0�(;$1�'%�*#%3�'#$�%//$(%(>*�&�0$��&1��11($**5�'#$�*%+-)-'�'-%&�&80�$(5��&1�'#$�1�'$��&1�'-0$�%//$(*��($�18$�

������"�����@A�?:

�($*)(-�$1��2��� �A��

��"@�����:�?����BA�"1:

See Attached

6. PROJECT PLAN

OFFER (Must be fully completed by offeror)

�B������

��� #$�%//$(%(��,($$*�'%�.$(/%(0�'#$�3%(;�($<8-($1��'�'#$�.(-)$*�*.$)-/-$1��$+%3�-&�*'(-)'��))%(1�&)$�3-'#�'#$�'$(0*�%/�'#-*�*%+-)-'�'-%&5�-/�'#-*�%//$(�-*��))$.'$1

�2�'#$��%4$(&0$&'�-&�3(-'-&,�3-'#-& )�+$&1�(�1�2*��/'$(�'#$�1�'$�%//$(*��($�18$������&

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

AWARD (To be completed by Government)

�B��

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

'%�/8(&-*#��&1�1$+-4$(��++� -'$0*�%(�.$(/%(0��++�3%(;�($<8-($0$&'*�-1$&'-/-$1�%&�'#-* /%(0��&1��&2�)%&'-&8�'-%&�*#$$'*�/%(�'#$�)%&*-1$(�'-%&�*'�'$1�-&�'#-*�)%&'(�)'��� #$ (-,#'*��&1�%�+-,�'-%&*�%/�'#$�.�('-$*�'%�'#-*�)%&'(�)'�*#�++��$�,%4$(&$1��2�"�:�'#-* )%&'(�)'� �3�(15� "�:� '#$� *%+-)-'�'-%&5� �&1� "):� '#$� )+�8*$*5� ($.($*$&'�'-%&*5 )$('-/-)�'-%&*5� �&1� *.$)-/-)�'-%&*� -&)%(.%(�'$1� �2� ($/$($&)$� -&� %(� �''�)#$1� '%� '#-*

�E��

%8(�%//$(

%&�'#-*�*%+-)-'�'-%&�-*�#$($�2��))$.'$1��*�'%�'#$�-'$0*�+-*'$1��� #-*��3�(1�)%&*800�'$* '#$�)%&'(�)'5�3#-)#�)%&*-*'*�%/�"�:�'#$��%4$(&0$&'�*%+-)-'�'-%&��&1�2%8(�%//$(5��&1�"�:

'#-*�)%&'(�)'��3�(1����%�/8('#$(�)%&'(�)'8�+�1%)80$&'�-*�&$)$**�(2�

������"�����@A�?:�����

Building 53, Denver Federal Center, Lakewood, Colorado

ACM Abatement and Space Demolition 0001 The Contractor shall provide all supervision, labor, materials, and equipment to complete Asbestos Containing Material Abatement and space demolition as required by the Scope of Work.

1.00 LS

SCHEDULE Continued

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

SECTION 00100 INSTRUCTIONS, CONDITIONS, AND NOTICES TO BIDDERS

00100. 1 52.215-1 I INSTRUCTIONS TO OFFERORS--COMPETITIVE ACQUISITION (JAN 2004)--ALTERNATE I (OCT

1997)

00100. 2 52.215-20 IV REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR

PRICING DATA (OCT 1997)--ALTERNATE IV (OCT 1997)

00100. 3 52.216-1 TYPE OF CONTRACT (APR 1984)

00100. 4 52.219-4 NOTICE OF PRICE EVALUATION PREFERENCE FOR HUBZONE SMALL BUSINESS CONCERNS (JUL

2005)

00100. 5 52.222-5 DAVIS-BACON ACT -- SECONDARY SITE OF THE WORK (JUL 2005)

00100. 6 52.225-10 NOTICE OF BUY AMERICAN ACT REQUIREMENT--CONSTRUCTION MATERIALS (FEB 2009)

00100. 7 52.233-2 SERVICE OF PROTEST (SEP 2006)

00100. 8 52.236-27 I SITE VISIT (CONSTRUCTION) (FEB 1995)--ALTERNATE I (FEB 1995)

00100. 9 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

00100. 10 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

00100. 11 52.253-1 COMPUTER GENERATED FORMS (JAN 1991)

00100. 12 552.233-70 PROTESTS FILED DIRECTLY WITH THE GENERAL SERVICES ADMINISTRATION (MAR

2000)

SECTION 00600 REPRESENTATIONS AND CERTIFICATIONS

00600. 1 52.203-11 CERTIFICATION AND DISCLOSURE REGARDING PAYMENTS TO INFLUENCE CERTAIN FEDERAL

TRANSACTIONS (SEP 2007)

00600. 2 52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS (SEP 2007)

00600. 3 52.203-3 GRATUITIES (APR 1984)

00600. 4 52.203-5 COVENANT AGAINST CONTINGENT FEES (APR 1984)

00600. 5 52.204-7 CENTRAL CONTRACTOR REGISTRATION (APR 2008)

00600. 6 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (FEB 2009)

00600. 7 52.209-5 CERTIFICATION REGARDING RESPONSIBILITY MATTERS (DEC 2008)

00600. 8 52.209-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH CONTRACTORS

DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (SEP 2006)

00600. 9 52.219-1 SMALL BUSINESS PROGRAM REPRESENTATIONS (MAY 2004)

00600. 10 52.222-22 PREVIOUS CONTRACTS AND COMPLIANCE REPORTS (FEB 1999)

00600. 11 52.222-38 COMPLIANCE WITH VETERANS' EMPLOYMENT REPORTING REQUIREMENTS (DEC 2001)

00600. 12 52.236-28 PREPARATION OF PROPOSALS--CONSTRUCTION (OCT 1997)

SECTION 00700 CONTRACT CLAUSES

00700. 1 52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (JAN 1997)

00700. 2 52.203-13 CONTRACTOR CODE OF BUSINESS ETHICS AND CONDUCT (DEC 2008)

00700. 3 52.203-7 ANTI-KICKBACK PROCEDURES (JUL 1995)

00700. 4 52.203-8 CANCELLATION, RESCISSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR IMPROPER ACTIVITY

(JAN1997)

00700. 5 52.204-4 PRINTED OR COPIED DOUBLE-SIDED ON RECYCLED PAPER (AUG 2000)

00700. 6 52.204-9 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL (SEP 2007)

00700. 7 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

00700. 8 52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

00700. 9 52.211-13 TIME EXTENSIONS (SEP 2000)

00700. 10 52.215-15 PENSION ADJUSTMENTS AND ASSET REVERSIONS (OCT 2004)

00700. 11 52.215-18 REVERSION OR ADJUSTMENT OF PLANS FOR POSTRETIREMENT BENEFITS (PRB) OTHER THAN

PENSIONS (JUL 2005)

00700. 12 52.215-19 NOTIFICATION OF OWNERSHIP CHANGES (OCT 1997)

00700. 13 52.215-2 AUDIT AND RECORDS--NEGOTIATION (MAR 2009)

00700. 14 52.215-21 REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR

PRICING DATA--MODIFICATIONS (OCT 1997)

00700. 15 52.219-14 LIMITATIONS ON SUBCONTRACTING (DEC 1996)

00700. 16 52.219-16 LIQUIDATED DAMAGES--SUBCONTRACTING PLAN (JAN 1999)

00700. 17 52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REPRESENTATION (APR 2009)

00700. 18 52.219-3 NOTICE OF TOTAL HUBZONE SET-ASIDE (JAN 1999)

00700. 19 52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS (MAY 2004)

Table of Contents

00700. 20 52.219-9 SMALL BUSINESS SUBCONTRACTING PLAN (APR 2008)

00700. 21 52.222-10 COMPLIANCE WITH COPELAND ACT REQUIREMENTS (FEB 1988)

00700. 22 52.222-11 SUBCONTRACTS (LABOR STANDARDS) (JUL 2005)

00700. 23 52.222-12 CONTRACT TERMINATION--DEBARMENT (FEB 1988)

00700. 24 52.222-13 COMPLIANCE WITH DAVIS-BACON AND RELATED ACT REGULATIONS (FEB 1988)

00700. 25 52.222-14 DISPUTES CONCERNING LABOR STANDARDS (FEB 1988)

00700. 26 52.222-15 CERTIFICATION OF ELIGIBILITY (FEB 1988)

00700. 27 52.222-19 CHILD LABOR--COOPERATION WITH AUTHORITIES AND REMEDIES (FEB 2008)

00700. 28 52.222-21 PROHIBITION OF SEGREGATED FACILITIES (FEB 1999)

00700. 29 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT

OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

00700. 30 52.222-26 EQUAL OPPORTUNITY (MAR 2007)

00700. 31 52.222-27 AFFIRMATIVE ACTION COMPLIANCE REQUIREMENTS FOR CONSTRUCTION (FEB 1999)

00700. 32 52.222-3 CONVICT LABOR (JUN 2003)

00700. 33 52.222-35 EQUAL OPPORTUNITY FOR SPECIAL DISABLED VETERANS, VETERANS OF THE VIETNAM ERA, AND OTHER ELIGIBLE VETERANS. [SEP 2006]

00700. 34 52.222-36 AFFIRMATIVE ACTION FOR WORKERS WITH DISABILITIES (JUN 1998)

00700. 35 52.222-37 EMPLOYMENT REPORTS ON SPECIAL DISABLED VETERANS, VETERANS OF THE VIETNAM ERA, AND OTHER ELIGIBLE VETERANS (SEP 2006)

00700. 36 52.222-39 NOTIFICATION OF EMPLOYEE RIGHTS CONCERNING PAYMENT OF UNION DUES OR FEES (DEC

2004)

00700. 37 52.222-4 CONTRACT WORK HOURS AND SAFETY STANDARDS ACT--OVERTIME COMPENSATION (JUL

2005)

00700. 38 52.222-50 COMBATING TRAFFICKING IN PERSONS (FEB 2009)

00700. 39 52.222-6 DAVIS-BACON ACT (JUL 2005)

00700. 40 52.222-7 WITHHOLDING OF FUNDS (FEB 1988)

00700. 41 52.222-8 PAYROLLS AND BASIC RECORDS (FEB 1988)

00700. 42 52.222-9 APPRENTICES AND TRAINEES (JUL 2005)

00700. 43 52.223-13 CERTIFICATION OF TOXIC CHEMICAL RELEASE REPORTING (AUG 2003)

00700. 44 52.223-14 TOXIC CHEMICAL RELEASE REPORTING (AUG 2003)

00700. 45 52.223-17 AFFIRMATIVE PROCUREMENT OF EPA-DESIGNATED ITEMS IN SERVICE AND CONSTRUCTION

CONTRACTS (MAY 2008)

00700. 46 52.223-5 POLLUTION PREVENTION AND RIGHT-TO-KNOW INFORMATION (AUG 2003)

00700. 47 52.223-6 DRUG-FREE WORKPLACE (MAY 2001)

00700. 48 52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JUN 2008)

00700. 49 52.225-9 BUY AMERICAN ACT--CONSTRUCTION MATERIALS (FEB 2009)

00700. 50 52.227-1 AUTHORIZATION AND CONSENT (DEC 2007)

00700. 51 52.227-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT ONFRINGEMENT (DEC 2007)...24

00700. 52 52.227-4 PATENT INDEMNITY--CONSTRUCTION CONTRACTS (DEC 2007)

00700. 53 52.228-11 PLEDGES OF ASSETS (FEB 1992)

00700. 54 52.228-12 PROSPECTIVE SUBCONTRACTOR REQUESTS FOR BONDS (OCT 1995)

00700. 55 52.228-14 IRREVOCABLE LETTER OF CREDIT (DEC 1999)

00700. 56 52.228-15 PERFORMANCE AND PAYMENT BONDS--CONSTRUCTION (NOV 2006)

00700. 57 52.228-2 ADDITIONAL BOND SECURITY (OCT 1997)

00700. 58 52.228-5 INSURANCE--WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

00700. 59 52.229-3 FEDERAL, STATE, AND LOCAL TAXES (APR 2003)

00700. 60 52.232-13 NOTICE OF PROGRESS PAYMENTS (APR 1984)

00700. 61 52.232-16 I PROGRESS PAYMENTS (APR 2003)--ALTERNATE I (MAR 2000)

00700. 62 52.232-17 INTEREST (OCT 2008)

00700. 63 52.232-23 ASSIGNMENT OF CLAIMS (JAN 1986)

00700. 64 52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (OCT 2008)

00700. 65 52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER--CENTRAL CONTRACTOR REGISTRATION (OCT

2003)

00700. 66 52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (SEP 2002)

00700. 67 52.233-1 I DISPUTES (JUL 2002)--ALTERNATE I (DEC 1991)

00700. 68 52.233-3 PROTEST AFTER AWARD (AUG 1996)

00700. 69 52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

00700. 70 52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984)

00700. 71 52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (APR 1984)

00700. 72 52.236-12 CLEANING UP (APR 1984)

00700. 73 52.236-13 ACCIDENT PREVENTION (NOV 1991)

00700. 74 52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES (APR 1984)

00700. 75 52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

00700. 76 52.236-17 LAYOUT OF WORK (APR 1984)

00700. 77 52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

00700. 78 52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997)

00700. 79 52.236-26 PRECONSTRUCTION CONFERENCE (FEB 1995)

00700. 80 52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984)

00700. 81 52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

00700. 82 52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

00700. 83 52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

00700. 84 52.236-8 OTHER CONTRACTS (APR 1984)

00700. 85 52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (APR 1984)

00700. 86 52.242-13 BANKRUPTCY (JUL 1995)

00700. 87 52.242-14 SUSPENSION OF WORK (APR 1984)

00700. 88 52.242-17 GOVERNMENT DELAY OF WORK (APR 1984)

00700. 89 52.243-1 III CHANGES--FIXED-PRICE (AUG 1987)--ALTERNATE III (APR 1984)

00700. 90 52.243-4 CHANGES (JUN 2007)

00700. 91 52.244-2 SUBCONTRACTS (JUN 2007)

00700. 92 52.244-5 COMPETITION IN SUBCONTRACTING (DEC 1996)

00700. 93 52.244-6 SUBCONTRACTS FOR COMMERCIAL ITEMS (MAR 2009)

00700. 94 52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

00700. 95 52.246-13 INSPECTION--DISMANTLING, DEMOLITION, OR REMOVAL OF IMPROVEMENTS (AUG 1996)

00700. 96 52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994)

00700. 97 52.248-3 VALUE ENGINEERING--CONSTRUCTION (SEP 2006)

00700. 98 52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)

00700. 99 52.249-10 I DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)--ALTERNATE I (APR 1984)

00700. 100 52.249-2 I TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE) (MAY 2004)--

ALTERNATE I (SEP 1996)

00700. 101 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

00700. 102 52.253-1 COMPUTER GENERATED FORMS (JAN 1991)

00700. 103 552.203-71 RESTRICTION ON ADVERTISING (SEP 1999)

00700. 104 552.211-71 STANDARD REFERENCES (SEP 1999)

00700. 105 552.211-72 REFERENCES TO SPECIFICATIONS IN DRAWINGS (FEB 1996)

00700. 106 552.211-84 NON-COMPLIANCE WITH CONTRACT REQUIREMENTS (FEB 1996)

00700. 107 552.215-70 EXAMINATION OF RECORDS BY GSA (FEB 1996)

00700. 108 552.228-70 WORKERS' COMPENSATION LAWS (SEP 1999)

00700. 109 552.232-70 INVOICE REQUIREMENTS (SEP 1999)

00700. 110 552.232-78 PAYMENT INFORMATION (JUL 2000)

00700. 111 552.236-70 DEFINITIONS (APR 1984)

00700. 112 552.236-71 AUTHORITIES AND LIMITATIONS (APR 1984)

00700. 113 552.236-72 SPECIALIST (APR 1984)

00700. 114 552.236-74 WORKING HOURS (APR 1984)

00700. 115 552.236-75 USE OF PREMISES (APR 1984)

00700. 116 552.236-76 MEASUREMENTS (APR 1984)

00700. 117 552.236-77 SPECIFICATIONS AND DRAWINGS (SEP 1999)

00700. 118 552.236-78 SHOP DRAWINGS, COORDINATION DRAWINGS, AND SCHEDULES (SEP 1999)

00700. 119 552.236-80 HEAT (APR 1984)

00700. 120 552.236-82 SUBCONTRACTS (APR 1984)

00700. 121 552.237-70 QUALIFICATIONS OF OFFERORS (MAY 1989)

00700. 122 552.237-71 QUALIFICATIONS OF EMPLOYEES (MAY 1989)

00700. 123 552.243-70 PRICING OF ADJUSTMENTS (APR 1989)

00700. 124 552.243-71 EQUITABLE ADJUSTMENTS (APR 1984)

00700. 125 552.246-72 FINAL INSPECTION AND TESTS (SEP 1999)

00700. 126 552.246-75 GUARANTEES (MAY 1989)

SECTION 00800 SPECIAL CONTRACT REQUIREMENTS

00800. 1 Local Clauses

SECTION 00100

INSTRUCTIONS, CONDITIONS, AND NOTICES TO BIDDERS

00100. 1 52.215-1 I INSTRUCTIONS TO OFFERORS--COMPETITIVE ACQUISITION (JAN 2004)--ALTERNATE I (OCT 1997)

(Reference 52.215-1 I)

00100. 2 52.215-20 IV REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR

PRICING DATA (OCT 1997)--ALTERNATE IV (OCT 1997)

(a) Submission of cost or pricing data is not required.

(b) Provide information described below: As Required in Attachment (5) Spreadsheet

00100. 3 52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm-Fixed-Price contract resulting from this solicitation.

(End of Provision)

00100. 4 52.219-4 NOTICE OF PRICE EVALUATION PREFERENCE FOR HUBZONE SMALL BUSINESS CONCERNS (JUL 2005)

(Reference 52.219-4)

00100. 5 52.222-5 DAVIS-BACON ACT -- SECONDARY SITE OF THE WORK (JUL 2005)

(a)

(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Davis-Bacon Act, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)

(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

(End of Provision)

00100. 6 52.225-10 NOTICE OF BUY AMERICAN ACT REQUIREMENT--CONSTRUCTION MATERIALS (FEB 2009)

(a) "Definitions." "Commercially available off-the-shelf (COTS) item," "Construction material," "domestic construction material," and "foreign construction material," as used in this provision, are defined in the clause of this solicitation entitled "Buy American Act-Construction Materials" (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) "Requests for determinations of inapplicability." An offeror requesting a determination regarding the inapplicability of the Buy American Act should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American Act before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) "Evaluation of offers."

(1) The Government will evaluate an offer requesting exception to the requirements of the Buy

American Act, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) "Alternate offers."

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph

(c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

(End of Provision)

00100. 7 52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the General Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from GSA/PBS/DFC Service Center, One Denver Federal Center, Building 41, W. 6th Ave & Kipling, P.O. Box 25546 (8PD), Denver, CO 80225-0546

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of Provision)

00100. 8 52.236-27 I SITE VISIT (CONSTRUCTION) (FEB 1995)--ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for--June 10, 2009 at 9:00 A.M.

(c) Participants will meet at--Denver Federal Center, Building 41, 2nd Floor, Montana Conference

Room, Denver, Colorado

(End of Provision)

00100. 9 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://www.acquisition.gov/far/

(End of Provision)

00100. 10 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://www.acquisition.gov/far/

(End of Clause)

00100. 11 52.253-1 COMPUTER GENERATED FORMS (JAN 1991)

(Reference 52.253-1)

00100. 12 552.233-70 PROTESTS FILED DIRECTLY WITH THE GENERAL SERVICES ADMINISTRATION (MAR 2000)

(Reference 552.233-70)

SECTION 00600

REPRESENTATIONS AND CERTIFICATIONS

00600. 1 52.203-11 CERTIFICATION AND DISCLOSURE REGARDING PAYMENTS TO INFLUENCE CERTAIN FEDERAL

TRANSACTIONS (SEP 2007)

(Reference 52.203-11)

00600. 2 52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS (SEP 2007)

(Reference 52.203-12)

00600. 3 52.203-3 GRATUITIES (APR 1984)

(Reference 52.203-3)

00600. 4 52.203-5 COVENANT AGAINST CONTINGENT FEES (APR 1984)

(Reference 52.203-5)

00600. 5 52.204-7 CENTRAL CONTRACTOR REGISTRATION (APR 2008)

(Reference 52.204-7)

00600. 6 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (FEB 2009)

(a)

(1) The North American Industry Classification System (NAICS) code for this acquisition is 238990, All Other Specialty Trade Contractors

(2) The small business size standard is $14 Million

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)

(1) If the clause at 52.204-7, Central Contractor Registration, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the clause at 52.204-7 is not included in this solicitation, and the offeror is currently registered in CCR, and has completed the ORCA electronic ally, the offeror may choose to use paragraph

(d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

/_/ (i) Paragraph (d) applies.

/_/ (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)

(1) The following representations or certifications in ORCA are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless--

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $100,000.

(iii) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the clause at 52.204-7, Central Contractor Registration.

(iv) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that--

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(v) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(vi) 52.214-14, Place of Performance-Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(vii) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(viii) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(ix) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(x) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xi) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xii) 52.222-38, Compliance with Veterans'' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xiii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xiv) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xv) 52.225-2, Buy American Act Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xvi) 52.225-4, Buy American Act-Free Trade Agreements-Israeli Trade Act Certificate. (Basic, Alternate I, and Alternate II) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $67,826, the provision with its Alternate II applies.

(xvii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xviii) 52.225-20, Prohibition on Conducting Restricted Business Operations in

Sudan-Certification.

(xix) 52.226-2, Historically Black College or University and Minority Institution

Representation. This provision applies to--

(A) Solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions; and

(B) For DoD, NASA, and Coast Guard acquisitions, solicitations that contain the clause at

52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns.

(2) The following certifications are applicable as indicated by the Contracting Officer:

(i) 52.219-19, Small Business Concern Representation for the Small Business Competitiveness Demonstration Program.

(ii) 52.219-21, Small Business Size Representation for Targeted Industry Categories Under the Small Business Competitiveness Demonstration Program.

(iii) 52.219-22, Small Disadvantaged Business Status.

(A) Basic.

(B) Alternate I.

(iv) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(v) 52.222-48, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment Certification.

(vi) 52.222-22 Exemption from Application of the Service Contract Act to Contracts for Certain Services-Certification.

(vii) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (Alternate I only).

(viii) 52.223-13, Certification of Toxic Chemical Release Reporting.

(ix) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(x) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the Online Representations and Certifications Application (ORCA) website at http://orca.bpn.gov. After reviewing the ORCA database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

| FAR | | | |

| Clause | Title | Date | Change |

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on ORCA.

(End of Provision)

00600. 7 52.209-5 CERTIFICATION REGARDING RESPONSIBILITY MATTERS (DEC 2008)

(a)

(1) The Offeror certifies, to the best of its knowledge and belief, that--

(i) The Offeror and/or any of its Principals--

(A) Are /_/ are not /_/ presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(B) Have /_/ have not /_/, within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, state, or local) contract or subcontract; violation of Federal or state antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property; and

(C) Are /_/ are not /_/ presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in paragraph (a)(1)(i)(B) of this provision.

(D) Have /_/, have not /_/, within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,000 for which the liability remains unsatisfied.

(1) Federal taxes are considered delinquent if both of the following criteria apply:

(i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(ii) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(2) Examples.

(i) The taxpayer has received a statutory notice of deficiency, under I.R.C. ?? 6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(ii) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. ?? 6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(iii) The taxpayer has entered into an installment agreement pursuant to I.R.C. ?? 6159.

The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(iv) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. 362 (the Bankruptcy Code).

(ii) The Offeror has /_/ has not /_/, within a three-year period preceding this offer, had one or more contracts terminated for default by any Federal agency.

(2) "Principal," for the purposes of this certification, means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a subsidiary, division, or business segment; and similar positions).

This Certification Concerns a Matter Within the Jurisdiction of an Agency of the United States and the Making of a False, Fictitious, or Fraudulent Certification May Render the Maker Subject to Prosecution Under Section 1001, Title 18, United States Code.

(b) The Offeror shall provide immediate written notice to the Contracting Officer if, at any time prior to contract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.

(c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this solicitation. However, the certification will be considered in connection with a determination of the Offeror?s responsibility. Failure of the Offeror to furnish a certification or provide such additional information as requested by the

Contracting Officer may render the Offeror nonresponsible.

(d) Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render, in good faith, the certification required by paragraph (a) of this provision. The knowledge and information of an Offeror is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.

(e) The certification in paragraph (a) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous certification, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation for default.

(End of Provision)

00600. 8 52.209-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH CONTRACTORS

DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (SEP 2006)

(Reference 52.209-6)

00600. 9 52.219-1 SMALL BUSINESS PROGRAM REPRESENTATIONS (MAY 2004)

(a)

(1) The North American Industry Classification System (NAICS) code for this acquisition is 238990, All Other Specialty Trade Contractors

(2) The small business size standard is $14 Million

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b) Representations.

(1) The offeror represents as part of its offer that it /_/ is, /_/ is not a small business concern.

(2) The offeror represents, for general statistical purposes, that it /_/ is, /_/ is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) The offeror represents as part of its offer that it /_/ is, /_/ is not a women-owned small business concern.

(4) The offeror represents as part of its offer that it /_/ is, /_/ is not a veteran-owned small business concern.

(5) The offeror represents as part of its offer that it /_/ is, /_/ is not a service-disabled veteran-owned small business concern.

(6) The offeror represents, as part of its offer, that--

(i) It /_/ is, /_/ is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material change in ownership and control, principal office, or HUBZone employee percentage has occurred since it was certified by the Small Business Administration in accordance with 13 CFR part 126; and

(ii) It /_/ is, /_/ is not a joint venture that complies with the requirements of 13 CFR part 126, and the representation in paragraph (b)(6)(i) of this provision is accurate for the HUBZone small business concern or concerns that are participating in the joint venture. [The offeror shall enter the name or names of the HUBZone small business concern or concerns that are participating in the joint venture:__________.] Each HUBZone small business concern participating in the joint venture shall submit a separate signed copy of the HUBZone representation.

(c) Definitions. As used in this provision-- "Service-disabled veteran-owned small business concern"--

(1) Means a small business concern--

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

"Small business concern" means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph

(a) of this provision.

"Veteran-owned small business concern" means a small business concern--

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C.

101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

"Women-owned small business concern" means a small business concern--

(1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

(d) Notice.

(1) If this solicitation is for supplies and has been set aside, in whole or in part, for small business concerns, then the clause in this solicitation providing notice of the set-aside contains restrictions on the source of the end items to be furnished.

(2) Under 15 U.S.C. 645(d), any person who misrepresents a firm's status as a small, HUBZone small, small disadvantaged, or women-owned small business concern in order to obtain a contract to be awarded under the preference programs established pursuant to section 8(a), 8(d), 9, or 15 of the Small Business Act or any other provision of Federal law that specifically references section 8(d) for a definition of program eligibility, shall--

(i) Be punished by imposition of fine, imprisonment, or both;

(ii) Be subject to administrative remedies, including suspension and debarment; and

(iii) Be ineligible for participation in programs conducted under the authority of the Act.

(End of Provision)

00600. 10 52.222-22 PREVIOUS CONTRACTS AND COMPLIANCE REPORTS (FEB 1999)

The offeror represents that--

(a) It /_/ has, /_/ has not participated in a previous contract or subcontract subject to the Equal

Opportunity clause of this solicitation;

(b) It /_/ has, /_/ has not filed all required compliance reports; and

(c) Representations indicating submission of required compliance reports, signed by proposed subcontractors, will be obtained before subcontract awards.

(End of Provision)

00600. 11 52.222-38 COMPLIANCE WITH VETERANS' EMPLOYMENT REPORTING REQUIREMENTS (DEC 2001)

(Reference 52.222-38)

00600. 12 52.236-28 PREPARATION OF PROPOSALS--CONSTRUCTION (OCT 1997)

(Reference 52.236-28)

SECTION 00700

CONTRACT CLAUSES

00700. 1 52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (JAN 1997)

(Reference 52.203-10)

00700. 2 52.203-13 CONTRACTOR CODE OF BUSINESS ETHICS AND CONDUCT (DEC 2008)

(Reference 52.203-13)

00700. 3 52.203-7 ANTI-KICKBACK PROCEDURES (JUL 1995)

(Reference 52.203-7)

00700. 4 52.203-8 CANCELLATION, RESCISSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR IMPROPER ACTIVITY

(JAN 1997)

(Reference 52.203-8)

00700. 5 52.204-4 PRINTED OR COPIED DOUBLE-SIDED ON RECYCLED PAPER (AUG 2000)

(Reference 52.204-4)

00700. 6 52.204-9 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL (SEP 2007)

(a) The Contractor shall comply with agency personal identity verification procedures identified in the contract that implement Homeland Security Presidential Directive-12 (HSPD-12), Office of Management and Budget (OMB) guidance M-05-24, as amended, and Federal Information Processing Standards Publication (FIPS PUB) Number 201, as amended.

(b) The Contractor shall insert this clause in all subcontracts when the subcontractor is required to have routine physical access to a Federally-controlled facility and/or routine access to a Federally-controlled information system.

(End of clause)

00700. 7 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to

(a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed,

(b) prosecute the work diligently, and

(c) complete the entire work ready for use not later than 120 calendar days of receiving Notice to

Proceed The time stated for completion shall include final cleanup of the premises.

(End of Clause)

00700. 8 52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $314.66 for the first day of delay and $82.97 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of Clause)

00700. 9 52.211-13 TIME EXTENSIONS (SEP 2000)

(Reference 52.211-13)

00700. 10 52.215-15 PENSION ADJUSTMENTS AND ASSET REVERSIONS (OCT 2004)

(Reference 52.215-15)

00700. 11 52.215-18 REVERSION OR ADJUSTMENT OF PLANS FOR POSTRETIREMENT BENEFITS (PRB) OTHER THAN

PENSIONS (JUL 2005)

(Reference 52.215-18)

00700. 12 52.215-19 NOTIFICATION OF OWNERSHIP CHANGES (OCT 1997)

(a) The Contractor shall make the following notifications in writing:

(1) When the Contractor becomes aware that a change in its ownership has occurred, or is certain to occur, that could result in changes in the valuation of its capitalized assets in the accounting records, the Contractor shall notify the Administrative Contracting Officer (ACO) within 30 days.

(2) The Contractor shall also notify the ACO within 30 days whenever changes to asset valuations or any other cost changes have occurred or are certain to occur as a result of a change in ownership.

(b) The Contractor shall--

(1) Maintain current, accurate, and complete inventory records of assets and their costs;

(2) Provide the ACO or designated representative ready access to the records upon request;

(3) Ensure that all individual and grouped assets, their capitalized values, accumulated depreciation or amortization, and remaining useful lives are identified accurately before and after each of the Contractor's ownership changes; and

(4) Retain and continue to maintain depreciation and amortization schedules based on the asset records maintained before each Contractor ownership change.

(c) The Contractor shall include the substance of this clause in all subcontracts under this contract that meet the applicability requirement of FAR 15.408(k).

(End of Clause)

00700. 13 52.215-2 AUDIT AND RECORDS--NEGOTIATION (MAR 2009)

(Reference 52.215-2)

00700. 14 52.215-21 REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR PRICING

DATA--MODIFICATIONS (OCT 1997)

(Reference 52.215-21)

00700. 15 52.219-14 LIMITATIONS ON SUBCONTRACTING (DEC 1996)

(Reference 52.219-14)

00700. 16 52.219-16 LIQUIDATED DAMAGES--SUBCONTRACTING PLAN (JAN 1999)

(Reference 52.219-16)

00700. 17 52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REPRESENTATION (APR 2009)

(a) Definitions. As used in this clause-- Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is "not dominant in its field of operation" when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/services/contractingopportunities/sizestandardstopics/.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the rerepresentation required by paragraph (b) of this clause by validating or updating all its representations in the Online Representations and Certifications Application and its data in the Central Contractor Registration, as necessary, to ensure that they reflect the Contractor?s current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of…